SPRRA118R0040.pdf

SOLICITATION, OFFER AND AWARD 1. This Contract Is A Rated Order Under

DPAS (15 CFR 700)

Rating Page of Pages

2. Contract Number 3. Solicitation Number 4. Type of Solicitation 5. Date Issued 6. Requisition/Purchase Number Sealed Bid (IFB)

Negotiated (RFP)

7. Issued By Code 8. Address Offer To (If Other Than Item 7)

NOTE: In sealed bid solicitations ‘offer’ and ‘offeror’ mean ‘bid’ and ‘bidder’.

SOLICITATION

9. Sealed offers in original and copies for furnishing the supplies or services in the Schedule will be received at the place specified in item 8, or if handcarried, in the depository located in until (hour) local time (Date).

Caution - Late Submissions, Modifications, and Withdrawals: See Section L, Provision No. 52.214-7 or 52.215-1. All offers are subject to all terms and conditions contained in this solicitation.

10. For Information A. Name B. Telephone (No Collect Calls) C. E-mail Address

Call: Area Code Number Ext.

11. Table Of Contents

(X) Sec. Description Page(s) (X) Sec. Description Page(s)

Part I - The Schedule Part II - Contract Clauses A Solicitation/Contract Form I Contract Clauses

B Supplies or Services and Prices/Costs Part III - List Of Documents, Exhibits, And Other Attach.

C Description/Specs./Work Statement J List of Attachments D Packaging and Marking Part IV - Representations And Instructions E Inspection and Acceptance K Representations, Certifications, and F Deliveries or Performance Other Statements of Offerors G Contract Administration Data L Instrs., Conds., and Notices to Offerors H Special Contract Requirements M Evaluation Factors for Award

OFFER (Must be fully completed by offeror) NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

12. In compliance with the above, the undersigned agrees, if this offer is accepted within _____ calendar days (60 calendar days unless a different period is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. Discount For Prompt Payment 10 Calendar Days (%) 20 Calendar Days (%) 30 Calendar Days (%) Calendar Days (%) (See Section I, Clause No. 52.232-8)

14. Acknowledgment of Amendments (The offeror acknowledges Amendment No. Date Amendment No. Date receipt of amendments to the SOLICITATION for offerors and related documents numbered and dated):

15A. Name and Code Facility 16. Name and Title of Person Authorized to Sign Offer Address of (Type or Print) Offeror

15B. Telephone Number 15C. Check if Remittance Address is 17. Signature 18. Offer Date Area Code Number Ext. Different From Above – Enter such

Address In Schedule

AWARD (To be completed by Government)

19. Accepted As To Items Numbered 20. Amount 21. Accounting And Appropriation

22. Authority For Using Other Than Full And Open Competition: 23. Submit Invoices To Address Shown In Item

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c)( ) (4 copies unless otherwise specified)

24. Administered By (If other than Item 7) Code 25. Payment Will Be Made By Code

26. Name of Contracting Officer (Type or Print) 27. United States Of America 28. Award Date

(Signature of Contracting Officer)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

AUTHORIZED FOR LOCAL REPRODUCTION Standard Form 33 (Rev. 9-97) Previous edition is unusable Prescribed By GSA-FAR (48 CFR) 53.214(c)

SPRRA1-18-R-0040

X

2018FEB01

2018MAR05

DOA1

2018FEB01 SEE SCHEDULE

SPRRA1

DEFENSE LOGISTICS AGENCY

5201 MARTIN ROAD/DLA-AVN-AH

REDSTONE ARSENAL AL 35898-7340

LASHONDRA ELLIS

(256)955-5331

DLA-AVN

LASHONDRA.ELLIS@DLA.MIL

1 62

X 1

X 4

X 17 X 18

X 20

X 22

X 31

X 42

X 43

X 51

X 61

CONTINUATION SHEET

Reference No. of Document Being Continued Page of

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION A - SUPPLEMENTAL INFORMATION

Buyer Name: LASHONDRA ELLIS

Buyer Office Symbol/Telephone Number: DLA-AVN/(256)955-5331

Type of Contract 1: Firm Fixed Price

Kind of Contract: Supply Contracts and Priced Orders

*** End of Narrative A0000 ***

A-1. THIS REQUIREMENT IS FOR LIMITED SOURCE TO ROTAIR INDUSTRIES, INC., CAGE 54878 , AEREX MANUFACTURING, INC., CAGE 5K840, AND SIKORSKY

AIRCRAFT CORPORATION, CAGE 78286, IAW 10 U.S.C. 2304 (c)(1) FAR 6.302-1(a)(2) A LIMITED NUMBER OF RESPONSIBLE SOURCES, AND NO OTHER

TYPE OF SUPPLIES OR SERVICES WILL SATISFY AGENCY REQUIREMENTS, FULL AND OPEN COMPETITION.

A-2. THIS REQUIREMENT IS IN SUPPORT OF THE UH-60 BLACKHAWK WEAPON SYSTEM.

A-3. FLIGHT SAFETY/CRITICAL SAFETY ITEM (CSI) IS NOT REQUIRED

A-4. PRODUCTION LOT TESTING (PLT) IS NOT REQUIRED.

A-5. FIRST ARTICLE TEST (FAT) IS REQUIRED

A-6. FAT UNIT SHALL NOT BE RETAINED AS A MATERIAL STANDARD. TEST ITEM WILL NOT BE DESTROYED AS PART OF TESTING.

A-7. SNRR MARKINGS ARE REQUIRED.

A-8. TAMMS-A ARE REQUIRED.

A-9. IUID MARKINGS ARE NOT REQUIRED.

A-10. ARMS EXPORT CONTROL IS APPLICABLE THE TECHNICAL DATA PACKAGE PROVIDED ON CD CONTAINS TECHNICAL DATA WHOSE EXPORT IS RESTRICTED BY

THE ARMS EXPORT CONTROL ACT (TITLE 22 U.S.C., SEC 2751 ET SEQ.) OR EXECUTIVE ORDER 12470. VIOLATION OF THESE EXPORT LAWS ARE SUBJECT TO

SEVERE CRIMINAL PENALTIES.

A-11. THIS IS A FIVE (5)YEAR INDEFINITE DELIVERY INDEFINITE QUANTITY (IDIQ), FIRM FIXED PRICE EFFORT. FUNDS WILL BE OBLIGATED UPON THE

ISSUANCE OF THE DELIVERY ORDER.

A-12. CONTRACTOR POINT OF CONTACT:

NAME: ___________________________________

TELEPHONE NUMBER: ___________________________________

E-MAIL ADDRESS: ________________________________________

A-13. DCMA ACO POINT OF CONTACT:

NAME: ___________________________

TELEPHONE NUMBER: ______________________________

E-MAIL ADDRESS: _______________________________________________

A-14. CONTRACT SPECIALIST POINT OF CONTACT:

NAME: _LASHONDRA T. ELLIS __________________

OFFICE SYMBOL: DLA-AVN-AHA ___________

TELEPHONE NUMBER: _256-955-5331_______ ____________

E-MAIL ADDRESS: __LASHONDRA.ELLIS@DLA.MIL_ _______________________

A-15. ACCELERATED DELIVERY IS ENCOURAGED AND AUTHORIZED AT NO ADDITIONAL COST TO THE GOVERNMENT.

A.16. REVERSE AUCTION EVALUATION IS INCLUDED ON THIS REQUIREMENT, REFER TO REVERSE AUCTION NOTICE IN SECTION L.

A-17. CONTRACTOR FIRST ARTICLE TEST

Number of samples to be tested = _1_ _

Deliver FOB: Destination

Inspection: Origin

Acceptance: Origin

BY: _348 DACA__ ________

Ship To: ATTN: DLA Aviation Huntsville Post Award Team

2 62

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

5201 Martin Road

Redstone Arsenal, Alabama 35898

(With an information copy to the Administering Contracting Officer)

Or

Email To: DLAHSVPostAwardTeam@dla.mil

Delivery Schedule:

348 Days ARO: Contractor First Article completed and Report Submission

30 Days: Government Review and Notification to Contractor

162 DAFAA: Delivery of Production Units

540 DARO

FIRST ARTICLE TEST TIME IS 3 DAYS. UNITS TO BE TESTED IS 1 EACH. FIRST ARTICLE TEST SHALL BEGIN ON A MUTUALLY AGREED UPON DATE BETWEEN

THE GOVERNMENT AND THE CONTRACTOR. THE DATE SHALL OCCUR WITH ENOUGH TIME IN ADVANCE TO BEGIN SCHEDULED DELIVERIES 540 DACA. THE _________

CONTRACTOR SHALL NOTIFY THE CONTRACTING OFFICER IN WRITING 30 DAYS PRIOR TO THE PROPOSED DATE OF FIRST ARTICLE TESTING. THE FIRST

ARTICLE TEST REPORT IS DUE 15 DAYS AFTER FAT. THE PREFERRED METHOD OF TRANSMITTAL IS CD. THE GOVERNMENT HAS 30 DAYS TO

APPROVE/DISAPPROVE THE TEST REPORT.

NOTICE: YOUR ATTENTION IS INVITED TO FEDERAL ACQUISITION REGULATION (FAR) 15.403-3, RELATIVE TO THE REQUIREMENTS FOR OBTAINING OTHER

THAN CERTIFIED COST OR PRICING DATA. IF THIS IS CONSIDERED TO BE A SOLE SOURCE REQUIREMENT, YOU ARE REQUIRED TO SUBMIT OTHER THAN COST

AND PRICING DATA, IF REQUESTED. OFFEROR MAY USE THEIR OWN FORMAT TO PROVIDE, AT A MINIMUM, A BREAKDOWN OF ALL THE COST ELEMENTS TO

INCLUDE PROFIT/FEE WHICH COMPRISE THE TOTAL PROPOSED PRICE OR SALES HISTORY. FAILURE TO PROVIDE OTHER THAN COST AND PRICING DATA IF

REQUESTED WILL RESULT IN YOUR OFFER BEING CONSIDERED NON-RESPONSIVE.

FOR LONG LEAD TIME ITEMS AND/OR LONG TERM CONTRACTS, THE PARTIES RECOGNIZE THERE IS A RISK THAT PART(S) OR COMPONENT(S) REQUIRED FOR

PERFORMANCE OF THE CONTRACT/PURCHASE ORDER MAY BECOME UNAVAILABLE DUE TO OBSOLESCENCE. UPON RECEIPT OF THE CONTRACT/PURCHASE ORDER, CONTRACTOR IS RESPONSIBLE FOR VERIFYING ITS SOURCES OF SUPPLY. IF AT ANY TIME DURING THE COURSE OF PERFORMANCE CONTRACTOR BECOMES AWARE

THAT IT IS UNABLE TO PROCURE A PART OR COMPONENT NECESSARY TO FULFILL THE REQUIREMENTS OF THE CONTRACT, THE CONTRACTOR SHALL NOTIFY THE

CONTRACTING OFFICER IN WRITING WITHIN THIRTY DAYS. NOTIFICATION SHALL INCLUDE CONTRACTORS RECOMMENDATION FOR CORRECTION OF THE PROBLEM, IF POSSIBLE, WITH ESTIMATED COST AND SCHEDULE IMPACT, IF ANY. THE CONTRACTING OFFICER WILL DETERMINE THE APPROPRIATE COURSE OF ACTION

AND PROVIDE DIRECTION TO THE CONTRACTOR. IN NO EVENT WILL CONTRACTOR PROCEED WITH IMPLEMENTATION OF ITS RECOMMENDATION WITHOUT WRITTEN

DIRECTION FROM THE CONTRACTING OFFICER. AT THE SOLE DISCRETION OF THE CONTRACTING OFFICER, THE CONTRACT MAY BE TERMINATED IN WHOLE OR IN

PART, AS APPROPRIATE.

*** END OF NARRATIVE A0001 ***

3 62

PIIN/SIIN

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

SECTION B - SUPPLIES OR SERVICES AND PRICES/COSTS

THIS IS A FIVE YEAR INDEFINITE DELIVERY INDEFINITE

QUANTITY (IDIQ) SOLICITATION. FUNDS WILL BE

OBLIGATED/CITED UPON THE ISSUANCE OF EACH DELIVERY

ORDER. THE GOVERNMENT WILL ONLY BE OBLIGATED TO

ORDER THE STATED MINIMUM QUANTITY. THE GOVERNMENT

IS NOT OBLIGATED TO ISSUE ANY ADDITIONAL ORDERS

AGAINST THIS CONTRACT; HOWEVER, THE GOVERNMENT

RESERVES THE RIGHT TO ORDER UP TO THE MAXIMUM

QUANTITY.

THE GOVERNMENT HAS SEGREGATED THE POTENTIAL

QUANTITIES INTO FIVE YEARS. HOWEVER, THIS DOES NOT

PRECLUDE EXERCISING ITS RIGHTS UNDER FAR 52.216-19

BY ORDERING THE MAXIMUM QUANTITY SPECIFIED IN FAR

52.216-19(B)(1) AT ANY TIME DURING THE INDEFINITE

QUANTITY PERIOD. THE GOVERNMENT'S MINIMUM QUANTITY

TO BE AWARDED SIMULTANEOUSLY WITH THE AWARD OF THE

BASIC CONTRACT IS 100 EACH MINIMUM OR UP TO 500

EACH MAXIMUM.

THE INITIAL DELIVERY ORDER WILL MEET OR EXCEED THE

MINIMUM QUANTITY AT THE FIRST YEAR PRICING. THE

GOVERNMENT'S MINIMUM DELIVERY ORDER QUANTITY DURING

THE INDEFINITE QUANTITY PERIOD IS 70 EACH AT A RATE

OF 25 PER MONTH. THE GOVERNMENT'S MAXIMUM

DELIVERY ORDER QUANTITY DURING THE INDEFINITE

QUANTITY PERIOD IS 500 EACH AT A RATE OF 25 PER

MONTH.

PRICES QUOTED FOR EACH YEAR WILL BE VALID FOR ALL

QUANTITIES ORDERED DURING THAT ORDERING PERIOD.

THE SOLICITATION IS FOR THE SUPPLIES AS DETAILED ON

THE FOLLOWING PAGES. OFFERORS ARE CAUTIONED TO

INSURE THAT OFFERS ARE PROVIDED ON ALL QUANTITIES.

FAILURE TO PROPOSE ALL CLINS, WILL RESULT IN A

DETERMINATION OF NON-RESPONSIVENESS.

YEAR 1 WILL BE FROM DATE OF AWARD THROUGH DAY 365

DAYS AFTER RECEIPT OF ORDER (DARO).

YEAR 2 WILL BEGIN 366 DARO AND END 730 DARO.

YEAR 3 WILL BEGIN 731 DARO AND END 1,095 DARO.

YEAR 4 WILL BEGIN 1096 DARO AND END 1,460 DARO.

YEAR 5 WILL BEGIN 1461 DARO AND END 1,825 DARO.

THE CONTRACTOR SHALL PROVIDE UNIT PRICES FOR EACH

CLIN BELOW.

ALL REFERENCES TO F.O.B. ORIGIN THROUGHOUT THIS

SOLICITATION APPLY ONLY TO ALL QUANTITIES ORDERED

AFTER THE FIRST ORDERING PERIOD.

THE ESTIMATED (E) QUANTITY LISTED HEREIN DOES NOT

COMMIT THE GOVERNMENT TO ORDER THAT OR ANY QUANTITY

ABOVE THE MINIMUM QUANTITY.

4 62

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

(End of narrative A001)

APPROVED SOURCES:

ROTAIR INDUSTRIES, INC., CAGE 54878

AEREX MANUFACTURING, INC., CAGE 5K840

SIKORSKY AIRCRAFT CORPORATION, CAGE 78286

AS A RESULT OF THIS SOLICITATION EITHER CLIN 0001AA

OR 0001AB WILL BE AWARDED.

IF CLIN 0001AA IS AWARDED WITH THE FIRST DELIVERY

ORDERS, ANY SUBSEQUENT DELIVERIES ORDERS UNDER THE

FIRST YEAR ORDERING PERIOD WILL BE AWARDED UNDER

CLIN 0001AB.

(End of narrative A002)

0001 HUB,ROTOR,HELICOPTE

NSN: 1615-01-083-6812

Mfr CAGE: 81996

Mfr Part Number: 70102-11101-042

0001AA PRODUCTION QTY W/FIRST ARTICLE TESTING 100 (E) EA $ $ ______________________________________ ______________ __________________

COMMODITY NAME: HUB,ROTOR,HELICOPTE

CLIN CONTRACT TYPE:

Firm Fixed Price

Description/Specs./Work Statement _________________________________

TOP DRAWING NR: 70102-11101-042

REVISION: 3

STDP 70102-11101 REVISION P

SS70102-11101 REVISION H

(End of narrative C001)

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

MIL-STD-129 MARKINGS SHALL APPLY

UNIT PACK: 001 INTERMEDIATE PACK: 000

5 62

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

LEVEL PRESERVATION: Military

LEVEL PACKING: B

**ADDITIONAL PACKAGING REQUIREMENTS**

ESTIMATED MAXIMUM UNIT PACKAGE WEIGHT (POUNDS) AND

SIZE (INCHES):

WT [22.7]

LN [22.0]

WD [22.0]

DP [11.0]

ALL WOOD PACKAGING MATERIAL (WPM) MUST BE ISPM-15

COMPLIANT.

MIL-STD-2073-1 CODES, APPENDIX J

JI/A/MP [41]

JII/CD [1]

JIII/PM [00]

JIV/WM [GB]

JV/CD [NA]

JVI/CT [B]

JVII/UC [ED]

JVII/IC [00]

JIX/A/PK [F]

JX/SM [00]

JVIIIA/OPI [M]

(End of narrative D001)

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Government Approval/Disapproval Days: 30

Deliveries or Performance _________________________

FOB POINT: Destination

SHIP TO:

(W25G1U) SU W1A8 DLA DISTRIBUTION

DDSP NEW CUMBERLAND FACILITY

2001 NORMANDY DRIVE DOOR 113 TO 134

NEW CUMBERLAND,PA,17070-5002

DELIVERIES SHALL COMMENCE 540 DAYS AFTER THE DATE

OF DELIVERY ORDER AWARD AT A RATE OF 25 EACH PER

MONTH.

FOR DELIVERIES TO NEW CUMBERLAND ARMY DEPOT

(W25G1U) ANNOTATE COMMERCIAL AND GOVERNMENT TRUCK

BILLS OF LADING: DELIVERY THROUGH SOUTH GATE ONLY,

BUILDING MISSION DOOR 113, 134. CARRIER TO CALL

(717) 770- 6969/7172 FOR APPOINTMENT 24 HOURS IN

ADVANCE OF DELIVERY. APPOINTMENT HOURS: MONDAY

THROUGH FRIDAY BETWEEN 0800-1600.

6 62

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

(End of narrative F001)

0001AB PRODUCTION QTY W/OUT FIRST ARTICLE TESTING 100 (E) EA $ $ __________________________________________ ______________ __________________

COMMODITY NAME: HUB,ROTOR,HELICOPTE

CLIN CONTRACT TYPE:

Firm Fixed Price

Description/Specs./Work Statement _________________________________

TOP DRAWING NR: 70102-11101-042

REVISION: 3

STDP 70102-11101 REVISION P

SS70102-11101 REVISION H

(End of narrative C001)

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

MIL-STD-129 MARKINGS SHALL APPLY

UNIT PACK: 001 INTERMEDIATE PACK: 000

LEVEL PRESERVATION: Military

LEVEL PACKING: B

**ADDITIONAL PACKAGING REQUIREMENTS**

ESTIMATED MAXIMUM UNIT PACKAGE WEIGHT (POUNDS) AND

SIZE (INCHES):

WT [22.7]

LN [22.0]

WD [22.0]

DP [11.0]

ALL WOOD PACKAGING MATERIAL (WPM) MUST BE ISPM-15

COMPLIANT.

MIL-STD-2073-1 CODES, APPENDIX J

JI/A/MP [41]

JII/CD [1]

JIII/PM [00]

JIV/WM [GB]

JV/CD [NA]

JVI/CT [B]

JVII/UC [ED]

JVII/IC [00]

JIX/A/PK [F]

JX/SM [00]

JVIIIA/OPI [M]

(End of narrative D001)

7 62

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Deliveries or Performance _________________________

FOB POINT: Destination

SHIP TO:

(W25G1U) SU W1A8 DLA DISTRIBUTION

DDSP NEW CUMBERLAND FACILITY

2001 NORMANDY DRIVE DOOR 113 TO 134

NEW CUMBERLAND,PA,17070-5002

DELIVERIES SHALL COMMENCE 360 DAYS AFTER THE DATE

OF DELIVERY ORDER AWARD AT A RATE OF 25 EACH PER

MONTH.

FOR DELIVERIES TO NEW CUMBERLAND ARMY DEPOT

(W25G1U) ANNOTATE COMMERCIAL AND GOVERNMENT TRUCK

BILLS OF LADING: DELIVERY THROUGH SOUTH GATE ONLY,

BUILDING MISSION DOOR 113, 134. CARRIER TO CALL

(717) 770-6969/7172 FOR APPOINTMENT 24 HOURS IN

ADVANCE OF DELIVERY. APPOINTMENT HOURS: MONDAY

THROUGH FRIDAY BETWEEN 0800-1600.

(End of narrative F001)

0002 HUB,ROTOR,HELICOPTE

NSN: 1615-01-083-6812

Mfr CAGE: 81996

Mfr Part Number: 70102-11101-042

0002AA PRODUCTION QTY YEAR 2 100 (E) EA $ $ _____________________ ______________ __________________

COMMODITY NAME: HUB,ROTOR,HELICOPTE

CLIN CONTRACT TYPE:

Firm Fixed Price

Description/Specs./Work Statement _________________________________

TOP DRAWING NR: 70102-11101-042

REVISION: 3

STDP 70102-11101 REVISION P

SS70102-11101 REVISION H

(End of narrative C001)

8 62

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

MIL-STD-129 MARKINGS SHALL APPLY

UNIT PACK: 001 INTERMEDIATE PACK: 000

LEVEL PRESERVATION: Military

LEVEL PACKING: B

**ADDITIONAL PACKAGING REQUIREMENTS**

ESTIMATED MAXIMUM UNIT PACKAGE WEIGHT (POUNDS) AND

SIZE (INCHES):

WT [22.7]

LN [22.0]

WD [22.0]

DP [11.0]

ALL WOOD PACKAGING MATERIAL (WPM) MUST BE ISPM-15

COMPLIANT.

MIL-STD-2073-1 CODES, APPENDIX J

JI/A/MP [41]

JII/CD [1]

JIII/PM [00]

JIV/WM [GB]

JV/CD [NA]

JVI/CT [B]

JVII/UC [ED]

JVII/IC [00]

JIX/A/PK [F]

JX/SM [00]

JVIIIA/OPI [M]

(End of narrative D001)

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Deliveries or Performance _________________________

FOB POINT: Origin

SHIP TO:

(Y00000) SHIPPING INSTRUCTIONS FOR CONSIGNEE

(SHIP-TO) WILL BE FURNISHED PRIOR

TO THE SCHEDULED DELIVERY DATE FOR

ITEMS REQUIRED UNDER THIS

REQUISITION.

DELIVERIES SHALL COMMENCE 360 DAYS AFTER THE DATE

OF DELIVERY ORDER AWARD AT A RATE OF 25 EACH PER

MONTH.

(End of narrative F001)

9 62

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

0003 HUB,ROTOR,HELICOPTE

NSN: 1615-01-083-6812

Mfr CAGE: 81996

Mfr Part Number: 70102-11101-042

0003AA PRODUCTION QTY YEAR 3 100 (E) EA $ $ _____________________ ______________ __________________

COMMODITY NAME: HUB,ROTOR,HELICOPTE

CLIN CONTRACT TYPE:

Firm Fixed Price

Description/Specs./Work Statement _________________________________

TOP DRAWING NR: 70102-11101-042

REVISION: 3

STDP 70102-11101 REVISION P

SS70102-11101 REVISION H

(End of narrative C001)

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

MIL-STD-129 MARKINGS SHALL APPLY

UNIT PACK: 001 INTERMEDIATE PACK: 000

LEVEL PRESERVATION: Military

LEVEL PACKING: B

**ADDITIONAL PACKAGING REQUIREMENTS**

ESTIMATED MAXIMUM UNIT PACKAGE WEIGHT (POUNDS) AND

SIZE (INCHES):

WT [22.7]

LN [22.0]

WD [22.0]

DP [11.0]

ALL WOOD PACKAGING MATERIAL (WPM) MUST BE ISPM-15

COMPLIANT.

MIL-STD-2073-1 CODES, APPENDIX J

JI/A/MP [41]

JII/CD [1]

JIII/PM [00]

JIV/WM [GB]

JV/CD [NA]

JVI/CT [B]

JVII/UC [ED]

JVII/IC [00]

JIX/A/PK [F]

10 62

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

JX/SM [00]

JVIIIA/OPI [M]

(End of narrative D001)

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Deliveries or Performance _________________________

FOB POINT: Origin

SHIP TO:

(Y00000) SHIPPING INSTRUCTIONS FOR CONSIGNEE

(SHIP-TO) WILL BE FURNISHED PRIOR

TO THE SCHEDULED DELIVERY DATE FOR

ITEMS REQUIRED UNDER THIS

REQUISITION.

DELIVERIES SHALL COMMENCE 360 DAYS AFTER THE DATE

OF DELIVERY ORDER AWARD AT A RATE OF 25 EACH PER

MONTH.

(End of narrative F001)

0004 HUB,ROTOR,HELICOPTE

NSN: 1615-01-083-6812

Mfr CAGE: 81996

Mfr Part Number: 70102-11101-042

0004AA PRODUCTION QTY YEAR 4 100 (E) EA $ $ _____________________ ______________ __________________

COMMODITY NAME: HUB,ROTOR,HELICOPTE

CLIN CONTRACT TYPE:

Firm Fixed Price

Description/Specs./Work Statement _________________________________

TOP DRAWING NR: 70102-11101-042

REVISION: 3

STDP 70102-11101 REVISION P

SS70102-11101 REVISION H

(End of narrative C001)

11 62

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

MIL-STD-129 MARKINGS SHALL APPLY

UNIT PACK: 001 INTERMEDIATE PACK: 000

LEVEL PRESERVATION: Military

LEVEL PACKING: B

**ADDITIONAL PACKAGING REQUIREMENTS**

ESTIMATED MAXIMUM UNIT PACKAGE WEIGHT (POUNDS) AND

SIZE (INCHES):

WT [22.7]

LN [22.0]

WD [22.0]

DP [11.0]

ALL WOOD PACKAGING MATERIAL (WPM) MUST BE ISPM-15

COMPLIANT.

MIL-STD-2073-1 CODES, APPENDIX J

JI/A/MP [41]

JII/CD [1]

JIII/PM [00]

JIV/WM [GB]

JV/CD [NA]

JVI/CT [B]

JVII/UC [ED]

JVII/IC [00]

JIX/A/PK [F]

JX/SM [00]

JVIIIA/OPI [M]

(End of narrative D001)

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Deliveries or Performance _________________________

FOB POINT: Origin

SHIP TO:

(Y00000) SHIPPING INSTRUCTIONS FOR CONSIGNEE

(SHIP-TO) WILL BE FURNISHED PRIOR

TO THE SCHEDULED DELIVERY DATE FOR

ITEMS REQUIRED UNDER THIS

REQUISITION.

DELIVERIES SHALL COMMENCE 360 DAYS AFTER THE DATE

OF DELIVERY ORDER AWARD AT A RATE OF 25 EACH PER

MONTH.

(End of narrative F001)

12 62

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

0005 HUB,ROTOR,HELICOPTE

NSN: 1615-01-083-6812

Mfr CAGE: 81996

Mfr Part Number: 70102-11101-042

0005AA PRODUCTION QTY YEAR 5 100 (E) EA $ $ _____________________ ______________ __________________

COMMODITY NAME: HUB,ROTOR,HELICOPTE

CLIN CONTRACT TYPE:

Firm Fixed Price

Description/Specs./Work Statement _________________________________

TOP DRAWING NR: 70102-11101-042

REVISION: 3

STDP 70102-11101 REVISION P

SS70102-11101 REVISION H

(End of narrative C001)

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

MIL-STD-129 MARKINGS SHALL APPLY

UNIT PACK: 001 INTERMEDIATE PACK: 000

LEVEL PRESERVATION: Military

LEVEL PACKING: B

**ADDITIONAL PACKAGING REQUIREMENTS**

ESTIMATED MAXIMUM UNIT PACKAGE WEIGHT (POUNDS) AND

SIZE (INCHES):

WT [22.7]

LN [22.0]

WD [22.0]

DP [11.0]

ALL WOOD PACKAGING MATERIAL (WPM) MUST BE ISPM-15

COMPLIANT.

MIL-STD-2073-1 CODES, APPENDIX J

JI/A/MP [41]

JII/CD [1]

JIII/PM [00]

JIV/WM [GB]

JV/CD [NA]

JVI/CT [B]

JVII/UC [ED]

JVII/IC [00]

JIX/A/PK [F]

JX/SM [00]

13 62

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

JVIIIA/OPI [M]

(End of narrative D001)

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Deliveries or Performance _________________________

FOB POINT: Origin

SHIP TO:

(Y00000) SHIPPING INSTRUCTIONS FOR CONSIGNEE

(SHIP-TO) WILL BE FURNISHED PRIOR

TO THE SCHEDULED DELIVERY DATE FOR

ITEMS REQUIRED UNDER THIS

REQUISITION.

DELIVERIES SHALL COMMENCE 360 DAYS AFTER THE DATE

OF DELIVERY ORDER AWARD AT A RATE OF 25 EACH PER

MONTH.

(End of narrative F001)

0006 FIRST ARTICLE TEST REPORT 1 EA $ ** NSP ** $ ** NSP ** _________________________ ______________ __________________

COMMODITY NAME: FIRST ARTICLE TEST REPORT

Packaging and Marking _____________________

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Destination

Deliveries or Performance _________________________

DOC SUPPL

REL CD MILSTRIP ADDR SIG CD MARK FOR TP CD ______ ________ ______ ______ ________ _____

001 3

DEL REL CD QUANTITY DEL DATE __________ ______________ ___________

001 1 AS REQUIRED

FOB POINT: Destination

SHIP TO:

(SPRRA1) DLA AVIATION AT HUNTSVILLE, AL

DLR PROCUREMENT OPERATIONS (AH)

5201 MARTIN ROAD

14 62

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

REDSTONE ARSENAL,AL,35898-7340

FIRST ARTICLE TEST TIME IS 3 DAYS. UNITS TO BE

TESTED IS 1 EACH. FIRST ARTICLE TEST SHALL BEGIN ON

A MUTUALLY AGREED UPON DATE BETWEEN THE

GOVERNMENT AND THE CONTRACTOR. THE DATE SHALL OCCUR

WITH ENOUGH TIME IN ADVANCE TO BEGIN SCHEDULED

DELIVERIES 540 DACA. THE CONTRACTOR SHALL NOTIFY

THE CONTRACTING OFFICER IN WRITING 30 DAYS PRIOR TO

THE PROPOSED DATE OF FIRST ARTICLE TESTING. THE

FIRST ARTICLE TEST REPORT IS DUE 15 DAYS AFTER FAT.

THE PREFERRED METHOD OF TRANSMITTAL IS CD. THE

GOVERNMENT HAS 30 DAYS TO APPROVE/DISAPPROVE THE

TEST REPORT.

(End of narrative F001)

0007 CONTRACT DATA REQUIREMENTS LIST _______________________________

A001 THE ARMY MAINTENANCE MANAGEMENT SYSTEM-AVIATION 1 EA $ ** NSP ** $ ** NSP ** _______________________________________________ ______________ __________________

COMMODITY NAME: HUB,ROTOR,HELICOPTE

Description/Specs./Work Statement _________________________________

PROCUREMENT DOCUMENTATION TITLE:

DI-SESS-81758A

Packaging and Marking _____________________

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Deliveries or Performance _________________________

DOC SUPPL

REL CD MILSTRIP ADDR SIG CD MARK FOR TP CD ______ ________ ______ ______ ________ _____

001 3

DEL REL CD QUANTITY DEL DATE __________ ______________ ___________

001 1 AS REQUIRED

FOB POINT: Destination

SHIP TO:

(W81D17) W0H9 US ARMY AVN & MISSILES CMD

MAINTENANCE INFO OP BRANCH MIO

SPARKMAN CIR BLDG 5301 2ND FLOOR

REDSTONE ARSENAL AL 35898-5230

15 62

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

A002 SERIAL NUMBER REQUIREMENT REPORTING 1 EA $ ** NSP ** $ ** NSP ** ___________________________________ ______________ __________________

COMMODITY NAME: HUB,ROTOR,HELICOPTE

Description/Specs./Work Statement _________________________________

PROCUREMENT DOCUMENTATION TITLE:

DI-SESS-81759A

Packaging and Marking _____________________

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Deliveries or Performance _________________________

DOC SUPPL

REL CD MILSTRIP ADDR SIG CD MARK FOR TP CD ______ ________ ______ ______ ________ _____

001 3

DEL REL CD QUANTITY DEL DATE __________ ______________ ___________

001 1 AS REQUIRED

FOB POINT: Destination

SHIP TO:

(W81D17) W0H9 US ARMY AVN & MISSILES CMD

MAINTENANCE INFO OP BRANCH MIO

SPARKMAN CIR BLDG 5301 2ND FLOOR

REDSTONE ARSENAL AL 35898-5230

16 62

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION E - INSPECTION AND ACCEPTANCE

This document incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at these addresses:

http://farsite.hill.af.mil/ or https://www.acquisition.gov/

If the clause requires additional or unique information, then that information is provided immediately after the clause title.

Regulatory Cite Title Date Regulatory Cite Title Date _______________ ______________________________________________________________________ ____________ _______________ ______________________________________________________________________ ____________

E-1 52.246-2 INSPECTION OF SUPPLIES--FIXED-PRICE AUG/1996

E-2 52.246-16 RESPONSIBILITY FOR SUPPLIES APR/1984

E-3 52.246-11 HIGHER-LEVEL CONTRACT QUALITY REQUIREMENT DEC/2014

(a) The contractor shall comply with the higher-level quality standard(s) listed below.

Quality systems -- Model for quality assurance and design, development, production, installation and servicing, American National

Standards Institute/American Society for Quality Control ANSI/ISO/ASQ 9001:2008, AS 9100 Or Equivalent, Tailoring: All Paragraphs Under

7.3 (DESIGN AND DEVELOPMENT) DO NOT APPLY.

Contractor must identify below the title, number (if any), date, and tailoring (if any) of the specific system(s) that will be used to satisfy this requirement.

(b) The contractor shall include applicable requirements of the higher-level quality standard(s) listed in paragraph (a) of this clause and the requirement to flow down such standards, as applicable, to lower-tier subcontracts in--

(1) Any subcontract for critical and complex items (see 46.203(b) and (c)); or

(2) When the technical requirements of a subcontract require--

(i) Control of such things as design, work operations, in-process control, testing and inspection; or

(ii) Attention to such factors as organization, planning, work instructions, documentation control, and advanced metrology.

(End of clause)

E06 Inspection and Acceptance at Origin (SEP 2016)

The contractor shall indicate the location where supplies will be inspected:

Commercial and Government Entity (CAGE) code:___________________________

Address:

Applicable to contract line-item numbers(s) (CLIN(s)):__________________

The contractor shall indicate the location where packaging will be inspected:

( ) Same as for supplies OR

CAGE code: ________________________________________________________________________

Address: ________________________________________________________________________

Applicable to CLIN(s): ________________________________________________________________________

*** END OF NARRATIVE E0001 ***

17 62

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION F - DELIVERIES OR PERFORMANCE

This document incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at these addresses:

http://farsite.hill.af.mil/ or https://www.acquisition.gov/

If the clause requires additional or unique information, then that information is provided immediately after the clause title.

Regulatory Cite Title Date Regulatory Cite Title Date _______________ ______________________________________________________________________ ____________ _______________ ______________________________________________________________________ ____________

F-1 52.211-17 DELIVERY OF EXCESS QUANTITIES SEP/1989

F-2 52.242-15 STOP-WORK ORDER AUG/1989

F-3 52.242-17 GOVERNMENT DELAY OF WORK APR/1984

F-4 52.247-34 F.O.B. DESTINATION NOV/1991

F-5 52.247-48 F.O.B. DESTINATION--EVIDENCE OF SHIPMENT FEB/1999

F-6 52.247-58 LOADING, BLOCKING, AND BRACING OF FREIGHT CAR SHIPMENTS APR/1984

F-7 52.211-8 TIME OF DELIVERY JUN/1997

(a) The Government requires delivery to be made according to the following schedule:

REQUIRED DELIVERY SCHEDULE

ITEM NO. QUANTITY WITHIN DAYS

AFTER DATE OF

CONTRACT

0001AA 100(E) 540 DARO

0001AB 100(E) 540 DARO

0002AA 100(E) 540 DARO

0003AA 100(E) 540 DARO

0004AA 100(E) 540 DARO

0005AA 100(E) 540 DARO

The Government will evaluate equally, as regards time of delivery, offers that propose delivery of each quantity within the applicable delivery period specified above. Offers that propose delivery that will not clearly fall within the applicable required delivery period specified above, will be considered nonresponsive and rejected. The Government reserves the right to award under either the required delivery schedule or the proposed delivery schedule, when an offeror offers an earlier delivery schedule than required above. If the offeror proposes no other delivery schedule, the required delivery schedule above will apply.

OFFERORS PROPOSED DELIVERY SCHEDULE

ITEM NO. QUANTITY WITHIN DAYS

AFTER DATE OF

CONTRACT

0001AA 100(E) ___ DARO

0001AB 100(E) ___ DARO

0002AA 100(E) ___ DARO

0003AA 100(E) ___ DARO

0004AA 100(E) ___ DARO

0005AA 100(E) ___ DARO

(b) Attention is directed to the Contract Award provision of the solicitation that provides that a written award or acceptance of offer mailed, or otherwise furnished to the successful offeror, results in a binding contract. The Government will mail or otherwise furnish to the offeror an award or notice of award not later than the day award is dated. Therefore, the offeror should compute the time available for performance beginning with the actual date of award, rather than the date the written notice of award is received from the

Contracting Officer through the ordinary mails. However, the Government will evaluate an offer that proposes delivery based on the

Contractors date of receipt of the contract or notice of award by adding

18 62

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

(1) five calendar days for delivery of the award through the ordinary mails, or

(2) one working day if the solicitation states that the contract or notice of award will be transmitted electronically. (The term working day excludes weekends and U.S. Federal holidays.) If, as so computed, the offered delivery date is later than the required delivery date, the offer will be considered nonresponsive and rejected.

(End of Clause)

F-8 52.211-11 LIQUIDATED DAMAGES--SUPPLIES, SERVICES, OR RESEARCH AND DEVELOPMENT SEP/2000

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of TBD AT THE TIME OF AWARD per calendar day of delay.

(b) If the Government terminates this contract in whole or in part under the Default -- Fixed-Price Supply and Service clause, the

Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default -- Fixed-Price Supply and Service clause in this contract.

(End of Clause)

19 62

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION G - CONTRACT ADMINISTRATION DATA

Regulatory Cite Title Date Regulatory Cite Title Date _______________ ______________________________________________________________________ ____________ _______________ ______________________________________________________________________ ____________

G-1 252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS MAY/2013

(a) Definitions. As used in this clause--

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this

Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice

Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the

WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer

Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

COMBO

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

ORIGIN/ORIGIN

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in

WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC TBD

Issue By DoDAAC SPRRA1

Admin DoDAAC TBD

Inspect By DoDAAC TBD

Ship To Code TBD

Ship From Code TBD

Mark For Code TBD

Service Approver (DoDAAC) N/A

Service Acceptor (DoDAAC) N/A

Accept at Other DoDAAC N/A

LPO DoDAAC N/A

DCAA Auditor DoDAAC TBD

Other DoDAAC(s) TBD

20 62

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the "Send Additional Email

Notifications" field of WAWF once a document is submitted in the system.

N/A

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

N/A

(2) For technical WAWF help, contact the WAWF helpdesk at 866-

618-5988.

(End of clause)

21 62

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION H - SPECIAL CONTRACT REQUIREMENTS

52.209-4005 SOURCES ELIGIBLE FOR AWARD CONSIDERATION____________________________________________________

(a) Competition under this solicitation is restricted to the following sources:

(1) Approved Sources listed in Section B -- sources that have been approved by the prime manufacturer or the Government for supply of item(s) listed in this solicitation, to assure the requisite safe, dependable, effective operation and support of military equipment;

(2) Sources that have been approved prior to award -- other than approved sources listed in Section B;

(3) Non-manufacturers--offers from non-manufacturers (distributors) will only be considered for award if the required item(s) is new material and has been or will be obtained from a source of supply which has been approved prior to award. The source and part number of the item the offeror intends to supply must be stated in the offer.

(4) Surplus Dealers--offerors of Government surplus in accordance with Section I clause entitled "Material Requirements, FAR 52.211-5, will only be considered for award if the former Government surplus or residual inventory resulting from terminated contracts was originally manufactured by an approved source of supply.

(b) Only offers submitted by the above sources will be considered for award under this solicitation.

(c) Offerors (prospective manufacturers or non-manufacturers [distributors]) who wish to become an approved source of supply for an item listed in this solicitation should proceed per the instructions set forth in paragraph (d) below. It is noted that offeror requests for source approval in conjunction with this procurement will not be a cause for delay in this solicitation action. However, if it is determined that additional sources will clearly benefit the Government and that any delay incident to their approval would not impact readiness, a reasonable delay may be entertained. Whether or not such delay will occur will be solely at the discretion of the

Government, and the time set for opening of the Invitation for Bids or the closing date of the Request for Proposals may or may not be extended. An extension will be witnessed by issuance of an amendment to this solicitation.

(d) Offerors (prospective manufacturers or non-manufacturers [distributors]) seeking to obtain source approval, must submit a Source

Approval Request (SAR) package, for review and approval, to the Engineering Directorate (ED), Quality Engineering Division. Source approval must be obtained prior to being considered for contract award. Approvals are made on an individual part number basis for a specific manufacturing location (CAGE). Firms are encouraged to seek source approval in order to compete for future solicitations by following the SAR submission guidance provided on the website http://amcomdmz.redstone.army.mil/casl_cmo/casldba.casl_cmo_samsar.

Questions concerning SAR submissions can be directed to the ED SAR Team at EDSAR@amrdec.army.mil or call the SAR Team at 256-313-8978, 256-313-0341, or 256-313-8994.

(e) The Aviation and Missile Lifecycle Management Command (AMCOM) may require additional data, testing, or plant visits before it is able to completely evaluate a SAR. This may require the offeror (at no expense to the Government) to supply parts for testing, engine run up, or flight tests. In that event, the requestor will be so advised. AMCOM reserves the right to approve a contractor for award prior to completion of physical testing of the offered item. In such cases, the contractor shall perform any outstanding tests and provide all required documentation at no cost to the Government prior to entering upon full production. Lack of successful performance within the specified timeframe shall be grounds for a no cost termination.

(f) When a SAR is received, it will be processed for evaluation. If the evaluation and approval (including preparation or update of the requisite technical data package (TDP)) occurs before award, the requestor will be considered for award if a proposal was submitted per

(d) above. If the evaluation/TDP preparation has not been completed prior to award, AMCOM will continue the process until complete. If the requestors SAR becomes approved, the requestor will be eligible for consideration on all future solicitations for the item.

(g) All approval or disapproval notices shall be officially provided to the contractor by the appropriate technical official.

(h) Non-manufacturers (distributors) seeking to supply an item from a non-approved source must first ensure that the source becomes approved in accordance with (d) above prior to contract award.

52.209-4020 FIRST ARTICLE INSPECTION AND TEST - CONTRACTOR TESTED - ADDITIONAL REQUIREMENTS___________________________________________________________________________________________

a. The first article shall be inspected and tested by the contractor in accordance with the requirements of the contract. The first article shall be representative of items to be manufactured using the same processes and procedures and at the same facility as contract production. All parts and materials, including packaging and packing, shall be obtained from the same source of supply as will be used

22 62

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

during regular production. All components, subassemblies, and assemblies in the first article sample shall have been produced by the

Contractor (including subcontractors) using the technical data package applicable to this procurement. If applicable, the Contractor or its subcontractor shall produce or demonstrate proof that any fixtures, tool masters, jigs, or similar devices used in the inspection and/or testing of the first article have been subjected to an initial inspection, or other suitable means supporting their accuracy, before being used in the manufacturing/production process.

b. At a minimum, first article inspection and test shall include:

(1) A 100% inspection (or as set forth in relevant specifications) of all physical and functional characteristics, to include but not limited to, any drawings, as well as any other requirements which may be set forth by other applicable specifications, or in any technical data packages, and/or any other special/functional testing as set forth in this contract;

(2) A review of parts, components and/or assemblies for compliance to identification markings;

(3) A review of packaging for compliance to preservation, packaging, packing, and marking requirements;

(4) A review for compliance within the Technical Data Package or as otherwise stated in this contract that approved manufacturing sources have been used for special processes, controlled parts, components, and/or assemblies;

(5) The verification through documented evidence that all inspection, testing, measuring and diagnostic equipment used in the inspection/test of the first article piece(s) have been subjected to an initial inspection, or other means supporting their accuracy, and are maintained in accordance with contractual calibration standards.

c. Unless otherwise specified in the contract, the contractor shall NOT retain the first article provided under this contract to serve as the manufacturing standard of acceptance.

d. A First Article Test Report (FATR) shall be prepared and submitted in accordance with FAR 52.209-3. The report will include all necessary documentation to demonstrate and support full compliance with the first article inspection and test requirements as set forth in this contract (including supplier's and vendor's inspection records and certifications, when applicable). The FATR shall include actual inspection and test results to include all measurements, recorded test data, and certifications (if applicable) keyed to each drawing, specifications and/or Quality Assurance Provision (QAP) requirement and identified by each individual QAP characteristic, drawing/specification characteristic and unlisted characteristic. The FATR shall contain sufficient narrative content, technical data, illustrations or photographic evidence, and an objective determination by the contrator to allow the designated Government representative to determine that the First Article test was successfully completed.

e. Additional first article testing may be ordered by the Contracting Officer in writing when (i) a major change is made to the technical data, (ii) whenever there is a lapse in production for a period in excess of 3 years, or (iii) whenever a change occurs in place of performance, manufacturing locations or processes, material used, drawing, specification or source of supply. When conditions

(i), (ii), or (iii) above occurs, the Contractor shall notify the Contracting Officer so that a determination can be made concerning the need for the additional first article sample or portion thereof, and instructions provided concerning the submission, inspection, and notification of results. Should the Government require additional first article testing the Contractor may be entitled to an equitable adjustment.

52.209-4024 REQUEST FOR WAIVER OF REQUIRED FIRST ARTICLE APPROVAL_________________________________________________________________

The requirement for FIRST ARTICLE APPROVAL may be waived, in whole or in part, by the Government, provided that sufficient information is provided to determine whether the request is to be approved. A partial waiver is defined as a waiver of only a specific test(s) of the First Article Test requirement as required by the Technical Data Package (TDP) and/or the solicitation/contract, i.e. vibration test, salt water spray test, or a test on a component or subassembly of the procured item. A full waiver is defined as a waiver of all

First Article testing as required by the TDP and/or the solicitation/contract.

All waiver requests require a First Article Waiver Worksheet to be completed and submitted to the Government along with all supporting documentation. The worksheet will be provided by the Buyer upon request. No requests will be considered if the worksheet and supporting

23 62

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

documentation are not submitted to the Government. The worksheet must be completed in its entirety. For those sections of the worksheet which do not apply, annotate with N/A (not applicable). To substantiate or clarify information provided, the Government may request additional information.

Submission of the FAT waiver request (and supporting documentation) to the Government does not guarantee that the waiver will be granted.

The First Article Waiver Worksheet and additional supporting documentation must be submitted on Company letterhead and signed by an authorized agent of the Company.

Supporting documentation.

(1) The request for waiver must be accompanied by the First Article Waiver Worksheet, and documentation in support of the request. The documentation may include, but is not limited to:

(i) Copy of the Administrative Contracting Officers (ACOs) or Procuring Contracting Officers (PCOs) letter approving a First Article

Test report on a recent contract for the same or similar item;

(ii) Copy of a First Article Test report for the same or a similar item as that solicited herein;

(iii) Copy of an ACO or PCO letter approving a prior waiver request; or

(iv) If the waiver request is based on similarity, a copy of the drawing/other appropriate technical requirements of the similar item.

(2) If a copy of a First Article Test report is submitted in support of a request for waiver, the test report must have been approved and signed by an authorized representative of the United States Government.

(3) The First Article Waiver Worksheet and all supporting documentation should be submitted by email. If the First Article Waiver

Worksheet and supporting documentation cannot be transmitted by email, the PCO should be contacted for further instruction.

Note: If a waiver is granted, an accelerated delivery schedule will apply.

Note: Cost considerations shall apply for approving a waiver or a portion thereof of a First Article Test.

52.211-4008 REVISIONS TO DRAWINGS/PART NUMBERS______________________________________________

(a) Sources in receipt of this solicitation are requested, at no cost to the Government, to immediately notify the Contracting Officer if they are aware of any change(s)/revision(s) to the drawing(s) or part number(s) in this solicitation which have been approved by the

Government for implementation. Notification of part number changes shall be supported by data which indicates the type of change, approving authority as required by ANSI EIA 649 MIL-STD-973 and date and method of submittal of provisioning documentation and drawings.

If complete data package has not been previously provided, the contractor shall, at no direct cost to the Government, immediately submit applicable drawings, along with a copy of the approval change authority, to the Contracting Officer, at the office symbol and mailing address listed in the "ISSUED BY" block on page one (1) of this document.