B08_W9098S19R0010_FINAL.pdf

SEE ADDENDUM

(No Collect Calls)

W9098S19R0010 11-Sep-2019

b. TELEPHONE NUMBER

309-782-5885

8. OFFER DUE DATE/LOCAL TIME

10:00 AM 18 Sep 2019

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

W9098S9. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

LYNN BAKER

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

0 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

ROCK ISLAND ARSENAL (ACC-RI)

JOINT MANUFACTURING & TECHNOLOGY CENTER

BLDG 211 RODMAN AVENUE

1 ROCK ISLAND ARSENAL

ROCK ISLAND IL 61299-5000

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE 16. ADMINISTERED BY

SEE SCHEDULE

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

FAX:

TEL: SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

NAICS:

332111

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF38

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

W9098S19R0010

Section SF 30 - BLOCK 14 CONTINUATION PAGE

SOLICITATION NARRATIVE

ADDENDUM TO FAR 52.212-1 INSTRUCTIONS TO OFFERORS – COMMERCIAL ITEMS (OCT 2018):

1. The Army Contracting Command – Rock Island (ACC-RI) hereby issues solicitation W9098S19R0010 for the procurement of Steel Forgings, in support of the Rock Island Arsenal, Joint Manufacturing and Technology Center (RIA-JMTC). This solicitation is issued in accordance with FAR Part 12 (Acquisition of Commercial Items) and FAR Part 13 (Simplified Acquisition Procedures). The result of this solicitation will be a Firm Fixed Price (FFP) purchase order.

2. This solicitation is issued as 100% Small Business set aside.

3. Drawings are applied Distribution Statement D, distribution authorized to the Department of Defense (DOD) and US DOD Contractors Only. These documents contain technical data whose export is restricted by the Arms Export Control Act (Title 22, U.S.C., SEC 2751, ET SEQ.) or the Export Administration Act of 1979 (Title 50, U.S.C., APP 2401 ET SEQ.), as Amended. Violations of these export laws are subject to severe criminal penalties.

Disseminate in accordance with provisions of DOD Directive 5230.25.

Drawings will be posted on FBO, however, based on their Distribution D status, explicit access is required which means that contractors must request access in FBO and will not be granted access unless they have an approved JCP account.

Drawings may be requested via the following link:

https://www.fbo.gov/notices/c60f9f845a3f0a7ac08cc22db77bb99b

4. Certificate of Conformance (COC) IAW FAR 52.246-15 and Certified Test Reports (CTR) are required on all CLINs. Vendor shall ship the COC and CTR in with the material.

5. Pricing information for all CLINs shall be provided on the Pricing Matrix, Attachment 001 and shall be IAW the Scope of Work (SOW), Attachment 002, and Drawings, Attachment 003, attached to this solicitation.

6. The Government intends to award a Firm Fixed Price type contract from this solicitation to the responsive, responsible offeror who submits the lowest price and meets the mil specs as listed on the drawings.

7. Delivery for these items should be entered on the pricing matrix from the date the contract is awarded. All quotes shall be quoted as FOB Destination – Rock Island, IL, see FAR 52.247-34.

8. Delivery Information: Failure to comply with the contractual delivery schedule after award may result in termination of the order or require consideration if the Government elects to extend your delivery schedule. The Government is not required to extend your delivery schedule if you encounter delays. The non-availability of raw materials, subcontractor issues, scheduling conflict, etc., are not acceptable excuse for failing to meet your delivery schedule. If there is going to be a delay in delivery, the contractor is required to notify the Contract Specialist and/or Contracting Officer designated in this Delivery Order no later than 10 days prior to scheduled delivery date.

Contractor must provide written notice of what the delay is, the new proposed delivery schedule, and offer consideration for the delay for Government consideration. If the Government elects to extend the delivery schedule, a formal modification will be executed.

Early Delivery is authorized if at no additional cost to the Government.

It is the responsibility of the contractor to ensure they are providing quality products that conform to the contract terms and conditions (to include delivery schedule). Delivery of non-conforming products results in delivery/acceptance delays and increased cost to the Government.

9. The contractor shall submit tracking information with the purchase order number on all deliveries to the Rock Island Arsenal. The Tracking information shall be sent via email to the Contract Specialist:

LYNN.D.BAKER8.CIV@MAIL.MIL

Delivery Address is as follows:

TACOM-ROCK ISLAND

TRANSPORTATION OFFICER

BLDG 299, BECK AND GILESPIE

EAST END, RECG DOOR 16A

ROCK ISLAND, IL 61299-5000

RECEIVING HOURS OF OPERATION

MONDAY – THURSDAY 6:30 TO 2:00PM CST/CDT

Deliveries before or after the above delivery hours will be turned away No appointments are necessary

10. Payment will be made by DFAS, via Wide Area Work Flow.

11. Proposed prices must remain valid for 60 days.

12. SHIPPING/DELIVERY INSTRUCTIONS AND INFORMATION

THE COMPLETE PURCHASE ORDER, DELIVERY ORDER, CALL ORDER, OR CONTRACT NUMBER (The Number that starts with W9098S----) MUST BE ON THE OUTSIDE OF THE SHIPPING CONTAINER. This number must also appear on all packing slips, invoices, bills, or any communications regarding this order.

A Packing List must be included with each shipment.

SHIPMENT OR DELIVERY TO ANY ADDRESS OTHER THAN THE “SHIP TO” ADDRESS DESIGNATED

IN THE PURCHASE ORDER /DELIVERY ORDER/ CALL ORDER/ CONTRACT (Block 14 of the DD1155, Block 15 of the SF1449, or Block 11 of the SF 26) MAY RESULT IN A DELAY IN PAYMENT.

ANY CHANGE IN THE “SHIP TO” ADDRESS MUST BE APPROVED BY A WRITTEN CONTRACT

MODIFICATION FROM THE CONTRACTING OFFICER.

13. ROCK ISLAND ARSENAL SAFETY REQUIREMENTS

All Contractors and Contractor personnel coming on to Arsenal Island must comply with the Rock Island Arsenal/Joint Manufacturing and Technology Center (RIA-JMTC), other Arsenal Island safety requirements and all federal, state, and local safety laws and regulations.

Contractors must provide their employees with, and the employees must use, all required safety equipment necessary for the work they are performing and/or the areas they are in. This includes safety glasses, safety shoes, proper clothing, proper protective equipment and rigging. All drivers on Arsenal Island must use seatbelts at all times when driving a motor vehicle.

If in doubt about any safety requirements, contact the Rock Island Safety Office Phone: 309-782-2579.

14. ROCK ISLAND ARSENAL LAW ENFORCEMENT, SECURITY, AND FIRE PREVENTION

REQUIREMENTS

Any contractor personnel entering Rock Island Arsenal (RIA) as a result of this order/contract are required to adhere to all regulations governing safety, law enforcement, security, and fire prevention in effect at the time of entrance.

Failure to comply with said regulations may result in immediate removal from RIA. The contractor shall bear full responsibility of the consequences of said removal. Further clarifications of RIA regulations are available from the Contracting Officer of this order/contract.

BADGING: ALL contractors who are performing services within the confines of Rock Island Arsenal are required to obtain a visitor badge. Contractors shall coordinate with Contracting Officer/Specialist and (if applicable) the Contracting Officer’s Representative (COR) designated for the contract/order. Contractors are required to display provided visitor badges above the waist in a conspicuous place on the upper part of the body. Badges are accountable and are required by the recipient to be safeguarded at all times to prevent theft, loss of misuse by unauthorized personnel.

PARKING: All parking is on a first come, first served basis, provided the parking space is not posted with a reserved, visitor, or Handicapped parking sign. Parking is allowed in “marked” spaces only. All valid spaces are clearly marked with white lines on both sides of the space. Vehicles parked in other than valid spaces are subject to being issued parking tickets.

Contractors will not be allowed in restricted areas of the Arsenal without proper identification and authorization.

INSPECTIONS: All contractor employee’s vehicles, equipment, and packages are subject to inspection or examination at entry/exit of the Arsenal.

SMOKING POLICY: Indoor smoking is not permitted. Outside smoking must occur at least 50 feet from any building entrance and exit.

15. CONCEALED CARRY RESTRICTIONS

Concealed carry permits do not apply on military installations. Contractors and delivery drivers shall ensure there are NO weapons or ammunition in their vehicles prior to entering the installation; a K-9 unit will find and alert if any prohibited items are detected.

16. Effective Immediately: Rock Island Arsenal (RIA) Visitor Access Passes are issued to individuals, not companies or groups. All visitors, to include transportation and freight services, official and unofficial, are highly suggested to pre-register at least three (3) business days prior to their visit. Pre-registration of visitors allows for the National Crime Information Center NCIC-III background check to be conducted prior to the individual arriving at RIA, reducing their wait time upon arrival. It is the responsibility of the prime contractor to ensure that this information is passed along to any subcontractor or transportation provider used during the performance of this purchase order. DRIVERS WHO DO NOT MEET THE INSTALLATION ACCESS REQUIREMENTS WILL

NOT BE ALLOWED ON THE INSTALLLATION AND WILL BE TURNED AWAY.

NOTE: As of 31 Dec 2015, Department of Defense and Department of the Army has directed that Driver Licenses and ID cards from Minnesota, Missouri and Washington are not compliant with the standards of the REAL ID Act and cannot be used on their own as a primary means of identification to apply for access to Rock Island Arsenal.

Driver’s Licenses that have written on the top of them “NOT FOR FEDERAL IDENTIFICATION PURPOSES” are also non-compliant. These non-compliant driver’s license or state issued identification cards may still be presented at the Rock Island Visitor Control Center, but they must be accompanied by one of the following secondary forms of identification before a records check is conducted and installation access is granted:

*Current vehicle registration showing name and address *Social Security card *US passport or passport card *US Military or Draft Record (DD-214 or Selective Service Registration Card) *Veteran Health Identification Card issued by the US Department of Veterans Affairs *Transportation Worker Identification Credential *Personal Identification Verification card issued by the Federal Government *Personal Identification Verification 0 Interoperable card issued by the Federal Government *US Certificate of Naturalization or certificate of citizenship (Form N-550) *US Department of Homeland Security “Trusted Traveler” card (Global Entry, NEXUS, SENTRI, or

FAST)

*Driver’s license issued by the US Department of State *US Military Identification Card for military members, dependents and retirees *US Permanent Resident/Alien Registration Receipt Card (Form 1-551)

*US Coast Guard or Department of Homeland Security Merchant Mariner card *Native American Tribal Photo Identification card

Visitor Access Request Forms and a complete list of acceptable identification can be found at https://home.army.mil/ria/ (click on Menu, then Visitor Information, and then under How to Visit Rock Island Arsenal click on the second bullet “How to obtain a visitor pass”. Then on the right side of the screen click on “Access Request Process”) or call 309-782-0551.

Forms may be emailed for faxed

All visitors must process through the Moline Visitor Center Gate (I-74) off of River Drive in Moline, IL.

Visitors (to include transportation and freight providers) will require proper identification to access RIA POC for this Policy are: RIA Visitor Center, Phone 309-782-0551, FAX 309-782-5029, email:

usarmy.ria.imcom.mbx.usag-access-request@mail.mil

RECEIVING HOURS OF OPERATION:

Monday – Friday, 6:30am to 2:00pm CST Deliveries before or after the above stated hours will be turned away. Appointments are not necessary.

For Directions call: 309-782-8539 (Automated)

END OF ADDENDUM TO FAR 52.212-1 INSTRUCTIONS TO OFFERORS – COMMERCIAL ITEMS (OCT

2018)

Section SF 1449 - CONTINUATION SHEET

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 4 Each

FORGING, REAR SECTION, FIXED BODY

FFP

Forging, steel. Part will be in full accordance with all notes and characteristics of drawing 525887, including, but not limited to, Notes 1 through 11. note dimensions and tolerances. Also note this part is critical safety item.

Certificate of Conformance (COC) and Certified Test Report (CTR) are required

IAW FAR 52.246-15

FOR INTERNAL USE ONLY:

PR#62083867

FOB: Destination

PSC CD: 3446

NET AMT

0002 4 Each

FORGING, REAR SEC, CROSSHEAD BODY

FFP

Forging, steel. Part will be in full accordance with all notes and characteristics of drawing 525885, including, but not limited to, Notes 1 through 11. note dimensions and tolerances. Also note this part is critical safety item.

Certificate of Conformance (COC) and Certified Test Report (CTR) are required

IAW FAR 52.246-15

FOR INTERNAL USE ONLY:

PR#62083684

0003 16 Each

FORGING, CTR SEC, FIXED/CROSSHEAD BODY

FFP

Forging, steel. Part will be in full accordance with all notes and characteristics of drawing 525889, including, but not limited to, Notes 1 through 11. note dimensions and tolerances. Also note this part is critical safety item.

Certificate of Conformance (COC) and Certified Test Report (CTR) are required

IAW FAR 52.246-15

FOR INTERNAL USE ONLY:

PR#62083870

0004 4 Each

FORGING, FRONT SECTION, FIXED BODY

FFP

Forging, steel. Part will be in full accordance with all notes and characteristics of drawing 525886, including, but not limited to, Notes 1 through 11. note dimensions and tolerances. Also note this part is critical safety item.

Certificate of Conformance (COC) and Certified Test Report (CTR) are required

IAW FAR 52.246-15

FOR INTERNAL USE ONLY:

PR#62083865

0005 4 Each

FORGING, FRT SEC, CROSSHEAD BODY

FFP

Forging, steel. Part will be in full accordance with all notes and characteristics of drawing 525884, including, but not limited to, Notes 1 through 11. note dimensions and tolerances. Also note this part is critical safety item.

Certificate of Conformance (COC) and Certified Test Report (CTR) are required

IAW FAR 52.246-15

FOR INTERNAL USE ONLY:

PR#62083455

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government 0003 Destination Government Destination Government 0004 Destination Government Destination Government 0005 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 N/A N/A N/A N/A

0002 N/A N/A N/A N/A

0003 N/A N/A N/A N/A

0004 N/A N/A N/A N/A

0005 N/A N/A N/A N/A

CLAUSES INCORPORATED BY REFERENCE

52.203-3 Gratuities APR 1984 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

252.203-7000 Requirements Relating to Compensation of Former DoD Officials

SEP 2011

252.203-7005 Representation Relating to Compensation of Former DoD Officials

NOV 2011

252.204-7007 Alternate A, Annual Representations and Certifications JUN 2019 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

OCT 2016

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.215-7008 Only One Offer JUL 2019 252.215-7010 Requirements for Certified Cost or Pricing Data and Data

Other Than Certified Cost or Pricing Data

JUL 2019

252.223-7001 Hazard Warning Labels DEC 1991

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7012 Preference For Certain Domestic Commodities DEC 2017 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.244-7000 Subcontracts for Commercial Items JUN 2013

CLAUSES INCORPORATED BY FULL TEXT

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

(End of provision)

52.212-1 INSTRUCTIONS TO OFFERORS--COMMERCIAL ITEMS (OCT 2018)

(a) North American Industry Classification System (NAICS) code and small business size standard. The NAICS code and small business size standard for this acquisition appear in Block 10 of the solicitation cover sheet (SF 1449). However, the small business size standard for a concern which submits an offer in its own name, but which proposes to furnish an item which it did not itself manufacture, is 500 employees.

(b) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. Offers may be submitted on the SF 1449, letterhead stationery, or as otherwise specified in the solicitation. As a minimum, offers must show--

(1) The solicitation number;

(2) The time specified in the solicitation for receipt of offers;

(3) The name, address, and telephone number of the offeror;

(4) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary;

(5) Terms of any express warranty;

(6) Price and any discount terms;

(7) "Remit to" address, if different than mailing address;

(8) A completed copy of the representations and certifications at FAR 52.212-3 (see FAR 52.212-3(b) for those representations and certifications that the offeror shall complete electronically);

(9) Acknowledgment of Solicitation Amendments;

(10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the same or similar items and other references (including contract numbers, points of contact with telephone numbers and other relevant information); and

(11) If the offer is not submitted on the SF 1449, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. Offers that fail to furnish required representations or information, or reject the terms and conditions of the solicitation may be excluded from consideration.

(c) Period for acceptance of offers. The offeror agrees to hold the prices in its offer firm for 30 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation.

(d) Product samples. When required by the solicitation, product samples shall be submitted at or prior to the time specified for receipt of offers. Unless otherwise specified in this solicitation, these samples shall be submitted at no expense to the Government, and returned at the sender's request and expense, unless they are destroyed during preaward testing.

(e) Multiple offers. Offerors are encouraged to submit multiple offers presenting alternative terms and conditions, including alternative line items (provided that the alternative line items are consistent with subpart 4.10 of the Federal Acquisition Regulation), or alternative commercial items for satisfying the requirements of this solicitation.

Each offer submitted will be evaluated separately.

(f) Late submissions, modifications, revisions, and withdrawals of offers:

(1) Offerors are responsible for submitting offers, and any modifications, revisions, or withdrawals, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that offers or revisions are due.

(2)(i) Any offer, modification, revision, or withdrawal of an offer received at the Government office designated in the solicitation after the exact time specified for receipt of offers is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and--

(A) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of offers; or

(B) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or

(C) If this solicitation is a request for proposals, it was the only proposal received.

(ii) However, a late modification of an otherwise successful offer, that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(3) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the offer wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(4) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(5) Offers may be withdrawn by written notice received at any time before the exact time set for receipt of offers.

Oral offers in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile offers, offers may be withdrawn via facsimile received at any time before the exact time set for receipt of offers, subject to the conditions specified in the solicitation concerning facsimile offers. An offer may be withdrawn in person by an offeror or its authorized representative if, before the exact time set for receipt of offers, the identity of the person requesting withdrawal is established and the person signs a receipt for the offer.

(g) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with offerors. Therefore, the offeror's initial offer should contain the offeror's best terms from a price and technical standpoint. However, the Government reserves the right to conduct discussions if later determined by the Contracting Officer to be necessary. The Government may reject any or all offers if such action is in the public interest; accept other than the lowest offer; and waive informalities and minor irregularities in offers received.

(h) Multiple awards. The Government may accept any item or group of items of an offer, unless the offeror qualifies the offer by specific limitations. Unless otherwise provided in the Schedule, offers may not be submitted for quantities less than those specified. The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit prices offered, unless the offeror specifies otherwise in the offer.

(i) Availability of requirements documents cited in the solicitation. (1)(i) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to--GSA Federal Supply Service Specifications Section, Suite 8100, 470 East L'Enfant Plaza, SW, Washington, DC 20407, Telephone (202) 619-8925, Facsimile (202) 619-8978.

(ii) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (i)(1)(i) of this provision.

Additional copies will be issued for a fee.

(2) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites:

(i) ASSIST (https://assist.dla.mil/online/start/).

(ii) Quick Search (http://quicksearch.dla.mil/).

(iii) ASSISTdocs.com (http://assistdocs.com).

(3) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point (DoDSSP) by--

(i) Using the ASSIST Shopping Wizard (https://assist.dla.mil/wizard/index.cfm);

(ii) Phoning the DoDSSP Customer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST; or

(iii) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone

(215) 697-2667/2179, Facsimile (215) 697-1462.

(4) Nongovernment (voluntary) standards must be obtained from the organization responsible for their preparation, publication, or maintenance.

(j) Unique entity identifier. (Applies to all offers exceeding $3,500, and offers of $3,500 or less if the solicitation requires the Contractor to be registered in the System for Award Management (SAM).) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation ``Unique Entity Identifier'' followed by the unique entity identifier that identifies the Offeror's name and address. The Offeror also shall enter its Electronic Funds Transfer (EFT) indicator, if applicable. The EFT indicator is a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the Offeror to establish additional SAM records for identifying alternative EFT accounts (see subpart 32.11) for the same entity. If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for unique entity identifier establishment directly to obtain one. The Offeror should indicate that it is an offeror for a Government contract when contacting the entity designated at www.sam.gov for establishing the unique entity identifier.

(k) Reserved.

(l) Debriefing. If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable:

(1) The agency's evaluation of the significant weak or deficient factors in the debriefed offeror's offer.

(2) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.

(3) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.

(4) A summary of the rationale for award;

(5) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror.

(6) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.

ADDENDUM TO FAR 52.212-1 – INSTRUCTIONS TO OFFERORS--COMMERCIAL ITEMS (OCT 2018)

52.203-11 Certification And Disclosure Regarding Payments To

Influence Certain Federal Transactions

SEP 2007

52.203-18 Prohibition on Contracting With Entities That Require Certain Internal Confidentiality Agreements or Statements-- Representation

JAN 2017

52.204-7 System for Award Management OCT 2018 52.204-17 Ownership or Control of Offeror JUL 2016 52.204-22 Alternative Line Item Proposal JAN 2017 52.215-20 Requirements for Certified Cost or Pricing Data or

Information Other Than Certified Cost or Pricing Data

OCT 2010

52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-- Representation and Certifications.

AUG 2018

52.204-20 Predecessor of Offeror (JUL 2016)

(a) Definitions. As used in this provision--

Commercial and Government Entity (CAGE) code means--

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity;

or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

Predecessor means an entity that is replaced by a successor and includes any predecessors of the predecessor.

Successor means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

(b) The Offeror represents that it [____] is or [____] is not a successor to a predecessor that held a Federal contract or grant within the last three years.

(c) If the Offeror has indicated “is” in paragraph (b) of this provision, enter the following information for all predecessors that held a Federal contract or grant within the last three years (if more than one predecessor, list in reverse chronological order):

Predecessor CAGE code: ____ (or mark “Unknown”).

Predecessor legal name: ____.

(Do not use a “doing business as” name).

52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment

(AUG 2019)

(a) Definitions. As used in this provision--

Covered telecommunications equipment or services, Critical technology, and Substantial or essential component have the meanings provided in clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition. Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Contractors are not prohibited from providing--

(1) A service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(2) Telecommunications equipment that cannot route or redirect user data traffic or permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Representation. The Offeror represents that--

It [ ] will, [ ] will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation.

(d) Disclosures. If the Offeror has responded affirmatively to the representation in paragraph (c) of this provision, the Offeror shall provide the following information as part of the offer--

(1) All covered telecommunications equipment and services offered (include brand; model number, such as original equipment manufacturer (OEM) number, manufacturer part number, or wholesaler number; and item description, as applicable);

(2) Explanation of the proposed use of covered telecommunications equipment and services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b) of this provision;

(3) For services, the entity providing the covered telecommunications services (include entity name, unique entity identifier, and Commercial and Government Entity (CAGE) code, if known); and

(4) For equipment, the entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known).

52.209-5 CERTIFICATION REGARDING RESPONSIBILITY MATTERS (OCT 2015)

(a)(1) The Offeror certifies, to the best of its knowledge and belief, that-

(i) The Offeror and/or any of its Principals-

(A) Are ( ) are not ( ) presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(B) Have ( ) have not ( ), within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) contract or subcontract; violation of Federal or State antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property (if offeror checks “have”, the offeror shall also see 52.209-7, if included in this solicitation); and

(C) Are ( ) are not ( ) presently indicted for, or otherwise criminally or civilly charged by a governmental entity with, commission of any of the offenses enumerated in paragraph (a)(1)(i)(B) of this provision.;

and

(D) Have , have not , within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied.

(1) Federal taxes are considered delinquent if both of the following criteria apply:

(i) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(ii) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(2) Examples. (i) The taxpayer has received a statutory notice of deficiency, under I.R.C. Sec. 6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(ii) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. Sec. 6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(iii) The taxpayer has entered into an installment agreement pursuant to I.R.C. Sec. 6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment.

(iv) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. 362 (the Bankruptcy Code).

(ii) The Offeror has ( ) has not ( ), within a three-year period preceding this offer, had one or more contracts terminated for default by any Federal agency.

(2) Principal, for the purposes of this certification, means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager;

head of a division or business segment; and similar positions).

(b) The Offeror shall provide immediate written notice to the Contracting Officer if, at any time prior to contract award, the Offeror learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.

(c) A certification that any of the items in paragraph (a) of this provision exists will not necessarily result in withholding of an award under this solicitation. However, the certification will be considered in connection with a determination of the Offeror's responsibility. Failure of the Offeror to furnish a certification or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible.

(d) Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render, in good faith, the certification required by paragraph (a) of this provision. The knowledge and information of an Offeror is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.

(e) The certification in paragraph (a) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous certification, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation for default.

52.223-22 Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation (DEC 2016)

(a) This representation shall be completed if the Offeror received $7.5 million or more in Federal contract awards in the prior Federal fiscal year. The representation is optional if the Offeror received less than $7.5 million in Federal contract awards in the prior Federal fiscal year.

(b) Representation. [Offeror is to check applicable blocks in paragraphs (b)(1) and (2).]

(1) The Offeror (itself or through its immediate owner or highest-level owner) [ ___ ] does, [ ___ ] does not publicly disclose greenhouse gas emissions, i.e., make available on a publicly accessible Web site the results of a greenhouse gas inventory, performed in accordance with an accounting standard with publicly available and consistently applied criteria, such as the Greenhouse Gas Protocol Corporate Standard.

(2) The Offeror (itself or through its immediate owner or highest-level owner) [ ___ ] does, [ ___ ] does not publicly disclose a quantitative greenhouse gas emissions reduction goal, i.e., make available on a publicly available Web site a target to reduce absolute emissions or emissions intensity by a specific quantity or percentage.

(3) A publicly accessible Web site includes the Offeror's own Web site or a recognized, third-party greenhouse gas emissions reporting program.

(c) If the Offeror checked ``does'' in paragraphs (b)(1) or (b)(2) of this provision, respectively, the Offeror shall provide the publicly accessible Web site(s) where greenhouse gas emissions and/or reduction goals are reported:

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from Rock Island, IL.

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://farsite.hill.af.hil

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of"(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Defense Federal Acquisition Regulations Supplement, Department of Defense (48 CFR Chapter Chapter 2) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

252.211-7002 AVAILABILITY FOR EXAMINATION OF SPECIFICATIONS, STANDARDS, PLANS,

DRAWINGS, DATA ITEM DESCRIPTIONS, AND OTHER PERTINENT DOCUMENTS (DEC. 1991)

The specifications, standards, plans, drawings, data item descriptions, and other pertinent documents cited in this solicitation are not available for distribution but may be examined at the following location:

https://www.fbo.gov/notices/c60f9f845a3f0a7ac08cc22db77bb99b

END ADDENDUM TO FAR 52.212-1 – INSTRUCTIONS TO OFFERORS--COMMERCIAL ITEMS (OCT 2018)

52.212-4 CONTRACT TERMS AND CONDITIONS-- COMMERCIAL ITEMS (OCT 2018)

(a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights (1) within a reasonable time after the defect was discovered or should have been discovered; and

(2) before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C. 3727). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract.

(c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties.

(d) Disputes. This contract is subject to 41 U.S.C. chapter 71, Contract Disputes'', as amended (41 U.S.C. 601-613).

Failure of…