Am-0002_W9128F-18-R-0001.pdf

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

Previous edition unusable

Amendment No. 0002

13 ASOS EXPANSION – AIR SUPPORT OPERATIONS CENTER (ASOC), FY18, ACC123301, FORT CARSON, COLORADO

See attached documentation for content of the amendment changes to RFP

Date for receipt of proposals is 21 DEC 2017 at 1400 hours

Government Point of Contact: Dawn Barnett,Contract Specialist (402) 995-2091

U.S ARMY CORPS OF ENGINEERS, OMAHA DISTRICT

CONTRACTING OFFICE

1616 CAPITOL AVE.

OMAHA, NE 68102-4901

See Item 6

W9128F-18-R-0001

11/21/2017

10/31/2017

11/21/2017

Am #0002 - 1

Am #0002 - 2 (Continuation of SF30)

DEPARTMENT OF THE ARMY

Omaha District, Corps of Engineers

1616 Capitol Avenue Omaha, Nebraska 68102-4901

:NOTICE: Failure to acknowledge : Solicitation No. W9128F-18-R-0001 :all amendments may cause rejec-:

:tion of the offer. See FAR : Date of Issue: 30 OCT 2017 :52.215-1 of Section 00 21 01. : Date of Receiving Proposals:

21 DEC 2017

Amendment No. 0002

21 NOV 2017

SUBJECT: Amendment No. 0002 to Request for Proposal Solicitation Package for Design and Construction of 13 ASOS EXPANSION – AIR SUPPORT OPERATIONS

CENTER (ASOC).

TO: Prospective Offerors and Others Concerned

1. The specifications and drawings for subject project are hereby modified as follows (revise all specification indices, attachment lists, and drawing indices accordingly).

a. Specifications. (Descriptive Changes). NONE

(1) Section 01 30 00.24 Attachments, delete General Wage Rate Decision Number CO170032 in its entirety and substitute General Wage Rate Decision Number CO170032 dated 11/10/2017. General Wage Rate Decision Number CO170032 dated 11/10/2017 is included as an attachment to this Amendment.

b. Specifications (New and/or Revised and Reissued). Delete and substitute or add specification pages as noted below. The substituted pages are revised and reissued with this Amendment. For convenience, on the revised specification pages, changes have been identified by highlighting text. (All portions of reissued specification pages shall apply whether or not changes thereon have been indicated.)

Pages Deleted Pages Substituted or Added 00 21 01 00 21 01 00 22 00 00 22 00 01 82 00 01 82 00 01 86 26 01 86 26 Appendix B, pages F-20-23, F-38 Appendix B, pages F-20-23, F-38

c. Drawings (Not Reissued). NONE

d. Drawings (Reissued). The following drawing(s) are revised with a revision date as indicated in the title block, and reissued with this amendment.

(1) Sheet G-002, VOLUME 1 INDEX

(2) Sheet B-302, SOIL BORING LOGS - DRILL HOLES FC17-07

THROUGH FC17-09

Am #0002 - 3 (Continuation of SF30)

2. This amendment is a part of the proposing papers and its receipt shall be acknowledged on the Standard Form 1442. All other conditions and requirements of the request for proposal remain unchanged. If the proposals have been mailed prior to receiving this amendment, you will notify the office where proposals are received, in the specified manner, immediately of its receipt and of any changes in your proposal thereby occasioned.

Electronic Proposals shall be delivered via AMRDEC Safe Access File Exchange (SAFE), https://safe.amrdec.army.mil/, to the USACE Contracting Activity at the following email addresses:

Dawn.S.Barnett@usace.army.mil

Denise.M.Cramer@usace.army.mil

3. Offers will be received until 2:00 p.m, local time at place of receiving proposals, 21 DEC 2017.

Attachments:

Wage Rate General Decision Number dated 11/10/2017: CO170032 Specification Page(s) listed in 1.b., above Drawing(s) listed in 1.d., above

U.S. Army Corps of Engineers, Omaha District 1616 Capitol Avenue Omaha, Nebraska 68102-4901

21 NOV 2017

NEP/2160

This page was intentionally left blank for duplex printing.

Am #0002 CO170032 - 1 11/10/2017

General Decision Number: CO170032 11/10/2017 CO32

Superseded General Decision Number: CO20160032

State: Colorado

Construction Type: Building

County: El Paso County in Colorado.

BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories).

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.20 for calendar year 2017 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.20 (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2017.

The EO minimum wage rate will be adjusted annually. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/06/2017 1 01/27/2017 2 04/07/2017 3 04/21/2017 4 05/19/2017 5 06/02/2017 6 06/09/2017 7 07/21/2017 8 08/18/2017 9 11/03/2017 10 11/10/2017

Am #0002 CO170032 - 2 11/10/2017

* ASBE0028-002 07/01/2017

Rates Fringes

ASBESTOS WORKER/HEAT & FROST

INSULATOR - MECHANICAL (Duct, Pipe & Mechanical System Insulation)......................$ 30.73 14.23

ELEC0113-005 06/01/2017

Rates Fringes

ELECTRICIAN (Includes Low Voltage Wiring)..................$ 31.00 15.38

ELEV0025-001 01/01/2017

Rates Fringes

ELEVATOR MECHANIC................$ 42.35 31.58

FOOTNOTE:

a.Vacation: 6%/under 5 years based on regular hourly rate for all hours worked. 8%/over 5 years based on regular hourly rate for all hours worked.

b. PAID HOLIDAYS: New Year's Day; Memorial Day; Independence Day; Labor Day; Veterans' Day; Thanksgiving Day; the Friday after Thanksgiving Day; and Christmas Day.

ENGI0009-017 05/01/2017

Rates Fringes

POWER EQUIPMENT OPERATOR

(Crane) 141 tons and over...........$ 29.82 10.10 50 tons and under...........$ 27.75 10.10 51 to 90 tons...............$ 27.92 10.10 91 to 140 tons..............$ 28.55 10.10

IRON0024-009 05/01/2017

Rates Fringes

IRONWORKER, ORNAMENTAL...........$ 26.30 12.25

IRON0024-011 05/01/2017

Rates Fringes

IRONWORKER, STRUCTURAL...........$ 26.30 12.25

Am #0002 CO170032 - 3 11/10/2017

PAIN0079-009 08/01/2017

Rates Fringes

PAINTER (Spray)..................$ 20.50 8.41

PLAS0577-002 05/01/2017

Rates Fringes

CEMENT MASON/CONCRETE FINISHER...$ 26.50 11.23

PLUM0058-003 07/01/2017

Rates Fringes

PLUMBER (Excludes HVAC Duct, Pipe and Unit Installation)......$ 32.00 14.10

PLUM0058-004 07/01/2017

Rates Fringes

PIPEFITTER, Includes HVAC Pipe Installation (Excludes HVAC Duct and Unit Installation)....................$ 32.00 14.10

SFCO0669-002 04/01/2017

Rates Fringes

SPRINKLER FITTER (Fire Sprinklers)......................$ 36.73 20.47

SHEE0009-005 07/01/2017

Rates Fringes

SHEET METAL WORKER (Excludes HVAC Duct, Pipe and Unit Installation)....................$ 33.26 16.61

SUCO2013-008 07/31/2015

Rates Fringes

BRICKLAYER.......................$ 21.96 0.00

CARPENTER........................$ 22.63 6.98

LABORER: Common or General......$ 13.40 1.40

LABORER: Mason Tender - Brick...$ 15.99 0.00

Am #0002 CO170032 - 4 11/10/2017

LABORER: Mason Tender - Cement/Concrete..................$ 16.00 0.00

LABORER: Pipelayer..............$ 16.96 3.68

OPERATOR:

Backhoe/Excavator/Trackhoe.......$ 20.26 8.62

OPERATOR: Bobcat/Skid Steer/Skid Loader................$ 18.58 2.42

OPERATOR: Grader/Blade..........$ 21.50 0.00

PAINTER (Brush and Roller).......$ 17.20 0.00

ROOFER...........................$ 16.71 0.00

SHEET METAL WORKER (HVAC Duct Installation Only)...............$ 25.18 6.30

SHEET METAL WORKER (HVAC Unit Installation Only)...............$ 24.00 2.18

TRUCK DRIVER: Dump Truck........$ 17.34 0.00

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

Am #0002 CO170032 - 5 11/10/2017

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than "SU" or "UAVG" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the "SU" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Am #0002 CO170032 - 6 11/10/2017

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Am #0002 CO170032 - 7 11/10/2017

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

This page was intentionally left blank for duplex printing.

13 ASOS Expansion - Air Support Operations Center (ASOC) - FCN FCAU

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION 00 21 01

INSTRUCTIONS TO OFFERORS (RFP)

01/17

PART 1 GENERAL

1.1 (FAR 52.204-7) SYSTEM FOR AWARD MANAGEMENT (OCT 2016)

1.2 (FAR 52.204-16) COMMERCIAL AND GOVERNMENT ENTITY CODE REPORTING

(JUL 2016)

1.3 (FAR 52.211-2) AVAILABILITY OF SPECIFICATIONS, STANDARDS, AND DATA

ITEM DESCRIPTIONS LISTED IN THE ACQUISITION STREAMLINING AND

STANDARDIZATION INFORMATION SYSTEM (ASSIST) (APR 2014)

1.4 (FAR 52.215-1) INSTRUCTIONS TO OFFERORS--COMPETITIVE ACQUISITION

(JAN 2017)

1.5 *FAR 52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT-CONSTRUCTION

MATERIALS UNDER TRADE AGREEMENTS (MAY 2014)

1.6 FAR 52. 215-20 REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA AND

DATA OTHER THAN CERTIFIED COST OR PRICING DATA (OCT 2010)

1.7 (FAR 52.216-1) TYPE OF CONTRACT (APR 1984)

1.8 (FAR 52.217-5) EVALUATION OF OPTIONS (JUL 1990)

1.9 FAR 52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS-SECONDARY SITE

OF THE WORK (MAY 2014)

1.10 FAR 52.222-58 SUBCONTRACTOR RESPONSIBILITY MATTERS REGARDING

COMPLIANCE WITH LABOR LAWS (EXECUTIVE ORDER 13673) (DEC 2016)

1.11 *FAR 52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT-CONSTRUCTION

MATERIALS UNDER TRADE AGREEMENTS (MAY 2014)

1.12 (FAR 52.232-18) AVAILABILITY OF FUNDS (APR 1984)

1.13 (FAR 52.236-27) SITE VISIT (CONSTRUCTION) (FEB 1995).

1.14 (FAR 52.252-1) SOLICITATION PROVISIONS INCORPORATED BY REFERENCE

(FEB 1998)

1.15 DFARS 252.204-7004) ALTERNATE A, SYSTEM FOR AWARD MANAGEMENT

(FEB 2014)

1.16 (DFARS 252.204-7008) COMPLIANCE WITH SAFEGUARDING COVERED

DEFENSE INFORMATION CONTROLS (OCT 2016)

1.17 (DFARS 252.215-7008) ONLY ONE OFFER (OCT 2013)

1.18 DEFINITION OF "DESIGN-BUILD" PROCESS

1.19 SOLICITATION RESTRICTIONS

1.19.1 GENERAL CONTRACTOR

1.19.2 DESIGN AND CONSTRUCTION COSTS

1.19.3 SUBMISSION, MODIFICATION, REVISION, AND WITHDRAWAL OF PROPOSALS

1.19.4 SUBMISSION DEADLINE

1.19.5 RETURN ADDRESS REQUIREMENTS

1.19.6 CADD AND ELECTRONIC DESIGN FILES (PROVIDED)

1.20 COPIES OF SOLICITATION DOCUMENT AND AMENDMENTS

1.21 OFFEROR'S QUESTIONS AND COMMENTS

1.21.1 BIDDER INQUIRY

1.21.2 PLAN HOLDER'S LIST

1.22 GENERAL DESCRIPTION OF WORK

1.23 PROPOSAL SUBMISSION REQUIREMENTS, EVALUATION AND CONTRACT AWARD

1.24 SOURCE SELECTION BOARD (SSB)

DOCUMENT 00 21 01 Page 1Am #0002

1.25 FEDERAL, STATE AND LOCAL TAXES

1.26 COLORADO SALES AND USE TAX

PART 2 PRODUCTS (NOT USED)

PART 3 EXECUTION (NOT USED)

-- End of Section Table of Contents --

DOCUMENT 00 21 01 Page 2Am #0002

SECTION 00 21 01

INSTRUCTIONS TO OFFERORS (RFP)

01/17

PART 1 GENERAL

1.1 (FAR 52.204-7) SYSTEM FOR AWARD MANAGEMENT (OCT 2016)

(a) Definitions. As used in this provision-

“Electronic Funds Transfer (EFT) indicator” means a fourcharacter suffix to the unique entity identifier. The suffix is assigned at the discretion of the commercial, nonprofit, or Government entity to establish additional System for Award Management records for identifying alternative EFT accounts (see subpart 32.11) for the same entity.

"Registered in the System for Award Management database" means that-

(1) The Offeror has entered all mandatory information, including the unique entity identifier and the EFT indicator, if applicable, the Commercial and Government Entity (CAGE) code, as well as data required by the Federal Funding Accountability and Transparency Act of 2006 (see subpart 4.14) into the SAM database;

(2) The offeror has completed the Core, Assertions, and Representations and Certifications, and Points of Contact sections of the registration in the SAM database;

(3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The offeror will be required to provide TIN validation to the Government as a part of the SAM registration process;

and

(4) The Government has marked the record "Active".

(b)(1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation "DUNS" or "DUNS +4" followed by the DUNS or DUNS +4 number that identifies the offeror's name and address exactly as stated in the offer. The DUNS number will be used by the Contracting Officer to verify that the offeror is registered in the SAM database.

(c) If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one.

(1) An offeror may obtain a DUNS number-

(i) Via the Internet at http://fedgov.dnb.com/webform or if the offeror does not have internet access, it may call Dun and Bradstreet at 1-866-705-5711 if located within the United States; or

(ii) If located outside the United States, by contacting the local Dun and Bradstreet office. The offeror should indicate that it is an offeror for a U.S. Government contract when contacting the local Dun and Bradstreet office.

DOCUMENT 00 21 01 Page 3Am #0002

(2) The offeror should be prepared to provide the following information:

(i) Company legal business.

(ii) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(iii) Company Physical Street Address, City, State, and

Zip Code.

(iv) Company Mailing Address, City, State and Zip Code

(if separate from physical).

(v) Company Telephone Number.

(vi) Date the company was started.

(vii) Number of employees at your location.

(viii) Chief executive officer/key manager.

(ix) Line of business (industry).

(x) Company Headquarters name and address (reporting relationship within your entity).

(d) If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror.

(e) Processing time, which normally takes 48 hours, should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) Offerors may obtain information on registration at https://www.acquisition.gov.

(End of provision)

1.2 (FAR 52.204-16) COMMERCIAL AND GOVERNMENT ENTITY CODE REPORTING (JUL

2016)

(a) Definition. As used in this provision –

“Commercial and Government Entity (CAGE) code” means –

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity; or

(2) An identifier assigned by a member of the North Atlantic

Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code..

(b) The Offeror shall enter its CAGE code in its offer with its name and address or otherwise include it prominently in its proposal. The CAGE code entered must be for that name and address. Enter “CAGE” before the number. The CAGE code is required prior to award.

(c) CAGE codes may be obtained via–

(1) Registration in the System for Award Management (SAM) at www.sam.gov. If the Offeror is located in the United States or its outlying

DOCUMENT 00 21 01 Page 4Am #0002 areas and does not already have a CAGE code assigned, the DLA Commercial and Government Entity (CAGE) Branch will assign a CAGE code as a part of the SAM registration process. SAM registrants located outside the United States and its outlying areas shall obtain a NCAGE code prior to registration in SAM (see paragraph (c)(3) of this provision).

(2) The DLA Contractor and Government Entity (CAGE) Branch. If registration in SAM is not required for the subject procurement, and the offeror does not otherwise register in SAM, an offeror located in the United States or its outlying areas may request that a CAGE code be assigned by submitting a request at https://cage.dla.mil.

(3) The appropriate country codification bureau. Entities located outside the United States and its outlying areas may obtain an NCAGE code by contacting the Codification Bureau in the foreign entity’s country if that country is a member of NATO or a sponsored nation. NCAGE codes may be obtained from the NSPA at https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx if the foreign entity’s country is not a member of NATO or a sponsored nation.

Points of contact for codification bureaus, as well as additional information on obtaining NCAGE codes, are available at http://www.nato.int/structur/AC/135/main/links/contacts.htm.

(d) Additional guidance for establishing and maintaining CAGE codes is available at https://cage.dla.mil.

(e) When a CAGE Code is required for the immediate owner and/or the highest-level owner by 52.204-17 or 52.212-3(p), the Offeror shall obtain the respective CAGE Code from that entity to supply the CAGE Code to the Government.

(f) Do not delay submission of the offer pending receipt of a CAGE code.

(End of provision)

1.3 (FAR 52.211-2) AVAILABILITY OF SPECIFICATIONS, STANDARDS, AND DATA ITEM

DESCRIPTIONS LISTED IN THE ACQUISITION STREAMLINING AND STANDARDIZATION

INFORMATION SYSTEM (ASSIST) (APR 2014)

(a) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites:

(1) ASSIST (https://assist.dla.mil/online/start/);

(2) Quick Search (http://quicksearch.dla.mil/);

(3) ASSISTdocs.com (http://assistdocs.com).

(b) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point (DoDSSP) by-

(1) Using the ASSIST Shopping Wizard (https://assist.dla.mil/wizard/index.cfm);

(2) Phoning the DoDSSP Customer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST; or

(3) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone (215) 697-2667/2179, Facsimile (215) 697-1462.

(End of provision)

1.4 (FAR 52.215-1) INSTRUCTIONS TO OFFERORS--COMPETITIVE ACQUISITION (JAN

2017)

(a) Definitions. As used in this provision-

DOCUMENT 00 21 01 Page 5Am #0002

"Discussions" are negotiations that occur after establishment of the competitive range that may, at the Contracting Officer's discretion, result in the offeror being allowed to revise its proposal.

"In writing," "writing," or "written" means any worded or numbered expression that can be read, reproduced, and later communicated, and includes electronically transmitted and stored information.

"Proposal modification" is a change made to a proposal before the solicitation's closing date and time, or made in response to an amendment, or made to correct a mistake at any time before award.

"Proposal revision" is a change to a proposal made after the solicitation closing date, at the request of or as allowed by a Contracting Officer as the result of negotiations.

"Time," if stated as a number of days, is calculated using calendar days, unless otherwise specified, and will include Saturdays, Sundays, and legal holidays. However, if the last day falls on a Saturday, Sunday, or legal holiday, then the period shall include the next working day.

(b) Amendments to solicitations. If this solicitation is amended, all terms and conditions that are not amended remain unchanged. Offerors shall acknowledge receipt of any amendment to this solicitation by the date and time specified in the amendment(s).

(c) Submission, modification, revision, and withdrawal of proposals.

(1) Unless other methods (e.g., electronic commerce or facsimile) are permitted in the solicitation, proposals and modifications to proposals shall be submitted in paper media in sealed envelopes or packages (i) addressed to the office specified in the solicitation, and (ii) showing the time and date specified for receipt, the solicitation number, and the name and address of the offeror. Offerors using commercial carriers should ensure that the proposal is marked on the outermost wrapper with the information in paragraphs (c)(1)(i) and (c)(1)(ii) of this provision.

(2) The first page of the proposal must show-

(i) The solicitation number;

(ii) The name, address, and telephone and facsimile numbers of the offeror (and electronic address if available);

(iii) A statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation and agreement to furnish any or all items upon which prices are offered at the price set opposite each item;

(iv) Names, titles, and telephone and facsimile numbers (and electronic addresses if available) of persons authorized to negotiate on the offeror's behalf with the Government in connection with this solicitation; and

(v) Name, title, and signature of person authorized to sign the proposal. Proposals signed by an agent shall be accompanied by evidence of that agent's authority, unless that evidence has been previously furnished to the issuing office.

(3) Submission, modification, revision, and withdrawal of proposals.

(i) Offerors are responsible for submitting proposals, and any modifications or revisions, so as to reach the Government office designated in the solicitation by the time specified in the solicitation.

If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that proposal or revision is due.

(ii)(A) Any proposal, modification, or revision received at the Government office designated in the solicitation after the exact time specified for receipt of offers is "late" and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and-

DOCUMENT 00 21 01 Page 6Am #0002

(1) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of proposals; or

(2) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or

(3) It is the only proposal received.

(B) However, a late modification of an otherwise successful proposal that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(iii) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the proposal wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(iv) If an emergency or unanticipated event interrupts normal Government processes so that proposals cannot be received at the office designated for receipt of proposals by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation, the time specified for receipt of proposals will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(v) Proposals may be withdrawn by written notice received at any time before award. Oral proposals in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile proposals, proposals may be withdrawn via facsimile received at any time before award, subject to the conditions specified in the provision at 52.215-5, Facsimile Proposals. Proposals may be withdrawn in person by an offeror or an authorized representative, if the identity of the person requesting withdrawal is established and the person signs a receipt for the proposal before award.

(4) Unless otherwise specified in the solicitation, the offeror may propose to provide any item or combination of items.

(5) Offerors shall submit proposals in response to this solicitation in English, unless otherwise permitted by the solicitation, and in U.S. dollars, unless the provision at FAR 52.225-17, Evaluation of Foreign Currency Offers, is included in the solicitation.

(6) Offerors may submit modifications to their proposals at any time before the solicitation closing date and time, and may submit modifications in response to an amendment, or to correct a mistake at any time before award.

(7) Offerors may submit revised proposals only if requested or allowed by the Contracting Officer.

(8) Proposals may be withdrawn at any time before award.

Withdrawals are effective upon receipt of notice by the Contracting Officer.

(d) Offer expiration date. Proposals in response to this solicitation will be valid for the number of days specified on the solicitation cover sheet (unless a different period is proposed by the offeror).

(e) Restriction on disclosure and use of data. Offerors that include in their proposals data that they do not want disclosed to the public for any purpose, or used by the Government except for evaluation purposes, shall-

(1) Mark the title page with the following legend:

This proposal includes data that shall not be disclosed outside the Government and shall not be duplicated, used, or disclosed-in whole or in part-for any purpose other than to evaluate this proposal. If, however, a

DOCUMENT 00 21 01 Page 7Am #0002 contract is awarded to this offeror as a result of-or in connection with-the submission of this data, the Government shall have the right to duplicate, use, or disclose the data to the extent provided in the resulting contract. This restriction does not limit the Government's right to use information contained in this data if it is obtained from another source without restriction. The data subject to this restriction are contained in sheets [insert numbers or other identification of sheets]; and

(2) Mark each sheet of data it wishes to restrict with the following legend:

Use or disclosure of data contained on this sheet is subject to the restriction on the title page of this proposal.

(f) Contract award. (1) The Government intends to award a contract or contracts resulting from this solicitation to the responsible offeror(s) whose proposal(s) represents the best value after evaluation in accordance with the factors and subfactors in the solicitation.

(2) The Government may reject any or all proposals if such action is in the Government's interest.

(3) The Government may waive informalities and minor irregularities in proposals received.

(4) The Government intends to evaluate proposals and award a contract without discussions with offerors (except clarifications as described in FAR 15.306(a)). Therefore, the offeror's initial proposal should contain the offeror's best terms from a cost or price and technical standpoint. The Government reserves the right to conduct discussions if the Contracting Officer later determines them to be necessary. If the Contracting Officer determines that the number of proposals that would otherwise be in the competitive range exceeds the number at which an efficient competition can be conducted, the Contracting Officer may limit the number of proposals in the competitive range to the greatest number that will permit an efficient competition among the most highly rated proposals.

(5) The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit cost or prices offered, unless the offeror specifies otherwise in the proposal.

(6) The Government reserves the right to make multiple awards if, after considering the additional administrative costs, it is in the Government's best interest to do so.

(7) Exchanges with offerors after receipt of a proposal do not constitute a rejection or counteroffer by the Government.

(8) The Government may determine that a proposal is unacceptable if the prices proposed are materially unbalanced between line items or subline items. Unbalanced pricing exists when, despite an acceptable total evaluated price, the price of one or more line items is significantly overstated or understated as indicated by the application of cost or price analysis techniques. A proposal may be rejected if the Contracting Officer determines that the lack of balance poses an unacceptable risk to the Government.

(9) If a cost realism analysis is performed, cost realism may be considered by the source selection authority in evaluating performance or schedule risk.

(10) A written award or acceptance of proposal mailed or otherwise furnished to the successful offeror within the time specified in the proposal shall result in a binding contract without further action by either party.

(11) If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable:

(i) The agency's evaluation of the significant weak or deficient factors in the debriefed offeror's offer.

DOCUMENT 00 21 01 Page 8Am #0002

(ii) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.

(iii) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.

(iv) A summary of the rationale for award.

(v) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror.

(vi) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.

(End of provision)

1.5 *FAR 52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT-CONSTRUCTION

MATERIALS UNDER TRADE AGREEMENTS (MAY 2014)

(a) Definitions. "Commercially available off-the-shelf (COTS) item," "construction material," "designated country construction material," "domestic construction material," and "foreign construction material," as used in this provision, are defined in the clause of this solicitation entitled "Buy American-Construction Materials Under Trade Agreements" (Federal Acquisition Regulation (FAR) clause 52.225-11).

(b) Requests for determination of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of FAR clause 52.225-11 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction materials, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(4)(i) of FAR clause 52.225-11.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material, other than designated country construction material, that is not listed by the Government in this solicitation in paragraph (b)(3) of FAR clause 52.225-11, the offeror also may submit an alternate offer based on use of equivalent domestic or designated country construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of FAR clause 52.225-11 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of FAR clause 52.225-11 does not

DOCUMENT 00 21 01 Page 9Am #0002 apply, the Government will evaluate only those offers based on use of the equivalent domestic or designated country construction material, and the offeror shall be required to furnish such domestic or designated country construction material. An offer based on use of the foreign construction material for which an exception was requested-

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

(End of provision)

1.6 FAR 52. 215-20 REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA AND

DATA OTHER THAN CERTIFIED COST OR PRICING DATA (OCT 2010)

(a) Exceptions from certified cost or pricing data.

(1) In lieu of submitting certified cost or pricing data, offerors may submit a written request for exception by submitting the information described in the following paragraphs.The Contracting Officer may require additional supporting information, but only to the extent necessary to determine whether an exception should be granted, and whether the price is fair and reasonable.

(i) Identification of the law or regulation establishing the price offered.

If the price is controlled under law by periodic rulings, reviews, or similar actions of a governmental body, attach a copy of the controlling document, unless it was previously submitted to the contracting office.

(ii) Commercial item exception. For a commercial item exception, the offeror shall submit, at a minimum, information on prices at which the same item or similar items have previously been sold in the commercial market that is adequate for evaluating the reasonableness of the price for this acquisition. Such information may include-

(A) For catalog items, a copy of or identification of the catalog and its date, or the appropriate pages for the offered items, or a statement that the catalog is on file in the buying office to which the proposal is being submitted. Provide a copy or describe current discount policies and price lists (published or unpublished), e.g., wholesale, original equipment manufacturer, or reseller. Also explain the basis of each offered price and its relationship to the established catalog price, including how the proposed price relates to the price of recent sales in quantities similar to the proposed quantities;

(B) For market-priced items, the source and date or period of the market quotation or other basis for market price, the base amount, and applicable discounts. In addition, describe the nature of the market;

(C) For items included on an active Federal Supply Service Multiple Award Schedule contract, proof that an exception has been granted for the schedule item.

(2) The offeror grants the Contracting Officer or an authorized representative the right to examine, at any time before award, books, records, documents, or other directly pertinent records to verify any request for an exception under this provision, and the reasonableness of price. For items priced using catalog or market prices, or law or regulation, access does not extend to cost or profit information or other data relevant solely to the offeror’s determination of the prices to be offered in the catalog or marketplace.

DOCUMENT 00 21 01 Page 10Am #0002

(b) Requirements for certified cost or pricing data. If the offeror is not granted an exception from the requirement to submit certified cost or pricing data, the following applies:

(1) The offeror shall prepare and submit certified cost or pricing data, data other than certified cost or pricing data, and supporting attachments in accordance with the instructions contained in Table 15-2 of FAR 15.408, which is incorporated by reference with the same force and effect as though it were inserted here in full text. The instructions in Table 15-2 are incorporated as a mandatory format to be used in this contract, unless the Contracting Officer and the Contractor agree to a different format and change this clause to use Alternate I.

(2) As soon as practicable after agreement on price, but before contract award (except for unpriced actions such as letter contracts), the offeror shall submit a Certificate of Current Cost or Pricing Data, as prescribed by FAR 15.406-2.

(End of provision)

1.7 (FAR 52.216-1) TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a firm fixed price contract resulting from this solicitation.

(End of provision)

1.8 (FAR 52.217-5) EVALUATION OF OPTIONS (JUL 1990)

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government's best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

(End of provision)

1.9 FAR 52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS-SECONDARY SITE OF

THE WORK (MAY 2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

(End of provision)

1.10 FAR 52.222-58 SUBCONTRACTOR RESPONSIBILITY MATTERS REGARDING

COMPLIANCE WITH LABOR LAWS (EXECUTIVE ORDER 13673) (DEC 2016)

(a) “Administrative merits determination”, “arbitral award or decision”, DOCUMENT 00 21 01 Page 11Am #0002

“civil judgment”, “DOL Guidance”, “enforcement agency”, “labor compliance agreement”, “labor laws”, and “labor law decision” as used in this provision have the meaning given in the clause in this solicitation entitled 52.222-59, Compliance with Labor Laws (Executive Order 13673).

(b) Subcontractor representation. (1) The requirements of this provision apply to all prospective subcontractors at any tier submitting an offer for subcontracts where the estimated subcontract value exceeds $500,000 for other than commercially available off-the-shelf items. The Offeror shall require these prospective subcontractors to represent, to the Offeror, to the best of the subcontractor’s knowledge and belief, whether there have been any administrative merits determinations, arbitral awards or decisions, or civil judgments for any labor law violation(s) rendered against the prospective subcontractor during the period beginning October 25, 2015 to the date of the offer, or for three years preceding the offer, whichever period is shorter.

(2) A contractor or subcontractor, acting in good faith, is not liable for misrepresentations made by its subcontractors about labor law decisions or about labor compliance agreements.

(c) Subcontractor responsibility determination. If the prospective subcontractor responded affirmatively to paragraph (b) of this provision and the Offeror initiates a responsibility determination, the Offeror shall follow the procedures in paragraph (c) of 52.222-59, Compliance with Labor Laws (Executive Order 13673).

Note to 52.222-58: By a court order issued on October 24, 2016, 52.222-58 is enjoined indefinitely as of the date of the order. The enjoined section will become effective immediately if the court terminates the injunction. At that time, GSA, DoD and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(End of provision)

1.11 *FAR 52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT-CONSTRUCTION

MATERIALS UNDER TRADE AGREEMENTS (MAY 2014)

(a) Definitions. "Commercially available off-the-shelf (COTS) item," "construction material," "designated country construction material," "domestic construction material," and "foreign construction material," as used in this provision, are defined in the clause of this solicitation entitled "Buy American-Construction Materials Under Trade Agreements" (Federal Acquisition Regulation (FAR)…