SPRRA122R0045 Signed.pdf

SOLICITATION, OFFER AND AWARD 1. This Contract Is A Rated Order Under

DPAS (15 CFR 700)

Rating Page of Pages

2. Contract Number 3. Solicitation Number 4. Type of Solicitation 5. Date Issued 6. Requisition/Purchase Number Sealed Bid (IFB)

Negotiated (RFP)

7. Issued By Code 8. Address Offer To (If Other Than Item 7)

NOTE: In sealed bid solicitations ‘offer’ and ‘offeror’ mean ‘bid’ and ‘bidder’.

SOLICITATION

9. Sealed offers in original and copies for furnishing the supplies or services in the Schedule will be received at the place specified in item 8, or if handcarried, in the depository located in until (hour) local time (Date).

Caution - Late Submissions, Modifications, and Withdrawals: See Section L, Provision No. 52.214-7 or 52.215-1. All offers are subject to all terms and conditions contained in this solicitation.

10. For Information A. Name B. Telephone (No Collect Calls) C. E-mail Address

Call: Area Code Number Ext.

11. Table Of Contents

(X) Sec. Description Page(s) (X) Sec. Description Page(s)

Part I - The Schedule Part II - Contract Clauses A Solicitation/Contract Form I Contract Clauses

B Supplies or Services and Prices/Costs Part III - List Of Documents, Exhibits, And Other Attach.

C Description/Specs./Work Statement J List of Attachments D Packaging and Marking Part IV - Representations And Instructions E Inspection and Acceptance K Representations, Certifications, and F Deliveries or Performance Other Statements of Offerors G Contract Administration Data L Instrs., Conds., and Notices to Offerors H Special Contract Requirements M Evaluation Factors for Award

OFFER (Must be fully completed by offeror) NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

12. In compliance with the above, the undersigned agrees, if this offer is accepted within _____ calendar days (60 calendar days unless a different period is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. Discount For Prompt Payment 10 Calendar Days (%) 20 Calendar Days (%) 30 Calendar Days (%) Calendar Days (%) (See Section I, Clause No. 52.232-8)

14. Acknowledgment of Amendments (The offeror acknowledges Amendment No. Date Amendment No. Date receipt of amendments to the SOLICITATION for offerors and related documents numbered and dated):

15A. Name and Code Facility 16. Name and Title of Person Authorized to Sign Offer Address of (Type or Print) Offeror

15B. Telephone Number 15C. Check if Remittance Address is 17. Signature 18. Offer Date Area Code Number Ext. Different From Above – Enter such

Address In Schedule

AWARD (To be completed by Government)

19. Accepted As To Items Numbered 20. Amount 21. Accounting And Appropriation

22. Authority For Using Other Than Full And Open Competition: 23. Submit Invoices To Address Shown In Item

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c)( ) (4 copies unless otherwise specified)

24. Administered By (If other than Item 7) Code 25. Payment Will Be Made By Code

26. Name of Contracting Officer (Type or Print) 27. United States Of America 28. Award Date

(Signature of Contracting Officer)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

AUTHORIZED FOR LOCAL REPRODUCTION Standard Form 33 (Rev. 9-97) Previous edition is unusable Prescribed By GSA-FAR (48 CFR) 53.214(c)

SPRRA1-22-R-0045

X

2022SEP14

2022OCT1405:00pm

DOA1

2022SEP14 SEE SCHEDULE

SPRRA1

DEFENSE LOGISTICS AGENCY

5201 MARTIN ROAD/DLA-AVN-AH

REDSTONE ARSENAL AL 35898-7340

MARK A. HIGHLAND

(256)690-5749

DLA-AVN-AHAA

MARK.HIGHLAND@DLA.MIL

1 55

X 1

X 4

X 10 X 11 X 12

X 14

X 16

X 21

X 38

X 52

X 55

CONTINUATION SHEET

Reference No. of Document Being Continued Page of

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION A - SUPPLEMENTAL INFORMATION

Buyer Name: MARK A. HIGHLAND

Buyer Office Symbol/Telephone Number: DLA-AVN-AHAA/(256)690-5749

Type of Contract 1: Firm Fixed Price

Kind of Contract: Supply Contracts and Priced Orders

*** End of Narrative A0000 ***

A-1. THIS REQUIREMENT IS FOR LIMITED SOURCES TO COLUMBUS JACK CORPORATION, CAGE CODE 00994 AND ATAP, CAGE CODE 22638. IAW 10 U.S.C. 2304

(c)(1) FAR 6.302-1 (a)(2) "A LIMITED NUMBER OF RESPONSIBLE SOURCES, AND NO OTHER TYPE OF SUPPLIES OR SERVICES WILL SATISFY AGENCY

REQUIREMENTS, FULL AND OPEN COMPETITION NEED NOT BE ACCOUNTED FOR."

A-2. THIS REQUIREMENT IS FOR NOUN: JACK, AIRCRAFT, LANDING; NSN: 1730-00-540-2343; PN: 53D22020 IN SUPPORT OF THE (BE) UH-60 BLACKHAWK

WEAPON SYSTEM.

A-3. THIS IS A FIVE (5)YEAR INDEFINITE DELIVERY REQUIREMENTS (IDR) TYPE, FIRM FIXED PRICE EFFORT.

A-4. FLIGHT SAFETY/CRITICAL SAFETY ITEM (CSI) IS NOT REQUIRED.

A-5. PRODUCTION LOT TESTING (PLT) IS NOT REQUIRED.

A-6. FIRST ARTICLE TEST (FAT) IS NOT REQUIRED

A-7. SNRR MARKINGS ARE NOT REQUIRED.

A-8. TAMMS-A MARKINGS ARE NOT REQUIRED.

A-9. IUID MARKINGS ARE NOT REQUIRED.

A.10. RFID MARKINGS ARE NOT REQUIRED.

A-11. FIT CHECK IS NOT REQUIRED.

A-12. BAR CODE MARKINGS ARE REQUIRED.

A-13. GOVERNMENT SURPLUS PROPERTY WILL NOT BE CONSIDERED FOR THIS ACQUISITION.

A-14. FUNDS WILL BE OBLIGATED /CITED UPON ISSUANCE OF EACH DELIVERY ORDER.

A-15. OFFERS SHALL BE SUBMITTED IN ACCORDANCE WITH FAR CLAUSE 52.215-1. FACSIMILE SUBMISSIONS ARE NOT AUTHORIZED. ALL PROPOSALS SHALL BE

E-MAILED.

CONTRACT SPECIALIST POINT OF CONTACT INFORMATION:

ATTN: MARK HIGHLAND

DLA-AVN-AHAA

PHONE: 256-427-9773

E-MAIL ADDRESS: MARK.HIGHLAND@DLA.MIL.

A-16. CONTRACTOR POINT OF CONTACT INFORMATION:

NAME: _______TBD____________________

TELEPHONE NUMBER: _______________

E-MAIL ADDRESS: _________________

A-17. DCMA ACO POINT OF CONTACT INFORMATION:

NAME: _______TBD___________________

TELEPHONE NUMBER: ______________

E-MAIL ADDRESS: ________________

A-18. ACCELERATED DELIVERY IS ENCOURAGED AND AUTHORIZED AT NO ADDITIONAL COST TO THE GOVERNMENT.

A-19. ATTENTION: IF NOT ALREADY COMPLETED IN SAM.GOV. PROVISIONS 52.204-24 AND 52.204-26 (NEW REQUIREMENTS IN DFARS AS OF AUGUST 13, 2020) MUST BE COMPLETED IN THE QUOTE OR PROPOSAL.

2 55

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

A-20. LONG LEAD TIME AND / OR LONG TERM CONTRACTS FOR LONG LEAD TIME ITEMS AND/OR LONG TERM CONTRACTS, THE PARTIES RECOGNIZE THERE IS A

RISK THAT PART(S) OR COMPONENT(S) REQUIRED FOR PERFORMANCE OF THE CONTRACT/PURCHASE ORDER MAY BECOME NAVAILABLE DUE TO OBSOLESCENCE.

UPON RECEIPT OF THE CONTRACT/PURCHASE ORDER, CONTRACTOR IS RESPONSIBLE FOR VERIFYING ITS SOURCES OF SUPPLY. IF AT ANY TIME DURING THE

COURSE OF PERFORMANCE CONTRACTOR BECOMES AWARE THAT IT IS UNABLE TO PROCURE A PART OR COMPONENT NECESSARY TO FULFILL THE REQUIREMENTS OF

THE CONTRACT, THE CONTRACTOR SHALL NOTIFY THE CONTRACTING OFFICER IN WRITING WITHIN THIRTY DAYS. NOTIFICATION SHALL INCLUDE ONTRACTORS

RECOMMENDATION FOR CORRECTION OF THE PROBLEM, IF POSSIBLE, WITH ESTIMATED COST AND SCHEDULE IMPACT, IF ANY. THE CONTRACTING OFFICER WILL

DETERMINE THE APPROPRIATE COURSE OF ACTION AND PROVIDE DIRECTION TO THE CONTRACTOR. IN NO EVENT WILL CONTRACTOR PROCEED WITH

IMPLEMENTATION OF ITS RECOMMENDATION WITHOUT WRITTEN DIRECTION FROM THE CONTRACTING OFFICER. AT THE SOLE DISCRETION OF THE CONTRACTING

OFFICER, THE CONTRACT MAY BE TERMINATED IN WHOLE OR IN PART, AS APPROPRIATE.

A-21. PLEASE SUBMIT ALL FAT REPORTS, INQUIRIES, AND QUESTIONS TO:

DLA AVIATION HUNTSVILLE POST AWARD TEAM

5206 MARTIN ROAD

REDSTONE ARSENAL, ALABAMA 35898

OR

EMAIL TO: DLAHSVPOSTAWARDTEAM@DLA.MIL

*** END OF NARRATIVE A0001 ***

3 55

PIIN/SIIN

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

SECTION B - SUPPLIES OR SERVICES AND PRICES/COSTS

0001 JACK, AIRCRAFT LANDING

NSN: 1730-00-540-2343

Mfr CAGE: 80049

Mfr Part Number: 53D22020

THIS IS A FIVE YEAR INDEFINITE DELIVERY

REQUIREMENTS (IDR)SOLICITATION.

FUNDS WILL BE OBLIGATED/CITED UPON THE ISSUANCE OF

EACH DELIVERY ORDER.

THE ESTIMATED (E) QUANTITIES HEREIN ARE NOT A

REPRESENTATION TO AN OFFEROR OR CONTRACTOR THAT THE

ESTIMATED QUANTITY WILL BE REQUIRED OR ORDERED, OR

THAT CONDITIONS AFFECTING REQUIREMENTS WILL BE

STABLE OR NORMAL.

THE ESTIMATED QUANTITIES ANNOTATED WITHIN THIS

SOLICITATION ARE BASED ON THE MOST CURRENT

REQUIREMENT INFORMATION AVAILALBLE.

THE GOVERNMENT INTENDS TO PROCURE A MINIMUM

QUANTITY OF 60 EACH. THE GOVERNMENT IS NOT

OBLIGATED TO ISSUE ANY ADDITIONAL ORDERS AGAINST

THIS CONTRACT; HOWEVER, THE GOVERNMENT RESERVES THE

RIGHT TO ORDER ANY QUANTITY ABOVE THE CONTRACT

MINIMUM QUANTITY FOR THE DURATION OF THIS CONTRACT.

THE GOVERNMENT HAS SEGREGATED THE POTENTIAL

QUANTITIES INTO FIVE YEAR PERIODS. THIS DOES NOT

PRECLUDE EXERCISING ITS RIGHTS UNDER FAR 52.216-21

AT ANY TIME DURING THE REQUIREMENT PERIOD.

THE INTENDED QUANTITY TO BE AWARDED SIMULTANEOUSLY

WITH THE AWARD OF THE BASIC CONTRACT IS 60 EACH.

THE MINIMUM DELIVERY ORDER QUANTITY IS 38. AT NO

TIME WILL THE CONTRACTOR BE REQUIRED TO SHIP MORE

THAN 38 UNITS PER MONTH UNLESS MUTUALLY AGREED TO BY

BOTH PARTIES. DELIVERY ORDERS ISSUED UNDER THE

RESULTING CONTRACT SHALL NOT HAVE OVERLAPPING

DELIVERY SCHEDULES.

PRICES QUOTED FOR EACH YEAR WILL BE VALID FOR ALL

QUANTITIES ORDERED DURING THAT ORDERING PERIOD.

BY REPLYING TO THIS SOLICITATION AND SUBMITTING A

QUOTATION OR PROPOSAL, THE OFFEROR IS ACKNOWLEDGING

ITS ABILITY TO SUPPORT THIS REQUIREMENT FOR THE FULL

SOLICITED TIME PERIOD.

THE SOLICITATION IS FOR THE SUPPLIES AS DETAILED ON

THE FOLLOWING PAGES. OFFERORS ARE CAUTIONED TO

INSURE THAT OFFERS ARE PROVIDED ON ALL QUANTITIES.

FAILURE TO PROPOSE ALL CLINS, MAY RESULT IN A

DETERMINATION OF NON RESPONSIVENESS. AN OFFER MAY

BE REJECTED IF THE GOVERNMENT DETERMINES THAT THE

OFFER IS MATERIALLY UNBALANCED OR IF THE OFFER

CONTAINS UNBALANCED PRICING.

4 55

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

YEAR 1 WILL BE FROM DATE OF AWARD THOUGH DAY 365

DAYS AFTER CONTRACT AWARD (DACA).

YEAR 2 WILL BEGIN 366 DACA AND END 730 DACA.

YEAR 3 WILL BEGIN 731 DACA AND END 1,095 DACA.

YEAR 4 WILL BEGIN 1,096 DACA AND END 1,460 DACA.

YEAR 5 WILL BEGIN 1,461 DACA AND END 1,825 DACA.

THE CONTRACTOR SHALL PROVIDE UNIT PRICES FOR

EACH CLIN BELOW.

ALL REFERENCES TO F.O.B. ORGIN THROUGHOUT THIS

SOLICITATION APPLY TO ALL QUANTITIES ORDERED AFTER

THE FIRST DELIVERY ORDER.

THE ESTIMATED (E) QUANTITY LISTED HEREIN DOES NOT

COMMIT THE GOVERNMENT TO ORDER THAT OR ANY QUANTITY.

THE GOVERNMENT INTENDS TO AWARD ONLY ONE REQUIREMENT

TYPE BASIC CONTRACT AS A RESULT OF THIS SOLICITATION.

(End of narrative B001)

0001AA PRODUCTION QUANTITY 60 (E) EA $ $ _______________________ ______________ __________________

PROGRAM YEAR: 1

COMMODITY NAME: JACK, AIRCRAFT LANDING

CLIN CONTRACT TYPE:

Firm Fixed Price

Description/Specs./Work Statement _________________________________

TOP DRAWING NR: 53D22020

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

MIL STD CODES 7023 APPENDIX J

UNIT PACK: 001 INTERMEDIATE PACK: 000

LEVEL PRESERVATION: Military

LEVEL PACKING: B

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Deliveries or Performance _________________________

FOB POINT: Destination

SHIP TO:

(W25G1U) SU W1A8 DLA DISTRIBUTION

DDSP NEW CUMBERLAND FACILITY

2001 NORMANDY DRIVE DOOR 113 TO 134

NEW CUMBERLAND,PA,17070-5002

5 55

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

0002 JACK, AIRCRAFT LANDING

NSN: 1730-00-540-2343

Mfr CAGE: 80049

Mfr Part Number: 53D22020

0002AA PRODUCTION QUANTITY 40 (E) EA $ $ _______________________ ______________ __________________

PROGRAM YEAR: 2

COMMODITY NAME: JACK, AIRCRAFT LANDING

CLIN CONTRACT TYPE:

Firm Fixed Price

Description/Specs./Work Statement _________________________________

TOP DRAWING NR: 53D22020

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

MIL STD CODES 7023 APPENDIX J

UNIT PACK: 001 INTERMEDIATE PACK: 000

LEVEL PRESERVATION: Military

LEVEL PACKING: B

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Deliveries or Performance _________________________

FOB POINT: Origin

SHIP TO:

(Y00000) SHIPPING INSTRUCTIONS FOR CONSIGNEE (SHIP

TO)

WILL BE FURNISHED PRIOR TO THE SCHEDULED DELIVERY

DATE FOR ITEMS REQUIRED UNDER THIS REQUISITION.

(End of narrative F001)

0003 JACK, AIRCRAFT LANDING

NSN: 1730-00-540-2343

Mfr CAGE: 80049

Mfr Part Number: 53D22020

0003AA PRODUCTION QUANTITY 40 (E) EA $ $ _______________________ ______________ __________________

PROGRAM YEAR: 3

6 55

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

COMMODITY NAME: JACK, AIRCRAFT LANDING

CLIN CONTRACT TYPE:

Firm Fixed Price

Description/Specs./Work Statement _________________________________

TOP DRAWING NR: 53D22020

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

MIL STD CODES 7023 APPENDIX J

UNIT PACK: 001 INTERMEDIATE PACK: 000

LEVEL PRESERVATION: Military

LEVEL PACKING: B

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Deliveries or Performance _________________________

FOB POINT: Origin

SHIP TO:

(Y00000) SHIPPING INSTRUCTIONS FOR CONSIGNEE (SHIP

TO)

WILL BE FURNISHED PRIOR TO THE SCHEDULED DELIVERY

DATE FOR ITEMS REQUIRED UNDER cTHIS REQUISITION.

(End of narrative F001)

0004 JACK, AIRCRAFT LANDING

NSN: 1730-00-540-2343

Mfr CAGE: 80049

Mfr Part Number: 53D22020

0004AA PRODUCTION QUANTITY 40 (E) EA $ $ _______________________ ______________ __________________

PROGRAM YEAR: 4

COMMODITY NAME: JACK, AIRCRAFT LANDING

CLIN CONTRACT TYPE:

Firm Fixed Price

Description/Specs./Work Statement _________________________________

TOP DRAWING NR: 53D22020

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

MIL STD CODES 7023 APPENDIX J

UNIT PACK: 001 INTERMEDIATE PACK: 000

LEVEL PRESERVATION: Military

7 55

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

LEVEL PACKING: B

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Deliveries or Performance _________________________

FOB POINT: Origin

SHIP TO:

(Y00000) SHIPPING INSTRUCTIONS FOR CONSIGNEE (SHIP

TO)

WILL BE FURNISHED PRIOR TO THE SCHEDULED DELIVERY

DATE FOR ITEMS REQUIRED UNDER THIS REQUISITION.

(End of narrative F001)

0005 JACK, AIRCRAFT LANDING

NSN: 1730-00-540-2343

Mfr CAGE: 80049

Mfr Part Number: 53D22020

0005AA PRODUCTION QUANTITY 40 (E) EA $ $ _______________________ ______________ __________________

PROGRAM YEAR: 5

COMMODITY NAME: JACK, AIRCRAFT LANDING

CLIN CONTRACT TYPE:

Firm Fixed Price

Description/Specs./Work Statement _________________________________

TOP DRAWING NR: 53D22020

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

MIL STD CODES 7023 APPENDIX J

UNIT PACK: 001 INTERMEDIATE PACK: 000

LEVEL PRESERVATION: Military

LEVEL PACKING: B

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Deliveries or Performance _________________________

FOB POINT: Origin

SHIP TO:

(Y00000) SHIPPING INSTRUCTIONS FOR CONSIGNEE (SHIP

8 55

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

TO)

WILL BE FURNISHED PRIOR TO THE SCHEDULED DELIVERY

DATE FOR ITEMS REQUIRED UNDER THIS REQUISITION.

(End of narrative F001)

9 55

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION D - PACKAGING AND MARKING

MIL-STD-129 MARKINGS SHALL APPLY

UNIT PACK: 001 INTERMEDIATE PACK: 000

LEVEL PRESERVATION: MILITARY LEVEL PACKING: B

ADDITIONAL PACKAGING REQUIREMENTS

ESTIMATED MAXIMUM UNIT PACKAGE WEIGHT (POUNDS) AND SIZE (INCHES)

WT [49.0] LB

LN [18.5] IN

WD [15.5] IN

DP [15.5] IN

ALL WOOD PACKAGING MATERIAL (WPM) MUST BE ISPM-15 COMPLIANT

MIL-STD-2073-1 Codes, APPENDIX J

JI/A/MP [20] JII/CD [1] JIII/PM [65] JIV/WM [GB] JV/CD [NA]

JVI/CT [Z] JVII/UC [ED] JVII/IC [00] JIX/A/PK [F] JX/SM [00]

JVIIIA/OPI [M]

SUPPLEMENTAL INFORMATION:

Z= AS REQUIRED FOR SNUG FIT, FILL ALL VOIDS.

*** END OF NARRATIVE D0001 ***

10 55

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION E - INSPECTION AND ACCEPTANCE

The Government's Quality Assurance Representative (QAR) will inspect supplies described by manufacturer's name/code and part number at origin location(s). The QAR may require that objective evidence be furnished establishing the name and address of the plant that manufactures the supplies to ensure that a domestic product is being supplied. Objective evidence of performance must be present for all quality assurance requirements specified in the contract. The QAR may require additional examinations and tests to determine:

Completeness of item

Material is new and unused

Absence of rust contamination, or deterioration\'dc

Correct identification/item marking

Correct packaging

Absence of any damage

Compliance with preparation for delivery

If the supplier is not the manufacturer of the supplies, objective evidence must be furnished to establish that the supplies were produced by the approved manufacturer. For supplies designated as former Government surplus (whether described by manufacturers name/code and part number, or by Military or federal specification or drawing), the original package markings of each item shall be verified to previous Government contract number and part number. Any deviation shall be cause for rejection of the item. The Procuring

Activity may add additional inspection requirements based on the evaluation of the surplus offer. Such additional requirements will be identified before the award.

*** END OF NARRATIVE E0001 ***

This document incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at these addresses:

For FAR clauses: https://www.acquisition.gov/

For DFARS clauses: https://www.acq.osd.mil/dpap/dars/dfarspgi/current/index.html

If the clause requires additional or unique information, then that information is provided immediately after the clause title.

Regulatory Cite Title Date Regulatory Cite Title Date _______________ ______________________________________________________________________ ____________ _______________ ______________________________________________________________________ ____________

E-1 52.246-2 INSPECTION OF SUPPLIES--FIXED-PRICE AUG/1996

E-2 52.246-16 RESPONSIBILITY FOR SUPPLIES APR/1984

E-3 52.246-11 HIGHER-LEVEL CONTRACT QUALITY REQUIREMENT DEC/2014

(a) The contractor shall comply with the higher-level quality standard(s) listed below.

ANSI/ISO/ASQ 9001:2008, AS 9100 OR EQUIVALENT, TAILORING: ALL PARAGRAPHS UNDER 7.3 (DESIGN AND DEVELOPMENT) DO NOT APPLY.

(b) The contractor shall include applicable requirements of the higher-level quality standard(s) listed in paragraph (a) of this clause and the requirement to flow down such standards, as applicable, to lower-tier subcontracts in--

(1) Any subcontract for critical and complex items (see 46.203(b) and (c)); or

(2) When the technical requirements of a subcontract require--

(i) Control of such things as design, work operations, in-process control, testing and inspection; or

(ii) Attention to such factors as organization, planning, work instructions, documentation control, and advanced metrology.

(End of clause)

11 55

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION F - DELIVERIES OR PERFORMANCE

FOR CLIN 0001AA: DELIVERIES SHALL COMMENCE 150 DAYS AFTER CONTRACT AWARD AT A RATE OF 15 PER MONTH TO NEW CUMBERLAND.

THE FIRST ORDER FOR CLIN 0001AA TO BE ISSUED IN CONJUNCTION WITH CONTRACT AWARD WILL BE DELIVERED TO : NEW CUMBERLAND ARMY DEPOT

(W25G1U).

FOR DELIVERIES TO NEW CUMBERLAND ARMY DEPOT (W25G1U) - ANNOTATE COMMERCIAL AND GOVERNMENT TRUCK BILLS OF LADING: DELIVERY THROUGH SOUTH

GATE ONLY TO:

SU W1A8 DLA DISTRIBUTION

DDSP NEW CUMBERLAND FACILITY

2001 NORMANDY DRIVE DOOR 113 TO 134

NEW CUMBERLAND, PA, 17070-5002

BUILDING MISSION DOOR 113, 134. CARRIER TO EMAIL Dsp.prelodge@dla.mil FOR AN APPOINTMENT 24 HOURS IN ADVANCE OF DELIVERY.

APPOINTMENT HOURS: MONDAY THROUGH SATURDAY BETWEEN 0700-1600. PRELODGE/DELIVERY APPOINTMENTS POC PHONE STAFFED.

CML: 717-770-7224

1-800-307-8496

M-Sat 0600-1600

FOR CLIN(s) 0002AA, 0003AA, 0004AA AND 0005AA: SHIP TO INSTRUCTIONS FOR CONSIGNEE WILL BE FURNISHED PRIOR TO SCHEDULED DELIVERY DATE FOR

ITEMS REQUIRED UNDER THIS REQUISITION.

*** END OF NARRATIVE F0001 ***

This document incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at these addresses:

For FAR clauses: https://www.acquisition.gov/

For DFARS clauses: https://www.acq.osd.mil/dpap/dars/dfarspgi/current/index.html

If the clause requires additional or unique information, then that information is provided immediately after the clause title.

Regulatory Cite Title Date Regulatory Cite Title Date _______________ ______________________________________________________________________ ____________ _______________ ______________________________________________________________________ ____________

F-1 52.211-17 DELIVERY OF EXCESS QUANTITIES SEP/1989

F-2 52.242-15 STOP-WORK ORDER AUG/1989

F-3 52.242-17 GOVERNMENT DELAY OF WORK APR/1984

F-4 52.247-30 F.O.B. ORIGIN, CONTRACTOR'S FACILITY FEB/2006

F-5 52.247-34 F.O.B. DESTINATION NOV/1991

F-6 52.247-48 F.O.B. DESTINATION--EVIDENCE OF SHIPMENT FEB/1999

F-7 52.247-58 LOADING, BLOCKING, AND BRACING OF FREIGHT CAR SHIPMENTS APR/1984

F-8 52.247-59 F.O.B. ORIGIN--CARLOAD AND TRUCKLOAD SHIPMENTS APR/1984

F-9 52.247-65 F.O.B. ORIGIN, PREPAID FREIGHT--SMALL PACKAGE SHIPMENTS JAN/1991

F-10 52.211-8 TIME OF DELIVERY JUN/1997

(a) The governments objective schedule is:

OBJECTIVE DELIVERY SCHEDULE

ITEM NO. QUANTITY WITHIN DAYS

AFTER DATE OF ORDER

0001AA 60(E) 150 DARO

0002AA 40(E) 150 DARO

0003AA 40(E) 150 DARO

0004AA 40(E) 150 DARO

0005AA 40(E) 150 DARO

The government will evaluate time of delivery and use that to determine award as stated in EVALUATION FACTORS FOR AWARD below. The

12 55

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

Government reserves the right to award under either the objective delivery schedule or the proposed delivery schedule when an offeror offers a later delivery schedule than the objective delivery schedule. If the offeror proposes no other delivery schedule, the objective delivery schedule above will apply.

OFFERORS PROPOSED DELIVERY SCHEDULE

ITEM NO. QUANTITY WITHIN DAYS

AFTER DATE OF ORDER

0001AA 60(E) __________DARO

0002AA 40(E) __________DARO

0003AA 40(E) __________DARO

0004AA 40(E) __________DARO

0005AA 40(E) __________DARO

(b) Attention is directed to the Contract Award provision of the solicitation that provides that a written award or acceptance of offer mailed, or otherwise furnished to the successful offeror, results in a binding contract. The Government will mail or otherwise furnish to the offeror an award or notice of award not later than the day award is dated. Therefore, the offeror should compute the time available for performance beginning with the actual date of award, rather than the date the written notice of award is received from the

Contracting Officer through the ordinary mails. However, the Government will evaluate an offer that proposes delivery based on the

Contractors date of receipt of the contract or notice of award by adding (1) five calendar days for delivery of the award through the ordinary mails, or (2) one working day if the solicitation states that the contract or notice of award will be transmitted electronically. (The term working day excludes weekends and U.S. Federal holidays.) If, as so computed, the offered delivery date is later than the required.

F-11 52.211-11 LIQUIDATED DAMAGES--SUPPLIES, SERVICES, OR RESEARCH AND DEVELOPMENT SEP/2000

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of TO BE DETERMINED per calendar day of delay.

(b) If the Government terminates this contract in whole or in part under the Default -- Fixed-Price Supply and Service clause, the

Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default -- Fixed-Price Supply and Service clause in this contract.

(End of Clause)

13 55

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION G - CONTRACT ADMINISTRATION DATA

Regulatory Cite Title Date Regulatory Cite Title Date _______________ ______________________________________________________________________ ____________ _______________ ______________________________________________________________________ ____________

G-1 252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS DEC/2018

(a) Definitions. As used in this clause--

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and

Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and

Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov ; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this

Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice

Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the

WAWF home page at https://wawf.eb.mil/ .

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer

Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items--

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

COMBO

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

N/A

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

[Note: The Contractor may use a WAWF "combo" document type to create some Combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in

14 55

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC TBD

Issue By DoDAAC SPRRA1

Admin DoDAAC TBD

Inspect By DoDAAC TBD

Ship To Code W25G1U

Ship From Code TBD

Mark For Code N/A

Service Approver (DoDAAC) N/A

Service Acceptor (DoDAAC) N/A

Accept at Other DoDAAC N/A

LPO DoDAAC N/A

DCAA Auditor DoDAAC N/A

Other DoDAAC(s) N/A

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and

Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

To Be Determined.

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

15 55

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION H - SPECIAL CONTRACT REQUIREMENTS

BAR CODE MARKINGS_________________

Bar Code Markings are required in accordance with the latest revision of MIL-STD-129 and ISO/IEC 16388 - Information Technology -

Automatic Identification and Data Capture Techniques - Bar Code Symbology Specification - Code 39.

CALIBRATION___________

The calibration of Test, Measurement and Diagnostic Equipment shall be in accordance with American National Standards Institute/National

Conference of Standards Laboratories (ANSI/NCSL) Z540-3-2006 (General Requirements for Calibration Laboratories and Measuring and Test

Equipment) or ISO 10012:2003 (Quality Assurance Requirements for Measuring Equipment). Terminology shall be as defined by International

Organization for Standardization (ISO) 8402, Quality Management and Quality Assurance - Vocabulary.

WOOD PACKING MATERIALS REQUIREMENTS___________________________________

A. Wood packaging material (WPM) means wood pallets, skids, load boards, pallet collars, wooden boxes, reels, dunnage, crates, frame and cleats. The definition excludes materials that have undergone a manufacturing process, such as corrugated fiberboard, plywood, particleboard, veneer, and oriented strand board (OSD).

B. All Wood Packaging Material (WPM)) acquired by DOD must meet requirements of International Standards for Phytosanitary Measures

(ISPM) 15, "Guidelines for Regulating Wood Packaging Materials International Trade." DOD shipments inside and outside of the United

States must meet ISPM 15 whenever WPM is used to ship DOD cargo.

(1) All WPM shall comply with the official quality control program for heat treatment (HT) or kiln dried heat treatment (KD HT) in accordance with American Lumber Standard Committee, incorporated (ALSC) Wood Packaging Material Program and WPM Enforcement

Regulations (see http://www.alsc.org/ ).

(2) All WPM shall include certification/quality markings in accordance with the ALSC standard. Marking shall be placed in an unobstructed area that will be readily visible to inspectors. Pallet markings shall be applied to the stringer or block on diagonally opposite sides of the pallet and be contrasting and clearly visible. All containers shall be marked on a side other than the top or bottom, contrasting and clearly visible. All dunnage used in configuring and/or securing the load shall also comply with ISPM 15 and be marked with an ALSC approved DUNNAGE stamp.

C. Failure to comply with the requirements of this restriction may result in refusal, destruction, or treatment at entry. The Agency reserves the right to recoup from the Contractor any remediation costs incurred by the Government.

D. Replacement Preservative for Pentachlorophenol

If packaging requirements of this contract specify the use of wood products and a preservative is required, Pentachlorophenol, commonly referred to as "Penta" or "PCP" is prohibited. Replacement preservatives are 2 percent copper naphthenate, 3 percent zinc naphthenate or

1.8 percent copper 8 quinolinolate.

(1) Heat Treatment: Boxes/pallets and any wood used as inner packaging made of non-manufactured wood shall be heat-treated. All non-manufactured wood used in packaging shall be heat treated to a core temperature of 56 degrees Celsius for a minimum of 30 minutes. The box/pallet manufacturer and the manufacturer of wood used as inner packaging shall be affiliated with an inspection agency accredited by the board of review of the American Lumber Standard Committee. The box/pallet manufacturer and the manufacturer of wood used as inner packaging shall ensure traceability to the original source of heat treatment.

(2) Marking: Each box/pallet shall be marked to show the conformance to the International Plant Protection Convention

Standard. The quality mark shall be placed on both ends of the outter packaging, between the end cleats or end battens: on two sides of the pallet. Foreign manufacturers shall have the heat treatment of non-manufactured wood proces verified in accordance with their National Plant Protection Organization's compliance program. In addition, wood used as dunnage for blocking and bracing shall be ordered with ALSC certified marking for dunnage or the markings may be applied locally at two foot intervals.

SOURCES ELIGIBLE FOR AWARD CONSIDERATION________________________________________

(a) Competition under this solicitation is restricted to the following sources:

(1) Approved Sources listed in Section B -- sources that have been approved by the prime manufacturer or the Government for supply of item(s) listed in this solicitation, to assure the requisite safe, dependable, effective operation and support of military equipment;

(2) Sources that have been approved prior to award -- other than approved sources listed in Section B;

(3) Non-manufacturers--offers from non-manufacturers (distributors) will only be considered for award if the required item(s) is new material and has been or will be obtained from a source of supply which has been approved prior to award. The source and part number of the item the offeror intends to supply must be stated in the offer.

(4) Surplus Dealers--offerors of Government surplus in accordance with Section I clause entitled "Material Requirements, FAR

52.211-5, will only be considered for award if the former Government surplus or residual inventory resulting from terminated contracts was originally manufactured by an approved source of supply.

(b) Only offers submitted by the above sources will be considered for award under this solicitation.

16 55

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

(c) Offerors (prospective manufacturers or non-manufacturers [distributors]) who wish to become an approved source of supply for an item listed in this solicitation should proceed per the instructions set forth in paragraph (d) below. It is noted that offeror requests for source approval in conjunction with this procurement will not be a cause for delay in this solicitation action. However, if it is determined that additional sources will clearly benefit the Government and that any delay incident to their approval would not impact readiness, a reasonable delay may be entertained. Whether or not such delay will occur will be solely at the discretion of the

Government, and the time set for opening of the Invitation for Bids or the closing date of the Request for Proposals may or may not be extended. An extension will be witnessed by issuance of an amendment to this solicitation.

(d) Offerors (prospective manufacturers or non-manufacturers [distributors]) seeking to obtain source approval, must submit a Source

Approval Request (SAR) package, for review and approval, to the Engineering Directorate (ED), Quality Engineering Division. Source approval must be obtained prior to being considered for contract award. Approvals are made on an individual part number basis for a specific manufacturing location (CAGE). Firms are encouraged to seek source approval in order to compete for future solicitations by following the SAR submission guidance provided on the website http://amcomdmz.redstone.army.mil/casl_cmo/casldba.casl_cmo_samsar .

Questions concerning SAR submissions can be directed to the ED SAR Team at EDSAR@amrdec.army.mil or call the SAR Team at 256-313-8978, 256-313-0341, or 256-313-8994.

(e) The Aviation and Missile Lifecycle Management Command (AMCOM) may require additional data, testing, or plant visits before it is able to completely evaluate a SAR. This may require the offeror (at no expense to the Government) to supply parts for testing, engine run up, or flight tests. In that event, the requestor will be so advised. AMCOM reserves the right to approve a contractor for award prior to completion of physical testing of the offered item. In such cases, the contractor shall perform any outstanding tests and provide all required documentation at no cost to the Government prior to entering upon full production. Lack of successful performance within the specified timeframe shall be grounds for a no cost termination.

(f) When a SAR is received, it will be processed for evaluation. If the evaluation and approval (including preparation or update of the requisite technical data package (TDP)) occurs before award, the requestor will be considered for award if a proposal was submitted per

(d) above. If the evaluation/TDP preparation has not been completed prior to award, AMCOM will continue the process until complete. If the requestors SAR becomes approved, the requestor will be eligible for consideration on all future solicitations for the item.

(g) All approval or disapproval notices shall be officially provided to the contractor by the appropriate technical official.

(h) Non-manufacturers (distributors) seeking to supply an item from a non-approved source must first ensure that the source becomes approved in accordance with (d) above prior to contract award.

REVISIONS TO DRAWINGS/PART NUMBERS__________________________________

(a) Sources in receipt of this solicitation are requested, at no cost to the Government, to immediately notify the Contracting Officer if they are aware of any change(s)/revision(s) to the drawing(s) or part number(s) in this solicitation which have been approved by the

Government for implementation. Notification of part number changes shall be supported by data which indicates the type of change, approving authority as required by ANSI EIA 649 MIL-STD-973 and date and method of submittal of provisioning documentation and drawings.

If complete data package has not been previously provided, the contractor shall, at no direct cost to the Government, immediately submit applicable drawings, along with a copy of the approval change authority, to the Contracting Officer, at the office symbol and mailing address listed in the "ISSUED BY" block on page one (1) of this document. The minimum acceptable data includes the next higher assembly and the item of Supply Detail Drawings which will allow provisioning, National Stock Number assignment and updating of AMCOM's data records.

(b) The contractor hereby verifies previous contractual submission of technical data:

Contract No.: _____________________________________________________

Contractor: _______________________________________________________

Explanation of Data Rights: __________________________________________

(c) The Government is not by this request soliciting, nor is the Government liable for cost incurred by the offeror in preparing or developing modifications, deviations, waivers, or other changes to drawings or part number(s). Furthermore, this request does not authorize changes to the drawing(s) or part number(s) for this acquisition, another contract, or for any other purpose. Offerors performing any contract awarded as a result of this solicitation must comply with the drawing(s) and specifications as set forth herein, unless this solicitation is amended or any resulting contract is modified by the Contracting Officer.

(d) All proposed part number changes shall be submitted pursuant to the requirements of the clause entitled, "Engineering Change

Proposal (ECP), Value Engineering Change Proposal (VECP), Request for Deviation (RFD), and Request for Waiver (RFW) (USAAMCOM).

POINT OF PRESERVATION, PACKAGING, PACKING AND MARKING OF SUPPLIES_________________________________________________________________

Preservation, packaging, packing and marking of supplies will be performed at the following location: (If other than the location set forth in block 9, page 1 of this purchase order):

17 55

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

(buyer fill-in)

Example:

SU W1A8 DLA DISTRIBUTION

DDSP NEW CUMBERLAND FACILITY

2001 NORMANDY DRIVE DOOR 113 TO 134

NEW CUMBERLAND, PA, 17070-5002

IDENTIFICATION MARKING______________________

Item shall be marked per MIL-STD-130.

ENG CHG PROPOSAL, VALUE ENG CHG PROPOSAL, REQUEST FOR DEVIATION, REQUEST FOR VARIANCE, ENG RELEASE RECORDS, NOTICE OF REVISION, &__________________________________________________________________________________________________________________________________

SPECIFICATION CHG NOTICE PREPARATION AND SUBMISSION INSTRUCTIONS________________________________________________________________

1. Contractor initiated Engineering Change Proposals (ECPs), Value Engineering Change Proposals (VECPs), Request for Deviations (RFDs), and Request for Variance (RFVs), collectively referred to as "proposals", shall be prepared, submitted and distributed in accordance with paragraphs 2, 3 and 4 below except as specified in paragraph 5 below.

2. Format.

a. Class 1 ECPs require the "Long Form Procedure" for documenting the change and describing the effects of the change on the suitability and supportability of the Configuration Item (CI). Class I ECPs should be limited to those that are necessary or offer significant benefit to the Government. Class I ECPs are those that affect the performance, reliability, maintainability, survivability, weight, balance, moment of inertia, interface characteristics, electromagnetic characteristics, or other technical requirements in the specifications and drawings. Class I ECPs also include those changes that affect Government

Furnished Equipment, safety, compatibility, retrofit, operation and maintenance manuals, interchangeability, substitutability, replaceability, source control specifications and drawings, costs, guarantees or warranties, deliveries, or schedules. Class II

ECPs are those that do not affect form, fit and function, cost, or schedule of the system CI and do not meet the other criteria described above for Class I ECPs.

b. Long Form Procedure: Class I changes to the CI require that RDMR Form 523, pages 1 through 7 (as applicable), be prepared.

Use of this procedure assures that all effects of the change on the CI are properly addressed and documented to the necessary detail to allow proper evaluation of the proposed change.

c. Short Form Procedure: ECPs and VECPs , which meet the requirements of Class II ECPs, shall be prepared using RDMR Form 523

(page 1 only). Supplemental pages may be used with the form as necessary. The responsible Contract Management Office (CMO) will enter the appropriate data in Block 5 "Class of ECP", Block 6 "Justification Codes", and Block 7 "Priority."

d. The Contractor shall not manufacture items for acceptance by the Government that incorporate a known departure from requirements, unless the Government has approved an RFD. RFDs shall be prepared using RDMR Form 527 or RDMR Form 530 (Type I, see block 5 of the form.)

e. The Contractor shall not submit items for acceptance by the Government that include a known departure from the requirements, unless the Government has approved a RFV. RFVs shall be prepared using RDMR Form 528.

f. Each ECP, RFD or RFV shall be accompanied by a written and signed evaluation prepared by the responsible Defense Contract

Management Agency (DCMA) technical representative. The DCMA written evaluation shall be considered part of the ECP/RFD/RFV proposal.

g. Classification of RFDs/RFVs.

(1) Major RFDs/RFVs. RFDs/RFVs written against CIs shall be designated as major when the RFD/RFV consists of acceptance of an item having a nonconformance with contract or configuration documentation involving health;

performance; interchangeability; reliability; survivability; maintainability; effective use or operation; weight;

appearance (when a factor); or when there is a departure from a requirement classified as major in the contractual documentation.

(2) Critical RFDs/RFVs. RFDs/RFVs written against CIs shall be designated as critical when the RFD/RFV consists of acceptance of an item having a nonconformance with contract or configuration documentation involving safety or when there is a departure from a requirement classified as critical in the contractual documentation.

(3) Minor RFDs/RFVs. RFDs/RFVs written against CIs shall be designated as minor when the RFD/RFV consists of acceptance of an item having a nonconformance with contract or configuration documentation which does not involve any of the factors listed above in paragraphs g(1) or g(2), or when there is a departure from a requirement classified as minor in the contractual documentation.

18 55

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

h. Proposals shall include sufficient technical data to describe all changes from existing contract requirements.

i. Proposals shall include sufficient justification for making the change, including a statement of contract impact, if the change is not authorized.

j. Proposals for ECPs shall set forth a "not to exceed" price and delivery adjustment acceptable to the Contractor if the

Government subsequently approves the proposal. If approved, the equitable increase shall not exceed this amount.

k. Times allowed for technical decisions for ECP and RFD/RFV proposals will be worked out via mutual agreement between the

Contractor and the Government.

l. The Contractor shall submit, concurrent with the ECP, a separate AMSAM-RD Form 525, "Specification Change Notice" (SCN), for each specification that would require revision if the ECP were approved.

m. Proposals for VECPs shall set forth a "not less than" price and delivery adjustment acceptable to the Contractor if the

Government subsequently approves the proposal. If approved, the savings shall not be less than this amount.

n. The Contractor shall utilize RDMR Form 526, "Engineering Release Record" (ERR) to release new or revised configuration documentation to the Government for approval.

o. The Contractor shall utilize RDMR Form 524, "Notice of Revision" (NOR) to describe the exact change(s) to configuration documentation specified as a data requirement in the contract. The Contractor shall describe the change using sub- sections entitled "WAS" to describe the current contractual technical requirement and "IS" to describe the proposed new requirement.

3. Submittal. The Contractor shall submit two (2) copies of each proposal to the responsible Administrative Contracting Officer (ACO).

One (1) copy of each proposal shall be returned to the Contractor within (5) working days after receipt by the ACO, stating whether or not the proposal is in compliance with this provision. Any unresolved differences between the ACO and the Contractor concerning ECPs, VECPs, RFVs or RFDs will be submitted to the PCO for resolution. Submittals may be made by electronic means by scanning the appropriate completed forms into a computer or preparing the forms electronically.

4. Distribution.

a. Electronic Distribution. The preferred method of distribution is through the Internet E-mail System to the PCO. Microsoft

Word is required for use with the transmittal letter (E-mail). Required forms will be attached to the E-mail. All forms may be obtained from the Army Contracting Command - Redstone Website (https://www.amrdec.army.mil/amrdec/rdmr-se/tdmd/ConfigMgt.htm ) by clicking on "Forms/Checksheets." The forms are in both "Adobe Acrobat" and "Form Flow" formats. In order to access and use the forms, the user must have the "Adobe Acrobat" or "Form Flow" software installed on their computer. Drawings may be scanned into the computer and sent as an attachment. In some cases, because of size, drawings may have to be sent as hard copies or sent under special electronic instructions provided by the PCO. Contractors who do not have access to the Army Contracting Command -

Redstone website will need to contact the PCO, the appropriate Project Office Configuration Management Office, or the Technical

Data Management Division (RDMR-SET) to have the forms sent to their facility.

b. Hard Copy Distribution of Class I or II ECPs and RFD/RFVs, For each Class I or II ECP, or each RFD/RFV that the ACO determines to be in compliance with this provision, the Contractor shall submit the original plus five copies to the PCO and one copy to the ACO. Upon receipt of any type of change proposal that is submitted to the PCO, the ACO shall immediately submit

DCMA's written evaluation pertaining to the proposed engineering change action to the PCO. Assistance in preparing any of these proposals may be obtained from the ACO or AMCOM Change Control Point at:

Aviation and Missile Research, Development, and Engineering Center

ATTN: RDMR-SET

Redstone Arsenal, Al 35898-5000

Telephone: 256-876-1335

c. Hard Copy Distribution of VECPs. For each VECP that the ACO determines to be in compliance with this provision, the

Contractor shall submit the original plus five copies to the PCO and one…