SPRDL120R0069.pdf

SOLICITATION, OFFER AND AWARD 1. This Contract Is A Rated Order Under

DPAS (15 CFR 700)

Rating Page of Pages

2. Contract Number 3. Solicitation Number 4. Type of Solicitation 5. Date Issued 6. Requisition/Purchase Number Sealed Bid (IFB)

Negotiated (RFP)

7. Issued By Code 8. Address Offer To (If Other Than Item 7)

NOTE: In sealed bid solicitations ‘offer’ and ‘offeror’ mean ‘bid’ and ‘bidder’.

SOLICITATION

9. Sealed offers in original and copies for furnishing the supplies or services in the Schedule will be received at the place specified in item 8, or if handcarried, in the depository located in until (hour) local time (Date).

Caution - Late Submissions, Modifications, and Withdrawals: See Section L, Provision No. 52.214-7 or 52.215-1. All offers are subject to all terms and conditions contained in this solicitation.

10. For Information A. Name B. Telephone (No Collect Calls) C. E-mail Address

Call: Area Code Number Ext.

11. Table Of Contents

(X) Sec. Description Page(s) (X) Sec. Description Page(s)

Part I - The Schedule Part II - Contract Clauses A Solicitation/Contract Form I Contract Clauses

B Supplies or Services and Prices/Costs Part III - List Of Documents, Exhibits, And Other Attach.

C Description/Specs./Work Statement J List of Attachments D Packaging and Marking Part IV - Representations And Instructions E Inspection and Acceptance K Representations, Certifications, and F Deliveries or Performance Other Statements of Offerors G Contract Administration Data L Instrs., Conds., and Notices to Offerors H Special Contract Requirements M Evaluation Factors for Award

OFFER (Must be fully completed by offeror) NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

12. In compliance with the above, the undersigned agrees, if this offer is accepted within _____ calendar days (60 calendar days unless a different period is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. Discount For Prompt Payment 10 Calendar Days (%) 20 Calendar Days (%) 30 Calendar Days (%) Calendar Days (%) (See Section I, Clause No. 52.232-8)

14. Acknowledgment of Amendments (The offeror acknowledges Amendment No. Date Amendment No. Date receipt of amendments to the SOLICITATION for offerors and related documents numbered and dated):

15A. Name and Code Facility 16. Name and Title of Person Authorized to Sign Offer Address of (Type or Print) Offeror

15B. Telephone Number 15C. Check if Remittance Address is 17. Signature 18. Offer Date Area Code Number Ext. Different From Above – Enter such

Address In Schedule

AWARD (To be completed by Government)

19. Accepted As To Items Numbered 20. Amount 21. Accounting And Appropriation

22. Authority For Using Other Than Full And Open Competition: 23. Submit Invoices To Address Shown In Item

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c)( ) (4 copies unless otherwise specified)

24. Administered By (If other than Item 7) Code 25. Payment Will Be Made By Code

26. Name of Contracting Officer (Type or Print) 27. United States Of America 28. Award Date

(Signature of Contracting Officer)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

AUTHORIZED FOR LOCAL REPRODUCTION Standard Form 33 (Rev. 9-97) Previous edition is unusable Prescribed By GSA-FAR (48 CFR) 53.214(c)

SPRDL1-20-R-0069

X

2020FEB14

2020MAR1605:00pm

DOA4

2020FEB14 SEE SCHEDULE

SPRDL1

DLA LAND WARREN

WARREN, MI 48397-5000

JOEL MAAS

(586)467-1161

ZGAC

JOEL.D.MAAS.CIV@MAIL.MIL

1 65

X 1

X 4 X 10

X 13 X 15 X 18

X 22

X 24

X 25

X 38

X 56

X 64

CONTINUATION SHEET

Reference No. of Document Being Continued Page of

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION A - SUPPLEMENTAL INFORMATION

Buyer Name: JOEL MAAS

Buyer Office Symbol/Telephone Number: ZGAC/(586)467-1161

Type of Contract 1: Firm Fixed Price

Kind of Contract: Supply Contracts and Priced Orders

*** End of Narrative A0000 ***

A.4 Acknowledgment of Amendments

Acknowledge all the amendments you've received from us by identifying the amendment number and its issue date below:

Amendment Number Date

************ End of Narrative A.4 ************

A.6 Notice of Reverse Auction Provision

After receipt of proposals, the contracting officer will determine if a reverse auction will be conducted. However, the use of a reverse auction does not preclude additional methods of price and/or cost analysis.

If a reverse auction is held, Contractors must be registered in the reverse auction system in order to participate in the auction. A dditionally, the Contractor representative participating in the auction must have taken the on-line reverse auction training prior to the reverse auction. Registration, on-line training, and other information regarding the reverse auction can be found at https://dla.procurexinc.com . If a reverse auction is held and a Contractor that provided a proposal to the solicitation does not participate in the auction, the initially proposed price(s) will be considered and evaluated.

************ End of Narrative A.6 ************

A.8 Electronic Contracting Provision

(a) Vendors should be aware that FedBizOpps (FBO) has moved to https://beta.SAM.gov and is now known as Contracting

Opportunities.

(b) All DLA Land Warren solicitations will be publicized on the Contract Opportunities website (https://beta.sam.gov ).

Any additional attachments, including Technical Data Packages (TDPs) when available electronically, will be separate attachments or referenced with instructions in the solicitation.

(c) As directed in Section L of this solicitation, interested vendors shall submit a quote or proposal via email to the

Contract Specialist listed on the solicitation. The email shall include subject header: Proposal Submission SPRDL1-XX-X-XXXX (company name) on the solicitation.

(d) Requirements for tracking solicitations and submitting bid submissions:

1. Vendors must be registered for a beta.sam.gov account through https://login.gov in order to manage searches and track solicitations. Using the Contract Opportunities search function in beta.sam.gov, vendors will to be able to view the Solicitation and any modifications or amendments made by the Contract Specialist.

2. Vendors may Request Access to controlled documents such as the Technical Data Package (TDP). Interested vendors must request TDPs via email to the Contracting Specialist as directed in Section C of this solicitation.

3. All bids and proposals must be submitted via email to the Contract Specialist on record.

(e) Note to offerors:

Please pay close attention to the solicitation closing date and time as stated on the cover page of this solicitation, local time (EST), for DLA Land

Warren. In accordance with FAR 15.208(a), offerors are responsible for submitting proposals, and any revisions, and modifications, so as to be received by the Government office designated in the solicitation by the time specified.

It is Offeror's responsibility to ensure the proposal/quote is received by the Contract Specialist by the date and time specified on the cover page of this solicitation. In accordance with FAR 15.208, if the proposal/quote was not received at the initial point of entry to the Government infrastructure by the exact date and time specified on the cover page of this solicitation, it will be determined late. Proposal/quote is defined to mean that ALL

2 65

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

volumes or parts required in the solicitation are included in the electronic submission.

Note: There is no "expected" or "target" length of time for proposal submission; size and content may be factors, therefore offerors are strongly cautioned when submitting proposals to allow adequate time for submission.

Solicitations may remain posted on beta.sam.gov after the solicitation closing date. If the response deadline has passed for the solicitation, vendors will need to send any late quotes, if applicable, directly to the Contract Specialist identified on the cover page of this solicitation.

(f) Any awards issued as a result of this solicitation will be distributed electronically. In the event of a

FOIA request for a copy of any award issued as a result of this solicitation, or any subsequent modifications to the contract, the contract and modifications will be released, including the awarded unit price. This is the notice required by Executive Order

12600 (June 23, 1987) of our intention to release unit prices in response to any request under the Freedom of Information Act (FOIA), 5

USC 552. Unit price is defined as the contract price per unit or item purchased as it appears in Section B of the contract and is NOT referring to nor does it include Cost or Pricing data/information. If you object to such release in the base contract or contract modifications, and you intend to submit an offer, notify the contracting officer in writing prior to the closing date identified in this solicitation and include the rationale for your objection consistent with the provisions of FOIA. A release determination will be made based on rationale given.

(g) Questions pertaining to this solicitation should be directed to the Contract Specialist identified on the cover page of this solicitation. For technical assistance in doing business with the Government, and doing business electronically, please visit the Procurement Technical Assistance Center (PTAC) website at https://www.sba.gov/tools/local-assistance/ptac to locate a regional center.

************ End of Narrative A.8 ************

A.9 All or None Provision

Offers in response to this solicitation must be submitted for the total quantity of the items identified in the solicitation.

(1) ONLY ONE AWARD WILL BE MADE AS A RESULT OF THIS SOLICITATION.

(2) OFFERS SUBMITTED FOR LESS THAN THE TOTAL QUANTITIES OF ALL THE ITEMS IN THIS SOLICITATION ARE INELIGIBLE FOR AWARD.

************ End of Narrative A.9 ************

*** END OF NARRATIVE A0001 ***

3 65

PIIN/SIIN

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

SECTION B - SUPPLIES OR SERVICES AND PRICES/COSTS

0001 WIRING HARNESS,BRAN

NSN: 5995-01-642-4322

Mfr CAGE: 19207

Mfr Part Number: 12496624-2

0001AA WIRING HARNESS, BRAN 50 EA $ $ ____________________ ______________ __________________

COMMODITY NAME: WIRING HARNESS,BRAN

CLIN CONTRACT TYPE:

Firm Fixed Price

PRON: EH7C1690EH PRON AMD: 02

AMS CD: SM2B1100000

Description/Specs./Work Statement _________________________________

TOP DRAWING NR: 12496624-2

DATE: 06-SEP-2017

First Article Test is required. Waiver may be authorized; see waiver provision in Section L.

(End of narrative C001)

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

SEE PACKAGING REQUIREMENTS CLAUSE

LEVEL PRESERVATION: Military

LEVEL PACKING: B

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Inspection/Acceptance at origin means that you MUST contact the DCMA to arrange for a Government inspection BEFORE you ship the supplies called out in this order. Failure to have the items inspected and accepted will result in their rejection at the destination. The rejected supplies will be returned to you at your expense.

(End of narrative E001)

Deliveries or Performance _________________________

DOC SUPPL

REL CD MILSTRIP ADDR SIG CD MARK FOR TP CD ______ ________ ______ ______ ________ _____

001 W56HZW7229752Z W562RM J 2

DEL REL CD QUANTITY DAYS AFTER AWARD __________ ______________ ________________

4 65

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

001 50 0510

FOB POINT: Destination

SHIP TO:

(W562RM) SU W0MC ARMY GENERAL SUPPLY

DLA DISTRIBUTION RED RIVER

HIGHWAY 82 WEST

TEXARKANA,TX,75507-5000

5 65

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

0001AB FIRST ARTICLE TEST REPORT 1 LO $ ** NSP ** _________________________ __________________

SERVICE REQUESTED: FIRST ARTICLE TEST REPORT

A FIRST ARTICLE TEST REPORT IS REQUIRED IN ACCORDANCE

WITH THE CLAUSE ENTITLED "FIRST ARTICLE APPROVAL--

CONTRACTOR TESTING",

FAR 52.209-3.

THE PRICE FOR FIRST ARTICLE TESTING IN THE TOTAL

AMOUNT OF $_______________ IS INCLUDED IN THE TOTAL

AMOUNT FOR CLIN 0001AA.

(End of narrative B001)

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

DEL REL CD QUANTITY DAYS AFTER AWARD __________ ______________ ________________

001 1 0270

6 65

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

0002 WIRING HARNESS, BRAN

NSN: 5995-01-642-4322

Mfr CAGE: 19207

Mfr Part Number: 12496624-2

0002AA UNEXERCISED OPTION CLIN 50 EA $ $ _______________________ ______________ __________________

COMMODITY NAME: WIRING HARNESS, BRAN

CLIN CONTRACT TYPE:

Firm Fixed Price

OPTION QUANTITY,

PURSUANT TO THE CLAUSE ENTITLED OPTION FOR

INCREASED QUANTITY --- SEPARATELY PRICED LINE ITEM

(52.217-4001).

The quantity stated for the option CLIN DOES NOT Form a part of the basic contractual quantity. Part or all of it may, however, be added to the contract by exercise of the option clause, at the discretion of the Government.

The failure of the offeror to insert a unit price applicable to the option quantity shall mean that the offeror will supply all or any part of the option, if exercised by the Government, at the basic contract unit price, and the offer will be evaluated for award.

(End of narrative B001)

Description/Specs./Work Statement _________________________________

TOP DRAWING NR: 12496624-2

DATE: 06-SEP-2017

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

SEE PACKAGING REQUIREMENTS CLAUSE

LEVEL PRESERVATION: Military

LEVEL PACKING: B

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Inspection/Acceptance at origin means that you MUST contact the DCMA to arrange for a Government inspection BEFORE you ship the supplies called out in this order. Failure to have the items inspected and accepted will result in their rejection at the destination. The rejected supplies will be returned to you at your expense.

7 65

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

(End of narrative E001)

Deliveries or Performance _________________________

DOC SUPPL

REL CD MILSTRIP ADDR SIG CD MARK FOR TP CD ______ ________ ______ ______ ________ _____

DEL REL CD QUANTITY DAYS AFTER AWARD __________ ______________ ________________

001 50 0210

FOB POINT: Destination

SHIP TO:

(Y00000) SHIPPING INSTRUCTIONS FOR CONSIGNEE

(SHIP-TO) WILL BE FURNISHED PRIOR

TO THE SCHEDULED DELIVERY DATE FOR

ITEMS REQUIRED UNDER THIS

REQUISITION.

8 65

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

9 65

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION C - DESCRIPTION/SPECIFICATIONS/WORK STATEMENT

C.11 Drawing Limitations

(a) The drawings supplied with this contract are not shop or process drawings. They are engineering design drawings. They are adequate to permit manufacture, and:

(1) depict the completed (item(s), and

(2) serve as the basis for inspection of the completed item(s).

(b) These drawings DON'T cover intermediate drawings/specifications or steps in the manufacturing process. As a result, even if you meet all the dimensions and tolerances specified in the engineering design drawing for each individual part, a cumulative unacceptable fit for the contract item could result.

(c) The Contractor is responsible for producing the shop or process drawings needed to cover intermediate steps in the manufacturing process.

(d) The Contractor is responsible for obtaining all specifications and drawings necessary to manufacture the items being solicited in accordance with the TDP including all incorporated specifications and drawings. Delivery delays are not excusable where the contractor asserts that it did not have a specification or drawing and has failed to request, in writing, the specification from either the Contracting Officer or Contract Specialist prior to the solicitation closing date.

(e) If you fail to produce an end item with a cumulative fit that conforms to Government drawings, specifications or other supplemental manufacturing documentation, you'll be responsible for correcting this condition at no additional cost to the Government and no delivery schedule extension.

************ End of Narrative C.11 ************

C.13 Configuration Control Engineering Changes

(a) The contractor may submit Engineering Change Proposal(s) (ECPs) and Request for Variance(s) (RFVs) for the requirements in the Government provided Technical Data Package (TDP). If a Value Engineering Change Proposal(s) (VECPs) clause is included on this contract, VECPs shall be submitted in the same manner as ECPs.

(1) ECPs - The contractor may request a permanent change to the requirements specified in the TDP or any other baseline documentation by submitting an ECP. ECPs shall be submitted to include all NORs necessary to completely define the requested change. Each ECP shall be accompanied with at least one NOR per affected document. The contractor shall not present any production items for acceptance that incorporate any change to the TDP or other baseline documentation until notified by the Government the ECP has been approved and incorporated in the contract.

(i) Page 1 of DD Form 1692 (or equivalent) shall be submitted for all ECPs. Pages 2-7 of DD Form 1692 shall be submitted when required to properly explain all the potential logistics and technical impacts of the proposed change. DD Form

1695 NOR or DD Form 1695-1 Tabulated NOR (or equivalents) shall be submitted to completely describe the desired change on each affected document.

(ii) All ECPs submitted by the contractor will be routine priority unless otherwise justified. If the contractor considers the ECP to be emergency or urgent, they shall include justification within

48 hours of submittal of the ECP.

(2) RFVs - The contractor may request to temporarily depart from a requirement specified in the TDP or any other baseline documentation, by submitting an RFV. RFVs may be submitted either pre-production (formerly known as Request for Deviation (RFD)) or post-production and prior to acceptance by the Government (formerly known as Request for Waiver (RFW)). DD Form 1694 (or equivalent) shall be submitted for all RFVs. The contractor shall not present any production items for acceptance with any nonconformance to the requirements in the TDP or other baseline documentation until notified by the Government the RFV has been approved and incorporated in the contract.

(b) Submission of requested changes - The submission of an ECP or RFV by the Contractor does not affect the required delivery dates specified within the contract, shall not constitute excusable delay in the performance of this Contract by the Contractor or in any way relieve the contractor from compliance with the contract delivery schedule. If a delivery date change is needed, it must be negotiated with the Contracting Officer and documented via modification to the contract. The submission of an ECP and/or RFV by the

Contractor shall not preclude the Government from exercising its rights under any clause of the Contract.

(c) Specifications - Permanent proposed changes to specifications which are part of the TDP or baseline documentation shall be requested with an ECP and NOR (i.e. Specification Change Notices (SCNs) are not required).

(d) Forms If any of the above listed forms are not included with the solicitation or contract, the contractor may locate

10 65

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

forms on the DOD Forms Website (http://www.dtic.mil/whs/directives/forms/ ) or contact the contract specialist listed on page 1 of the solicitation or contract for copies of the forms.

************ End of Narrative C.13 ************

C.1 Use of MIL-STD 1916

The Government will not accept lots whose samples submitted for acceptance contain nonconformances unless appropriately documented and approved by the contracting officer. The contractor shall use MIL-STD-1916, DOD Preferred Methods of Acceptance of Product. Th e Verification Level (VL) shall be VL IV for major characteristics and VL II for minor characteristics. MIL-HDBK-1916 provides guidance on the use of MIL-STD 1916.

************ End of Narrative C.1 ************

C.5 Technical Data Package Information (DoD Safe Site) Version

The following Xd item applies to this solicitation:

[ ] 1. There is no Technical Data Package (TDP) included with this solicitation.

[ x ] 2. This solicitation contains one or more TDPs.

To access the TDP, you will need to send an e-mail request to the Contract Specialist listed on the cover page of this solicitation.

Include the following information in the body of the email:

1. Solicitation Number

2. Contractor Name

3. Data Custodian Name (as stated in the JCP)

4. Data Custodian's Email

5. Cage Code

a. If solicitation is Export Controlled:

(1) TDPs that have an Export Control Warning Notice are subject to the Arms Export Control Act (Title 22, U.S.C., Sec

2751, et.seq.) or the Export Administration Act of 1979, as amended, Title 50, U.S.C, App. 2401 et. seq..

(2) Further dissemination must be in accordance with provisions of DoD Directive 5230.25. This also applies to distribution of the TDP to all SUBCONTRACTORS at every level.

(3) To obtain these TDPs, vendors and contractors must have a current DD 2345, Militarily Critical Technical Data

Agreement on file with Defense Logistics Information Service (DLIS). If you are currently certified, your Marketing Partner

Identification Number (MPIN) will be verified and the TDPs will be provided to you. To obtain certification, go to https://public.logisticsinformationservice.dla.mil/PublicHome/jcp/default.aspx click on documents and follow instructions provided.

Processing time is estimated at six (6) to ten (10) weeks after receipt. The Contract Specialist will provide the export controlled

TDPs once certification is confirmed.

(4) Upon completion of the purposes for which Government Technical Data has been provided, the Contractor is required to destroy all documents, including all reproductions, duplications, or copies thereof as may have been further distributed by the

Contractor. Destruction of this technical data shall be accomplished by: shredding, pulping, burning, or melting any physical copies of the TDP and/or deletion or removal of downloaded TDP files from computer drives and electronic devices, and any copies of those files.

b. Only the Data Custodian listed in the JCP in can be granted access to the Technical Data Package (TDP) for a solicitation. The Data

Custodian MUST be registered for a beta.sam.gov account through https://login.gov . Questions related to registration in https://login.gov should be directed to https://login.gov/help/ . Questions related to accounts in beta.sam.gov should be directed to https://beta.sam.gov/help/ . Vendors are responsible for placing correct information in login.gov and beta.sam.gov accounts.

c. It is strongly suggested that you submit an e-mail request and provide the contract specialist with the completed Use and Non-

Disclosure Agreement at the same time if the solicitation requires both to gain access to view the TDP.

11 65

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

[ ] 3. The Government requires a Use and Non-Disclosure Agreement (NDA) to be signed by an authorized representative of your firm before you are granted access to the technical data. The appropriate Agreement is titled N/A-, and is:

[ ] available by emailing the contract specialist listed on page 1 of this solicitation.

[ ] available as an attachment to this solicitation.

Follow the instructions on the Agreement, and email it to the contract specialist at N/A. If you have any questions/problems viewing the

TDP contact the contract specialist.

************ End of Narrative C.5 ************

C.18 Use of Class 1 Ozone Depleting Substances (CIODS)

(a) Definitions.

(1) Class I and Class II Ozone-Depleting Substances (CIODS) refers to the class of substances identified in Section 602(a) of the Clean Air Act, (42 U.S.C. 7671a(a)), complete list provided at: http://www.epa.gov/ozone/science/ods/index.html .

(2) Directly requires the use of CIODS means that the Government's specification or technical data package, at any tier, explicitly requires the use of any Class I Ozone-Depleting Substance (CIODS) in performance of the contract.

(3) Indirectly requires the use of CIODS means that the Government's specification or technical data package, while not explicitly requiring the use of any CIODS, does require a feature that you can meet or produce only by the use of CIODS.

(b) No CIODS shall be used in meeting the requirements of this contract. If the use of CIODS is required in the performance of this contract, please notify the Contracting Officer immediately in writing.

(c) No Class II Ozone Depleting Substances shall be required in the performance of this contract without government approval. If the use of Class II ODS is required in the performance of this contract, please notify the Contracting Officer immediately in writing

************ End of Narrative C.18 ************

*** END OF NARRATIVE C0001 ***

12 65

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION D - PACKAGING AND MARKING

D.7 Packaging Requirements (Selective Group Packaging Requirements)

(a) Military preservation, packing, and marking for this contract shall be accomplished in accordance with the specific requirements identified below and all the applicable requirements of MIL-STD-2073-1.

(1) LEVEL OF PRESERVATION: Military

(2) LEVEL OF PACKING: B

(3) QUANTITY PER UNIT PACKAGE: 0001

(b) MIL-STD-2073-1, Appendix J establishes and defines codes used in describing military packaging methods and materials. The following codes from Appendix J apply:

(1) Preservation Method Code: 32 (Table j.i. and j.ia.)

(2) Cleaning Procedure Code: 1 (Table j.ii)

(3) Preservative Material Code: 00 (zero) (Table j.iii)

(4) Wrapping Material Code: 00 (zero)Table j.iv)

(5) Cushioning and Dunnage Code: ZZ (Table j.v)

(6) Thickness of Cushioning or Dunnage Code: Z (Table j.vi)

(7) Unit Container Code: ED (Table j.vii)

(8) Intermediate Container Code: 00 (zero)(Table j.vii)

(9) Quantity per Intermediate Container Code: AAA (Appendix J.4.11)

(10) Packing Code: A (Table j.IX and J.IXa)

(11) Special Marking Code: 00 (zero)(Table j.x)

(c) Unitization: Shipments of identical items going to the same destination shall be palletized if they have a total cubic displacement of 50 cubic feet or more unless skids or other forklift handling features are included on the containers. Pa llet loads must be stable, and to the greatest extent possible, provide a level top for ease of stacking. A palletized load shall be of a size to allow for placement of two loads high and wide in a conveyance. The weight capacity of the pallet must be adequate for the load. The preferred pallet is a 40 x 48 inch, 4-way entry pallet although variations may be permitted as dictated by the characteristics of the items being unitized. The load shall be contained in a manner that will permit safe handling during shipment and storage.

(d) Marking:

(1) All unit packages, intermediate packs, exterior shipping containers, and, as applicable, unitized loads shall be marked in accordance with MIL-STD-129, Revision R, including bar coding and Military Shipment Label (MSL). The contractor is responsible for application of special markings as discussed in the Military Standard regardless of whether specified in the contract or not. Special markings include, but are not limited to, Shelf-life markings, structural markings, and transportation special handling markings. The marking of pilferable and sensitive material will not identify the nature of the material. Passive

RFID tagging is required in all contracts that contain DFARS clause 252.211-7006. Contractors must check the solicitation and/or contract for this clause. For details and most recent information, see http://www.acq.osd.mil/log/sci/ait.html for the current DoD Suppliers Passive RFID Information Guide. When an item is assigned Unique Item Identifier (UII) markings as indicated by the inclusion of contract clause DFARS 252.211-7003, refer to the DoD Guide to Uniquely Identifying Items (available at http://dodprocurementtoolbox.com/page/unique- id/tools ) for development of the UII and MIL-STD-129, Revision R for UII package marking requirements. Contractors must verify the RFID and UII clauses cited above are included in this solicitation/contract.

(e) Heat Treatment and Marking of Wood Packaging Materials (WPM):

(1) In accordance with DOD 4140.625-M and the requirements of the International Standards for Phytosanitary Measures 1

5 (ISPM), Regulation of Wood Packaging Material in International Trade, current edition, (hereinafter ISPM 15), the following commercial heat treatment and marking process has been approved by the American Lumber Standards Committee (ALSC) and is required for all Wood

Packaging Material (WPM). Foreign manufacturers shall comply with ISPM 15, and have the WPM heat treatment and marking verified in

13 65

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

accordance with their National Plant Protection Organizations compliance program.

(2) Boxes/pallets and any wood used as inner packaging made of non- manufactured wood shall be heat-treated. All WPM using a conventional steam or dry kiln heat chamber (treatment code for the mark: HT) shall be heat treated to a minimum core temperature of

56 degrees Celsius for a minimum of

30 minutes, and certified by an agency accredited by the ALSC in accordance with Wood Packaging Material Policy and Wood Packaging

Material Enforcement Regulations (see URL: http://www.alsc.org ). WPM heat treated wood using dielectric heating

(treatment code for the mark: DH) shall follow the requirements in ISPM 15, and shall be certified by an agency accredited by the ALSC in accordance with Wood Packaging Material Policy and Wood Packaging Material Enforcement Regulations (see URL: http://www.alsc.org ). The box/pallet manufacturer and the manufacturer of wood used as inner packaging shall ensure the materials used in manufacture can be traced to the original source of heat treatment, and that the original source of the heat treatment obtained the necessary certifications.

(3) Marking. Each box/pallet shall be marked to show the conformance to the International Plant Protection

Convention Standard. The ALSC approved quality mark shall be placed on both ends of the outer packaging, between the end cleats or end battens. Pallet markings shall be applied to the side of the stringer or end of the block on diagonally opposite sides and ends of the pallet and be contrasting and clearly visible. All dunnage used in configuring and/or securing the load shall also comply with ISPM 15 and be marked with an ALSC approved DUNNAGE stamp.

(f) These packaging requirements are intended to provide protection against environmentally induced corrosion and deterioration, physical and mechanical damage, and other forms of degradation during storage, multiple handling, and shipment associated with the military distribution system. The Government encourages contractors to submit requests for changes that will result in savings or improve the packaging. Please submit request for changes in accordance with the RFD clause of the contract. Government reserves the right to require testing to validate alternate industrial preservation methods, materials, blocking, bracing, cushioning, and packing at contractors expense.

(g) Hazardous Materials(as applicable):

(1) Hazardous Materials is defined as a substance or waste which has been determined by the Secretary of Transportation to be capable of posing an unreasonable risk to health, safety, and property when transported in commerce and which has been so designated.

(This includes all items listed as hazardous in Titles 29, 40 and 49 CFR and other applicable modal regulations effective at the time of shipment.)

(2) Packaging and marking for hazardous material shall comply with the requirements herein for the mode of transport and the applicable performance packaging contained in the following documents:

- International Air Transport Association (IATA) Dangerous Goods Regulations

- International Maritime Dangerous Goods Code (IMDG)

- Code of Federal Regulations (CFR) Title 29, Title 40 and Title 49

- Joint Service Regulation AFJMAN24-204(I)/TM38-250/NAVSUPPUB 505/MCO P4030.19(I)/DLAM 4145.3(I) (for military air shipments).

(3) If the shipment originates from outside the continental United States, the shipment shall be prepared in accordance with the United Nations Recommendations on the Transport of Dangerous Goods in a manner acceptable to the Competent Authority of the nation of origin and in accordance with regulations of all applicable carriers.

A Product Material Safety Data Sheets (MSDS) is required to be included with every unit pack and intermediate container and shall be included with the packing list inside the sealed pouch attached to the outside of the package.

SUPPLEMENTAL INSTRUCTIONS: CONFIGURE TO MINIMUM CUBE SUCH THAT KINKING OR DEFORMATION WILL NOT OCCUR. CAP CONNECTORS IN

ACCORDANCE WITH NAS847. CUSHION WIRIMG HARNESS USING A-A-59165 OR PPP-C-1797, THICKNESS AS REQUIRED TO PROTECT THE ITEM AND ELEMENTS OF

THE PACKAGE. USE INNER BOX EC WITHIN BAG BL WITHIN BOX ED AS UNIT CONTAINER.

************ End of Narrative D.7 ************

*** END OF NARRATIVE D0001 ***

14 65

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION E - INSPECTION AND ACCEPTANCE

E.18 Inspection and Acceptance Points - Origin

The Government's inspection and acceptance of the supplies offered under this contract/purchase order shall take place at ORIGIN. O fferor must specify below the exact name, address, and CAGE of the facility where supplies to be furnished under this contract/purchase order will be available for inspection/acceptance.

INSPECTION POINT:

(Name) (CAGE)

(Address)

ACCEPTANCE

POINT: (City) (State) (Zip)

(Name) (CAGE)

Address) (City) (State) (Zip)

************ End of Narrative E.18 ************

E.25 Notice Regarding First Article

(a) Notwithstanding the provisions for waiver of first article, an additional first article sample (or portion thereof) may be ordered by the Contracting Officer in writing when (i) a major change is made to the technical data, (ii) whenever there is a lapse in production for a period in excess of one year, or (iii) whenever a change occurs in place of performance, manufacturing process, material used, drawing, specification or source of supply.

(b) When any of the conditions above occurs, the Contractor shall notify the Contracting Officer so that a determination can be made concerning the need for the additional first article sample (or portion thereof), and instructions can be provided concerning the submission, inspection, and notification of results.

(c) Costs of any additional testing and inspection resulting from conditions specified above shall be borne by the

Contractor, unless the change was directed by the Government. Further, any production delays caused by additional testing and inspection will not be the basis for an excusable delay as defined in the default clause of this contract. Such delays shall not form the basis for adjustment in contract price or delivery schedule.

************ End of Narrative E.25 ************

E.12 Notice Regarding First Article Test Sample

(a) The approved first article items, as described elsewhere in this contract, consist of a quantity of 2 that will be consumed or destroyed in testing. Any items consumed or destroyed in testing shall not be delivered as part of the contractually required quantity as set forth in the schedule. The cost of any items that are consumed or destroyed shall be included in the overall offer or contract price. A quantity of 1 that successfully passes all specified tests, less the destructive tests, if any, shall serve as a manufacturing standard for the remainder of the contract.

(b) A manufacturing standard is an item, which conforms to all technical performance requirements. A manufacturing standard will serve as

1) an aid in identifying configuration changes not controlled by the contractual design. 2) as an aid in identifying any process changes, or 3) as the approved workmanship sample, when required, unless alternate samples are submitted for specific characteristics by the Contractor and approved by the Government.

(c) The manufacturing standard will only be used to supplement contractual acceptance/rejection criteria for those process characteristics that require approved workmanship samples. For other characteristics, if configuration or process changes are identified in production units, the contractor will notify the contracting officer for disposition. Manufacturing items that serve as a manufacturing standard may be delivered as part of the contractual quantity with the last shipment made under this contract provided it meets all contractual requirements existing at time of delivery.

************ End of Narrative E.12 ************

E.13 Inspection and Acceptance First Article Approval

In addition to inspection requirements specified in applicable drawings and/or specifications, the following provisions shall apply to

15 65

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

this contract:

(1) FIRST ARTICLE APPROVAL-CONTRACTOR TESTING: First Article Approval-Contractor Testing shall be performed in accordance with FAT IAW Spec. #12465333

(2) The First Article Test Report (FATR) shall be compiled by the contractor to the contractor's own format. The FATR shall document the results of all inspections and tests (including supplier's and vendor's inspection records and certifications, when applicable). The FATR shall include actual inspections and test results to include all measurements, recorded test data, and certifications (if applicable) keyed to each drawing, specification and Quality Assurance Provision (QAP) requirement and identified by each individual QAP characteristic, drawing/specification characteristic and unlisted characteristic. The FATR shall contain sufficient narrative content, technical data, illustrations or photographic evidence, and an objective determination by the contractor to allow the designated Government representative to determine that the First Article Test was successfully completed.

************ End of Narrative E.13 ************

E.36 Delegation of Authority for First Article Approval

The DCMA Administrative Contracting Officer (ACO) is hereby delegated the authority to approve or disapprove the First Article Test

Report submitted in accordance with this contract (FAR 52.209-3 First Article Testing- Contractor First Article). Any reference to

Contracting Officer(PCO) as it relates to the submission of, and approval/disapproval of the FAT Report shall be deemed to mean the DCMA

ACO. ACO approval will be predicated upon QAR acceptance of the FAT Report. ACO approval authorizes the contractor to proceed with production.

************ End of Narrative E.36 ************

E.25 Notice Regarding First Article

(d) Notwithstanding the provisions for waiver of first article, an additional first article sample (or portion thereof) may be ordered by the Contracting Officer in writing when (i) a major change is made to the technical data, (ii) whenever there is a lapse in production for a period in excess of one year, or (iii) whenever a change occurs in place of performance, manufacturing process, material used, drawing, specification or source of supply.

(e) When any of the conditions above occurs, the Contractor shall notify the Contracting Officer so that a determination can be made concerning the need for the additional first article sample (or portion thereof), and instructions can be provided concerning the submission, inspection, and notification of results.

(f) Costs of any additional testing and inspection resulting from conditions specified above shall be borne by the

Contractor, unless the change was directed by the Government. Further, any production delays caused by additional testing and inspection will not be the basis for an excusable delay as defined in the default clause of this contract. Such delays shall not form the basis for adjustment in contract price or delivery schedule.

************ End of Narrative E.25 ************

E.26 Interchangeability of Components

(g) DESIGN CHANGES TO ITEMS NOT UNDER GOV'T DESIGN CONTROL. Once the Government accepts the first production test item, or accepts the first end item you deliver, (whichever comes first) you must not make design changes to any item or part that is not under Government design control.

(h) WHEN THE POLICY CAN BE WAIVED. The Procuring Contracting Officer (PCO) will consider waiving this policy at your request. If your request reaches the PCO after the first production item test has been performed, then we may conduct another first production test at your expense.

(i) PRODUCTION OR DELIVERY DELAYS. Any production or delivery delays caused by this retesting will not be the basis for:

(1) an "excusable delay" as defined in the DEFAULT clause of this contract.

(2) be the basis for an increase in contract price or delivery schedule extension.

************ End of Narrative E.26 ************

16 65

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

*** END OF NARRATIVE E0001 ***

This document incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at these addresses:

http://farsite.hill.af.mil/ or https://www.acquisition.gov/

If the clause requires additional or unique information, then that information is provided immediately after the clause title.

Regulatory Cite Title Date Regulatory Cite Title Date _______________ ______________________________________________________________________ ____________ _______________ ______________________________________________________________________ ____________

E-1 52.246-2 INSPECTION OF SUPPLIES--FIXED-PRICE AUG/1996

E-2 52.246-16 RESPONSIBILITY FOR SUPPLIES APR/1984

E-3 52.246-11 HIGHER-LEVEL CONTRACT QUALITY REQUIREMENT DEC/2014

(a) The contractor shall comply with the higher-level quality standard(s) listed below.

ISO 9001:2015

(b) The contractor shall include applicable requirements of the higher-level quality standard(s) listed in paragraph (a) of this clause and the requirement to flow down such standards, as applicable, to lower-tier subcontracts in--

(1) Any subcontract for critical and complex items (see 46.203(b) and (c)); or

(2) When the technical requirements of a subcontract require--

(i) Control of such things as design, work operations, in-process control, testing and inspection; or

(ii) Attention to such factors as organization, planning, work instructions, documentation control, and advanced metrology.

(End of clause)

17 65

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION F - DELIVERIES OR PERFORMANCE

F.8 Delivery of Supplies from Foreign Firms to U.S. Port of Entry

This clause applies only to foreign firms when shipments are required to destinations within the Continental United States (CONUS).

(1) The F.O.B. point for this acquisition is DESTINATION. You must arrange and pay for (i) transportation to the U.S. port of entry, (ii) port handling, (iii) customs clearance, and (iv) all transportation from the port of entry to the consignee(s) listed in this solicitation.

(2) Acceptance will be at destination if the awardee is an OCONUS (Outside Continental United States) foreign firm.

(3) Identification of shipment. The Contractor must insure that all shipments be clearly marked in accordance with MIL-STD-

129 and other marking requirements specified in the Schedule. The Duty-Free Entry clauses in this contract contain instructions on the documentation required to accompany the shipment for duty-free entry.

(4) Notification of Shipment. The Contractor shall send electronic notification to the Procuring Contracting Officer (PCO) when shipment is made, which includes the following information:

(i) Mode of transportation, carrier, bill of lading number, customs broker (if any), and estimated time of arrival of materiel at OCONUS port authority

(ii) Mode of transportation, carrier, bill of lading number, and estimated dates for pick-up from CONUS port authority and delivery to final destination.

(5) You assume all responsibility for risk of loss or damage to the supplies until received at the destination. See the clause entitled RESPONSIBILITY FOR SUPPLIES (FAR 52.246-16).

************ End of Narrative F.8 ************

F.1 Delivery Schedule

(a) Delivery under this contract must conform to the required schedule specified below, unless acceleration is acceptable.

(b) DEFINITIONS:

(1) DAYS means the number of days after the date of contract award when you must deliver the stated quantity (QTY) of supplies.

(2) DELIVERY is defined as follows:

FOB Origin - Contractor is required to deliver its shipment as provided in FAR 52.247-29(a)(1)-(4) by the time specified in the individual contract; or

FOB Destination - Contractor is required to deliver its shipment as provided in FAR 52.247-34(a)(1)-(2) by the time specified in the individual contract. The contractor must take into consideration the length of time necessary to deliver its shipment to the destination designated in the contract, to ensure that the item reaches its destination by the time reflected in the contract.

(c) The Government requires delivery to be made according to the following schedule:

(1) GOVERNMENT REQUIRED DELIVERY SCHEDULE WITH FIRST ARTICLE TEST

(FAT)

ITEM NO. QTY WITHIN DAYS AFTER DATE OF

CONTRACT AWARD

0001AA 50 510

0001AB 1 270

0002AA 50 210 (if/when exercised)

(2) GOVERNMENT REQUIRED DELIVERY SCHEDULE IF THERE IS NO FIRST ARTICLE TEST (FAT), OR IF FAT IS WAIVED

ITEM NO. QTY WITHIN DAYS AFTER DATE OF

CONTRACT AWARD

0001AA 50 210

18 65

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

0002AA 50 210 (if/when exercised)

(d) Accelerated delivery schedule is acceptable at no additional cost to the Government.

(e) If an accelerated delivery schedule is not acceptable, the required delivery schedule above will apply. If it is acceptable, you may propose an accelerated delivery schedule at no additional cost; fill in the appropriate information here:

(1) OFFERORS PROPOSED ACCELERATED DELIVERY SCHEDULE WITH FIRST

ARTICLE TEST (FAT)

ITEM NO. QTY WITHIN DAYS AFTER DATE OF

CONTRACT AWARD

(2) OFFERORS PROPOSED ACCELERATED DELIVERY SCHEDULE WITHOUT FIRST

ARTICLE TEST (FAT), or IF FAT IS WAIVED

ITEM NO. QTY WITHIN DAYS AFTER DATE OF

CONTRACT AWARD

************ End of Narrative F.1 ************

F.5 DEPOT ADDRESS FOR THE APPLICABLE MODE OF SHIPMENTS: IN-THE-CLEAR ADDRESSES

Rail/ Motor SPLC*: 206721 and 209405 MILSTRIP Address Code: W2561U

Rail Ship to: Transportation Officer

Defense Dist. Depot Susquehanna

New Cumberland, PA

Motor Ship to: Transportation Officer

Defense Dist. Depot Susquehanna

New Cumberland, PA

Parcel Post Mail to: Transportation Officer

Defense Dist. Depot Susquehanna

New Cumberland, PA 17070-5001

NOTE: All deliveries to New Cumberland MUST be scheduled at least 10 days prior to the delivery date. The carrier or contractor must call the New Cumberland DDSP customer service number, 800-307-8496 and provide the following information: contract number, item name, National Stock Number, total weight and cube, and vendor. All shipments to this MILSTRIP address code (W25G1U) are for mission stock and they will need to know that as well, but if you have instructions from the Contracting Officer to use MILSTRIP address code W25N14 instead, you must inform the appointment-taker that the delivery is for Consolidation and Containerization Point

(CCP) stock.

Appointments for FOB Origin shipments should be coordinated with DCMA Transportation.

Rail/ Motor SPLC*: 875670 and 875675 MILSTRIP Address Code: W62G2T

Rail Ship to: Transportation Officer

XU Def Dist. Depot San Joaquin

2600 S. Chrisman Rd. Rec Whse 10

Tracy, CA 95376-5000

Motor Ship to: Transportation Officer

XU Def Dist. Depot San Joaquin

2600 S. Chrisman Rd. Rec Whse 10

Tracy, CA 95376-5000

19 65

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

Parcel Post Mail to: Transportation Officer

Dist. Depot San Joaquin

P.O. Box 96001 Stockton, CA 95296-0130

Rail/ Motor SPLC*: 471995 and 471996 MILSTRIP Address Code: W31G1Z

Rail Ship to: Transportation Officer

Anniston Army Depot Bynum, AL

Motor Ship to: Transportation Officer

Anniston Army Depot Bynum, AL

Parcel Post Mail to: Transportation Officer

Anniston Army Depot Bynum, AL 36201-5021

Rail/ Motor SPLC*: 209741 and 209770 MILSTRIP Address Code: W25G1R

Rail Ship to: Transportation Officer

Letterkenny Army Depot Culbertson, PA

Motor Ship to: Transportation Officer

Letterkenny Army Depot Chambersburg, PA

Parcel Post Mail to: Transportation Officer

Letterkenny Army Depot Chambersburg, PA 17201-4150

Rail/ Motor SPLC*: 661136 and 661157 MILSTRIP Address Code: W45G19 and W562RM

Rail Ship to: Transportation Officer

Red River Army Depot Defense, TX

Motor Ship to: Transportation Officer

Red River Army Depot Texarkana, TX

Parcel Post Mail to: Transportation Officer

Red River Army Depot Texarkana, TX 75507-5000

NOTE: Drivers must schedule an appointment for delivery at least 24 hours in advance. Deliveries will be scheduled for Monday-Friday, 0700-1300. E-mail or fax the PCO at CML (903)334-2208 or CML (903)334-2881. POC's are available Monday-Saturday, 0700-1730 with the exception of government holidays. For directions, please call CML (903)334-3060.