SPRRA2-19-Q-0159.pdf

REQUEST FOR QUOTATION This RFQ is is not a small business set-aside Page Of

(This is NOT an Order)

1. Request No. 2. Date Issued 3. Requisition/Purchase Request No. 4. Cert For Nat Def. Under BDSA Rating

See Schedule Reg. 2 and/or DMS Reg. 1 5A. Issued By 6. Deliver by (Date)

See Schedule

7. Delivery

FOB Other Destination

5B. For Information Call: (Name and telephone no.) (No collect calls)

8. To: Name and Address, Including Zip Code 9. Destination (Consignee and address, including Zip Code)

See Schedule

10. Please Furnish Quotations to the Issuing Office in Block 5A On or Before Close of Business (Date)

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please indicate on this form and return it to the address in Block 5B. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services.

Supplies are of domestic origin unless otherwise indicated by quoter. Any interpretations and/or certifications attached to this Request for Quotation must be completed by the quoter.

11. Schedule (Include applicable Federal, State, and local taxes)

Item Number (a)

Supplies/Services (b)

Quantity (c)

Unit (d)

Unit Price (e)

Amount (f)

(See Schedule)

12. Discount For Prompt Payment a. 10 Calendar Days b. 20 Calendar Days c. 30 Calendar Days d. Calendar Days % % % Number Percentage

NOTE: Additional provisions and representations are are not attached.

13. Name and Address of Quoter (Street, City, County, State and 14. Signature of Person Authorized to Sign 15. Date of Quotation Zip Code) Quotation

16. Signer

a. Name (Type or Print) b. Telephone

Area Code

c. Title (Type or Print) Number

AUTHORIZED FOR LOCAL REPRODUCTION Standard Form 18 (Rev. 8-95) PREVIOUS EDITIONS NOT USABLE 18-118 Prescribed by GSA-FAR (43 CFR) 53.215-1(a)

X

SPRRA2-19-Q-0159 DOA2

SPRRA2DEFENSE LOGISTICS AGENCY

5201 MARTIN ROAD/DLA-AVN-AH

REDSTONE ARSENAL AL 35898-7340

LATOYA S. ORR (256)924-7926

DLA-AVN-AHC

EMAIL: LATOYA.ORR@DLA.MIL

X

2019OCT07

1 41

CONTINUATION SHEET

Reference No. of Document Being Continued Page of

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SUPPLEMENTAL INFORMATION

Buyer Name: LATOYA S. ORR

Buyer Office Symbol/Telephone Number: DLA-AVN-AHC/(256)924-7926

Type of Contract 1: Firm Fixed Price

Kind of Contract: Supply Contracts and Priced Orders

*** End of Narrative A0000 ***

A-1. THIS REQUIREMENT IS 100% SMALL BUSINESS SET-ASIDE IN ACCORDANCE WITH FAR 19.502-2. ONLY OFFERS FROM SMALL BUSINESS FIRMS WILL BE

CONSIDERED.

A-2. THIS REQUIREMENT IS IN SUPPORT OF THE PATRIOT WEAPON SYSTEM: M-D6.

A-3. GOVERNMENT FIRST ARTICLE (FAT) IS REQUIRED.

A-4. THE TEST ITEM WILL NOT BE DESTROYED AS PART OF THE TESTING PROGRAM.

A-5. THE TECHNICAL DATA PACKAGE PROVIDED ON CD CONTAINS TECHNICAL DATA WHOSE EXPORT IS RESTRICTED BY THE ARMS EXPORT CONTROL ACT (TITLE

22 U.S.C., SEC 2751 ET SEQ.) OR EXECUTIVE ORDER 12470. VIOLATION OF THESE EXPORT LAWS ARE SUBJECT TO SEVERE CRIMINAL PENALTIES.

A-6. SERIAL NUMBERING IS NOT REQUIRED

A-7. THIS IS A FIVE YEAR INDEFINITE DELIVERY INDEFINITE QUANTITY, FIRM FIXED PRICE EFFORT.

A-8. CONTRACTOR POINT OF CONTACT INFORMATION:

NAME: ___________________________________

E-MAIL ADDRESS: ________________________________________

TELEPHONE NUMBER: ___________________________________

CAGE CODE: __________________________________

A-9. DCMA ACO POINT OF CONTACT INFORMATION:

NAME: ___________________________

E-MAIL ADDRESS: _________________________________________

TELEPHONE NUMBER: ______________________________

A-10. PROPOSALS ARE ONLY TO BE EMAILED TO THE EMAIL ADDRESS BELOW OR MAILED TO REDSTONE:

DEFENSE LOGISTICS AGENCY

ATTN: LATOYA ORR

5202 MARTIN ROAD

REDSTONE ARSENAL, AL 35898-5280

TELEPHONE NUMBER: 256-924-7926

E-MAIL ADDRESS: latoya.orr@dla.mil

A-11. CONTRACT WILL BE AWARDED SUBJECT TO CERTIFICATION OF FUNDS.

A-12. ACCELERATED DELIVERY IS ENCOURAGED AND AUTHORIZED AT NO ADDITIONAL COST TO THE GOVERNMENT.

A-13. FOR LONG LEAD TIME ITEMS AND/OR LONG TERM CONTRACTS, THE PARTIES RECOGNIZE THERE IS A RISK THAT PART(S) OR COMPONENT(S) REQUIRED

FOR PERFORMANCE OF THE CONTRACT/PURCHASE ORDER MAY BECOME UNAVAILABLE DUE TO OBSOLESCENCE. UPON RECEIPT OF THE CONTRACT/PURCHASE ORDER, CONTRACTOR IS RESPONSIBLE FOR VERIFYING ITS SOURCES OF SUPPLY. IF AT ANY TIME DURING THE COURSE OF PERFORMANCE CONTRACTOR BECOMES AWARE

THAT IT IS UNABLE TO PROCURE A PART OR COMPONENT NECESSARY TO FULFILL THE REQUIREMENTS OF THE CONTRACT, THE CONTRACTOR SHALL NOTIFY THE

CONTRACTING OFFICER IN WRITING WITHIN THIRTY DAYS. NOTIFICATION SHALL INCLUDE CONTRACTORS RECOMMENDATION FOR CORRECTION OF THE PROBLEM, IF POSSIBLE, WITH ESTIMATED COST AND SCHEDULE IMPACT, IF ANY. THE CONTRACTING OFFICER WILL DETERMINE THE APPROPRIATE COURSE OF ACTION

AND PROVIDE DIRECTION TO THE CONTRACTOR. IN NO EVENT WILL CONTRACTOR PROCEED WITH IMPLEMENTATION OF ITS RECOMMENDATION WITHOUT WRITTEN

DIRECTION FROM THE CONTRACTING OFFICER. AT THE SOLE DISCRETION OF THE CONTRACTING OFFICER, THE CONTRACT MAY BE TERMINATED IN WHOLE OR IN

PART, AS APPROPRIATE.

2 41

SPRRA2-19-Q-0159

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

*** END OF NARRATIVE A0001 ***

3 41

PIIN/SIIN

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

SUPPLIES OR SERVICES AND PRICES/COSTS

THIS IS A FIVE YEAR INDEFINITE DELIVERY INDEFINITE

QUANTITY (IDIQ) SOLICITATION. FUNDS WILL BE

OBLIGATED/CITED UPON THE ISSUANCE OF EACH DELIVERY

ORDER. THE GOVERNMENT WILL ONLY BE OBLIGATED TO

ORDER THE STATED MINIMUM QUANTITY. THE GOVERNMENT

IS NOT OBLIGATED TO ISSUE ANY ADDITIONAL ORDERS

AGAINST THIS SOLICITATION; HOWEVER, THE GOVERNMENT

RESERVES THE RIGHT TO ORDER UP TO THE MAXIMUM

QUANTITY.

THE GOVERNMENT HAS SEGREGATED THE POTENTIAL

QUANTITIES INTO FIVE ORDERING PERIODS. HOWEVER,

THIS DOES NOT PRECLUDE EXERCISING ITS RIGHTS UNDER

FAR 52.216-19 BY ORDERING THE MAXIMUM QUANTITY

SPECIFIED IN FAR 52.216-19(b)(1) AT ANY TIME DURING

THE INDEFINITE QUANTITY PERIOD.

THE QUANTITY TO BE AWARDED SIMULTANEOUSLY WITH THE

AWARD OF THE BASIC CONTRACT IS 10 EACH. THE

GOVERNMENT'S MAXIMUM QUANTITY DURING THE CONTRACT

PERIOD IS 30 EACH. THE MINIMUM DELIVERY ORDER

QUANTITY IS 5 EACH.

PRICES QUOTED FOR EACH YEAR WILL BE VALID FOR

QUANTITIES ORDERED DURING THAT YEAR.

ORDERING PERIOD 1 WILL BE FROM DATE OF AWARD

THROUGH DAY 365 DAYS AFTER CONTRACT AWARD (DACA).

ORDERING PERIOD 2 WILL BEGIN 366 DACA AND END 730

DACA.

ORDERING PERIOD 3 WILL BEGIN 731 DACA AND END 1,095

DACA.

ORDERING PERIOD 4 WILL BEGIN 1,096 DACA AND END

1,460 DACA.

ORDERING PERIOD 5 WILL BEGIN 1,461 DACA AND END

1,826 DACA.

THE ESTIMATED (E) QUANTITY LISTED HEREIN DOES NOT

COMMIT THE GOVERNMENT TO ORDER THAT OR ANY QUANTITY

ABOVE THE MINIMUM QUANTITY.

(End of narrative A001)

0001 BEAM, HOISTING

NSN: 3940-01-168-3897

Mfr CAGE: 18876

Mfr Part Number: 11462252

4 41

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

APPROVED SOURCE:

THIS IS A 100% SMALL BUSINESS SET-ASIDE

(End of narrative B001)

0001AA GOVERNMENT FIRST ARTICLE TEST 1 EA $ $ _____________________________ ______________ __________________

COMMODITY NAME: BEAM, HOISTING

CLIN CONTRACT TYPE:

Firm Fixed Price

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

MIL-STD-129 MARKINGS SHALL APPLY

UNIT PACK: 001 INTERMEDIATE PACK: 000

LEVEL PRESERVATION: Military

LEVEL PACKING: A

MIL-STD-129 MARKINGS SHALL APPLY

PRESERVATION REQUIREMENTS AND PACKING REQUIREMENTS

CONTAINED IN SPECIAL PACKAGING INSTRUCTIONS

(SPI) NUMBER: AL11683897

ESTIMATED MAXIMUM UNIT PACKAGE WEIGHT (POUNDS) AND

SIZE (INCHES):

WT [57.9]

LN [76.5]

WD [19.5]

DP [4.5]

ALL WOOD PACKAGING MATERIAL (WPM) MUST BE ISPM-15

COMPLIANT

(End of narrative D001)

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Destination

Government Approval/Disapproval Days: 90

Deliveries or Performance _________________________

DOC SUPPL

REL CD MILSTRIP ADDR SIG CD MARK FOR TP CD ______ ________ ______ ______ ________ _____

DEL REL CD QUANTITY DAYS AFTER AWARD __________ ______________ ________________

001 1 0285

FOB POINT: Destination

5 41

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

SHIP TO:

(W31POW) USA MISSIEL COMD, TEST AND EVAL DIR

BLDG 4500 ATTN: AMSMI RD TE C

REDSTONE, ARSENAL AL 35809-5280

0001AB PRODUCTION QUANTITY - YEAR ONE 9 EA $ $ ______________________________ ______________ __________________

PROGRAM YEAR: 1

COMMODITY NAME: BEAM, HOISTING

CLIN CONTRACT TYPE:

Firm Fixed Price

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

MIL-STD-129 MARKINGS SHALL APPLY

UNIT PACK: 001 INTERMEDIATE PACK: 000

LEVEL PRESERVATION: Military

LEVEL PACKING: A

MIL-STD-129 MARKINGS SHALL APPLY

PRESERVATION REQUIREMENTS AND PACKING REQUIREMENTS

CONTAINED IN SPECIAL PACKAGING INSTRUCTIONS

(SPI) NUMBER: AL11683897

ESTIMATED MAXIMUM UNIT PACKAGE WEIGHT (POUNDS) AND

SIZE (INCHES):

WT [57.9]

LN [76.5]

WD [19.5]

DP [4.5]

ALL WOOD PACKAGING MATERIAL (WPM) MUST BE ISPM-15

COMPLIANT

(End of narrative D001)

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Deliveries or Performance _________________________

DOC SUPPL

REL CD MILSTRIP ADDR SIG CD MARK FOR TP CD ______ ________ ______ ______ ________ _____

DEL REL CD QUANTITY DAYS AFTER AWARD __________ ______________ ________________

001 9 0308

FOB POINT: Destination

6 41

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

SHIP TO:

(W90BTD) SR HEADQUARTERS US ARMY AVIATION &

AMCOM FLEET MGT CENTER AFMC

HOLBROOK RD BLDG 738

FORT BLISS,TX,79916-5801

0002 BEAM, HOISTING

NSN: 3940-01-168-3897

Mfr CAGE: 18876

Mfr Part Number: 11462252

0002AA PRODUCTION QUANTITY - YEAR TWO 5 EA $ $ ______________________________ ______________ __________________

PROGRAM YEAR: 2

COMMODITY NAME: BEAM, HOISTING

CLIN CONTRACT TYPE:

Firm Fixed Price

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

MIL-STD-129 MARKINGS SHALL APPLY

UNIT PACK: 001 INTERMEDIATE PACK: 000

LEVEL PRESERVATION: Military

LEVEL PACKING: A

MIL-STD-129 MARKINGS SHALL APPLY

PRESERVATION REQUIREMENTS AND PACKING REQUIREMENTS

CONTAINED IN SPECIAL PACKAGING INSTRUCTIONS

(SPI) NUMBER: AL11683897

ESTIMATED MAXIMUM UNIT PACKAGE WEIGHT (POUNDS) AND

SIZE (INCHES):

WT [57.9]

LN [76.5]

WD [19.5]

DP [4.5]

ALL WOOD PACKAGING MATERIAL (WPM) MUST BE ISPM-15

COMPLIANT

(End of narrative D001)

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

7 41

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

Deliveries or Performance _________________________

DOC SUPPL

REL CD MILSTRIP ADDR SIG CD MARK FOR TP CD ______ ________ ______ ______ ________ _____

DEL REL CD QUANTITY DAYS AFTER AWARD __________ ______________ ________________

001 5 0210

FOB POINT: Destination

SHIP TO:

(Y00000) SHIPPING INSTRUCTIONS FOR CONSIGNEE

(SHIP-TO) WILL BE FURNISHED PRIOR

TO THE SCHEDULED DELIVERY DATE FOR

ITEMS REQUIRED UNDER THIS

REQUISITION.

0003 BEAM, HOISTING

NSN: 3940-01-168-3897

Mfr CAGE: 18876

Mfr Part Number: 11462252

0003AA PRODUCTION QUANTITY - YEAR THREE 5 EA $ $ ________________________________ ______________ __________________

PROGRAM YEAR: 3

COMMODITY NAME: BEAM, HOISTING

CLIN CONTRACT TYPE:

Firm Fixed Price

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

MIL-STD-129 MARKINGS SHALL APPLY

UNIT PACK: 001 INTERMEDIATE PACK: 000

LEVEL PRESERVATION: Military

LEVEL PACKING: A

MIL-STD-129 MARKINGS SHALL APPLY

PRESERVATION REQUIREMENTS AND PACKING REQUIREMENTS

CONTAINED IN SPECIAL PACKAGING INSTRUCTIONS

(SPI) NUMBER: AL11683897

ESTIMATED MAXIMUM UNIT PACKAGE WEIGHT (POUNDS) AND

SIZE (INCHES):

WT [57.9]

LN [76.5]

WD [19.5]

DP [4.5]

ALL WOOD PACKAGING MATERIAL (WPM) MUST BE ISPM-15

COMPLIANT

8 41

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

(End of narrative D001)

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Deliveries or Performance _________________________

DOC SUPPL

REL CD MILSTRIP ADDR SIG CD MARK FOR TP CD ______ ________ ______ ______ ________ _____

DEL REL CD QUANTITY DAYS AFTER AWARD __________ ______________ ________________

001 5 0210

FOB POINT: Destination

SHIP TO:

(Y00000) SHIPPING INSTRUCTIONS FOR CONSIGNEE

(SHIP-TO) WILL BE FURNISHED PRIOR

TO THE SCHEDULED DELIVERY DATE FOR

ITEMS REQUIRED UNDER THIS

REQUISITION.

0004 BEAM, HOISTING

NSN: 3940-01-168-3897

Mfr CAGE: 18876

Mfr Part Number: 11462252

0004AA PRODUCTION QUANTITY - YEAR FOUR 5 EA $ $ _______________________________ ______________ __________________

PROGRAM YEAR: 4

COMMODITY NAME: BEAM, HOISTING

CLIN CONTRACT TYPE:

Firm Fixed Price

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

MIL-STD-129 MARKINGS SHALL APPLY

UNIT PACK: 001 INTERMEDIATE PACK: 000

LEVEL PRESERVATION: Military

LEVEL PACKING: A

MIL-STD-129 MARKINGS SHALL APPLY

PRESERVATION REQUIREMENTS AND PACKING REQUIREMENTS

CONTAINED IN SPECIAL PACKAGING INSTRUCTIONS

(SPI) NUMBER: AL11683897

ESTIMATED MAXIMUM UNIT PACKAGE WEIGHT (POUNDS) AND

SIZE (INCHES):

9 41

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

WT [57.9]

LN [76.5]

WD [19.5]

DP [4.5]

ALL WOOD PACKAGING MATERIAL (WPM) MUST BE ISPM-15

COMPLIANT

(End of narrative D001)

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Deliveries or Performance _________________________

DOC SUPPL

REL CD MILSTRIP ADDR SIG CD MARK FOR TP CD ______ ________ ______ ______ ________ _____

DEL REL CD QUANTITY DAYS AFTER AWARD __________ ______________ ________________

001 5 0210

FOB POINT: Destination

SHIP TO:

(Y00000) SHIPPING INSTRUCTIONS FOR CONSIGNEE

(SHIP-TO) WILL BE FURNISHED PRIOR

TO THE SCHEDULED DELIVERY DATE FOR

ITEMS REQUIRED UNDER THIS

REQUISITION.

0005 BEAM, HOISTING

NSN: 3940-01-168-3897

Mfr CAGE: 18876

Mfr Part Number: 11462252

0005AA PRODUCTION QUANTITY - YEAR FIVE 5 EA $ $ _______________________________ ______________ __________________

PROGRAM YEAR: 5

COMMODITY NAME: BEAM, HOISTING

CLIN CONTRACT TYPE:

Firm Fixed Price

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

MIL-STD-129 MARKINGS SHALL APPLY

UNIT PACK: 001 INTERMEDIATE PACK: 000

LEVEL PRESERVATION: Military

LEVEL PACKING: A

10 41

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

MIL-STD-129 MARKINGS SHALL APPLY

PRESERVATION REQUIREMENTS AND PACKING REQUIREMENTS

CONTAINED IN SPECIAL PACKAGING INSTRUCTIONS

(SPI) NUMBER: AL11683897

ESTIMATED MAXIMUM UNIT PACKAGE WEIGHT (POUNDS) AND

SIZE (INCHES):

WT [57.9]

LN [76.5]

WD [19.5]

DP [4.5]

ALL WOOD PACKAGING MATERIAL (WPM) MUST BE ISPM-15

COMPLIANT

(End of narrative D001)

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Deliveries or Performance _________________________

DOC SUPPL

REL CD MILSTRIP ADDR SIG CD MARK FOR TP CD ______ ________ ______ ______ ________ _____

DEL REL CD QUANTITY DAYS AFTER AWARD __________ ______________ ________________

001 5 0210

FOB POINT: Destination

SHIP TO:

(Y00000) SHIPPING INSTRUCTIONS FOR CONSIGNEE

(SHIP-TO) WILL BE FURNISHED PRIOR

TO THE SCHEDULED DELIVERY DATE FOR

ITEMS REQUIRED UNDER THIS

REQUISITION.

11 41

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

INSPECTION AND ACCEPTANCE

This document incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at these addresses:

http://farsite.hill.af.mil/ or https://www.acquisition.gov/

If the clause requires additional or unique information, then that information is provided immediately after the clause title.

Regulatory Cite Title Date Regulatory Cite Title Date _______________ ______________________________________________________________________ ____________ _______________ ______________________________________________________________________ ____________

1 52.246-1 CONTRACTOR INSPECTION REQUIREMENTS APR/1984

2 52.246-2 INSPECTION OF SUPPLIES--FIXED-PRICE AUG/1996

3 52.246-16 RESPONSIBILITY FOR SUPPLIES APR/1984

DELIVERIES OR PERFORMANCE

This document incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at these addresses:

http://farsite.hill.af.mil/ or https://www.acquisition.gov/

If the clause requires additional or unique information, then that information is provided immediately after the clause title.

4 52.242-15 STOP-WORK ORDER AUG/1989

5 52.242-17 GOVERNMENT DELAY OF WORK APR/1984

6 52.247-48 F.O.B. DESTINATION--EVIDENCE OF SHIPMENT FEB/1999

7 52.247-58 LOADING, BLOCKING, AND BRACING OF FREIGHT CAR SHIPMENTS APR/1984

8 252.211-7008 USE OF GOVERNMENT-ASSIGNED SERIAL NUMBERS SEP/2010

9 52.211-8 TIME OF DELIVERY JUN/1997

(a) The Government requires delivery to be made according to the following schedule:

REQUIRED DELIVERY SCHEDULE

ITEM NO. QUANTITY WITHIN DAYS

AFTER DATE OF

CONTRACT

CLIN 0001AA 1 285

CLIN 0001AB 9 308

CLIN 0002AA 5 210

CLIN 0003AA 5 210

CLIN 0004AA 5 210

CLIN 0005AA 5 210

The Government will evaluate equally, as regards time of delivery, offers that propose delivery of each quantity within the applicable delivery period specified above. Offers that propose delivery that will not clearly fall within the applicable required delivery period specified above, will be considered nonresponsive and rejected. The Government reserves the right to award under either the required delivery schedule or the proposed delivery schedule, when an offeror offers an earlier delivery schedule than required above. If the offeror proposes no other delivery schedule, the required delivery schedule above will apply.

OFFERORS PROPOSED DELIVERY SCHEDULE

ITEM NO. QUANTITY WITHIN DAYS

12 41

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

AFTER DATE OF

CONTRACT

CLIN 0001AA 1

CLIN 0001AB 9

CLIN 0002AA 5

CLIN 0003AA 5

CLIN 0004AA 5

CLIN 0005AA 5

(b) Attention is directed to the Contract Award provision of the solicitation that provides that a written award or acceptance of offer mailed, or otherwise furnished to the successful offeror, results in a binding contract. The Government will mail or otherwise furnish to the offeror an award or notice of award not later than the day award is dated. Therefore, the offeror should compute the time available for performance beginning with the actual date of award, rather than the date the written notice of award is received from the

Contracting Officer through the ordinary mails. However, the Government will evaluate an offer that proposes delivery based on the

Contractors date of receipt of the contract or notice of award by adding

(1) five calendar days for delivery of the award through the ordinary mails, or

(2) one working day if the solicitation states that the contract or notice of award will be transmitted electronically. (The term working day excludes weekends and U.S. Federal holidays.) If, as so computed, the offered delivery date is later than the required delivery date, the offer will be considered nonresponsive and rejected.

(End of Clause)

13 41

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

CONTRACT ADMINISTRATION DATA

10 252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS DEC/2018

(a) Definitions. As used in this clause--

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and

Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and

Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov ; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this

Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice

Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the

WAWF home page at https://wawf.eb.mil/ .

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer

Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items--

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

COMBO REPORT

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

[Note: The Contractor may use a WAWF "combo" document type to create some Combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in

WAWF when creating payment requests and receiving reports in the system.

14 41

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC TBD

Issue By DoDAAC SPRRA2

Admin DoDAAC TBD

Inspect By DoDAAC TBD

Ship To Code W90BTD

Ship From Code TBD

Mark For Code W90BTD

Service Approver (DoDAAC) N/A

Service Acceptor (DoDAAC) N/A

Accept at Other DoDAAC N/A

LPO DoDAAC N/A

DCAA Auditor DoDAAC N/A

Other DoDAAC(s) N/A

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and

Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

DCMA/ACO POC: TBD

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

15 41

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SPECIAL CONTRACT REQUIREMENTS

BAR CODE MARKINGS_________________

Bar Code Markings are required in accordance with the latest revision of MIL-STD-129 and ISO/IEC 16388 - Information Technology -

Automatic Identification and Data Capture Techniques - Bar Code Symbology Specification - Code 39.

ENG CHG PROPOSAL, VALUE ENG CHG PROPOSAL, REQUEST FOR VARIANCE, ENG RELEASE RECORDS, NOTICE OF REVISION, AND SPECIFICATION CHG NOTICE______________________________________________________________________________________________________________________________________

PREPARATION AND SUBMISSION INSTRUCTIONS_______________________________________

1. Contractor initiated Engineering Change Proposals (ECPs), Value Engineering Change Proposals (VECPs), and Requests for Variance

(RFVs), collectively referred to as "proposals", shall be prepared, submitted and distributed in accordance with paragraphs 2, 3 and 4 below except as specified in paragraph 5 below.

2. Format. _______

a. Class 1 ECPs require the "Long Form Procedure" for documenting the change and describing the effects of the change on the suitability and supportability of the Configuration Item (CI). Class I ECPs should be limited to those that are necessary or offer significant benefit to the Government. Class I ECPs are those that affect the performance, reliability, maintainability, survivability, weight, balance, moment of inertia, interface characteristics, electromagnetic characteristics, or other technical requirements in the specifications and drawings. Class I ECPs also include those changes that affect Government Furnished

Equipment, safety, compatibility, retrofit, operation and maintenance manuals, interchangeability, substitutability, replaceability, source control specifications and drawings, costs, guarantees or warranties, deliveries, or schedules. Class II ECPs are those that do not affect form, fit and function, cost, or schedule of the system CI and do not meet the other criteria described above for

Class I ECPs.

b. Long Form Procedure: Class I changes to the CI require that DD Form 1692, pages 1 through 7 (as applicable), be prepared. Use of this procedure assures that all effects of the change on the CI are properly addressed and documented to the necessary detail to allow proper evaluation of the proposed change.

c. Short Form Procedure: ECPs and VECPs, which meet the requirements of Class II ECPs, shall be prepared using DD Form 1692 (page

1 only). Supplemental pages may be used with the form as necessary. The responsible Contract Management Office (CMO) will enter the appropriate data in Block 5 "Class of ECP", Block 6 "Priority", and Block 8 "Justification Codes."

d. The Contractor shall not manufacture items for acceptance by the Government that incorporate a known departure from requirements, unless the Government has approved an RFV. RFVs shall be prepared using DD Form 1694.

e. Each ECP and RFV shall be accompanied by a written and signed evaluation prepared by the responsible Defense Contract Management

Agency (DCMA) technical representative. The DCMA written evaluation shall be considered part of the ECP/RFV proposal.

f. Classification of RFVs.

(1) Major RFVs. RFVs written against CIs shall be designated as major when the RFV consists of acceptance of an item having a nonconformance with contract or configuration documentation involving health; performance; interchangeability; reliability;

survivability; maintainability; effective use or operation; weight; appearance (when a factor); or when there is a departure from a requirement classified as major in the contractual documentation.

(2) Critical RFVs. RFVs written against CIs shall be designated as critical when the RFV consists of acceptance of an item having a nonconformance with contract or configuration documentation involving safety or when there is a departure from a requirement classified as critical in the contractual documentation.

(3) Minor RFVs. RFVs written against CIs shall be designated as minor when the RFV consists of acceptance of an item having a nonconformance with contract or configuration documentation which does not involve any of the factors listed above in paragraphs f(1) or g(2), or when there is a departure from a requirement classified as minor in the contractual documentation.

g. Proposals shall include sufficient technical data to describe all changes from existing contract requirements.

h. Proposals shall include sufficient justification for making the change, including a statement of contract impact, if the change is not authorized.

i. Proposals for ECPs shall set forth a "not to exceed" price and delivery adjustment acceptable to the Contractor if the

Government subsequently approves the proposal. If approved, the equitable increase shall not exceed this amount.

j. Times allowed for technical decisions for ECP and RFV proposals will be worked out via mutual agreement between the Contractor and the Government.

16 41

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

k. The Contractor shall submit, concurrent with the ECP, a separate DD Form 1696, "Specification Change Notice" (SCN), for each specification that would require revision if the ECP were approved.

l. Proposals for VECPs shall set forth a "not less than" price and delivery adjustment acceptable to the Contractor if the

Government subsequently approves the proposal. If approved, the savings shall not be less than this amount.

m. The Contractor shall utilize DD Form 2617, "Engineering Release Record" (ERR) to release new or revised configuration documentation to the Government for approval.

n. The Contractor shall utilize DD Form 1695, "Notice of Revision" (NOR) to describe the exact change(s) to configuration documentation specified as a data requirement in the contract. The Contractor shall describe the change using sub-sections entitled

"WAS" to describe the current contractual technical requirement and "IS" to describe the proposed new requirement.

3. Submittal. The Contractor shall submit two (2) copies of each proposal to the responsible Administrative Contracting Officer (ACO). __________

One (1) copy of each proposal shall be returned to the Contractor within (5) working days after receipt by the ACO, stating whether or not the proposal is in compliance with this provision. Any unresolved differences between the ACO and the Contractor concerning ECPs, VECPs, or RFVs will be submitted to the PCO for resolution. Submittals may be made by electronic means by scanning the appropriate completed forms into a computer or preparing the forms electronically.

4. Distribution. ____________

a. Electronic Distribution. The preferred method of distribution is through the Internet E-mail System to the PCO. Microsoft Word _______________________ is required for use with the transmittal letter (E-mail). Required forms will be attached to the E-mail. All forms may be obtained from the Office of the Secretary of Defense Executive Services Directorate DoD Directives Division website

(http://www.esd.whs.mil/DD/ ) via the DoD Forms menu. The forms are provided in fillable Adobe Acrobat Portable Document Format

(PDF). In order to access and use the forms, the user must have the "Adobe Acrobat" software installed on their computer. Drawings may be scanned into the computer and sent as an attachment. In some cases, because of size, drawings may have to be sent as hard copies or sent under special electronic instructions provided by the PCO.

b. Hard Copy Distribution of Class I or II ECPs and RFVs, For each Class I or II ECP, or each RFV that the ACO determines to be in ______________________________________________________ compliance with this provision, the Contractor shall submit the original plus five copies to the PCO and one copy to the ACO. Upon receipt of any type of change proposal that is submitted to the PCO, the ACO shall immediately submit DCMA's written evaluation pertaining to the proposed engineering change action to the PCO. Assistance in preparing any of these proposals may be obtained from the ACO or AMCOM Change Control Point at:

Aviation and Missile Research, Development, and Engineering Center

ATTN: RDMR-SET

Redstone Arsenal, Al 35898-5000

Telephone: 256-876-1335

c. Hard Copy Distribution of VECPs. For each VECP that the ACO determines to be in compliance with this provision, the Contractor _______________________________ shall submit the original plus five copies to the PCO and one copy to the ACO. Upon receipt of any VECP that is submitted to the

PCO, the ACO shall immediately submit DCMA's written evaluation to the PCO. The Contractor shall also submit one copy of the VECP to the Value Engineering Program Manager (VEPM) whose address is below. Assistance in preparing VECPs may be obtained from the

VEPM.

Aviation and Missile Research, Development, and Engineering Center

ATTN: RDMR-SEI

Redstone Arsenal, Al 35898-5000

Telephone: 256-876-8163

5. Alternate Format, Submittal, or Distribution Process. Proposals may be prepared in a different format, submitted using a different ____________________________________________________ submittal process or distributed in a different manner than specified in paragraphs 2, 3 and 4 above, so long as the alternate approach is in accordance with a Government approved configuration management plan governed by this contract or the PCO authorizes the alternate format, submittal, or distribution process.

6. Government Acceptance. Acceptance of a proposal by the Government shall be affected by the issuance of a change order or execution _____________________ of a supplemental agreement incorporating the proposal into the contract unless the PCO authorizes another method of acceptance. The

Government will notify the Contractor in writing if a proposal is determined to be unacceptable.

(End of Clause)

FIRST ARTICLE INSPECTION AND TEST - GOVERNMENT TESTED - ADDITIONAL REQUIREMENTS_______________________________________________________________________________

a. The first article shall conform to the requirements of the contract and the Technical Data Package drawing(s), the Quality Assurance

17 41

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

Provisions (QAPs), and specification(s) referenced thereon. The first article shall be representative of items to be manufactured using the same processes and procedures and at the same facility as contract production. All components, subassemblies, and assemblies in the first article sample shall have been produced by the Contractor (including subcontractors) using the technical data package applicable to this procurement.

b. Unless otherwise specified in the contract, the contractor shall NOT retain the first article provided under this contract to serve as the manufacturing standard of acceptance.

c. Additional first article testing may be ordered by the Contracting Officer in writing whenever (i) a major change is made to the technical data, (ii) there is a lapse in production for a period in excess of 18 months, or (iii) a change occurs in place of performance, manufacturing locations or processes, material used, drawing, specification or source of supply. When conditions (i), (ii), or (iii) above occurs, the Contractor shall notify the Contracting Officer so that a determination can be made concerning the need for the additional first article sample or portion thereof, and instructions provided concerning the submission, inspection, and notification of results. Should the Government require additional first article testing the Contractor may be entitled to an equitable adjustment.

d. Rejected first articles or portions thereof not destroyed during inspection and testing will be held at the government first article test site for a period of 3 years following the date of notification of rejection, pending receipt of instructions from the Contractor for the disposition of the rejected material. The Contractor agrees that failure to furnish such instructions within said time period shall constitute abandonment of said material by the Contractor and shall confer upon the Government the right to destroy or otherwise dispose of the rejected items at the discretion of the Government without liability to the Contractor by reason of such destruction or disposition.

NOTICE TO OFFERORS - USE OF CLASS I OZONE-DEPLETING SUBSTANCES (ASSISTANT SECRETARY OF THE ARMY RDA)____________________________________________________________________________________________________

(a) In accordance with Section 326 of P.L. 102-484, the Government is prohibited from awarding any contract which includes a specification or standard that requires the use of a Class I ozone-depleting substance (ODS) identified in Section 602(a) of the Clean

Air Act, (42 U.S.C. 767a(1), or that can be met only through the use of such a substance unless such use has been approved, on an individual basis, by a senior acquisition official who determines that there is no suitable substitute available.

(b) To comply with this statute, the Government has conducted a best efforts screening of the specifications and standards associated with this acquisition to determine whether they contain any ODS requirements. To the extent that ODS requirements were revealed by this review they are identified below with the disposition determined in each case.

(c) If offerors possess any special knowledge about any other ODSs required directly or indirectly at any level of contract performance, the U.S. Army would appreciate if such information was surfaced to the Contracting Officer for appropriate action. To preclude delay to the procurement, offerors should provide any information as soon as possible after release of the solicitation and prior to the submission of offers to the extent practicable. It should be understood that there is no obligation on offerors to comply with this request and that no compensation can be provided for doing so.

ODS Identified Specification/Standard Disposition

-1- -2- -3-

POINT OF PRESERVATION, PACKAGING, PACKING AND MARKING OF SUPPLIES_________________________________________________________________

Preservation, packaging, packing and marking of supplies will be performed at the following location: (If other than the location set forth in block 9, page 1 of this purchase order):

SU W1A8 DLA DISTRIBUTION DDSP

NEW CUMBERLAND FACILITY

2001 NORMANDY DRIVE DOOR 113 TO 134

NEW CUMBERLAND, PA, 17070-5002

REQUEST FOR WAIVER OF REQUIRED FIRST ARTICLE APPROVAL_____________________________________________________

The requirement for FIRST ARTICLE APPROVAL may be waived, in whole or in part, by the Government, provided that sufficient information is provided to determine whether the request is to be approved. A partial waiver is defined as a waiver of only a specific test(s) of the First Article Test requirement as required by the Technical Data Package (TDP) and/or the solicitation/contract, i.e. vibration test, salt water spray test, or a test on a component or subassembly of the procured item. A full waiver is defined as a waiver of all

First Article testing as required by the TDP and/or the solicitation/contract.

All waiver requests require a First Article Waiver Worksheet to be completed and submitted to the Government along with all supporting documentation. The worksheet will be provided by the Buyer upon request. No requests will be considered if the worksheet and supporting documentation are not submitted to the Government. The worksheet must be completed in its entirety. For those sections of the worksheet

18 41

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

which do not apply, annotate with N/A (not applicable). To substantiate or clarify information provided, the Government may request additional information.

Submission of the FAT waiver request (and supporting documentation) to the Government does not guarantee that the waiver will be granted.

The First Article Waiver Worksheet and additional supporting documentation must be submitted on Company letterhead and signed by an authorized agent of the Company.

Supporting documentation.

(1) The request for waiver must be accompanied by the First Article Waiver Worksheet, and documentation in support of the request. The documentation may include, but is not limited to:

(i) Copy of the Administrative Contracting Officers (ACOs) or Procuring Contracting Officers (PCOs) letter approving a First

Article Test report on a recent contract for the same or similar item;

(ii) Copy of a First Article Test report for the same or a similar item as that solicited herein;

(iii) Copy of an ACO or PCO letter approving a prior waiver request; or

(iv) If the waiver request is based on similarity, a copy of the drawing/other appropriate technical requirements of the similar item.

(2) If a copy of a First Article Test report is submitted in support of a request for waiver, the test report must have been approved and signed by an authorized representative of the United States Government.

(3) The First Article Waiver Worksheet and all supporting documentation should be submitted by email. If the First Article Waiver

Worksheet and supporting documentation cannot be transmitted by email, the PCO should be contacted for further instruction.

Note: If a waiver is granted, an accelerated delivery schedule will apply.

Note: Cost considerations shall apply for approving a waiver or a portion thereof of a First Article Test.

REVISIONS TO DRAWINGS/PART NUMBERS__________________________________

(a) Sources in receipt of this solicitation are requested, at no cost to the Government, to immediately notify the Contracting Officer if they are aware of any change(s)/revision(s) to the drawing(s) or part number(s) in this solicitation which have been approved by the

Government for implementation. Notification of part number changes shall be supported by data which indicates the type of change, approving authority as required by ANSI EIA 649 MIL-STD-973 and date and method of submittal of provisioning documentation and drawings.

If complete data package has not been previously provided, the contractor shall, at no direct cost to the Government, immediately submit applicable drawings, along with a copy of the approval change authority, to the Contracting Officer, at the office symbol and mailing address listed in the "ISSUED BY" block on page one (1) of this document. The minimum acceptable data includes the next higher assembly and the item of Supply Detail Drawings which will allow provisioning, National Stock Number assignment and updating of AMCOM's data records.

(b) The contractor hereby verifies previous contractual submission of technical data:

Contract No.:_______________________________________________________ _______________________________________________________

Contractor:_________________________________________________________ _________________________________________________________

Explanation of Data Rights:_________________________________________ _________________________________________

(c) The Government is not by this request soliciting, nor is the Government liable for cost incurred by the offeror in preparing or developing modifications, deviations, waivers, or other changes to drawings or part number(s). Furthermore, this request does not authorize changes to the drawing(s) or part number(s) for this acquisition, another contract, or for any other purpose. Offerors performing any contract awarded as a result of this solicitation must comply with the drawing(s) and specifications as set forth herein, unless this solicitation is amended or any resulting contract is modified by the Contracting Officer.

(d) All proposed part number changes shall be submitted pursuant to the requirements of the clause entitled, "Engineering Change

Proposal (ECP), Value Engineering Change Proposal (VECP), Request for Deviation (RFD), and Request for Waiver (RFW) (USAAMCOM).

SOURCES ELIGIBLE FOR AWARD CONSIDERATION________________________________________

19 41

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

(a) Competition under this solicitation is restricted to the following sources:

(1) Approved Sources listed in Section B -- sources that have been approved by the prime manufacturer or the Government for supply of item(s) listed in this solicitation, to assure the requisite safe, dependable, effective operation and support of military equipment;

(2) Sources that have been approved prior to award -- other than approved sources listed in Section B;

(3) Non-manufacturers--offers from non-manufacturers (distributors) will only be considered for award if the required item(s) is new material and has been or will be obtained from a source of supply which has been approved prior to award. The source and part number of the item the offeror intends to supply must be stated in the offer.

(4) Surplus Dealers--offerors of Government surplus in accordance with Section I clause entitled "Material Requirements, FAR 52.211-

5, will only be considered for award if the former Government surplus or residual inventory resulting from terminated contracts was originally manufactured by an approved source of supply.

(b) Only offers submitted by the above sources will be considered for award under this solicitation.

(c) Offerors (prospective manufacturers or non-manufacturers [distributors]) who wish to become an approved source of supply for an item listed in this solicitation should proceed per the instructions set forth in paragraph (d) below. It is noted that offeror requests for source approval in conjunction with this procurement will not be a cause for delay in this solicitation action. However, if it is determined that additional sources will clearly benefit the Government and that any delay incident to their approval would not impact readiness, a reasonable delay may be entertained. Whether or not such delay will occur will be solely at the discretion of the

Government, and the time set for opening of the Invitation for Bids or the closing date of the Request for Proposals may or may not be extended. An extension will be witnessed by issuance of an amendment to this solicitation.

(d) Offerors (prospective manufacturers or non-manufacturers [distributors]) seeking to obtain source approval, must submit a Source

Approval Request (SAR) package, for review and approval, to the Engineering Directorate (ED), Quality Engineering Division. Source approval must be obtained prior to being considered for contract award. Approvals are made on an individual part number basis for a specific manufacturing location (CAGE). Firms are encouraged to seek source approval in order to compete for future solicitations by

"http://amcomdmz.redstone.army.mil/casl_cmo/casldba.casl_cmo_samsar"

Questions concerning SAR submissions can be directed to the ED SAR Team at "mailto:EDSAR@amrdec.army.mil" or call the SAR Team at 256-

313-8978, 256-313-0341, or 256-313-8994.

(e) The Aviation and Missile Lifecycle Management Command (AMCOM) may require additional data, testing, or plant visits before it is able to completely evaluate a SAR. This may require the offeror (at no expense to the Government) to supply parts for testing, engine run up, or flight tests. In that event, the requestor will be so advised. AMCOM reserves the right to approve a contractor for award prior to completion of physical testing of the offered item. In such cases, the contractor shall perform any outstanding tests and provide all required documentation at no cost to the Government prior to entering upon full production. Lack of successful performance within the specified timeframe shall be grounds for a no cost termination.

(f) When a SAR is received, it will be processed for evaluation. If the evaluation and approval (including preparation or update of the requisite technical data package (TDP)) occurs before award, the requestor will be considered for award if a proposal was submitted per

(d) above. If the evaluation/TDP preparation has not been completed prior to award, AMCOM will continue the process until complete. If the requestors SAR becomes approved, the requestor will be eligible for consideration on all future solicitations for the item.

(g) All approval or disapproval notices shall be officially provided to the contractor by the appropriate technical official.

(h) Non-manufacturers (distributors) seeking to supply an item from a non-approved source must first ensure that the source becomes approved in accordance with (d) above prior to contract award.

WOOD PACKING MATERIALS REQUIREMENTS___________________________________

A. Wood packaging material (WPM) means wood pallets, skids, load boards, pallet collars, wooden boxes, reels, dunnage, crates, frame and cleats. The definition excludes materials that have undergone a manufacturing process, such as corrugated fiberboard, plywood, particleboard, veneer, and oriented strand board (OSD).

B. All Wood Packaging Material (WPM)) acquired by DOD must meet requirements of International Standards for Phytosanitary Measures

(ISPM) 15, "Guidelines for Regulating Wood Packaging Materials International Trade." DOD shipments inside and outside of the United

States must meet ISPM 15 whenever WPM is used to ship DOD cargo.

(1) All WPM shall comply with the official quality control program for heat treatment (HT) or kiln dried heat treatment (KD HT) in accordance with American Lumber Standard Committee, incorporated (ALSC) Wood Packaging Material Program and WPM Enforcement

"http://www.alsc.org/)"

20 41

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

(2) All WPM shall include certification/quality markings in accordance with the ALSC standard. Marking shall be placed in an unobstructed area that will be readily visible to inspectors. Pallet markings shall be applied to the stringer or block on diagonally opposite sides of the pallet and be contrasting and clearly visible. All containers shall be marked on a side other than the top or bottom, contrasting and clearly visible. All dunnage used in configuring and/or securing the load shall also comply with

ISPM 15 and be marked with an ALSC approved DUNNAGE stamp.

C. Failure to comply with the requirements of this restriction may…