SPRDL119R0164.pdf

SOLICITATION, OFFER AND AWARD 1. This Contract Is A Rated Order Under

DPAS (15 CFR 700)

Rating Page of Pages

2. Contract Number 3. Solicitation Number 4. Type of Solicitation 5. Date Issued 6. Requisition/Purchase Number Sealed Bid (IFB)

Negotiated (RFP)

7. Issued By Code 8. Address Offer To (If Other Than Item 7)

NOTE: In sealed bid solicitations ‘offer’ and ‘offeror’ mean ‘bid’ and ‘bidder’.

SOLICITATION

9. Sealed offers in original and copies for furnishing the supplies or services in the Schedule will be received at the place specified in item 8, or if handcarried, in the depository located in until (hour) local time (Date).

Caution - Late Submissions, Modifications, and Withdrawals: See Section L, Provision No. 52.214-7 or 52.215-1. All offers are subject to all terms and conditions contained in this solicitation.

10. For Information A. Name B. Telephone (No Collect Calls) C. E-mail Address

Call: Area Code Number Ext.

11. Table Of Contents

(X) Sec. Description Page(s) (X) Sec. Description Page(s)

Part I - The Schedule Part II - Contract Clauses A Solicitation/Contract Form I Contract Clauses

B Supplies or Services and Prices/Costs Part III - List Of Documents, Exhibits, And Other Attach.

C Description/Specs./Work Statement J List of Attachments D Packaging and Marking Part IV - Representations And Instructions E Inspection and Acceptance K Representations, Certifications, and F Deliveries or Performance Other Statements of Offerors G Contract Administration Data L Instrs., Conds., and Notices to Offerors H Special Contract Requirements M Evaluation Factors for Award

OFFER (Must be fully completed by offeror) NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

12. In compliance with the above, the undersigned agrees, if this offer is accepted within _____ calendar days (60 calendar days unless a different period is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. Discount For Prompt Payment 10 Calendar Days (%) 20 Calendar Days (%) 30 Calendar Days (%) Calendar Days (%) (See Section I, Clause No. 52.232-8)

14. Acknowledgment of Amendments (The offeror acknowledges Amendment No. Date Amendment No. Date receipt of amendments to the SOLICITATION for offerors and related documents numbered and dated):

15A. Name and Code Facility 16. Name and Title of Person Authorized to Sign Offer Address of (Type or Print) Offeror

15B. Telephone Number 15C. Check if Remittance Address is 17. Signature 18. Offer Date Area Code Number Ext. Different From Above – Enter such

Address In Schedule

AWARD (To be completed by Government)

19. Accepted As To Items Numbered 20. Amount 21. Accounting And Appropriation

22. Authority For Using Other Than Full And Open Competition: 23. Submit Invoices To Address Shown In Item

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c)( ) (4 copies unless otherwise specified)

24. Administered By (If other than Item 7) Code 25. Payment Will Be Made By Code

26. Name of Contracting Officer (Type or Print) 27. United States Of America 28. Award Date

(Signature of Contracting Officer)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

AUTHORIZED FOR LOCAL REPRODUCTION Standard Form 33 (Rev. 9-97) Previous edition is unusable Prescribed By GSA-FAR (48 CFR) 53.214(c)

SPRDL1-19-R-0164

X

2019APR16

2019MAY2002:00pm

DOA4

2019APR16 SEE SCHEDULE

SPRDL1

DLA LAND WARREN

WARREN, MI 48397-5000

JOSUE R. SIERRA

(614)692-7017

ZGCT

JOSUE.R.SIERRA.CIV@MAIL.MIL

X 1 25

1 63

X 1

X 5 X 9

X 13 X 16

X 20

X 22

X 23

X 36

X 53

X 62

CONTINUATION SHEET

Reference No. of Document Being Continued Page of

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION A - SUPPLEMENTAL INFORMATION

Buyer Name: JOSUE R. SIERRA

Buyer Office Symbol/Telephone Number: ZGCT/(614)692-7017

Type of Contract 1: Firm Fixed Price

Kind of Contract: Supply Contracts and Priced Orders

*** End of Narrative A0000 ***

Regulatory Cite Title Date Regulatory Cite Title Date _______________ ______________________________________________________________________ ____________ _______________ ______________________________________________________________________ ____________

A-1 52.204-4016 WARREN ELECTRONIC CONTRACTING OCT/2015

(TACOM)

(a) All DLA Land Warren solicitations will be publicized on the Federal Business Opportunities website (fbo.gov). Any additional attachments, including Technical Data Packages (TDPs) when available electronically, will be separate attachments or links embedded in the solicitation.

(b) Unless directed to do otherwise in Section L of this solicitation, vendors are required to submit a quote or proposal via the

Federal Business Opportunities (FBO) system.

(c) Requirements for the online FBO bid submission:

1. Vendors must log into the FBO System to be able to submit electronic responses for opportunities.

2. Vendors must be registered in the System for Award Management (SAM) at (sam.gov) (a Federal Government owned and operated free web site) and have a CAGE Code and CCR Marketing Partner Identification Number (MPIN).

3. Once logged into the FBO System, vendors will be asked to enter basic information and directed to upload one or more files containing the proposal/quote and any additional information as outlined in the solicitation.

4. FBO will send an email to the vendors registered email address confirming the electronic submission.

5. For additional information on submitting electronic bid responses via the FBO system see the FBO Vendor Guide Section 4.3.1

Submitting an Electronic Response (fbo.gov).

(d) Note to offerors:

Please pay close attention to the solicitation closing date and time as stated on the cover page of this solicitation, local time (EST), for DLA Land Warren. In accordance with FAR 15.208(a), offerors are responsible for submitting proposals, and any revisions, and modifications, so as to be received by the Government office designated in the solicitation by the time specified.

It is Offeror's responsibility to ensure the proposal/quote is received by the date and time specified on the cover page of this solicitation. In accordance with FAR 15.208, if the proposal/quote was not received at the initial point of entry to the Government infrastructure (in this case, received through FBO) by the exact date and time specified on the cover page of this solicitation, it will be determined late. Proposal/quote is defined to mean that ALL volumes or parts required in the solicitation are included in the electronic submission.

Note: There is no "expected" or "target" length of time for proposal submission; size and content may be factors, therefore offerors are strongly cautioned when submitting proposals to allow adequate time for submission.

Solicitations may remain posted on the FBO after the solicitation closing date. If the response deadline has passed for the solicitation, vendors will no longer be able to submit electronic responses. In this case, send any late quotes, if applicable, directly to the contract specialist identified on the cover page of this solicitation.

(e) Any award issued as a result of this solicitation will be distributed electronically. In the event of a FOIA request for a copy of any award issued as a result of this solicitation, or any subsequent modifications to the contract, the contract and modifications will be released, including the awarded unit price. This is the notice required by Executive Order 12600 (June 23, 1987) of our intention to release unit prices in response to any request under the Freedom of Information Act (FOIA), 5 USC 552. Unit price is defined as the contract price per unit or item purchased as it appears in Section B of the contract and is NOT referring to nor does it include Cost or

Pricing data/information. If you object to such release in the base contract or contract modifications, and you intend to submit an offer, notify the contracting officer in writing prior to the closing date identified in this solicitation and include the rationale for your objection consistent with the provisions of FOIA. A release determination will be made based on rationale given.

2 63

SPRDL1-19-R-0164 REPRINT

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

(f) Questions pertaining to this solicitation should be directed to the Contract Specialist identified on the cover page of this solicitation. For technical assistance in doing business with the Government, and doing business electronically, please visit the

Procurement Technical Assistance Center (PTAC) website at ahttps://www.sba.gov/tools/local-assistance/ptac to locate a regional center.

[End of Provision]

A-2 52.214-4003 ALL OR NONE MAR/1998

(TACOM)

Offers in response to this solicitation must be submitted for the total quantity of the items identified in the solicitation.

(1) ONLY ONE AWARD WILL BE MADE AS A RESULT OF THIS SOLICITATION.

(2) OFFERS SUBMITTED FOR LESS THAN THE TOTAL QUANTITIES OF ALL THE ITEMS IN THIS SOLICITATION ARE INELIGIBLE FOR AWARD.

[End of clause]

A-3 52.215-4000 ACKNOWLEDGMENT OF AMENDMENTS OCT/1993

Acknowledge all the amendments you've received from us by identifying the amendment number and its issue date below:

Amendment Number Date

(End of Provision)

A-4 52.215-4801 NOTICE OF REVERSE AUCTION PROVISION JAN/2014

(DLA LAND-

WARREN)

This solicitation contains standard DLA Land Warren provision 52.215-9023, Reverse Auction. After receipt of proposals, the contracting officer will determine if a reverse auction will be conducted. However, the use of a reverse auction does not preclude additional methods of price and/or cost analysis.

If a reverse auction is held, Contractors must be registered in the reverse auction system in order to participate in the auction.

Additionally, the Contractor representative participating in the auction must have taken the on-line reverse auction training prior to the reverse auction. Registration, on-line training, and other information regarding the reverse auction can be found at . If a reverse auction is held and a Contractor that provided a proposal to the solicitation does not participate in the auction, the initially proposed price(s) will be considered and evaluated.

3 63

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

[End of Provision]

4 63

PIIN/SIIN

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

SECTION B - SUPPLIES OR SERVICES AND PRICES/COSTS

0001 ARM ASSEMBLY,PIVOT,

NSN: 2530-01-647-0913

Mfr CAGE: 19207

Mfr Part Number: 12577924-2

This Procurement is a Total Small Business Set-Aside.

(End of narrative A001)

0001AA Production Quantity 48 EA $ $ ____________________ ______________ __________________

COMMODITY NAME: ARM ASSEMBLY,PIVOT,

CLIN CONTRACT TYPE:

Firm Fixed Price

PRON: EH66E632EH PRON AMD: 01

First Article Test is required. Waiver may be authorized; see waiver provision in Section L.

(End of narrative C001)

Packaging and Marking _____________________

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Inspection/Acceptance at origin means that you MUST contact the DCMA to arrange for a Government inspection BEFORE you ship the supplies called out in this order. Failure to have the items inspected and accepted will result in their rejection at the destination. The rejected supplies will be returned to you at your expense.

(End of narrative E001)

Deliveries or Performance _________________________

DOC SUPPL

REL CD MILSTRIP ADDR SIG CD MARK FOR TP CD ______ ________ ______ ______ ________ _____

001 W56HZW6195Z638 W25G1U J 2

DEL REL CD QUANTITY DAYS AFTER AWARD __________ ______________ ________________

001 48 0270

5 63

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

FOB POINT: Origin

SHIP TO:

(W25G1U) SU W1A8 DLA DISTRIBUTION

DDSP NEW CUMBERLAND FACILITY

2001 NORMANDY DRIVE DOOR 113 TO 134

NEW CUMBERLAND,PA,17070-5002

6 63

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

0001AB First Article Quantity 1 EA $ $ ______________________ ______________ __________________

COMMODITY NAME: FIRST ARTICLE TEST AND REPORT

A FIRST ARTICLE TEST REPORT IS REQUIRED IN ACCORDANCE

WITH THE CLAUSE ENTITLED "FIRST ARTICLE APPROVAL--

CONTRACTOR TESTING",

FAR 52.209-3.

THE PRICE FOR FIRST ARTICLE TESTING IN THE TOTAL

AMOUNT OF $_______________ IS INCLUDED IN THE TOTAL

AMOUNT FOR CLIN XXXXXX.

(End of narrative B001)

Packaging and Marking _____________________

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Government Approval/Disapproval Days: 60

Deliveries or Performance _________________________

DOC SUPPL

REL CD MILSTRIP ADDR SIG CD MARK FOR TP CD ______ ________ ______ ______ ________ _____

DEL REL CD QUANTITY DAYS AFTER AWARD __________ ______________ ________________

001 1 0160

FOB POINT: Origin

SHIP TO:

(Y00000) SHIPPING INSTRUCTIONS FOR CONSIGNEE

(SHIP-TO) WILL BE FURNISHED PRIOR

TO THE SCHEDULED DELIVERY DATE FOR

ITEMS REQUIRED UNDER THIS

REQUISITION.

7 63

Page of

Name of Offeror or Contractor:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Reference No. of Document Being Continued

MOD/AMD

0002 ARM, ASSEMBLY, PIVOT

NSN: 2530-01-647-0913

Mfr CAGE: 19207

Mfr Part Number: 12577924-2

0002AA UNEXERCISED OPTION QUANTITY 48 EA $ $ ___________________________ ______________ __________________

COMMODITY NAME: ARM, ASSEMBLY, PIVOT

CLIN CONTRACT TYPE:

Firm Fixed Price

OPTION QUANTITY,

PURSUANT TO THE CLAUSE ENTITLED OPTION FOR

INCREASED QUANTITY --- SEPARATELY PRICED LINE ITEM

(52.217-4001).

The quantity stated for the option CLIN DOES NOT Form a part of the basic contractual quantity. Part or all of it may, however, be added to the contract by exercise of the option clause, at the discretion of the Government.

(End of narrative B001)

Packaging and Marking _____________________

PACKAGING/PACKING/SPECIFICATIONS:

SEE PACKAGING CLAUSE

LEVEL PRESERVATION: Military

LEVEL PACKING: A

Inspection and Acceptance _________________________

INSPECTION: Origin ACCEPTANCE: Origin

Deliveries or Performance _________________________

DOC SUPPL

REL CD MILSTRIP ADDR SIG CD MARK FOR TP CD ______ ________ ______ ______ ________ _____

DEL REL CD QUANTITY DAYS AFTER AWARD __________ ______________ ________________

001 48 0270

FOB POINT: Origin

SHIP TO:

(Y00000) SHIPPING INSTRUCTIONS FOR CONSIGNEE

(SHIP-TO) WILL BE FURNISHED PRIOR

TO THE SCHEDULED DELIVERY DATE FOR

ITEMS REQUIRED UNDER THIS

REQUISITION.

8 63

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION C - DESCRIPTION/SPECIFICATIONS/WORK STATEMENT

Regulatory Cite Title Date Regulatory Cite Title Date _______________ ______________________________________________________________________ ____________ _______________ ______________________________________________________________________ ____________

C-1 52.211-4072 TECHNICAL DATA PACKAGE INFORMATION SEP/2015

(TACOM)

The following Xd item applies to this solicitation:

[ ] 1. There is no Technical Data Package (TDP) included with this solicitation.

[ ] 2. This solicitation contains one or more web-located TDPs. If multiple Contract Line Item Numbers (CLINS) are listed below, each one will have its own URL just under the CLIN listing. The URL will take you to that CLINs Web-located TDP. To access the TDP, you will have to copy or type the links URL to your web browser address bar at the top of the screen.

Note: To copy a link from a .pdf file, click on the Text Select Tool, then highlight the URL, copy and paste it into your browser, and hit the Enter key.

CLIN: -1-

TDP Link (URL): -2-

[X] 3. The TDP for this solicitation resides within FedBizOpps (), and is associated with this solicitation number and can be accessed via this URL:

https://www.fbo.gov/fedteds/SPRDL119R0164

a. Log on to the FBO web site.

b. Enter your Marketing Partner Identification Number (MPIN).

c. Search for the solicitation number.

d. If solicitation is Export Controlled, select Verify MPIN.

(1) TDPs that have an Export Control Warning Notice are subject to the Arms Export Control Act (Title 22, U.S.C., Sec 2751, et.seq.)

or the Export Administration Act of 1979, as amended, Title 50, U.S.C, App. 2401 et. seq..

(2) Further dissemination must be in accordance with provisions of DoD Directive 5230.25. This also applies to distribution of the TDP to all SUBCONTRACTORS at every level.

(3) To obtain these TDPs, vendors and contractors must have a current DD 2345, Militarily Critical Technical Data Agreement on file with Defense Logistics Information Service (DLIS). If you are currently certified, your MPIN will be verified and you may proceed to the next step. To obtain certification, go to htt ps://public.logisticsinformationservice.dla.mil/PublicHome/jcp/default.aspx click on documents and follow instructions provided. Processing time is estimated at six (6) to ten (10) weeks after receipt. FBO will allow you to access export controlled TDPs once certification is confirmed.

(4) Upon completion of the purposes for which Government Technical Data has been provided, the Contractor is required to destroy all documents, including all reproductions, duplications, or copies thereof as may have been further distributed by the Contractor.

Destruction of this technical data shall be accomplished by: shredding, pulping, burning, or melting any physical copies of the TDP and/or deletion or removal of downloaded TDP files from computer drives and electronic devices, and any copies of those files.

e. If technical data is otherwise restricted, select Request Explicit Access. This will generate an email to the FBO system administrator at TACOM Warren with all the information needed for them to grant you access. FBO will subsequently automatically generate an email stating when you have permission to view or download TDP items. Allow 2 3 working days to complete this FBO-TDP access/approval process through the FBO system.

f. If multiple individuals in your company need access to the Technical Data Package (TDP) for a solicitation and an explicit access request is required, each individual MUST submit an explicit access request to be granted approval to view the TDP. Those same individuals MUST be registered in Federal Business Opportunities (FBO). Any individuals no longer with the company should be deleted.

Questions related to registration in FBO should be directed to The FBO helpdesk phone number is (866) 606-8220. Vendors are responsible for placing correct information in FBO.

9 63

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

g. It is strongly suggested that you submit the explicit access request and provide the contract specialist with the completed Use and

Non-Disclosure Agreement at the same time if the solicitation requires both to gain access to view the TDP.

h. A user guide for FBO can be found at - on the right is User Guides - click on Vendor.

[ ] 4. The Government requires a Use and Non-Disclosure Agreement (NDA) to be signed by an authorized representative of your firm before you are granted access to the technical data. The appropriate Agreement is titled -4-, and is:

[ ] available by emailing the contract specialist listed on page 1 of this solicitation.

[ ] available as an attachment to this solicitation.

Follow the instructions on the Agreement, and email/fax it to the contract specialist at -5-. The contract specialist will notify the

FBO administrator upon receiving the NDA. The administrator will grant approval to view/download the TDP. An email stating approval has been granted will be sent to the vendor. It can take up to 24 hours after approval before you are able to view the TDP. If you have any questions/problems viewing the TDP contact the contract specialist.

[End of Clause]

C-2 52.246-4053 USE OF MIL-STD 1916 JAN/2001

(TACOM)

The Government will not accept lots whose samples submitted for acceptance contain nonconformances unless appropriately documented and approved by the contracting officer. The contractor shall use MIL-STD-1916, DOD Preferred Methods of Acceptance of Product. The

Verification Level (VL) shall be VL IV for major characteristics and VL II for minor characteristics. MIL-HDBK-1916 provides guidance on the use of MIL-STD 1916.

[End of Clause]

C-3 52.211-4008 DRAWING LIMITATIONS NOV/2005

(TACOM)

(a) The drawings supplied with this contract are not shop or process drawings. They are engineering design drawings. They are ___ adequate to permit manufacture, and:

(1) depict the completed (item(s), and

(2) serve as the basis for inspection of the completed item(s).

(b) These drawings DON'T cover intermediate drawings/specifications or steps in the manufacturing process. As a result, even if you meet all the dimensions and tolerances specified in the engineering design drawing for each individual part, a cumulative unacceptable fit for the contract item could result.

(c) The Contractor is responsible for producing the shop or process drawings needed to cover intermediate steps in the _____________________________ manufacturing process.

(d) The Contractor is responsible for obtaining all specifications and drawings necessary to manufacture the items being solicited _____________________________ in accordance with the TDP including all incorporated specifications and drawings. Delivery delays are not excusable where the contractor asserts that it did not have a specification or drawing and has failed to request, in writing, the specification from either the Contracting Officer or Contract Specialist prior to the solicitation closing date.

(e) If you fail to produce an end item with a cumulative fit that conforms to Government drawings, specifications or other supplemental manufacturing documentation, you'll be responsible for correcting this condition at no additional cost to the Government and no delivery schedule extension.

[End of clause]

10 63

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

C-4 52.211-4011 ACQUISITION OF MANUFACTURER'S PART NUMBER: COMPONENTS FEB/1998

(TACOM)

One or more of the drawings for part of the contract item set forth in the Schedule and in the Technical Data Package specify manufacturer's part numbers. Since complete Government technical data for such part or parts are not available, it is understood that the Contractor, by accepting this contract, agrees to furnish only the listed manufacturer's part number(s) for those components of the contract item, except as provided in the provision entitled NOTICE REGARDING "SOURCE-CONTROLLED" COMPONENTS. (In Section L or near the end of this solicitation.) It is further understood and agreed that references to manufacturer's part numbers herein shall be deemed to include all changes or revisions thereto which the approved manufacturer has made effective as of the first date of delivery of any of the items under this contract; provided, that no change or revision that affects the interchangeability (ability to be interchanged with ________ previous parts and to match with all mating parts when assembled) of the listed manufacturer's part shall be incorporated into the contract item without the prior written approval of the Procuring Contracting Officer.

[End of Clause]

C-5 52.211-4015 CONFIGURATION CONTROL - ENGINEERING CHANGES JAN/2016

(TACOM/ARDEC)

(a) The contractor may submit Engineering Change Proposal(s) (ECPs) and Request for Variance(s) (RFVs) for the requirements in the

Government provided Technical Data Package (TDP). If a Value Engineering Change Proposal(s) (VECPs) clause is included on this contract, VECPs shall be submitted in the same manner as ECPs.

(1) ECPs - The contractor may request a permanent change to the requirements specified in the TDP or any other baseline documentation by submitting an ECP. ECPs shall be submitted to include all NORs necessary to completely define the requested change. Each ECP shall be accompanied with at least one NOR per affected document. The contractor shall not present any production items for acceptance that incorporate any change to the TDP or other baseline documentation until notified by the Government the ECP has been approved and incorporated in the contract.

(i) Page 1 of DD Form 1692 (or equivalent) shall be submitted for all ECPs. Pages 2-7 of DD Form 1692 shall be submitted when required to properly explain all the potential logistics and technical impacts of the proposed change. DD Form 1695 NOR or DD

Form 1695-1 Tabulated NOR (or equivalents) shall be submitted to completely describe the desired change on each affected document.

(ii) All ECPs submitted by the contractor will be routine priority unless otherwise justified. If the contractor considers the ECP to be emergency or urgent, they shall include justification within 48 hours of submittal of the ECP.

(2) RFVs - The contractor may request to temporarily depart from a requirement specified in the TDP or any other baseline documentation, by submitting an RFV. RFVs may be submitted either pre-production (formerly known as Request for Deviation (RFD)) or post-production and prior to acceptance by the Government (formerly known as Request for Waiver (RFW)). DD Form 1694 (or equivalent) shall be submitted for all RFVs. The contractor shall not present any production items for acceptance with any nonconformance to the requirements in the TDP or other baseline documentation until notified by the Government the RFV has been approved and incorporated in the contract.

(b) Submission of requested changes - The submission of an ECP or RFV by the Contractor does not affect the required delivery dates specified within the contract, shall not constitute excusable delay in the performance of this Contract by the Contractor or in any way relieve the contractor from compliance with the contract delivery schedule. If a delivery date change is needed, it must be negotiated with the Contracting Officer and documented via modification to the contract. The submission of an ECP and/or RFV by the Contractor shall not preclude the Government from exercising its rights under any clause of the Contract.

(c) Specifications - Permanent proposed changes to specifications which are part of the TDP or baseline documentation shall be requested with an ECP and NOR (i.e. Specification Change Notices (SCNs) are not required).

(d) Forms If any of the above listed forms are not included with the solicitation or contract, the contractor may locate froms on the

DOD Forms Website (http://www.dtic.mil/whs/directives/forms/) or contact the contract specialist listed on page 1 of the solicitation or contract for copies of the forms.

(End of clause)

C-6 52.223-4002 USE OF CLASS I OZONE-DEPLETING SUBSTANCES (CIODS) OCT/2008

(TACOM)

(a) Definitions.

11 63

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

(1) Class I and Class II Ozone-Depleting Substances (CIODS) refers to the class of substances identified in Section 602(a) _________________________________________________________ of the Clean Air Act, (42 U.S.C. 7671a(a)), complete list provided at: http://www.epa.gov/ozone/science/ods/index.html.

(2) Directly requires the use of CIODS means that the Government's specification or technical data package, at any tier, __________________________________ explicitly requires the use of any Class I Ozone-Depleting Substance (CIODS) in performance of the contract.

(3) Indirectly requires the use of CIODS means that the Government's specification or technical data package, while not _____________________________________ explicitly requiring the use of any CIODS, does require a feature that you can meet or produce only by the use of CIODS.

(b) No CIODS shall be used in meeting the requirements of this contract. If the use of CIODS is required in the performance of this contract, please notify the Contracting Officer immediately in writing.

(c) No Class II Ozone Depleting Substances shall be required in the performance of this contract without government approval. If the use of Class II ODS is required in the performance of this contract, please notify the Contracting Officer immediately in writing.

[End of Provision]

12 63

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION E - INSPECTION AND ACCEPTANCE

This document incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at these addresses:

http://farsite.hill.af.mil/ or https://www.acquisition.gov/

If the clause requires additional or unique information, then that information is provided immediately after the clause title.

Regulatory Cite Title Date Regulatory Cite Title Date _______________ ______________________________________________________________________ ____________ _______________ ______________________________________________________________________ ____________

E-1 52.246-2 INSPECTION OF SUPPLIES--FIXED-PRICE AUG/1996

E-2 52.246-15 CERTIFICATE OF CONFORMANCE APR/1984

E-3 52.246-16 RESPONSIBILITY FOR SUPPLIES APR/1984

E-4 52.209-4000 NOTICE REGARDING FIRST ARTICLE TEST SAMPLE MAR/2000

(TACOM)

(a) The approved first article items, as described elsewhere in this contract, consist of a quantity of 1 that will be consumed or destroyed in testing. Any items consumed or destroyed in testing shall not be delivered as part of the contractually required quantity as set forth in the schedule. The cost of any items that are consumed or destroyed shall be included in the overall offer or contract price. A quantity of 2 that successfully passes all specified tests, less the destructive tests, if any, will serve as a manufacturing standard for the remainder of the contract.

(b) A manufacturing standard is an item, which conforms to all technical performance requirements. A manufacturing standard will serve as 1) an aid in identifying configuration changes not controlled by the contractual design. 2) as an aid in identifying any process changes, or 3) as the approved workmanship sample, when required, unless alternate samples are submitted for specific characteristics by the Contractor and approved by the Government.

(c) The manufacturing standard will only be used to supplement contractual acceptance/rejection criteria for those process characteristics that require approved workmanship samples. For other characteristics, if configuration or process changes are identified in production units, the contractor will notify the contracting officer for disposition. Manufacturing items that serve as a manufacturing standard may be delivered as part of the contractual quantity with the last shipment made under this contract provided it meets all contractual requirements existing at time of delivery.

E-5 52.209-4333 INSPECTION AND ACCEPTANCE (FIRST ARTICLE APPROVAL) APR/2006

(TACOM)

In addition to inspection requirements specified in applicable drawings and/or specifications, the following provisions shall apply to this contract:

(1) FIRST ARTICLE APPROVAL-CONTRACTOR TESTING: First Article Approval-Contractor Testing shall be performed in accordance with IAW 12577924-2

(2) The First Article Test Report (FATR) shall be compiled by the contractor to the contractor's own format.The FATR shall document the results of all inspections and tests (including supplier's and vendor's inspection records and certifications, when applicable). The FATR shall include actual inspections and test results to include all measurements, recorded test data, and certifications (if applicable) keyed to each drawing, specification and Quality Assurance Provision (QAP) requirement and identified by each individual QAP characteristic, drawing/specification characteristic and unlisted characteristic. The FATR shall contain sufficient narrative content, technical data, illustrations or photographic evidence, and an objective determination by the contractor to allow the designated Government representative to determine that the First Article Test was successfully completed.

[End of Clause]

E-6 52.209-4012 NOTICE REGARDING FIRST ARTICLE APR/2000

(TACOM)

(a) Notwithstanding the provisions for waiver of first article, an additional first article sample (or portion thereof) may be

13 63

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

ordered by the Contracting Officer in writing when (i) a major change is made to the technical data, (ii) whenever there is a lapse in production for a period in excess of one year, or (iii) whenever a change occurs in place of performance, manufacturing process, material used, drawing, specification or source of supply.

(b) When any of the conditions above occurs, the Contractor shall notify the Contracting Officer so that a determination can be made concerning the need for the additional first article sample (or portion thereof), and instructions can be provided concerning the submission, inspection, and notification of results.

(c) Costs of any additional testing and inspection resulting from conditions specified above shall be borne by the Contractor, unless the change was directed by the Government. Further, any production delays caused by additional testing and inspection will not be the basis for an excusable delay as defined in the default clause of this contract. Such delays shall not form the basis for adjustment in contract price or delivery schedule.

[End of Clause]

E-7 52.209-4014 DELEGATION OF AUTHORITY FOR FIRST ARTICLE APPROVAL SEP/2018

(DLA LAND

WARREN)

The DCMA Administrative Contracting Officer (ACO) is hereby delegated the authority to approve or disapprove the First Article Test

Report submitted in accordance with this contract (FAR 52.209-3 First Article Testing- Contractor First Article). Any reference to

Contracting Officer(PCO) as it relates to the submission of, and approval/disapproval of the FAT Report shall be deemed to mean the DCMA

ACO. ACO approval will be predicated upon QAR acceptance of the FAT Report. ACO approval authorizes the contractor to proceed with production.

(END OF CLAUSE)

E-8 52.211-4029 INTERCHANGEABILITY OF COMPONENTS MAY/1994

(TACOM)

(a) DESIGN CHANGES TO ITEMS NOT UNDER GOV'T DESIGN CONTROL. Once the Government accepts the first production test item, or ______________________________________________________ accepts the first end item you deliver, (whichever comes first) you must not make design changes to any item or part that is not under

Government design control.

(b) WHEN THE POLICY CAN BE WAIVED. The Procuring Contracting Officer (PCO) will consider waiving this policy at your request. If _____________________________ your request reaches the PCO after the first production item test has been performed, then we may conduct another first production test at your expense.

(c) PRODUCTION OR DELIVERY DELAYS. Any production or delivery delays caused by this retesting will not be the basis for: _____________________________

(1) an "excusable delay" as defined in the DEFAULT clause of this contract.

(2) be the basis for an increase in contract price or delivery schedule extension.

[End of clause]

E-9 52.246-4028 INSPECTION AND ACCEPTANCE POINTS: ORIGIN NOV/2005

(TACOM)

The Government's inspection and acceptance of the supplies offered under this contract/purchase order shall take place at ORIGIN.

Offeror must specify below the exact name, address, and CAGE of the facility where supplies to be furnished under this contract/purchase order will be available for inspection/acceptance.

INSPECTION POINT: ___________________________________________________________________________

(Name) (CAGE)

(Address) (City) (State) (Zip)

ACCEPTANCE POINT: ____________________________________________________________________________

(Name) (CAGE)

14 63

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

(Address) (City) (State) (Zip)

[End of Clause]

15 63

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION F - DELIVERIES OR PERFORMANCE

This document incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at these addresses:

http://farsite.hill.af.mil/ or https://www.acquisition.gov/

If the clause requires additional or unique information, then that information is provided immediately after the clause title.

Regulatory Cite Title Date Regulatory Cite Title Date _______________ ______________________________________________________________________ ____________ _______________ ______________________________________________________________________ ____________

F-1 52.211-17 DELIVERY OF EXCESS QUANTITIES SEP/1989

F-2 52.242-15 STOP-WORK ORDER AUG/1989

F-3 52.242-17 GOVERNMENT DELAY OF WORK APR/1984

F-4 52.247-29 F.O.B. ORIGIN FEB/2006

F-5 52.247-58 LOADING, BLOCKING, AND BRACING OF FREIGHT CAR SHIPMENTS APR/1984

F-6 52.247-59 F.O.B. ORIGIN--CARLOAD AND TRUCKLOAD SHIPMENTS APR/1984

F-7 52.247-65 F.O.B. ORIGIN, PREPAID FREIGHT--SMALL PACKAGE SHIPMENTS JAN/1991

F-8 52.242-4022 DELIVERY SCHEDULE SEP/2008

(TACOM)

(a) Delivery under this contract must conform to the required schedule specified below, unless acceleration is acceptable.

(b) DEFINITIONS:

(1) DAYS means the number of days after the date of contract award when you must deliver the stated quantity (QTY) of supplies.

(2) DELIVERY is defined as follows:

FOB Origin - Contractor is required to deliver its shipment as provided in FAR 52.247-29(a)(1)-(4) by the time specified in the individual contract; or

FOB Destination - Contractor is required to deliver its shipment as provided in FAR 52.247-34(a)(1)-(2) by the time specified in the individual contract. The contractor must take into consideration the length of time necessary to deliver its shipment to the destination designated in the contract, to ensure that the item reaches its destination by the time reflected in the contract.

(c) The Government requires delivery to be made according to the following schedule:

(1) GOVERNMENT REQUIRED DELIVERY SCHEDULE WITH FIRST ARTICLE TEST (FAT)

ITEM NO. QTY WITHIN DAYS AFTER DATE OF CONTRACT AWARD

0001AA 48 270

0001AB 1 270

(2) GOVERNMENT REQUIRED DELIVERY SCHEDULE IF THERE IS NO FIRST ARTICLE TEST (FAT), OR IF FAT IS WAIVED

ITEM NO. QTY WITHIN DAYS AFTER DATE OF CONTRACT AWARD

0002AA 48 160

(d) Accelerated delivery schedule -5- acceptable.

(e) If an accelerated delivery schedule is not acceptable, the required delivery schedule above will apply. If it is acceptable, you may propose an accelerated delivery schedule at no additional cost; fill in the appropriate information here:

(1) OFFERORS PROPOSED ACCELERATED DELIVERY SCHEDULE WITH FIRST ARTICLE TEST (FAT)

ITEM NO. QTY WITHIN DAYS AFTER DATE OF CONTRACT AWARD

16 63

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

(2) OFFERORS PROPOSED ACCELERATED DELIVERY SCHEDULE WITHOUT FIRST ARTICLE TEST (FAT), or IF FAT IS WAIVED

ITEM NO. QTY WITHIN DAYS AFTER DATE OF CONTRACT AWARD

[End of Clause]

F-9 52.247-4005 SHIPMENT OF SUPPLIES AND DETENTION OF CARRIERS EQUIPMENT AUG/2003

(TACOM)

(a) Unless otherwise directed, shipment items under this contract in following order of priority:

(1) Government/Commercial Bill(s) of Lading or US Postal Services;

(2) Prepaid Commercial Bill(s) of Lading with transportation charges entered as a separate item on the invoice; or

(3) As otherwise instructed when the contract prohibits use of Government funds for transportation costs.

(b) The Contractor will request:

(1) Government Bills of Lading and

(2) Routing and other instructions, including Defense Transportation Regulation (DTR), DOD Regulation 4500.9-R-Part 2 Cargo

Movement, as to the methods of shipment to be followed by the Contractor, or

(c) The Contractor and subcontractor(s) must allow prompt and convenient access of carrier's equipment to loading docks or platforms where the contract items supplies will be loaded. Any charges for detention of carrier's equipment shall be for the account of the Contractor, except when the detention is required or caused by the Government.

[End of Clause]

F-10 52.247-4010 TRANSPORTATION DATA FOR FOB ORIGIN OFFERS FEB/1994

(TACOM)

(a) Provide the following information for us to use in selecting the most favorable mode of shipment. We'll also use this information in our evaluation of transportation costs.

Offeror represents that: ________________________

(1) Facilities for shipping by rail

[ ] are

[ ] are not available at the F.O.B. point(s) stated in this solicitation.

(2) If rail facilities are not available at the F.O.B. point(s), the name and location of the nearest team track is:

(NAME) (LOCATION)

(3) Facilities for shipping by water

[ ] are

[ ] are not

17 63

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

available at the F.O.B. point(s) stated in this solicitation.

(4) Facilities for shipping by motor

[ ] are

[ ] are not available at the F.O.B. point(s) stated in this solicitation.

(5) If there is a Contractor Reimbursable Loading Charge and you didn't include it in the offered unit price in Section B, please indicate it below, per unit:

RAIL: /Unit MOTOR: /Unit WATER: /Unit __________ __________ __________

CAUTION: GIVE THE COST OF REIMBURSABLE LOADING CHARGE (NOT ALREADY IN THE OFFERED UNIT PRICE) ON A PER UNIT BASIS. THE UNIT

OF MEASURE IS AS INDICATED ON THE SCHEDULE PAGE, SECTION B, UNDER THE UNIT COLUMN.

(b) We will consider any charge listed above in the overall transportation evaluation of this solicitation. Unless you fill-in the above information for loading charges, we will consider all costs associated with loading to be included in the item price offered in Section B. These costs include: (i) loading, (ii) blocking, (iii) bracing, (iv) drayage, (v) switching, or (vi) any other service necessary to effect delivery F.O.B. carrier's equipment you've indicated as available and we specify at time of shipment.

(c) If rail facilities aren't available at the designated F.O.B. point(s), rail won't be used unless directed by the

Administrative Contracting Officer (ACO). If the ACO tells you rail facilities will be used, we'll adjust the contract price by adding the loading charge filled in above for transportation to the nearest rail facility.

(d) IF YOU DO NOT FILL IN AN ADDITIONAL CHARGE FOR RAIL SHIPMENT ABOVE, YOU AGREE THAT THE CONTRACT PRICE ALREADY INCLUDES ALL

CHARGES FOR SUCH SHIPMENTS. THEREFORE, SHIPMENT BY RAIL WILL NOT COST US ANY MORE.

[End of Clause]

F-11 52.247-4011 FOB POINT SEP/1978

(TACOM)

Delivery on F.O.B. origin offers will be F.O.B. Carrier's equipment, wharf, or freight station, at the Government's option, at or near:

(1) Contractor's Plant: ______________________________________________________________________________

(City) (State) (ZIP) (County)

(2) Subcontractor's Plant: _______________________________________________________________________________

(City) (State) (ZIP) (County)

[End of Clause]

F-12 52.247-4017 DEPOT ADDRESS FOR THE APPLICABLE MODE OF SHIPMENTS: IN-THE-CLEAR NOV/2009

(TACOM) ADDRESSES

Rail/ MILSTRIP

Motor Address Rail Motor Parcel Post

SPLC* Code Ship To: Ship To: Mail To:______ ________ ________ ________ ___________

206721/ W25G1U Transportation Officer Transportation Officer Transportation Officer

209405 Defense Dist Depot Defense Dist Depot Defense Dist Depot

Susquehanna Susquehanna Susquehanna

New Cumberland, PA New Cumberland, PA New Cumberland, PA 17070-5001

NOTE: All deliveries to New Cumberland MUST be scheduled at least 10 days prior to the delivery date. The carrier or contractor must call the New Cumberland DDSP customer service number, 800-307-8496 and provide the following information: contract number, item name, National Stock Number, total weight and cube, and vendor. All shipments to this MILSTRIP address code (W25G1U) are for mission stock and they will need to know that as well, but if you have instructions from the Contracting Officer to use MILSTRIP address code W25N14 instead, you must inform the appointment-taker that the delivery is for Consolidation and Containerization Point (CCP) stock.

Appointments for FOB Origin shipments should be coordinated with DCMA Transportation.

18 63

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

875670/ W62G2T Transportation Officer Transportation Officer Transportation Officer

875675 XU Def Dist Depot XU Def Dist Depot Dist Depot San Joaquin

San Joaquin San Joaquin P O Box 96001

25600 S Chrisman Rd 25600 S Chrisman Rd Stockton, CA 95296-0130

Rec Whse 10 Rec Whse 10

Tracy, Ca 95376-5000 Tracy, Ca 95376-5000

471995/ W31G1Z Transportation Officer Transportation Officer Transportation Officer

471996 Anniston Army Depot, Anniston Army Depot, Anniston Army Depot, Bynum, AL Bynum, AL Anniston, AL 36201-5021

209741/ W25G1R Transportation Officer Transportation Officer Transportation Officer

209770 Letterkenny Army Depot, Letterkenny Army Depot, Letterkenny Army Depot, Culbertson, PA Chambersburg, PA Chambersburg, PA 17201-4150

661136/ W45G19 Transportation Officer Transportation Officer Transportation Officer

661157 W562RM Red River Army Depot, Red River Army Depot, Red River Army Depot, Defense, TX Texarkana, TX Texarkana, TX 75507-5000

NOTE: Drivers must schedule an appointment for delivery at least 24 hours in advance. Deliveries will be scheduled for Monday-Friday, 0700-1300. E-mail or fax the PCO at CML (903)334-2208 or CML (903)334-2881. POC's are available Monday-Saturday, 0700-1730 with the exception of government holidays. For directions, please call CML (903)334-3060. Trucks enter through the commercial carrier route entrance and report to building 23 Truck Control 30 minutes prior to their scheduled appointment. Carriers that arrive at Truck Control without appointments will be placed at the end of the day's schedule unless there is an earlier opening and will be worked/unloaded as soon as possible.

POCs: ddrt-appt@dla.mil, Randy Cox, CML (903)334-2945, Randy.Cox@dla.mil; Angela Carr, CML (903)334-4950 Angela.Carr@dla.mil; Jane

Haley, CML (903)334-4671 Jane.Haley@dla.mil; Darlene Phelps, CML (903)334-3818 Darlene.Phelps@dla.mil.

764538/ W67G23 Transportation Officer Transportation Officer Transportation Officer

764535 Tooele Army Depot, Tooele Army Depot, Tooele Army Depot, Warner, UT Tooele, UT Tooele, UT 84074-5003

***SPLC indicates Standard Point Locator Code. _ _ _ _

NOTE: The following is applicable only when so specified in an individual order or delivery increment:_____ ____

This requirement is a depot replenishment buy, a portion of which is or may be required to fill Direct Support System (DSS) requisitions. Shipment shall be made, as specified, to one or more of:

New Cumberland Army Depot

Red River Army Depot

Sharpe Army Depot prior to shipments to any other depots as may be designated. When more than one depot is designated for DSS shipments, priority shipments will be made equally to each of the designated destinations.

[End of Clause]

19 63

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION G - CONTRACT ADMINISTRATION DATA

Regulatory Cite Title Date Regulatory Cite Title Date _______________ ______________________________________________________________________ ____________ _______________ ______________________________________________________________________ ____________

G-1 252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS DEC/2018

(a) Definitions. As used in this clause--

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and

Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and

Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov ; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this

Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice

Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the

WAWF home page at https://wawf.eb.mil/ .

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer

Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items--

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

-1-

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

-2-

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) Fast Pay requests are only…