W912DR18B0013.pdf

Project Title: Wicomico River Maintenance Dredging, Wicomico County, Maryland

Type of Contract: Firm Fixed Price Type of Solicitation: Invitation for Bid

NAICS Code: 237990 Size Standard: $27.5 Million

100% Small Business Set Aside

X

ROBERT N JACKSON JR 410-962-3464

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

30-Sep-2018

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________120 calendar days after receiving aw ard, X notice to proceed. This performance period is mandatory, negotiable. (See _________________________FAR 52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________30 Oct 2018 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

USACE, BALTIMORE DISTRICT

2 HOPKINS PLAZA

ROOM 03-G-01

BALTIMORE MD 21201

W912DR

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

11:00 AM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: 410-962-2196 TEL: FAX:

W912DR18B0013 42

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W912DR18B0013

Section 00 10 00 - Solicitation

PRICE SCHEDULE

UNIT PRICE SCHEDULE

Item Estimated No. Description Quantity Unit Price Amount

Reimbursement of Performance and Payment Bonds

JOB

L.S.

Weir Box Replacement

Mobilization and Demobilization

Maintenance Dredging Wicomico River- Stations 128+900 to 135+500

20,031

CY

0005 Maintenance Dredging

139+600 to 156+600

51,434

Maintenance Dredging

157+100 to 158+500

4,332

TOTAL ESTIMATED BID AMOUNT $

NOTES TO BIDDERS

Bidders must bid on all items. Failure to bid on all items may be cause for rejection of the proposal.

VARIATION IN ESTIMATED QUANTITIES. If the quantity of a unit-price item in this contract is an estimated quantity and the actual quantity of the unit-price item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.

(FAR 52.211-18 APR 1984)

SCOPE OF WORK

The project includes the maintenance dredging of the federal channel in the upper half of the Wicomico River, Wicomico County, MD. Dredging will occur via hydraulic dredge and placement will occur via pipeline to a preexisting upland placement site. Construction will also occur at the existing upland placement site to replace weir boxes. The upland site is known as the Sharps Point Disposal Site, Salisbury, Wicomico County, Maryland.

Approximately 100,000 cubic yards of material will be dredged consisting of sand, silt, clay, mixed shell, gravel and other materials. The construction duration will be approximately 120 calendar days.

Section 00 21 13 - Instructions to Bidders

INSTRUCTIONS TO BIDDERS

IMPORTANT NOTES REGARDING THIS ACQUISITION:

A. BIDDING MATERIAL

Copies of the Solicitation, Specifications, and Drawings forms are available by INTERNET ACCESS ONLY. All solicitation documents will be posted to the Federal Business Opportunity (FedBizOpps) website at: https://www.fbo.gov.

BID DOCUMENTS: The following documents must be submitted with your bid package:

1. SF 1442, Solicitation, Offer and Award

2. Schedule of bids/prices

3. Representations and Certifications (Section 004500)

5. Standard Form LLL (Section 007300)

6. Certificate of Corporate Authority (Section 007300)

7. All amendments (if any) must be acknowledged

8. Bid Bond (Standard Form 24)

9. One (1) compact disk (CD) with the above documents in individual PDF files.

B. PROPOSAL CONDITIONS

1. Contractors must bid all items in the above price schedule, with no exceptions. Should a contractor fail to fully complete the price schedule, its BID will not be considered responsive to the solicitation and will be ineligible for the resultant contract award.

2. Split awards or multiple award contracts will not result from this Solicitation.

3. Arithmetic Discrepancies:

a) For the purpose of initial evaluation of bids, the following will be utilized in resolving arithmetic discrepancies found on the face of the bidding schedule as submitted by bidder:

(1) Obviously misplaced decimal points will be corrected;

(2) Discrepancy between unit price and extended price, the unit price will govern;

(3) Apparent errors in extension of unit prices will be corrected;

(4) Apparent errors in addition of lump-sum and extended prices will be corrected.

b) For the purpose of bid evaluation, the Government will proceed on the assumption that the bidder intends his bid to be evaluated on the basis of the unit prices and the total bid amount, subject to any arithmetic discrepancies as provided above. The resultant unit prices and total amounts will then be so reflected on the abstract of bids.

c) These correction procedures shall not be used to resolve any ambiguity concerning which bid is low.

4. Caution to Bidders – Bid Errors: You are cautioned to exercise extreme care in preparation of your bid.

Errors in bids are costly and could result in substantial loss to you as well as delayed award of contracts.

C. COMPETITION: Competition for this acquisition is 100% Small Business Set-Aside.

D. SUBMISSION OF BIDS

1. All bids shall be submitted in accordance with the procedures set forth in Block 13 of Page 1 of this Solicitation document. BIDS OR MODIFICATIONS TO BIDS THAT ARE RECEIVED BY FACSIMILE WILL NOT BE

CONSIDERED.

2. SF 1442 BACK (Page 2 of the Solicitation): Bidders are required to acknowledge the receipt of all amendments to the Solicitation on the Standard Form 1442 in Block 19. Bidders shall fully complete all the required areas located under the section designated as “OFFER” (refer to Items 14 through 20C).

3. Section 004500 (Representation and Certifications): The bidders must fully complete Section 004500 of this Solicitation and submit it along with all other documents required by this Solicitation. Bidders received without this Section fully completed may be rejected, considered non-responsive and ineligible for award.

4. BID GUARANTEE: The bidders are required to submit a Bid Guarantee for this procurement. Any bidders failing to submit an authentic Bid Guarantee will be considered non-responsive to the Solicitation and ineligible for award. The Bid Guarantee shall be in the amount of 20% of the bidder’s price or $3,000,000.00, whichever is less.

5. BONDS AND INSURANCE: The Contractor will be required to furnish proof of insurance, including copies of the required endorsements, and performance and payment bonds within 10 calendar days following the Contractor’s receipt of the contract award.

E. REQUESTS FOR INFORMATION

Technical inquiries and questions relating to this solicitation are to be submitted via Bidder Inquiry in ProjNet at (https://www.projnet.org) No Later Than (NLT) 10:00 A.M. (EST), 24 September 2018. To submit and review inquiry items, prospective vendors will need to use the Bidder Inquiry Key presented below and follow the instructions listed below the key for access. A prospective vendor who submits a comment /question will receive an acknowledgement of their comment/question via email. Another email to the same address will notify the prospective vendor once the reply is available for viewing.

The Bidder Inquiry Key is: 4S8E6V-99R9NT

Specific Instructions for ProjNet Bid Inquiry Access:

1. From the ProjNet home page linked above, click on Quick Add on the upper right side of the screen.

2. Identify the Agency. This should be marked as USACE.

3. Key. Enter the Bidder Inquiry Key listed above.

4. Email. Enter the email address you would like to use for communication.

5. Click Continue. A page will then open saying that a user account was not found and will ask you to create one using the provided form.

6. Enter your First Name, Last Name, Company, City, State, Phone, Email, Secret Question, Secret Answer, and Time Zone. Make sure to remember your Secret Question and Answer as they will be used from this point on to access the ProjNet system.

7. Click Add User. Once this is completed you are now registered within ProjNet and are currently logged into the system.

Specific Instructions for Future ProjNet Bid Inquiry Access:

1. For future access to ProjNet, you will not be provided any type of password. You will utilize your Secret Question and Secret Answer to log in.

2. From the ProjNet home page linked above, click on Quick Add on the upper right side of the screen.

3. Identify the Agency. This should be marked as USACE.

4. Key. Enter the Bidder Inquiry Key listed above.

5. Email. Enter the email address you used to register previously in ProjNet.

6. Click Continue. A page will then open asking you to enter the answer to your Secret Question.

7. Enter your Secret Answer and click Login. Once this is completed you are now logged into the system.

The call center operates weekdays from 8AM to 5PM U.S. Central Time Zone (Chicago). The telephone number for the Call Center is 800-428-HELP.

Offers will NOT be publicly opened. Information concerning the status of the evaluation and/or award will NOT be available after receipt of proposals.

PLEASE NOTE: THE LAST DAY FOR INTERESTED BIDDERS TO SUBMIT THEIR CONTRACTING

AND TECHNICAL REQUESTS FOR INFORMATION IN PROJNET IS 24 September 2018 AT 10:00AM EST. NO OTHER REQUESTS FOR INFORMATION WILL BE ACCEPTED AFTER 24 Sept 2018 AT

10:00AM EST.

****** NOTE: QUESTIONS ANSWERED IN PROJNET ARE NOT OFFICIAL UNTIL AN

AMENDMENT IS ISSUED. ***

F. DELIVERY OF BIDS

1. Sealed Bids: Regardless of the method of delivery (mailed or hand-carried), bids and all other documents called out in the Solicitation shall be enclosed and sealed in an envelope that is clearly marked “Bid” and shall include the assigned Solicitation Number, and the Bid Opening Date and Time.

2. Hand Carried Bids: It is the responsibility of each bidder to ensure that its Sealed Bid is received by the Baltimore District’s – Contracting Branch at the following location:

Contracting Division, Baltimore District, Corps of Engineers ATTN: Robert Jackson

W912DR18B0012

2 Hopkins Plaza, Room 00-A-26 Baltimore, Maryland 21201

Sealed bids must be received prior to the date and time set for the opening of the bids – See Block 13A of Page 1 of the Solicitation.

G. EVIDENCE OF AUTHORITY TO SIGN BIDS/PROPOSALS

Evidence of the authority of individuals signing bids/proposals to submit firm bids/proposals on behalf of the bidder/offeror is required except where the bid/offer is signed, and shows that it is so signed, by: The President, Vice-President, or Secretary of Incorporated bidders; a partner in case of partnership; the owner in the case of sole proprietorships. Failure to submit with the bid satisfactory evidence of authority of all other persons may be cause for rejection of bid as an invalid or non-responsive bid.

H. BID OPENING ROOM:

1. In order to gain access, all interested participants must check in at the Security Desk in the lobby with a valid photo ID, and will then be directed to the Bid Opening Room 00-A-26. All individuals attending the Bid Opening must allow enough time to go through security and arrive at the Bid Opening room no later than than the time prescribed in (Block 13 of the SF1442).

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2016 52.209-7 Information Regarding Responsibility Matters JUL 2013 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-12 Preparation Of Bids APR 1984 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-29 Order Of Precedence--Sealed Bidding JAN 1986 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.222-5 Construction Wage Rate Requirements--Secondary Site of the

Work

MAY 2014

52.222-12 Contract Termination-Debarment MAY 2014 52.225-10 Notice of Buy American Requirement--Construction

Materials

MAY 2014

52.232-13 Notice Of Progress Payments APR 1984 52.232-38 Submission of Electronic Funds Transfer Information with

Offer

JUL 2013

252.204-7006 Billing Instructions OCT 2005 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.236-7008 Contract Prices-Bidding Schedules DEC 1991

CLAUSES INCORPORATED BY FULL TEXT

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a firm fixed priced contract resulting from this solicitation.

(End of provision)

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

23.6% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is MD Caroline;

MD Dorchester; MD Kent, MD Queen Annes; MD Somerset; MD Talbot; MD Wicomico; MD Worcester; VA Accomack; VA Northampton.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 30% percent of the bid price or $3 Million, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

(Email):

Patricia.Morrow@usace.army.mil

(For hand delivered and mailed protests):

USACE Baltimore District ATTN: Patricia Morrow 2 Hopkins Plaza Baltimore, MD 21201

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) The site visit will be held 10:00 AM EST on 19 Sept 2018. Attendees will meet at Sharps Point Upland Placement Site. 622 Sharps Point Road, Fruitland MD 21826. The POC for the sitie visit is Danielle Szimanski Danielle.M.Szimanski@usace.army.mil

52.251-1 GOVERNMENT SUPPLY SOURCES (APR 2012)

The Contracting Officer may issue the Contractor an authorization to use Government supply sources in the performance of this contract. Title to all property acquired by the Contractor under such an authorization shall vest in the Government unless otherwise specified in the contract. The provisions of the clause at FAR 52.245-1, Government Property, apply to all property acquired under such authorization.

(End of clause)

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil/ http://farsite.hill.af.mil/vmdfara.htm https://www.acquisition.gov/browsefar

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of"(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any (48 CFR Chapter ) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

Section 00 45 00 - Representations and Certifications

52.204-6 Unique Entity Identifier OCT 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.222-38 Compliance With Veterans' Employment Reporting Requirements

FEB 2016

52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

252.203-7005 Representation Relating to Compensation of Former DoD Officials

NOV 2011

252.204-7007 Alternate A, Annual Representations and Certifications JAN 2015

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

52.209-11 REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A

FELONY CONVICTION UNDER ANY FEDERAL LAW (FEB 2016)

(a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that--

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that--

(1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

52.222-25 AFFIRMATIVE ACTION COMPLIANCE (APR 1984)

The offeror represents that

(a) [ ] it has developed and has on file, [ ] has not developed and does not have on file, at each establishment, affirmative action programs required by the rules and regulations of the Secretary of Labor (41 CFR 60-1 and 60-2), or

(b) [ ] has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor.

252.209-7004 SUBCONTRACTING WITH FIRMS THAT ARE OWNED OR CONTROLLED BY THE

GOVERNMENT OF A COUNTRY THAT IS A STATE SPONSOR OF TERRORISM (OCT 2015)

(a) Unless the Government determines that there is a compelling reason to do so, the Contractor shall not enter into any subcontract in excess of $35,000 with a firm, or a subsidiary of a firm, that is identified in the Exclusions section of the System for Award Management System (SAM Exclusions) as being ineligible for the award of Defense contracts or subcontracts because it is owned or controlled by the government of a country that is a state sponsor of terrorism.

(b) A corporate officer or a designee of the Contractor shall notify the Contracting Officer, in writing, before entering into a subcontract with a party that is identified, in SAM Exclusions, as being ineligible for the award of Defense contracts or subcontracts because it is owned or controlled by the government of a country that is a state sponsor of terrorism. The notice must include the name of the proposed subcontractor and the compelling reason(s) for doing business with the subcontractor notwithstanding its inclusion in SAM Exclusions.

INFORMATIONAL TEXT

CONSTRUCTION DURATION

The anticipated construction duration for this procurement is 120 calendar days.

MAGNITUDE OF CONSTRUCTION PROJECT

The estimated magnitude of construction is between $1,000,000.00 and $5,000,000.00.

PREAWARD SAFETY CONFERENCE

Where an apparent low bidder, in performance of contracts during the previous three year period incurred one or more accidents, or where, in the opinion of the Contracting Officer, there is any question regarding his compliance with any safety or accident prevention requirement, such bidder, on request of the Contracting Officer prior to any award under this solicitation, shall attend a conference with representatives of the Contracting Officer to discuss any such accidents or non-compliance, the reasons for their occurrence, and measures which will be taken to preclude any recurrence thereof. Information elicited at this conference will be used by the Contracting Officer, in conjunction with other information obtained in the pre award survey, in determining the bidder's responsibility.

The items discussed, the preventive measures considered, and any conclusions reached in this conference shall be recorded in minutes of the meeting, which shall be authenticated by the signatures of representatives of the bidder and the Contracting Officer, and any procedures noted therein as agreed upon shall become an obligation of the bidder, along with all other safety and accident prevention requirements of the contract, if award is made to him.

End of Text

SAFETY REQUIREMENTS

The Contractor is advised that he shall be expected to comply with the OSHA Standards as well as the most recent Corps of Engineers Safety and Health Requirements Manual (EM 385-1-1). EM 385-1-1 with applicable addenda and the OSHA Standards are hereby incorporated by reference, as if fully set forth

HARBOR MAINTENANCE FEE

Offerors contemplating use of U.S. ports in the performance of the contract are subject to paying a harbor maintenance fee on cargo. Federal law establishes an ad valorem port use fee on commercial cargo imported into or exported from various U.S. ports. The fee is 0.125 percent (.00125). Cargo to be used in performing work under contracts with the U.S. Government is not exempt from the fee, although certain exemptions do exist. Offerors are responsible for ensuring that the applicable fee and associated costs are taken into consideration in the preparation of their offers. Failure to pay the harbor maintenance fee may result in assessment of penalties by the Customs Service.

The statute is at Title 26 U.S. Code sections 4461 and 4462. Department of Treasury Customs Service regulations implementing the statute, including a list of ports submit to the fee, are found at 19 CFR Section 24.24, Harbor Maintenance Fee. Additional information may be obtained from local U.S. Customs Service Offices or by writing to the Director, Budget Division, Office of Finance, Room 6328, U.S. Customs Service, 1301 Constitution Avenue, N.W., Washington, D.C. 20229.

Section 00 70 00 - Conditions of the Contract

Section 00 72 00 - General Conditions

52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-13 Contractor Code of Business Ethics and Conduct OCT 2015 52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

APR 2014

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements

JAN 2017

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-7 System for Award Management OCT 2016 52.204-8 Annual Representations and Certifications JAN 2018 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.204-13 System for Award Management Maintenance OCT 2016 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-17 Ownership or Control of Offeror JUL 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-20 Predecessor of Offeror JUL 2016 52.204-22 Alternative Line Item Proposal JAN 2017 52.208-6 Marking of Leased Vehicles APR 1984 52.209-9 Updates of Publicly Available Information Regarding

Responsibility Matters

JUL 2013

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.210-1 Market Research APR 2011 52.211-12 Liquidated Damages--Construction SEP 2000 52.211-13 Time Extensions SEP 2000 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-10 Contract Award--Sealed Bidding JUL 1990 52.214-12 Preparation Of Bids APR 1984 52.214-16 Minimum Bid Acceptance Period APR 1984 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-22 Evaluation Of Bids For Multiple Awards MAR 1990 52.214-26 Audit and Records--Sealed Bidding OCT 2010

52.214-28 Subcontracting Certified Cost Or Pricing Data-- Modifications--Sealed Bidding

OCT 2010

52.214-29 Order Of Precedence--Sealed Bidding JAN 1986 52.215-19 Notification of Ownership Changes OCT 1997 52.219-8 Utilization of Small Business Concerns NOV 2016 52.219-9 Alt I Small Business Subcontracting Plan (JAN 2017) Alternate I NOV 2016 52.219-16 Liquidated Damages-Subcontracting Plan JAN 1999 52.219-28 Post-Award Small Business Program Rerepresentation JUL 2013 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards - Overtime

Compensation

MAY 2018

52.222-5 Construction Wage Rate Requirements--Secondary Site of the Work

MAY 2014

52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-35 Equal Opportunity for Veterans OCT 2015 52.222-35 Alt I Equal Opportunity for Veterans (Oct 2015) Alternate I JUL 2014 52.222-36 Equal Opportunity for Workers with Disabilities JUL 2014 52.222-36 Alt I Equal Opportunity for Workers with Disabilities (July 2014) -

Alternate I

JUL 2014

52.222-37 Employment Reports on Veterans FEB 2016 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons MAR 2015 52.222-54 Employment Eligibility Verification OCT 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2017 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

SEP 2013

52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.223-22 Public Disclosure of Greenhouse Gas Emissions and Reduction Goals -- Representation.

DEC 2016

52.225-3 Buy American --Free Trade Agreement--Israeli Trade Act MAY 2014 52.225-25 Prohibition on Contracting with Entities Engaging in Certain

Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

52.227-1 Authorization and Consent DEC 2007

52.227-2 Notice And Assistance Regarding Patent And Copyright Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-1 Bid Guarantee SEP 1996 52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-13 Notice Of Progress Payments APR 1984 52.232-16 Progress Payments APR 2012 52.232-17 Interest MAY 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-15 Schedules for Construction Contracts APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.241-5 Contractor's Facilities FEB 1995 52.242-5 Payments to Small Business Subcontractors JAN 2017 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-1 Changes--Fixed Price AUG 1987 52.243-4 Changes JUN 2007 52.243-6 Change Order Accounting APR 1984 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.247-64 Preference for Privately Owned U.S. - Flag Commercial

Vessels

FEB 2006

52.248-3 Value Engineering-Construction OCT 2015 52.249-2 Alt II Termination For Convenience Of The Government (Fixed

Price) (Apr 2012) - Alternate II

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991

252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7003 Agency Office of the Inspector General DEC 2012 252.203-7004 Display of Hotline Posters OCT 2016 252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7000 Disclosure Of Information OCT 2016 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7006 Billing Instructions OCT 2005 252.204-7007 Alternate A, Annual Representations and Certifications JAN 2015 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

OCT 2016

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of Terrorism

OCT 2015

252.219-7003 Small Business Subcontracting Plan (DOD Contracts) APR 2018 252.222-7006 Restrictions on the Use of Mandatory Arbitration Agreements DEC 2010 252.223-7004 Drug Free Work Force SEP 1988 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7012 Preference For Certain Domestic Commodities DEC 2017 252.225-7048 Export-Controlled Items JUN 2013 252.226-7001 Utilization of Indian Organizations and Indian-Owned

Economic Enterprises, and Native Hawaiian Small Business Concerns

SEP 2004

252.228-7004 Bonds Or Other Security DEC 1991 252.231-7000 Supplemental Cost Principles DEC 1991 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.236-7001 Contract Drawings, and Specifications AUG 2000 252.236-7002 Obstruction of Navigable Waterways DEC 1991 252.236-7004 Payment for Mobilization and Demobilization DEC 1991 252.236-7008 Contract Prices-Bidding Schedules DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.247-7023 Transportation of Supplies by Sea APR 2014 252.247-7024 Notification Of Transportation Of Supplies By Sea MAR 2000

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 120 Calendar Days. The time stated for completion shall include final cleanup of the premises.

52.211-18 VARIATION IN ESTIMATED QUANTITY (APR 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.

52.225-11 BUY AMERICAN--CONSTRUCTION MATERIALS UNDER TRADE AGREEMENTS (OCT

2016)

(a) Definitions. As used in this clause--

Caribbean Basin country construction material means a construction material that--

(1) Is wholly the growth, product, or manufacture of a Caribbean Basin country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a Caribbean Basin country into a new and different construction material distinct from the materials from which it was transformed.

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4)such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site.

Materials purchased directly by the Government are supplies, not construction material.

Cost of components means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Designated country means any of the following countries:

(1) A World Trade Organization Government Procurement Agreement (WTO GPA) country (Armenia, Aruba, Austria, Belgium, Bulgaria, Canada, Croatia, Cyprus, Czech Republic, Denmark, Estonia, Finland, France, Germany, Greece, Hong Kong, Hungary, Iceland, Ireland,…