W912DY-18-R-0004.pdf

SEE ADDENDUM

(No Collect Calls)

W912DY18R0004 08-Nov-2017

b. TELEPHONE NUMBER

2568958095

8. OFFER DUE DATE/LOCAL TIME

03:00 PM 07 Dec 2017

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

W912DY9. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

RONALD E CLARK

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

0 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

US ARMY ENGINEERING & SUPPORT CENTER

HUNTSVILLE ENGINEERING & SUPPORT CENTER

P.O. BOX 1600

HUNTSVILLE AL 35807-4301

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE W912DY 16. ADMINISTERED BY

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

DIRECTORATE INSTALLATION SPTPT

PROJECT MANAGER

USA ENGINEER AND SUPPORT CENTER,HUNTSVILLE PO

HUNTSVILLE AL 35807-4301

TEL: 256-895-1200 FAX:

FAX:

TEL: SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

1,000

NAICS:

333318

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT 41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

Section SF 1449 - CONTINUATION SHEET

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 7 Each

ICE MAKER/WATER DISPENSER INSTALLATION

FFP

The contractor shall provide Icemaker/Water Dispenser installation in support of the HNC for US Army Corps of Engineers, Huntsville Center FOB: Destination

NET AMT

0002 7 Each Stand

FFP

The contractor shall provide Ice and Water Dispenser Stand for the Icemaker/Dispenser in support of the HNC for US Army Corps of Engineers, Huntsville Center

0003 1 Job 5 yr. Full Service Extended Warranty

FFP

TThe contractor shall provide 5 years of Full Service Extended Warranty for the Icemaker/Dispenser in support of the HNC for US Army Corps of Engineers, Huntsville Center in accordance with the attached Performance Work Statement.

The service agreement shall provide a maintenance response within seventy-two

(72) hours after being contacted and require that the water and ice dispensers will be fixed or replaced within seven (7) calendar days of notification of an issue.

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 N/A N/A N/A Government 0002 N/A N/A N/A Government 0003 N/A N/A N/A Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 01-JAN-2018 7 DIRECTORATE INSTALLATION SPTPT

PROJECT MANAGER

USA ENGINEER AND SUPPORT

CENTER,HUNTSVILLE PO

HUNTSVILLE AL 35807-4301

256-895-1200

W912DY

0002 01-JAN-2018 7 (SAME AS PREVIOUS LOCATION)

0003 POP 01-JAN-2018 TO

31-DEC-2022

N/A (SAME AS PREVIOUS LOCATION)

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

APR 2014

52.204-3 Taxpayer Identification OCT 1998 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-6 Unique Entity Identifier OCT 2016 52.204-7 System for Award Management OCT 2016 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.211-5 Material Requirements AUG 2000 52.212-1 Instructions to Offerors--Commercial Items JAN 2017 52.212-2 Evaluation - Commercial Items OCT 2014 52.212-4 Contract Terms and Conditions--Commercial Items JAN 2017 52.222-50 Combating Trafficking in Persons MAR 2015 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

SEP 2013

52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.223-19 Compliance with Environmental Management Systems MAY 2011 52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.225-18 Place of Manufacture MAR 2015 52.225-25 Prohibition on Contracting with Entities Engaging in Certain

Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

52.232-1 Payments APR 1984 52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.243-1 Changes--Fixed Price AUG 1987 52.244-6 Subcontracts for Commercial Items JAN 2017 52.247-34 F.O.B. Destination NOV 1991 52.252-2 Clauses Incorporated By Reference FEB 1998 252.201-7000 Contracting Officer's Representative DEC 1991 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006

CLAUSES INCORPORATED BY FULL TEXT

52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR

EXECUTIVE ORDERS--COMMERCIAL ITEMS (JAN 2017)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015).

(3) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(4) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (Contracting Officer check as appropriate.)

___ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

____ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

____ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (June 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

xx (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. L. 109-

282) (31 U.S.C. 6101 note).

___ (5) [Reserved]

___ (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div.

C).

___ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub.

L. 111-117, section 743 of Div. C).

xx (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Oct 2015) (31 U.S.C. 6101 note).

____ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (July 2013) (41 U.S.C. 2313).

____ (10) [Reserved]

____ (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (NOV 2011) (15 U.S.C. 657a).

____ (ii) Alternate I (NOV 2011) of 52.219-3.

____ (12) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

____ (ii) Alternate I (JAN 2011) of 52.219-4.

____ (13) [Reserved] xx (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (NOV 2011) (15 U.S.C. 644).

____ (ii) Alternate I (NOV 2011).

____ (iii) Alternate II (NOV 2011).

____ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644).

____ (ii) Alternate I (Oct 1995) of 52.219-7.

____ (iii) Alternate II (Mar 2004) of 52.219-7.

____ (16) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)).

____ (17)(i) 52.219-9, Small Business Subcontracting Plan (Jan 2017) (15 U.S.C. 637(d)(4)).

____ (ii) Alternate I (Nov 2016) of 52.219-9.

____ (iii) Alternate II (Nov 2016) of 52.219-9.

____ (iv) Alternate III (Nov 2016) of 52.219-9.

____ (v) Alternate IV (Nov 2016) of 52.219-9.

____ (18) 52.219-13, Notice of Set-Aside of Orders (NOV 2011) (15 U.S.C. 644(r)).

____ (19) 52.219-14, Limitations on Subcontracting (JAN 2017) (15 U.S.C. 637(a)(14)).

____ (20) 52.219-16, Liquidated Damages—Subcon-tracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)).

____ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (NOV 2011) (15 U.S.C.

657f).

xx (22) 52.219-28, Post Award Small Business Program Rerepresentation (July 2013) (15 U.S.C. 632(a)(2)).

____ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women- Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)).

____(24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m)).

xx (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

xx(26) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (Oct 2016) (E.O. 13126).

xx (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

xx (28) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246).

____ (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

xx (30) 52.222-36, Equal Opportunity for Workers with Disabilities (July 2014) (29 U.S.C. 793).

____ (31) 52.222-37, Employment Reports on Veterans (FEB 2016) (38 U.S.C. 4212).

____ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O.

13496).

____ (33)(i) 52.222-50, Combating Trafficking in Persons (March 2, 2015) (22 U.S.C. chapter 78 and E.O. 13627).

____ (ii) Alternate I (March 2, 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

____ (34) 52.222-54, Employment Eligibility Verification (Oct 2015). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

____ (35) 52.222-59, Compliance with Labor Laws (Executive Order 13673) (OCT 2016). (Applies at $50 million for solicitations and resultant contracts issued from October 25, 2016 through April 24, 2017; applies at $500,000 for solicitations and resultant contracts issued after April 24, 2017).

Note to paragraph (b)(35): By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

____ (36) 52.222-60, Paycheck Transparency (Executive Order 13673) (OCT 2016).

____ (37)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

____ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

____ (38) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (June, 2016) (E.O. 13693).

____ (39) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (June, 2016) (E.O. 13693).

____ (40) (i) 52.223-13, Acquisition of EPEAT® Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514).

____ (ii) Alternate I (OCT 2015) of 52.223-13.

____ (41)(i) 52.223-14, Acquisition of EPEAT® Registered Televisions (Jun 2014) (E.O.s 13423 and 13514).

____ (ii) Alternate I (Jun 2014) of 52.223-14.

____ (42) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b).

____ (43)(i) 52.223-16, Acquisition of EPEAT[supreg]-Registered Personal Computer Products (OCT 2015) (E.O.s 13423 and 13514).

____ (ii) Alternate I (Jun 2014) of 52.223-16.

xx (44) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Aug 2011) (E.O.

13513).

____ (45) 52.223-20, Aerosols (June, 2016) (E.O. 13693).

____ (46) 52.223-21, Foams (June, 2016) (E.O. 13693).

____ (47)(i) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

____ (ii) Alternate I (JAN 2017) of 52.224-3.

____ (48) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83).

____(49) (i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L.

103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

____ (ii) Alternate I (May 2014) of 52.225-3.

____ (iii) Alternate II (May 2014) of 52.225-3.

____ (iv) Alternate III (May 2014) of 52.225-3.

____ (50) 52.225-5, Trade Agreements (Oct 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

xx (51) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

____ (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

____ (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150

____ (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C.

5150).

____ (55) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

____ (56) 52.232-30, Installment Payments for Commercial Items (Jan 2017) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

xx (57) 52.232-33, Payment by Electronic Funds Transfer—System for Award Management (July 2013) (31 U.S.C.

3332).

____ (58) 52.232-34, Payment by Electronic Funds Transfer—Other than System for Award Management (July 2013) (31 U.S.C. 3332).

____ (59) 52.232-36, Payment by Third Party (MAY 2014) (31 U.S.C. 3332).

____ (60) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

____ (61) 52.242-5, Payments to Small Business Subcontractors (JAN 2017)(15 U.S.C. 637(d)(12)).

____ (62)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C.

Appx. 1241(b) and 10 U.S.C. 2631).

____ (ii) Alternate I (Apr 2003) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (Contracting Officer check as appropriate.)

_____(1) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495).

xx (2) 52.222-41, Service Contract Labor Standards (MAY 2014) (41 U.S.C. chapter 67).

xx (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (MAY 2014) (29 U.S.C. 206 and 41 U.S.C.

chapter 67).

xx (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (Multiple Year and Option Contracts) (MAY 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

_____ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (MAY 2014) (29 U.S.C 206 and 41 U.S.C. chapter 67).

_____ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (MAY 2014) (41 U.S.C. chapter 67).

_____ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (MAY 2014) (41 U.S.C. chapter 67).

_____(8) 52.222-55, Minimum Wages Under Executive Order 13658 (DEC 2015) (E.O. 13658).

_____ (9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706).

_____ (10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (MAY 2014) (42 U.S.C. 1792).

_____ (11) 52.237-11, Accepting and Dispensing of $1 Coin (Sept 2008) (31 U.S.C. 5112(p)(1)).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph

(d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records--Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1)in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause—

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

(ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iii) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(iv) 52.222-17, Nondisplacement of Qualified Workers (MAY 2014) (E.O. 13495). Flow down required in accordance with paragraph (l) of FAR clause 52.222-17.

(v) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(vi) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246).

(vii) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

(viii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

(ix) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212).

(x) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xi) 52.222-41, Service Contract Labor Standards (May 2014), (41 U.S.C. chapter 67).

(xii) _____ (A) 52.222-50, Combating Trafficking in Persons (March 2, 2015) (22 U.S.C. chapter 78 and E.O.

13627).

_____ (B) Alternate I (March 2, 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

(xiii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67.)

(xiv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67)

(xv) 52.222-54, Employment Eligibility Verification (Oct 2015) (E. O. 12989).

(xvi)52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015) (E.O. 13658).

(xvii) 52.222-59, Compliance with Labor Laws (Executive Order 13673) (OCT 2016) (Applies at $50 million for solicitations and resultant contracts issued from October 25, 2016 through April 24, 2017; applies at $500,000 for solicitations and resultant contracts issued after April 24, 2017).

Note to paragraph (e)(1)(xvii): By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(xviii) 52.222-60, Paycheck Transparency (Executive Order 13673) (OCT 2016)).

(xix) (A) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

(B) Alternate I (JAN 2017) of 52.224-3.

(xx) 52.222-62 Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706).

(xxi) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(xxii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxiii) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

(End of clause)

52.216-24 LIMITATION OF GOVERNMENT LIABILITY (APR 1984)

(a) In performing this contract, the Contractor is not authorized to make expenditures or incur obligations exceeding dollars.

(b) The maximum amount for which the Government shall be liable if this contract is terminated is dollars.

52.216-25 CONTRACT DEFINITIZATION (OCT 2010)

(a) A -------- [insert specific type of contract] definitive contract is contemplated. The Contractor agrees to begin promptly negotiating with the Contracting Officer the terms of a definitive contract that will include (1) all clauses required by the Federal Acquisition Regulation (FAR) on the date of execution of the letter contract, (2) all clauses required by law on the date of execution of the definitive contract, and (3) any other mutually agreeable clauses, terms, and conditions. The Contractor agrees to submit a -------- [insert specific type of proposal (e.g., fixed-price or cost-and-fee)] proposal, including data other than certified cost or pricing data, and certified cost or pricing data, in accordance with FAR 15.408, Table 15-2, supporting its proposal.

(b) The schedule for definitizing this contract is [insert date] .

(c) If agreement on a definitive contract to supersede this letter contract is not reached by the target date in paragraph (b) above, or within any extension of it granted by the Contracting Officer, the Contracting Officer may, with the approval of the head of the contracting activity, determine a reasonable price or fee in accordance with Subpart 15.4 and Part 31 of the FAR, subject to Contractor appeal as provided with completion of the contract, subject only to the Limitation of Government Liability clause.

(1) After the Contracting Officer's determination of price or fee, the contract shall be governed by--

(i) All clauses required by the FAR on the date of execution of this letter contract for either fixed-price or cost-reimbursement contracts, as determined by the Contracting Officer under this paragraph (c);

(ii) All clauses required by law as of the date of the Contracting Officer's determination; and

(iii) Any other clauses, terms, and conditions mutually agreed upon.

(2) To the extent consistent with subparagraph (c)(1) above, all clauses, terms, and conditions included in this letter contract shall continue in effect, except those that by their nature apply only to a letter contract.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from ______________________. (Contracting Officer designate the official or location where a protest may be served on the Contracting Officer.)

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of provision)

PERFORMANCE WORK STATEMENT

Performance Work Statement (PWS) Ice and Water Dispensers USACE, Engineering and Support Center, Huntsville, Alabama

Revision 2, Date 08/11/2017

1. Synopsis: The Contractor shall furnish and install seven Ice and Water Dispensers to include service agreement for five years at the Engineering and Support Center, Huntsville, Alabama. The Contractor shall provide a fully functional and complete working system in compliance with activity specific requirements itemized in the PWS.

Background: CEHNC presently has the Scotsman HID312A-1 ice and water dispensers at several locations. There is also one under-the -counter unit in Suite 19. This unit has been deemed unhealthy and must be disposed of. All HID312A-1 units are operating satisfactorily and customers are satisfied with the performance. The offices have expanded into several other locations from the main building. Some of these are the sites for the new dispensers.

2. Specific work to be accomplished:

2.1 Description of work. Provide seven Ice and Water Dispensers. Each of these ice and water dispensers shall be adequately sized for a load of no less than eighty (80) people per day. In accordance with FAR 52.211-6, the Government has elected to use brand names in an effort to assist the Contractor in the bidding of this project. Any brand names specified are being used to establish a minimum quality level for various items and products. Any manufacturer or vendor whose products are equivalent to the brand names specified and meet the specification will be accepted by the Government. The Government does not intend or imply that by providing vendors’ or manufacturers’ names in the specification that subject products or items are the only items that will be acceptable to the Government. All products and items, whether named or not named, must clearly meet the salient characteristics of the specifications identified. Current use is Scotsman HID312A, counter top ice and water dispenser.

Stands (If needed) sized appropriately.

Minimum Manufacturer Warranty Requirements:

• 3 years parts and labor

• 5 years parts on the compressor and condenser

Service/Maintenance:

• 5 yr. Full Service Extended Warranty

Salient characteristics are: serves 80 persons per day, nugget ice, air cooled, up to 260 lb. production/24 hrs., external water filter, antimicrobial protection, R-134a refrigerant, UL and NSF certified, powered by 115volts, Phase 1, Dimensions: Weight not to exceed 200lbs per unit. Must fit on a 22 inch deep counter, if under an overhead cabinet, not greater than 20 inches high, if no overhead cabinet, 42 inches max height and maximum width approx. 20 inches. Suite 19 has a current under the sink counter space of an existing unit, to be replaced at approximately, 34 inch height x 15 inches wide x 23 inches deep. Free standing units are expected to meet all previous requirements and dimensions to not exceed 23 inch deep, nor 20 inches wide, nor 6 feet above the existing floor.

Stands (If needed) sized appropriately.

Minimum Manufacturer Warranty Requirements:

3 years parts and labor 5 years parts on the compressor and condenser

Service/Maintenance:

5 yr. Full Service Extended Warranty

A service agreement shall be required to be included in the RFP/RFQ response. The service agreement shall provide a maintenance response within seventy-two (72) hours after being contacted and require that the water and ice dispensers will be fixed or replaced within seven (7) calendar days of notification of an issue.

Installation shall include providing water lines from existing sink water supply lines to the dispensers. Others might only require connection to existing water supply lines for the former dispensers. Plumbing to nearest drain shall also be installed. All water supply lines shall have filtration systems with cartridge type filters; these filters shall be changed semi-annually or per manufacturers suggested O&M process (whichever is more stringent) on all dispensers and have performance capabilities of 1 micron, chlorine reduction, and scale inhibitor.

3. Locations:

In the break rooms for:

1. First Floor 4801 University Square, Suite #1, Huntsville, AL

2. First Floor 4910 University Square, Suite #2, Huntsville, AL

3. First Floor 4901 University Square, Suite #16, Suite #18, Suite #19, Huntsville, AL

4. Redstone Arsenal Bldg. 3447 and;

5. Redstone Arsenal Bldg. 3461, Huntsville, AL

The one existing ice and water dispenser in Suite 19 shall be disposed of after full installation of new dispenser.

2.2 Work area shall be cleaned and brought back to prior-to-work condition at the end of each day.

3. Schedule: The Contractor shall develop, maintain, and submit for Government approval, an integral master project schedule identifying critical path events for all requirements to be performed by the Contractor in accordance with this PWS. The Contractor shall provide a final schedule to the COR, coordinated with the customer POC, no later than 5 calendar days after award. This schedule shall include delivery dates, start and finish dates for installation on each location. The work shall be completed in accordance with, and no later than, the following schedule.

Final Schedule is due at 5 calendar days after award. Products shall be delivered within 15 calendar days after award. Installation shall be complete at 30 calendar days after award.

If any of these milestones falls on a Saturday, Sunday or Federal holiday, then the date will be deemed to occur on the next working day.

4. Delivery/Installation: Delivery of products: The Contractor and/or the Contractor’s installation team shall coordinate and schedule all deliveries. The Contractor shall manage the delivery and installation services to correspond appropriately, not having more than 24 hours of time between any scheduled delivery of products and the start of installation. All unpacking and placement of product into the facility shall be performed by the Contractor and/or the Contractor’s installation team. The Contractor shall provide all necessary transportation and equipment to successfully accomplish the delivery and installation of all products in their final location within the facility.

Installation. The Contractor shall install all products at their final locations in the building(s) in accordance with the PWS requirements. Installation shall include removal from packaging, inspection, assembly of dispensers, placement of plumbing items at the correct location, and removal and disposal of all old equipment, dunnage and packaging.

5. Period of Performance: The Contractor shall develop and submit a detailed project schedule showing all milestone events required by this PWS. The schedule shall adhere to Period of Performance (POP) as awarded.

POP extension requests are not guaranteed and may require consideration from the Contractor depending upon the circumstances of the request. If a specific delivery date is required by the Government, it will be specified in the Request for Proposal (RFP). Otherwise, the Contractor shall propose a period of performance (POP) in response to the level of effort required to fulfill the requirements of the RFP. This POP may be negotiated prior to award of the contract. The government reserves the right to award a POP date beyond the contractor’s proposed date.

These days are for government close out actions and are not to be interpreted as additional time or float for the contractor to use for project completion.

6. Payments:

6.1 Payment will be in accordance with the following schedule. All days are business days.

Milestone Schedule

Description Required Date

Government acceptance of Accident Prevention Plan (APP) Submitted within 5 days of award and before start of physical site work and kept current

Government acceptance of Project Schedule Submitted within 5 days of award and kept current.

Monthly Activities In arrears

6.2 First Payment will be made after successful install of dispensers. First payment shall be the price for machines and installation. Subsequent payments will be divided equally throughout the awarded contract period. Contractor shall invoice monthly, in arrears, in applicable increments of the contract award amount for the services provided.

7. Invoicing Instructions:

All invoices must be submitted electronically for technical review and payment. Electronic invoice submissions must be created in black and white in Adobe's Portable Document Format (PDF). The contractor shall submit invoices to each of the following email addresses:

Jeffrey.L.Arranz@usace.army.mil Keith.R.Morris@usace.army.mil Suzanne.U.McKnight@usace.army.mil SPPInvoice@usace.army.mil

Note: Invoices must match purchase order/contract in description. Defective/deficient invoices will be returned.

Invoices submitted for payment by Contractors shall contain the following minimum information:

1) Name and address of the contractor

2) Invoice date and number

3) Contract number, contract line item number and if applicable, the order number

4) Description, quantity, unit of measure, unit price and extended price of the item delivered

5) Shipping and payment terms

6) Terms of any discount for prompt payment offered

7) Name and address of official to whom payment will be sent

Payments will be made after submission of a proper invoice and only for Government accepted services.

Safety Compliance Requirements: Contractor shall execute all work IAW the latest version of the US Army Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1.

http://www.usace.army.mil/SafetyandOccupationalHealth/SafetyandHealthRequirementsManual.aspx

Accident Prevention Plan (APP) for Limited Scope. The Contractor shall be required to submit a Corporate Accident Prevention Plan to the Contracting Officer and Contracting Officer Representative within five business days after initial award of the contract. The APP shall address applicable items listed in Appendix A of the US Army Corps of Engineers Safety and Health Requirements Manual (EM 385-1-1) in addition to the other applicable requirements of EM 385-1-1 and OSHA requirements. An APP is, in essence, a safety and health policy and program document. The plan shall provide enough information to be generally applicable to all of the work items listed above. The APP is a document that details how, the safety and health requirements of OSHA, other applicable regulatory codes and documents, and the U. S. Army Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1, are to be accomplished. No work shall be performed until the APP has been reviewed and accepted by CEHNC.

8. Quality Control: The Contractor shall establish and maintain a complete Quality Control Plan (QCP) to verify that contract performance is achieved as specified. A copy of the plan or any updates to the plan shall be provided to the Contracting Officer within 10 business days of receipt of Notice to Proceed and any other time upon request. Personnel performing quality control functions shall be identified to the COR and given sufficient responsibility, authority, and organizational freedom to identify and evaluate quality problems, initiate, recommend, provide solutions or stop the work. The program shall include, but not be limited to, the following:

8.1 Quality Control System. A Quality Control System (QCS), covering all services performed by this contract must specify the areas to be inspected on either a scheduled or unscheduled basis and how often inspections will be conducted and documented.

8.2 Quality Assurance shall be performed by visual inspection.

9. Points of Contact:

Project Manager:

Name: Sue McKnight Phone: 265-895-1064 Email: Suzanne.U.McKnight@usace.army.mil mailto:Jeffrey.L.Arranz@usace.army.mil mailto:Jeffrey.L.Arranz@usace.army.mil mailto:Suzanne.U.McKnight@usace.army.mil mailto:Suzanne.U.McKnight@usace.army.mil http://www.usace.army.mil/SafetyandOccupationalHealth/SafetyandHealthRequirementsManual.aspx mailto:Suzanne.U.McKnight@usace.army.mil

Technical Manager and Contracting Officer’s Representative:

Name: Jeff Arranz or Keith Morris Phone: 256-895-1333 E-mail: Jeffrey.L.Arranz@usace.army.mil Or Keith.R.Morris@usace.army.mil

Contracting Officer:

Name: Tondra Madison Phone: 256-895-1980 E-mail: Tondra.R.Madison@usace.army.mil

10. Security: All contractor personnel shall read applicable security regulations, to be provided by the government, to familiarize them with the government’s guidance on security.

10.1 AT Level I Training. All contractor employees, to include subcontractor employees, requiring access to Army installations, facilities, controlled access areas, or require network access, shall complete AT Level I awareness training within 30 calendar days after contract start date or effective date of incorporation of this requirement into the contract, whichever is applicable. Upon request, the contractor shall submit certificates of completion for each affected contractor employee and subcontractor employee, to the COR or to the contracting officer (if a COR is not assigned), within 5 calendar days after completion of training by all employees and subcontractor personnel. AT Level I awareness training is available at the following website:

http://jko.jten.mil/courses/atl1/launch.html; or it can be provided by the RA ATO in presentation form which will be documented via memorandum.

10.2 All contractor and all associated sub-contractors employees shall comply with applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative). The contractor shall also provide all information required for background checks to meet installation/facility access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9, Personal Identity Verification of Contractor Personnel) as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any installation or facility change, the Government may require changes in contractor security matters or processes.

10.3 The contractor and all associated sub-contractors shall receive a brief/training (provided by the RA) on the local suspicious activity reporting program. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the project manager, security representative or law enforcement entity. This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance with the results reported to the COR NLT 5 calendar days after the completion of the training.

10.4 All new contractor employees will complete Level I OPSEC Training within 30 calendar days of their reporting for duty. Additionally, all contractor employees must complete annual OPSEC awareness training. The contractor shall submit certificates of completion for each affected contractor and subcontractor employee, to the COR or to the contracting officer (if a COR is not assigned), within 5 calendar days after completion of training.

OPSEC awareness training is available at the following websites: https://www.iad.gov/ioss/ or http://www.cdse.edu/catalog/operations-security.html; or it can be provided by the RA OPSEC Officer in presentation form which will be documented via memorandum.

10.5 All contract employees, including subcontractor employees who are not in possession of the appropriate security clearance or access privileges, will be escorted in areas where they may be exposed to classified and/or sensitive materials and/or sensitive or restricted areas.

10.6 The Prime Contractor Company must have a Facility Clearance (FCL) at the appropriate level (IAW the NISPOM DOD 5220.22-M and AR 380-49) prior to the start of the contract awarded period of performance.

Contractor personnel performing work under this contract must have the required security clearance, per AR 380- 67, at the appropriate level at the start of the period of performance. Security Clearances and FCL requirements mailto:Jeffrey.L.Arranz@usace.army.mil mailto:Keith.R.Morris@usace.army.mil mailto:Tondra.R.Madison@usace.army.mil http://jko.jten.mil/courses/atl1/launch.html%3B http://www.iad.gov/ioss/ http://www.iad.gov/ioss/ http://www.cdse.edu/catalog/operations-security.html%3B

W912DY18R0004

are required to be maintained for the life of the contract IAW the DD Form 254 attached to the contract. If no FCL, the supporting Government Contracting Activity will sponsor the prime contract company in obtaining the

FCL.

10.7 The Contractor must pre-screen Candidates using the E-verify Program (http://www.uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award.

10.8 All new contractor employees will complete annual Threat Awareness and Reporting Program (TARP) Training provided by a Counterintelligence Agent, IAW AR 381-12. The contractor shall submit certificates of completion for each affected contractor and subcontractor employee(s) or a memorandum for the record, to the COR or to the contracting officer (if a COR is not assigned), within 5 calendar days after completion of training.

Authorized web-based TARP training for CAC card holders is available at the following website:

https://www.us.army.mil/suite/page/655474 security policies and procedures (provided by government representative). The contractor shall also provide all information required for background checks or background investigation and to meet installation/facility access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any installation or facility change, the Government may require changes in contractor security matters or processes.

11. Prosecution and Completion of Work:

11.1 The Contractor shall prosecute the work under the direction of a responsible representative approved by the Government. The company officer or representative shall be designated as the Contractor’s Project Manager and shall be responsible for complete coordination of all work under this contract. All work shall be accomplished with adequate internal controls, quality assurance processes, and review procedures. These controls and procedures shall be established by the Contractor to ensure technical accuracy and eliminate conflicts, errors, and omissions. The Government may elect to provide third party technical inspection.

11.2 The contractor is required to pay wage rates in accordance with the criteria set forth below:

11.2.1 Wage Rate Requirements (Construction) (WRRC) shall be utilized for construction based labor efforts.

These activities include but are not limited to high/medium voltage wiring, excavation, trenching, removing/repairing walls, flooring, framing, foundation work, masonry, plumbing, lighting replacement, demolition (if other construction work is to follow), painting, replacement of boilers/chillers/air handling units (not including purchase of equipment), installation of new fire alarm systems, and any other work required to be performed by a construction trade.

11.2.2 Service Contract Labor Standards (SCLS) wage rates shall be utilized for non-professional service-based labor efforts if the work is predominantly services. Service activities include but are not limited to the design, project oversight, commissioning, engineering, meter installation, programming, test and balancing, survey, low voltage wiring not requiring an electrician, control system components (motors, actuators, sensors, controls, etc.), repairs to fire alarm systems/chillers/boilers/air handling units, repair/replacement to other ancillary equipment, installation/repair of electronic security systems, and any other work of a services nature that is not required to be performed by a construction trade.

12.3.3 SCLS/WWRC Wage Rate Applicability by Location: WWRC wage rates are only applicable within the United States. SCLS rates are applicable within the United States, Northern Mariana Islands, Guam, Puerto http://www.uscis.gov/e-verify) http://www.uscis.gov/e-verify) http://www.us.army.mil/suite/page/655474 http://www.us.army.mil/suite/page/655474

W912DY18R0004

Rico, American Samoa, Johnson Island, the U.S. Virgin Islands, Wake Island, and Outer Continental Shelf Lands.

INSTRUCTIONS TO OFFEROR

The U.S. Army Corps of Engineers, Huntsville, AL has a requirement to acquire seven (7) Ice & Water Dispensers for seven (7) locations. Please see Performance Work Statement.

A site visit will be conducted…