W9128F17Q0098_OA_Replace_Lighting_Feeders.pdf

COE OAHE PRJT OFC TECH SPT SEC

KRIS CLEVELAND

USAED, OMAHACENWO-OD-OA-T

28563 POWERHOUSE RD

PIERRE SD 57501

TEL: 605-945-3410 FAX:

W59XQG72027778

REQUEST FOR QUOTATIONS

(THIS IS NOT AN ORDER) 1

PAGE OF PAGES

1. REQUEST NO. 2. DATE ISSUED RATING

W9128F17Q0098 11-Aug-2017 5a. ISSUED BY

8. TO: NAME AND ADDRESS, INCLUDING ZIP CODE

IMPO RTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State, and local taxes)

ITEM NO.

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e) (f)

SEE SCHEDULE

AMOUNT

% No. % NO TE: Additional provisions and representations [ ] are [ ] are not attached.

13. NAME AND ADDRESS OF QUOTER (Street, City, County, State, and

ZIP Code)

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

15. DATE OF

QUOTATION

16. NAME AND TITLE OF SIGNER (Type or print) ( Include area code)

TELEPHONE NO.

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 18 (REV. 6-95)

PREVIOUS EDITION NOT USABLE Prescribed by GSA

FAR (48 CFR) 53.215-1(a)

THIS RFQ X[ ] IS [ ] IS NOT A SMALL BUSINESS SET-ASIDE

6. DELIVER BY (Date)

SEE SCHEDULE

AND/OR DMS REG. 1

UNDER BDSA REG. 2

4. CERT. FOR NAT. DEF.3. REQUISITION/PURCHASE

REQUEST NO.

U.S. ARMY CORPS OF ENGINEERS, OMAHA DIST

CONTRACTING OFFICE

1616 CAPITOL AVENUE

OMAHA NE 68102-4901

9. DESTINATION (Consignee and address, including ZIP Code)

7. DELIVERY

[ ]X FOB

DESTINATION

[ ] OTHER

(See Schedule)

25-Aug-2017(Date) PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS:10.

605-945-3403BRIANNA N BOLGER

(Name and Telephone no.) (No collect calls)5b. FOR INFORMATION CALL:

d. CALENDAR DAYSc. 30 CALENDAR DAYSb. 20 CALENDAR DAYS12. DISCOUNT FOR PROMPT PAYMENT a. 10 CALENDAR DAYS

W9128F17Q0098

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job

FY17 OAHE - REPLACE MAINTENANCE FACILITY

FFP

LIGHTING FEEDER --- All work complete for the Replacement of the Maintenance Faciility Lighting Power Feeder per specifications and drawings.

PROJECT NO.: 451802

FOB: Destination

MILSTRIP: W59XQG72027778

PURCHASE REQUEST NUMBER: W59XQG72027778

NET AMT

Section C - Descriptions and Specifications

SCOPE OF WORK

Technical Specifications Replace Lighting Power Feeder at Oahe Maintenance Facility

Scope of Work:

Contractor is to install new conductors in conduit for the perimeter lighting system at the Oahe Maintenance Facility. The contractor will furnish, supply, and install conductors and conduit for the entire system. This facility is at the Oahe Project located approximately 7 miles North of Pierre, SD. All work shall conform to the requirements of the current National Electrical Code and these specifications. Licenses, permits, and any required state taxes will be obtained and/or paid by the contractor.

1. General: The existing conductors are not in conduit and will be abandoned in place. The conductors will be installed as indicated on the drawings. The approximate length of the main feeder for 11 lights is about 2100 feet. The other feeder to supply power to a single light is about 150 feet. Most of the installation will be trenched, with areas under roads or concrete parking lots to be directionally bored.

All conductors will be installed in PVC conduit and will be connected to the existing conduit at each light. The conduit connections to the pole conduit will be sealed. Cables shall be installed using methods that will not injure the jacket, insulation, or conductors. All cables within a single conduit shall be placed at the same time. When powder or compound is required to ease pulling, the powder or compound shall be used according to manufacturer’s recommendations and the use shall not damage the cable.

The contractor will leave 2 feet of extra conductor at the hand hole of each light pole.

Connections will be made by USACE personnel. Trenches shall be backfilled and compacted to the same density as the adjoining ground.

At the Maintenance building, the contractor will supply all labor and materials to install:

1) Rigid conduit connections from the buried conduit (with rigid fittings) through the exterior walls to the interior EMT conduit.

2) EMT conduits through the Maintenance building to the electrical room installed and anchored according to NEC requirements.

3) Metal junction box that will be sized appropriately for the two lines out of the poles and the connection to the electrical source.

4) Enough excess conductor will be left in the junction box to make the connections.

USACE personnel will make the connections.

Equipment and materials furnished shall be new. All measurements are to be field verified by the contractor prior to ordering any materials.

2. Demolition: The existing conductors are direct buried and will be abandoned in place.

3. Installation: Contractor shall install new conductors and conduit according to manufacturer’s recommendations and instructions. Care shall be taken to not damage interior or exterior walls of the facilities any more than necessary to drill through walls.

4. Materials: The conductors will be feeding a three-phase 480 volt system. The conductors will be three #8 and one #10 (ground) THHW. The Contractor shall supply and install Schedule 40 PVC conduit for the underground installation, except Schedule 80 is required under roadways. Junction box will be an 8” by 8” metal junction box. The Contractor shall supply all materials and incidentals as required for the installation. All products and materials shall be standard products that meet industry standards and National Electrical Code. Electrical conduit shall meet the following specifications:

1) Rigid Steel Conduit: Conduit and fittings shall meet the requirements of UL 6 and

514 and shall be hot dip galvanized. Each section of conduit shall bear the UL label.

2) Rigid Nonmetallic Conduit: Conduit and fittings shall be polyvinyl chloride heavy wall meeting the requirements of UL 651 and 514. Use and installation of PVC Schedule 40 and 80 shall be in accordance with NEC and each section shall bear the UL label. When nonmetallic conduit is to be used in areas subject to vehicular traffic, it shall be Schedule 80.

5. Protection of Existing Facilities and Works: The Contractor shall be responsible for the protection of the work area from damage and upon completion of the work shall leave existing works in a condition equal to that which existed when the work started. All work, storage of materials, and construction plant shall be kept within the limits of the areas assigned. Prior to construction operations, the Contractor shall confer with the Contracting Officer's Representative to determine the proximity of any possible obstructions, pipe or equipment that could be damaged as a result of construction operations. Surfaces and utilities shall be protected from damage by the work being performed by the Contractor, if damaged the Contractor shall repair with equal materials at no additional expense to the Government. Protection of the fiber optic line is critical.

At all times the plant and work areas shall be kept in a condition conducive to safety of workmen and the public and neat in appearance. Waste or surplus materials shall not be allowed to accumulate in the construction areas.

6. Care of Water: Full responsibility for care of water shall be borne by the Contractor until completion of work under this contract. The Contractor shall provide the materials and equipment and perform all work necessary to facilitate construction and to protect the work from damage by water. The Contractor shall make his own investigations and determinations of conditions, both existing and anticipated concerning care of water. Facilities shall be removed upon completion of the work.

7. Security Requirements: All Contractor and all associated sub-contractors employees shall comply with applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative). The Contractor shall also provide all information required for background checks to meet installation access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any individual facility or installation change, the Government may require changes in Contractor security matters or processes. Directions for background check are in paragraph 7.3

7.1 Submit a complete, updated and signed, list of all Contractor and subcontractor personnel, including their titles and intended working hours, who will be working on site prior to start of work. This listing shall be revised and resubmitted when personnel changes occur.

7.2 Personnel Risk Assessment

A minimum of seven days prior to engaging in work submit, to the CO or Project POC, a Personnel Risk Assessment (PRA) for each employee requiring authorized unescorted access to the Jobsite. The Contractor employee will only be allowed authorized unescorted physical access after the PRA is shown to and approved by the Government.

7.3 Authorized Unescorted Access Requirements

Perform a PRA on all Contractor personnel that require authorized unescorted access to the Jobsite. Costs associated with the execution of the PRA shall be at the expense of the Contractor. The content of the PRA is defined by the requirements as follows:

a. Criminal Check - Obtain a criminal background check, completed within the last seven years, on all Contractor personnel that require authorized unescorted access to the Jobsite.

A minimum of a 7-year criminal background check with the state patrol office shall be performed from all states of residence and employment, for the past seven years. The COR through the Contacting Officer will approve, disapprove, or revoke authorized unescorted access to the Jobsite as a result of the seven-year background check in accordance with Army Directive 2014-05 Enclosure 2.

b. Identity Verification - Contractor employees shall provide positive verification of individual identity prior to authorized unescorted access to the Jobsite. Acceptable forms of identity verification are documents issued by a federal Government agency that include: the individual's photograph, name, and date of birth, such as a passport or military identification (ID) card. Additionally, a state issued driver's license or ID card is acceptable for identity verification.

c. The Criminal Check and Identity Verification shall be updated at least every seven years for each employee requiring authorized unescorted access to the Jobsite.

d. Escort Requirements - Contractor personnel not cleared for authorized access to the Jobsite may be escorted by Government or Contractor personnel that have authorized unescorted access to the Jobsite. All costs related to the escorting of non-cleared personnel shall be at the expense of the Contractor. Additional burden shall not be placed upon the Government to provide these escorts. Prior to access, coordination with the Project Security Officer is required, including but not limited to:

(1) Verification of identity with photo identification

(2) Name of escorting individual and verification of unescorted status

(3) Time of entry into the Jobsite

(4) Time exiting the Jobsite.

7.5 Physical Access/Special Qualifications:

7.5.1 All contract employees, including subcontractor employees who are not in possession of the appropriate access privileges, will be escorted in areas where they may be exposed to sensitive materials and/or sensitive or restricted areas.

7.5.2 The Contractor must pre‐screen Candidates using the E‐verify Program

(http://www.dhs.gov/E‐Verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to ensure the correct information is entered into the E‐verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award. When contracts are with individuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, with the designated Government representative. This Form will be provided to the Contracting Officer and shall become part of the official contract file.

8. Work by Others: Government personnel and other contractors may be working in the area during the life of this contract. The Contractor shall coordinate his work with others to avoid undue interference, and shall conduct his operations, other than required access, within the limits of the assigned construction area.

9. Toilets. Toilet facilities will be available for Contractor's use.

10. Post-Construction Cleanup or Obliteration: The Contractor shall obliterate all signs of temporary construction facilities such as work areas or any other vestiges of construction as http://www.dhs.gov/E%E2%80%90Verify directed by the Contracting Officer's Representative. No separate payment will be made for post-construction cleanup or obliteration and all costs shall be considered incident to and included in the applicable contract unit price items.

11. Protection of Water Resources: The Contractor shall not pollute streams, lakes or reservoirs with fuels, oils, bitumen, calcium chloride, acids, insecticides, herbicides or other harmful materials. The Contractor shall investigate and comply with all applicable Federal, State, County, and Municipal laws concerning pollution of rivers and streams.

12. Protection of Fish and Wildlife: The Contractor shall at all times perform all work and take such steps required to minimize interference with or disturbance to fish and wildlife. The Contractor will not be permitted to alter water flows or otherwise disturb native habitat adjacent to the project area, which, in the opinion of the Contracting Officer, are critical to fish, or wildlife.

13. Burning: No burning will be permitted.

14. Safety Requirements: All Contractor and associated sub-contractors employees shall comply with the requirements of USACE EM 385-1-1. The Government considers the Prime Contractor to be the "controlling authority" for all work site safety and health of the subcontractors.

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 60 dys. ADC 1 COE OAHE PRJT OFC TECH SPT SEC

KRIS CLEVELAND

USAED, OMAHACENWO-OD-OA-T

28563 POWERHOUSE RD

PIERRE SD 57501

605-945-3410 FOB: Destination

968821

CLAUSES INCORPORATED BY REFERENCE

52.211-10 Commencement, Prosecution, and Completion of Work APR 1984

Section G - Contract Administration Data

INSTRUCTIONS TO QUOTERS

Instructions to Quoters – Other than Commercial Items

NAICS. North American Industry Classification System (NAICS) code and small business size standard. The NAICS code and small business size standard for this acquisition appear in FAR 52.204-8 of the solicitation.

Submitting your quote. Submission of quotations. Submit quotations to the office specified in this solicitation at or before the exact time specified in this solicitation. Quotations may be submitted on the SF 18, letterhead stationery, or as otherwise specified in the solicitation.

Quotations are due by 4:00 PM (CST) on 08/25/2017. Send you completed quotation package to the attention of Brianna Bolger: Brianna.n.bolger@usace.army.mil. Electronic quotations are preferred over paper responses, unless other arrangements have been made with the individual identified above. You may submit more than one quote. If you do, we will evaluate each separately.

https://www.acquisition.gov/sites/default/files/current/far/html/FormsStandard67.html#wp1189284

We will not consider any quote that we receive after the deadline unless we receive it before we issue a purchase order and considering it will not delay our purchase. In case of an emergency that delays our operations and makes submission or receipt of your quote impossible, we will extend the deadline by one working day.

As a minimum, quotations must show-

(1) The solicitation number;

(2) The time specified in the solicitation for receipt of quotations;

(3) The name, address, and telephone number of the quoter;

(4) A technical description of the items being quoted in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary;

(5) Terms of any express warranty;

(6) Price and any discount terms;

(7) “Remit to” address, if different than mailing address;

(8) A completed copy of the representations and certifications at FAR 52.204-8 if applicable.

(9) Acknowledgment of Solicitation Amendments;

(10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the same or similar items and other references (including contract numbers, points of contact with telephone numbers and other relevant information); and

(11) If the quotation is not submitted on the SF 18, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. Quotations that fail to furnish required representations or information, or reject the terms and conditions of the solicitation may be excluded from consideration.

Terms and content of your quote. Your quote must be based on the terms of this RFQ. We might reject any quote that is not based on these terms in every respect. Your quote must contain all of the information described below.

Small Business Status. In order to submit a quote, you must know whether your company is a small business. The small business size standard that applies to this purchase is stated in FAR 52.204-8, along with the North American Industry Classification System (NAICS) code on which it is based.

Issuance of purchase order. Your quote should contain your best terms. The Contracting Officer may reject any or all quotes. After the evaluation of quotes, the Contracting Officer may negotiate final terms with one or more quoters of the Government’s choice before issuing a purchase order. The Contracting Officer will not negotiate with any quoters other than those of the Government’s choice and will not use the formal source selection procedures described in FAR Part 15.

The Contracting Officer may issue a purchase order to other than the quoter with the lowest price. We might issue multiple orders, purchasing various items or groups of items from different quoters. We might issue an order for less than the quantity on which your quote is based, at the quoted price, unless you tell us that you will not accept an order on that basis.

System for Award Management (SAM). Unless exempted by the Contracting Officer, you must register in SAM before we will issue a purchase order to you. If you do not register by the date set by the Contracting Officer, the Contracting Officer might issue the order to a different quoter. Once registered, you must remain registered throughout performance until final payment. Go to https://www.acquisition.gov for information on SAM registration and annual confirmation.

DUNS Number (Data Universal Numbering System Number). [This applies to all quote if the solicitation requires that you be registered in the System for Award Management (SAM).] Place the annotation “DUNS” or “DUNS+4” next to your name and address on the first page of your quote followed by the DUNS or DUNS+4 number that identifies the quoter’s name and address.

If you do not have a DUNS number, contact Dun and Bradstreet to obtain one. If you are located within the United States, you may contact Dun and Bradstreet by calling 1-866-705-5711 or via the internet at http://fedgov.dnb.com/webform.

https://www.acquisition.gov/sites/default/files/current/far/html/FormsStandard67.html#wp1189284 https://www/ http://fedgov.dnb.com/webform

If you are located outside the United States, you must contact the local Dun and Bradstreet office for a DUNS number. Tell Dun and Bradstreet that you are a quoter for a Government contract when contacting the local Dun and Bradstreet office.

The DUNS+4 is the DUNS number plus a 4-character suffix that you may use at your discretion to establish additional SAM records for identifying alternative Electronic Funds Transfer (EFT) accounts (see FAR Subpart 32.11) for your company.

Insurance Required (FAR 52.228-5):

In accordance with FAR 28.307-2, “Liability,” the contractor shall procure the following minimum insurance:

Type Amount Workman’s Compensation and Employer’s Liability Insurance $100,000 General Liability Insurance $1,000,000 per occurrence

And, when automobiles are used in connection with performing the contract:

Type Amount Automobile Liability Insurance $200,000 per person Bodily Injury $500,000 per occurrence Property Damage $ 20,000 per occurrence

And, when aircraft is used in connection with performing the contract:

Type Amount Aircraft Public and Passenger Liability Insurance $200,000 per person Bodily Injury (other than passenger injury) $500,000 per occurrence Property Damage $200,000 per occurrence Passenger Liability Bodily Injury $200,000 multiplied by the number of seats or passengers, whichever is greater

And, when contract performance involves use of vessels, the Contracting Officer shall require, as determined by the agency, vessel collision liability and protection and indemnity insurance. The contractor is responsible for contacting the state for compliance with its workman’s compensation laws.

State and Local Taxes. The U.S. Army Corps of Engineers is exempt from paying state and local taxes per Title 4 United States Code 104-107. The U.S. Army Corps of Engineers Tax ID Number is 62-1642142.

Contractors performing services for the U.S. Army Corps of Engineers are not exempt from state and local taxes in transactions with vendors, suppliers or subcontractors.

In the State of South Dakota, there is an excise tax on the total gross receipts of all prime contractors and subcontractors engaged in realty improvement. Contractor shall include the excise tax in its quotation.

For information concerning the taxes contact: Sales and Use Tax Division, Capital Lake Plaza, Pierre, South Dakota.

Telephone 605-773-3311.

https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2032_11.html#wp1043964 https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2032_11.html#wp1043964

Section I - Contract Clauses

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.204-13 System for Award Management Maintenance OCT 2016 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.209-10 Prohibition on Contracting With Inverted Domestic

Corporations

NOV 2015

52.215-8 Order of Precedence--Uniform Contract Format OCT 1997 52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.219-28 Post-Award Small Business Program Rerepresentation JUL 2013 52.222-5 Construction Wage Rate Requirements--Secondary Site of the

Work

MAY 2014

52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-50 Combating Trafficking in Persons MAR 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2017 52.223-1 Biobased Product Certification MAY 2012 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

SEP 2013

52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-10 Waste Reduction Program MAY 2011 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.223-19 Compliance with Environmental Management Systems MAY 2011 52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-38 Submission of Electronic Funds Transfer Information with Offer

JUL 2013

52.232-40 Providing Accelerated Payments to Small Business Subcontractors

DEC 2013

52.236-5 Material and Workmanship APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.242-14 Suspension of Work APR 1984 52.243-5 Changes and Changed Conditions APR 1984 52.249-10 Default (Fixed-Price Construction) APR 1984 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.204-7000 Disclosure Of Information OCT 2016 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7004 Alt A System for Award Management Alternate A FEB 2014 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

OCT 2016

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991

CLAUSES INCORPORATED BY FULL TEXT

52.204-17 OWNERSHIP OR CONTROL OF OFFEROR (JUL 2016)

(a) Definitions. As used in this provision--

Commercial and Government Entity (CAGE) code means—

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity;

or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

Highest-level owner means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

Immediate owner means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

(b) The Offeror represents that it [ ___ ] has or [ ___ ] does not have an immediate owner. If the Offeror has more than one immediate owner (such as a joint venture), then the Offeror shall respond to paragraph (c) and if applicable, paragraph (d) of this provision for each participant in the joint venture.

(c) If the Offeror indicates ``has'' in paragraph (b) of this provision, enter the following information:

Immediate owner CAGE code:

Immediate owner legal name: ___

(Do not use a ``doing business as'' name)

Is the immediate owner owned or controlled by another entity?:

[ ___ ] Yes or [ ___ ] No.

(d) If the Offeror indicates ``yes'' in paragraph (c) of this provision, indicating that the immediate owner is owned or controlled by another entity, then enter the following information:

Highest-level owner CAGE code:

Highest-level owner legal name:

(Do not use a ``doing business as'' name)

(End of provision)

52.213-4 TERMS AND CONDITIONS--SIMPLIFIED ACQUISITIONS (OTHER THAN COMMERCIAL

ITEMS) (JAN 2017).

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are ncorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

(iii) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(iv) 52.222-26, Equal Opportunity (SEPT 2016) (E.O. 11246).

(v) 52.225-13, Restrictions on Certain Foreign Purchases (JUN 2008) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(vi) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(vii) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78 (19 U.S.C. 3805 note).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (APR 1984).

(ii) 52.232-8, Discounts for Prompt Payment (FEB 2002).

(iii) 52.232-11, Extras (APR 1984).

(iv) 52.232-25, Prompt Payment (JAN 2017).

(v) 52.232-39, Unenforceability of Unauthorized Obligations (JUN 2013).

(vi) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (DEC 2013).

(vii) 52.233-1, Disputes (MAY 2014).

(viii) 52.244-6, Subcontracts for Commercial Items (JAN 2017).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (MAR 2016) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)).

(b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. L. 109-282) (31 U.S.C. 6101 note) (Applies to contracts valued at $30,000 or more).

(ii) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (Oct 2016) (E.O. 13126). (Applies to contracts for supplies exceeding the micro-purchase threshold).

(iii) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment Exceeding $15,000 (MAY 2014) (41 U.S.C. chapter 65) (Applies to supply contracts over $15,000 in the United States, Puerto Rico, or the U.S. Virgin Islands).

(iv) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212) (applies to contracts of $150,000 or more).

(v) 52.222-36, Equal Employment for Workers with Disabilities (JUL 2014) (29 U.S.C. 793) (Applies to contracts over $15,000, unless the work is to be performed outside the United States by employees recruited outside the United States). (For purposes of this clause, ``United States'' includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.)

(vi) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212) (Applies to contracts of $150,000 or more).

(vii) 52.222-41, Service Contract Labor Standards (MAY 2014) (41 U.S.C. chapter 67) (Applies to service contracts over $2,500 that are subject to the Service Contract Labor Standards statute and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S.

Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf).

(viii)(A) 52.222-50, Combating Trafficking in Persons (MAR 2015) (22 U.S.C. chapter 78 and E.O 13627) (Applies to all solicitations and contracts).

(B) Alternate I (MAR 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (DEC 2015) (Executive Order 13658) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)).

(x) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia.))

(xi) 52.223-5, Pollution Prevention and Right-to-Know Information (MAY 2011) (E.O. 13423) (Applies to services performed on Federal facilities).

(xii) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (June, 2016) (E.O. 13693)(applies to contracts for products as prescribed at FAR 23.804(a)(1)).

(xiii) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (June, 2016) (E.O. 13693) (Applies to maintenance, service, repair, or disposal of refrigeration equipment and air conditioners).

(xiv) 52.223-15, Energy Efficiency in Energy-Consuming Products (DEC 2007) (42 U.S.C. 8259b) (Unless exempt pursuant to 23.204, applies to contracts when energy-consuming products listed in the ENERGY STAR[supreg] Program or Federal Energy Management Program (FEMP) will be--

(A) Delivered;

(B) Acquired by the Contractor for use in performing services at a Federally-controlled facility;

(C) Furnished by the Contractor for use by the Government; or

(D) Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance).

(xv) 52.223-20, Aerosols (June, 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons as a propellant or as a solvent; or contracts for maintenance or repair of electronic or mechanical devices).

(xvi) 52.223-21, Foams (June, 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent;

or contracts for construction of buildings or facilities.

(xvii) 52.225-1, Buy American--Supplies (MAY 2014) (41 U.S.C. chapter 67) (Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold and the acquisition--

(A) Is set aside for small business concerns; or

(B) Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $25,000).

(xviii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (MAY 2014) (42 U.S.C. 1792) (Applies to contracts greater than $25,000 that provide for the provision, the service, or the sale of food in the United States).

(xix) 52.232-33, Payment by Electronic Funds Transfer--System for Award Management (JUL 2013) (Applies when the payment will be made by electronic funds transfer (EFT) and the payment office uses the System for Award Management (SAM) database as its source of EFT information.)

(xx) 52.232-34, Payment by Electronic Funds Transfer--Other than System for Award Management (JUL 2013) (Applies when the payment will be made by EFT and the payment office does not use the SAM database as its source of EFT information.)

(xxi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (FEB 2006) (46 U.S.C. App. 1241) (Applies to supplies transported by ocean vessels (except for the types of subcontracts listed at 47.504(d).)

(2) Listed below are additional clauses that may apply:

(i) 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (June, 2016) (Applies to contracts when the contractor or a subcontractor at any tier may have Federal contract information residing in or transiting through its information system.

(ii) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Oct 2015) (Applies to contracts over $35,000).

(iii) 52.211-17, Delivery of Excess Quantities (SEP 1989) (Applies to fixed-price supplies).

(iv) 52.247-29, F.o.b. Origin (FEB 2006) (Applies to supplies if delivery is f.o.b. origin).

(v) 52.247-34, F.o.b. Destination (NOV 1991) (Applies to supplies if delivery is f.o.b. destination).

(c) FAR 52.252-2, Clauses Incorporated by Reference (FEB 1998). This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://www.arnet.gov/far http://farsite.hill.af.mil

(d) Inspection/Acceptance. The Contractor shall tender for acceptance only those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. The Government must exercise its postacceptance rights--

(1) Within a reasonable period of time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(e) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

http://farsite.hill.af.mil/

(f) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges that the Contractor can demonstrate to the satisfaction of the Government, using its standard record keeping system, have resulted from the termination.

The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred that reasonably could have been avoided.

(g) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(h) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

(End of clause)

52.225-9 BUY AMERICAN—CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. As used in this clause--

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4) such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site.

Materials purchased directly by the Government are supplies, not construction material.

Cost of components means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Domestic construction material means--

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if--

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

Foreign construction material means a construction material other than a domestic construction material.

United States means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows:

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American Act is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American Act to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American Act. (1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison Construction material description Unit of measure Quantity Price (dollars) \1\ Item 1 Foreign construction material.... ........... ___ ........ ....... ………. ___ ................ ........ ___ Domestic construction material... ........ ___ ............... .............. ___ .................. ...... ___ Item 2 Foreign construction material.... ......... ___ ............. ........ ……. ___ ............... ......... ___ Domestic construction material... ....... ___ .................. ............. ___ ................. ....... ___ Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).

List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.

Include other applicable supporting information.

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at these addresses:

http://www.arnet.gov/far http://farsite.hill.af.mil

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in…