SPRDL120R0085-0003 Solicitation Amendment.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. Contract ID Code Page Of

2. Amendment/Modification No.

3. Effective Date

4. Requisition/Purchase Req No.

5. Project No. (If applicable)

6. Issued By Code 7. Administered By (If other than Item 6) Code

8. Name And Address Of Contractor (No., Street, City, County, State and Zip Code)

9A. Amendment Of Solicitation No.

9B. Dated (See Item 11)

10A. Modification Of Contract/Order No.

10B. Dated (See Item 13) Code Facility Code

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing items 8 and 15, and returning ____________ copies of the amendments: (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. Accounting And Appropriation Data (If required)

13. THIS ITEM ONLY APPLIES TO MODIFICATIONS OF CONTRACTS/ORDERS

It Modifies The Contract/Order No. As Described In Item 14.

A. This Change Order is Issued Pursuant To: The Changes Set Forth In Item 14 Are Made In

The Contract/Order No. In Item 10A.

B. The Above Numbered Contract/Order Is Modified To Reflect The Administrative Changes (such as changes in paying office, appropriation data, etc.) Set

Forth In Item 14, Pursuant To The Authority of FAR 43.103(b).

C. This Supplemental Agreement Is Entered Into Pursuant To Authority Of:

D. Other (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return _______________ copies to the Issuing Office.

14. Description Of Amendment/Modification (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. Name And Title Of Signer (Type or print)

16A. Name And Title Of Contracting Officer (Type or print)

15B. Contractor/Offeror 15C. Date Signed 16B. United States Of America 16C. Date Signed

By (Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070

PREVIOUS EDITIONS UNUSABLE

30-105-02 STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

SEE SCHEDULE

X

Firm Fixed Price

0003 2020FEB27

SPRDL1

DLA LAND WARREN

WARREN, MI 48397-5000

DRAKE MARTINEZ

EMAIL: DRAKE.G.MARTINEZ.CIV@MAIL.MIL

SPRDL1-20-R-0085

2020JAN29

X

X 2020MAR12 05:00pm

/SIGNED/

2 signed

SEE SECOND PAGE FOR DESCRIPTION

1 5

CONTINUATION SHEET

Reference No. of Document Being Continued Page of

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION A - SUPPLEMENTAL INFORMATION

Buyer Name: DRAKE MARTINEZ

Buyer Office Symbol/Telephone Number: ZGBC/(586)467-1249

Type of Contract 1: Firm Fixed Price

Kind of Contract: Supply Contracts and Priced Orders

*** End of Narrative A0000 ***

1. The purpose of this Amendment 0003 to solicitation SPRDL1-20-R-0085 is to provide information in Narrative E.4g, First Article

Testing (Contractor Testing).

2. Any questions concerning this amendment should be directed to the Contracting Specialist.

3. All other terms and conditions of the solicitation remain the same.

*** END OF NARRATIVE A0006 ***

E.4 First Article Test (Contractor Testing)___________________________________________

a. The first article shall be examined and tested in accordance with contract requirements, the item specification(s), Quality Assurance

Provisions (QAPs) and all drawings listed in the Technical Data Package.

b. The first article shall be representative of items to be manufactured using the same processes and procedures and at the same facility as contract production. All parts and materials, including packaging and packing, shall be obtained from the same source of supply as will be used during regular production. All components, subassemblies, and assemblies in the first article sample shall have been produced by the Contractor (including subcontractors) using the technical data package applicable to this procurement.

c. The first article shall be inspected and tested by the contractor for all requirements of the drawing(s), the QAPs, and specification(s) referenced thereon, except for:

(1) Inspections and tests contained in material specifications provided that the required inspection and tests have been performed previously and certificates of conformance are submitted with the First Article Test Report.

(2) Inspections and tests for Military Standard (MS) components and parts provided that inspection and tests have been performed previously and certifications for the components and parts are submitted with the First Article Test Report.

(3) Corrosion resistance tests over 10 days in length provided that a test specimen or sample representing the same process has successfully passed the same test within 30 days prior to processing the first article, and results of the tests are submitted with the

First Article Test Report.

(4) Life cycle tests over 10 days in length provided that the same or similar items manufactured using the same processes have successfully passed the same test within 1 year prior to processing the first article and results of the tests are submitted with the

First Article Test Report.

(5) Onetime qualification tests, which are defined as a one-time on the drawing(s), provided that the same or similar item manufactured using the same processes has successfully passed the tests, and results of the test are on file at the contractor's facility and certifications are submitted with the First Article Test Report.

d. Those inspections which are of a destructive nature shall be performed upon additional sample parts selected from the same lot(s) or batch(es) from which the first article was selected.

e. A First Article Test Report shall be compiled by the contractor documenting the results of all inspections and tests (including supplier's and vendor's inspection records and certifications, when applicable). The First Article Test Report shall include actual inspection and test results to include all measurements, recorded test data, and certifications (if applicable) keyed to each drawing, 2 5

SPRDL1-20-R-0085

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

specification and QAP requirement and identified by each individual QAP characteristic, drawing/specification characteristic and unlisted characteristic. Evidence of the QAR's verification will be provided. One copy of the First Article Test Report will be copy furnished to Don Merkel, "mailto:donald.merkle@dla.mil " ; Drake Martinez, "mailto:drake.martinez@dla.mil " ; ____________ __________________ __ e"mailto:mail%20to:%20usarmy.ria.rdecom-ardec.mbx.rdar-qep@mail.mil " ._ _

f. Notwithstanding the provisions for waiver of first article, an additional first article sample or portion thereof, may be ordered by the Contracting Officer in writing when (i) a major change is made to the technical data, (ii) whenever there is a lapse in production for a period in excess of 90 days, or (iii) whenever a change occurs in place of performance, manufacturing process, material used, drawing, specification or source of supply. When conditions (i), (ii), or (iii) above occurs, the Contractor shall notify the

Contracting Officer so that a determination can be made concerning the need for the additional first article sample or portion thereof, and instructions provided concerning the submission, inspection, and notification of results. Costs of the additional first article testing resulting from any of the causes listed herein that were instituted by the contractor and not due to changes directed by the

Government shall be borne by the Contractor.

g. In lieu of a Full FAT and environmental tests, offerors can choose to submit a Partial FAT that should include the following at a______________________________________________________________________________________________________________________________________ minimum: Continuity Testing, Workmanship, Wiring and Dielectric Tests, Insulation Resistance, Certified Crimping, and other fundtional_______________________________________________________________________________________________________________________________________ and performance tests at a minimum. This would be considered a limited testing requirement with the data being sent to the same_________________________________________________________________________________________________________________________________ location as a Full FAT for review and approval. If a Full Fat is not conducted offerors are required to follow instructions in________________________________________________________________________________________________________________________________ narrative L.16, Provisions for Waiver of Required First Article Approval, including submitting a FAT Waiver document.All relevant FAT______________________________________________________________________________________________________________________________________ information should be included in the contractor developed Test and Acceptance Plan._____________________________________________________________________________________

************ End of Narrative E.4 ************

E.12 Notice Regarding First Article Test Sample_______________________________________________

(a) The approved first article items, as described elsewhere in this contract, consist of a quantity of 1 each that will be consumed or ______ destroyed in testing. Any items consumed or destroyed in testing shall not be delivered as part of the contractually required quantity as set forth in the schedule. The cost of any items that are consumed or destroyed shall be included in the overall offer or contract price. A quantity of 2 each that successfully passes all specified tests, less the destructive tests, if any, Shall serve as a ______ _____ manufacturing standard for the remainder of the contract.

(b) A manufacturing standard is an item, which conforms to all technical performance requirements. A manufacturing standard will serve as 1) an aid in identifying configuration changes not controlled by the contractual design. 2) as an aid in identifying any process changes, or 3) as the approved workmanship sample, when required, unless alternate samples are submitted for specific characteristics by the Contractor and approved by the Government.

(c) The manufacturing standard will only be used to supplement contractual acceptance/rejection criteria for those process characteristics that require approved workmanship samples. For other characteristics, if configuration or process changes are identified in production units, the contractor will notify the contracting officer for disposition. Manufacturing items that serve as a manufacturing standard may be delivered as part of the contractual quantity with the last shipment made under this contract provided it meets all contractual requirements existing at time of delivery.

************ End of Narrative E.12 ************

E.18 Inspection and Acceptance Points - Origin______________________________________________

The Government's inspection and acceptance of the supplies offered under this contract/purchase order shall take place at ORIGIN.

Offeror must specify below the exact name, address, and CAGE of the facility where supplies to be furnished under this contract/purchase order will be available for inspection/acceptance.

INSPECTION POINT:

(Name) (CAGE)

(Address) (City) (State) (Zip)

ACCEPTANCE POINT:

3 5

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

(Name) (CAGE)

Address) (City) (State) (Zip)

************ End of Narrative E.18 ************

E.20 Rework and Repair of Nonconforming Material________________________________________________

a. Rework and Repair are defined as follows:

(1) Rework - The reprocessing of nonconforming material to make it conform completely to the drawings, specifications or contract requirements.

(2) Repair - The reprocessing of nonconforming material in accordance with approved written procedures and operations to reduce, but not completely eliminate, the nonconformance. The purpose of repair is to bring nonconforming material into a usable condition. Repair is distinguished from rework in that the item after repair still does not completely conform to all of the applicable drawings, specifications or contract requirements.

b. Rework procedures along with the associated inspection procedures shall be documented by the Contractor and submitted to the

Government Quality Assurance Representative (QAR) for review prior to implementation. Rework procedures are subject to the QAR's disapproval.

c. Repair procedures shall be documented by the Contractor and submitted on a Request for Deviation/Waiver, to the Contracting Officer for review and written approval prior to implementation.

d. Whenever the Contractor submits a repair or rework procedure for Government review, the submission shall also include a description of the cause for the nonconformances and a description of the action taken or to be taken to prevent recurrence.

e. The rework or repair procedure shall also contain a provision for reinspection which will take precedence over the Technical Data

Package requirements and shall, in addition, provide the Government assurance that the reworked or repaired items have met reprocessing requirements.

************ End of Narrative E.20 ************

E.25 Notice Regarding First Article___________________________________

(a) Notwithstanding the provisions for waiver of first article, an additional first article sample (or portion thereof) may be ordered by the Contracting Officer in writing when (i) a major change is made to the technical data, (ii) whenever there is a lapse in production for a period in excess of one year, or (iii) whenever a change occurs in place of performance, manufacturing process, material used, drawing, specification or source of supply.

(b) When any of the conditions above occurs, the Contractor shall notify the Contracting Officer so that a determination can be made concerning the need for the additional first article sample (or portion thereof), and instructions can be provided concerning the submission, inspection, and notification of results.

(c) Costs of any additional testing and inspection resulting from conditions specified above shall be borne by the Contractor, unless the change was directed by the Government. Further, any production delays caused by additional testing and inspection will not be the basis for an excusable delay as defined in the default clause of this contract. Such delays shall not form the basis for adjustment in contract price or delivery schedule.

************ End of Narrative E.25 ************

E.26 Interchangeability of Components_____________________________________

4 5

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

(a) DESIGN CHANGES TO ITEMS NOT UNDER GOV'T DESIGN CONTROL. Once the Government accepts the first production test item, or ______________________________________________________ accepts the first end item you deliver, (whichever comes first) you must not make design changes to any item or part that is not under

Government design control.

(b) WHEN THE POLICY CAN BE WAIVED. The Procuring Contracting Officer (PCO) will consider waiving this policy at your request. If _____________________________ your request reaches the PCO after the first production item test has been performed, then we may conduct another first production test at your expense.

(c) PRODUCTION OR DELIVERY DELAYS. Any production or delivery delays caused by this retesting will not be the basis for: _____________________________

(1) an "excusable delay" as defined in the DEFAULT clause of this contract.

(2) be the basis for an increase in contract price or delivery schedule extension.

************ End of Narrative E.26 ************

E.28 Drawings for Inspection____________________________

(a) When requested, the Contractor shall make available to the Government Inspector the drawings and specifications to which the product was manufactured. Upon completion of product inspection and acceptance by the Government inspector, all drawings and specifications will be returned to the Contractor.

(b) If the Contractor is not the actual manufacturer of the item being procured (i.e. dealer, distributor, etc.), the Contractor shall ensure that subcontractor drawings are available for review to support the Government's inspection requirements.

(c) The Government may rely on the Contractor's Certificate of Conformance, IAW FAR 52.246-15, that the item tendered for acceptance conforms to the contract requirements. However, conditions may warrant that the Contractor be required to make available to the

Government the drawings, specifications, or other technical data such that the Government can determine if the item meets the contract requirements. These conditions may include, but are not limited to, the following: 1) Complex items or items which have quality characteristics for which contractual conformance must be established through precise measurements and functional operation, either as an individual item or in conjunction with other items. 2) Items used in critical applications or items denoted as critical on technical data. 3) Items with known quality conformance issues. 4) Items with an unstable design history. 5) Contractor changes in technical requirements, technical data, and/or production processes which impact the fit, form, or function of the item.

************ End of Narrative E.28 ************

*** END OF NARRATIVE A0005 ***

5 5

SECTION A