SPRDL118R0088-0002.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. Contract ID Code Page Of

2. Amendment/Modification No.

3. Effective Date

4. Requisition/Purchase Req No.

5. Project No. (If applicable)

6. Issued By Code 7. Administered By (If other than Item 6) Code

8. Name And Address Of Contractor (No., Street, City, County, State and Zip Code)

9A. Amendment Of Solicitation No.

9B. Dated (See Item 11)

10A. Modification Of Contract/Order No.

10B. Dated (See Item 13) Code Facility Code

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing items 8 and 15, and returning ____________ copies of the amendments: (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. Accounting And Appropriation Data (If required)

13. THIS ITEM ONLY APPLIES TO MODIFICATIONS OF CONTRACTS/ORDERS

It Modifies The Contract/Order No. As Described In Item 14.

A. This Change Order is Issued Pursuant To: The Changes Set Forth In Item 14 Are Made In

The Contract/Order No. In Item 10A.

B. The Above Numbered Contract/Order Is Modified To Reflect The Administrative Changes (such as changes in paying office, appropriation data, etc.) Set

Forth In Item 14, Pursuant To The Authority of FAR 43.103(b).

C. This Supplemental Agreement Is Entered Into Pursuant To Authority Of:

D. Other (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return _______________ copies to the Issuing Office.

14. Description Of Amendment/Modification (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. Name And Title Of Signer (Type or print)

16A. Name And Title Of Contracting Officer (Type or print)

15B. Contractor/Offeror 15C. Date Signed 16B. United States Of America 16C. Date Signed

By (Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070

PREVIOUS EDITIONS UNUSABLE

30-105-02 STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

SEE SCHEDULE

X

Firm Fixed Price

0002 2019MAR08

SPRDL1

DLA LAND WARREN

WARREN, MI 48397-5000

ERICA WINSTRAND

EMAIL: ERICA.L.WINSTRAND.CIV@MAIL.MIL

SPRDL1-18-R-0088

2019JAN22

X

X 2019MAR15 05:00pm

/SIGNED/

2 signed

SEE SECOND PAGE FOR DESCRIPTION

1 6

CONTINUATION SHEET

Reference No. of Document Being Continued Page of

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION A - SUPPLEMENTAL INFORMATION

Buyer Name: ERICA WINSTRAND

Buyer Office Symbol/Telephone Number: ZGBA/(586)467-1191

Type of Contract 1: Firm Fixed Price

Kind of Contract: Supply Contracts and Priced Orders

*** End of Narrative A0000 ***

1. The purpose of Amendment 0002 to Solicitation SPRDL1-18-R-0088 is to:

a. Extend the closing date to 15 March 2019

b. Revise the following clauses:

52.209-3 entitled "First Article Approval--Contractor Testing"

52.209-4000 entitled "Notice Regarding First Article Test Sample"

c. Remove clause 52.209-4008, entitled "Caution Concerning The Pricing Of First Article Approval"

d. Add the following clauses:

52.209-4005 entitled "Contract Price Reduction for Waiver of Required First Article Approval"

52.209-4007 entitled "Provision for Waiver of Required First Article Approval"

2. All other terms and conditions set forth in Solicitation SPRDL1-18-R-0088 remain unchanged.

*** END OF NARRATIVE A0002 ***

2 6

SPRDL1-18-R-0088

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION E - INSPECTION AND ACCEPTANCE

Status Regulatory Cite Title Date Status Regulatory Cite Title Date _______ _______________ ______________________________________________________________________ ____________ _______ _______________ ______________________________________________________________________ ____________

E-1 CHANGED 52.209-4000 NOTICE REGARDING FIRST ARTICLE TEST SAMPLE MAR/2000

(TACOM)

(a) The approved first article items, as described elsewhere in this contract, consist of a quantity of 0 that will be consumed or destroyed in testing. Any items consumed or destroyed in testing shall not be delivered as part of the contractually required quantity as set forth in the schedule. The cost of any items that are consumed or destroyed shall be included in the overall offer or contract price. A quantity of 1 that successfully passes all specified tests, less the destructive tests, if any, SHALL serve as a manufacturing standard for the remainder of the contract.

(b) A manufacturing standard is an item, which conforms to all technical performance requirements. A manufacturing standard will serve as 1) an aid in identifying configuration changes not controlled by the contractual design. 2) as an aid in identifying any process changes, or 3) as the approved workmanship sample, when required, unless alternate samples are submitted for specific characteristics by the Contractor and approved by the Government.

(c) The manufacturing standard will only be used to supplement contractual acceptance/rejection criteria for those process characteristics that require approved workmanship samples. For other characteristics, if configuration or process changes are identified in production units, the contractor will notify the contracting officer for disposition. Manufacturing items that serve as a manufacturing standard may be delivered as part of the contractual quantity with the last shipment made under this contract provided it meets all contractual requirements existing at time of delivery.

3 6

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION I - CONTRACT CLAUSES

Status Regulatory Cite Title Date Status Regulatory Cite Title Date _______ _______________ ______________________________________________________________________ ____________ _______ _______________ ______________________________________________________________________ ____________

I-1 CHANGED 52.209-3 FIRST ARTICLE APPROVAL -- CONTRACTOR TESTING (SEP 1989) -- ALTERNATE SEP/1989

I (JAN 1997) AND ALTERNATE II (SEP 1989)

(a) The Contractor shall test 1 unit(s) of Lot/Item CLIN 0001AA as specified in this contract. At least 30 calendar days before the beginning of first article tests, the Contractor shall notify the Contracting Officer, in writing, of the time and location of the testing so that the Government may witness the tests.

(b) The Contractor shall submit the first article test report within 270 calendar days from the date of this contract to the PCO, Jamal

Brooks, jamal.brooks@dla.mil marked First Article Test Report: Contract No. __________________, Lot/Item No. CLIN 0001AB. Within 30 calendar days after the Government receives the test report, the Contracting Officer shall notify the Contractor, in writing, of the conditional approval, approval, or disapproval of the first article. The notice of conditional approval or approval shall not relieve the Contractor from complying with all requirements of the specifications and all other terms and conditions of this contract. A notice of conditional approval shall state any further action required of the Contractor. A notice of disapproval shall cite reasons for the disapproval.

(c) If the first article is disapproved, the Contractor, upon Government request, shall repeat any or all first article tests. After each request for additional tests, the Contractor shall make any necessary changes, modifications, or repairs to the first article or select another first article for testing. All costs related to these tests are to be borne by the Contractor, including any and all costs for additional tests following a disapproval. The Contractor shall then conduct the tests and deliver another report to the

Government under the terms and conditions and within the time specified by the Government. The Government shall take action on this report within the time specified in paragraph (b) above. The Government reserves the right to require an equitable adjustment of the contract price for any extension of the delivery schedule, or for any additional costs to the Government related to these tests.

(d) If the Contractor fails to deliver any first article report on time, or the Contracting Officer disapproves any first article, the

Contractor shall be deemed to have failed to make delivery within the meaning of the Default clause of this contract.

(e) Unless otherwise provided in the contract, and if the approved first article is not consumed or destroyed in testing, the Contractor may deliver the approved first article as part of the contract quantity if it meets all contract requirements for acceptance.

(f) If the Government does not act within the time specified in paragraph (b) or (c) above, the Contracting Officer shall, upon timely written request from the Contractor, equitably adjust under the changes clause of this contract the delivery or performance dates and/or the contract price, and any other contractual term affected by the delay.

(g) Before first article approval, the Contracting Officer may, by written authorization, authorize the Contractor to acquire specific materials or components or to commence production to the extent essential to meet the delivery schedules. Until first article approval is granted, only costs for the first article and costs incurred under this authorization are allocable to this contract for

(1) progress payments, or

(2) termination settlements if the contract is terminated for the convenience of the Government. If first article tests reveal deviations from contract requirements, the Contractor shall, at the location designated by the Government, make the required changes or replace all items produced under this contract at no change in the contract price.

(h) The Government may waive the requirement for first article approval test where supplies identical or similar to those called for in the schedule have been previously furnished by the offeror/contractor and have been accepted by the Government. The offeror/contractor may request a waiver.

(i) The Contractor shall produce both the first article and the production quantity at the same facility.

(End of Clause)

4 6

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION L - INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

Status Regulatory Cite Title Date Status Regulatory Cite Title Date _______ _______________ ______________________________________________________________________ ____________ _______ _______________ ______________________________________________________________________ ____________

L-1 CHANGED 52.209-4005 CONTRACT PRICE REDUCTION FOR WAIVER OF FIRST ARTICLE TEST FEB/1998

(TACOM)

(a) All offerors are required to insert an amount for CLIN 0001AA which includes the full price for First Article testing. ___

(b) In addition, those offerors intending to request a waiver of the First Article Approval requirement, as described elsewhere in this Section L, shall insert the total price for First Article Testing under Item CLIN 0001AB(See Section B of this solicitation). If the successful offeror requests and is granted a waiver, the dollar amount entered for item CLIN 0001AB will be deducted from the total amount cited for CLIN 0001AA. The remaining dollar amount will constitute the price at which award will be made.

[End of Provision]

L-2 ADDED 52.209-4007 PROVISION FOR WAIVER OF REQUIRED FIRST ARTICLE APPROVAL MAY/2006

(TACOM)

(a) The requirement entitled FIRST ARTICLE APPROVAL in Section I of this solicitation may be waived by the Government, provided that the offeror meets the conditions identified below.

(1) Offerors who intend to request a waiver or partial waiver of the First Article Test must provide sufficient information in order for the Government to determine whether the request is to be approved. If the offeror intends to request a waiver, a First Article

Waiver Worksheet must be completed and submitted to the Government along with any supporting documentation. The worksheet can be found as an attachment/exhibit to the solicitation or by contating the contract specialist on page 1.

The offerors request will not be considered if the worksheet and any supporting documentation is not submitted to the Government. The ___ worksheet must be completed in its entirety. For those sections of the worksheet which do not apply, annotate with N/A (not applicable).

To substantiate or clarify information provided by the offeror, the Government may request additional information

(2) Offerors should not assume that the FAT waiver request will be granted even if the completed worksheet and any supporting information is submitted to the Government.

(3) The worksheet and any additional supporting documentation is part of your quote/offer and must be submitted as part of the response to this solicitation on Company letterhead and signed by an agent of the Company.

(4) The offeror may request a waiver for only a portion of the First Article Test, such as a vibration test or a salt water spray test, or the test on a component or subassembly of the procured item.

(5) The offeror shall list specifically on the worksheet, by technical data package reference, that portion of the test requested to be waived. The references shall include but may not be limited to the following as applicable:

(i) Identification of the specification or standard along with the specific specification or standard paragraph(s)

(ii) Identification of the drawing with specific references to the drawing notes.

(iii) Identification of the Quality Assurance Provision (QAP), or Quality Assurance Requirement (QAR) or Supplemental

Quality Assurance Provision (SQAP)with specific references to the specific paragraph.

(6) Supporting documentation.

(i) The request for waiver must be accompanied by documentation in support of the request. The documentation may include information such as the following; (1) Copy of the Administrative Contracting Officers (ACOs) or Procuring Contracting Officers (PCO) letter approving a First Article Test report on a recent contract for the same or similar item. (2) Copy of a First Article Test report for the same or a similar item as that herein solicited. (3) Copy of an ACO or PCO letter approving a prior waiver request. (4) If the waiver request is based on similarity, a copy of the drawing/other appropriate technical requirements of the similar item.

(ii) If a copy of a First Article Test report is submitted in support of a request for waiver under this solicitation, the test report must have been approved and signed by an authorized representative of the Government.

(iii) The FAT report and all supporting documentation should be submitted by electronic media and should accompany the offerors proposal. If the FAT report and supporting documentation cannot be transmitted by electronic media, the offeror shall contact

5 6

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

the PCO for further instruction.

(b) Note that if a waiver is granted to the successful offeror, an accelerated delivery schedule will apply. See Section F.

(c) Note: Cost considerations shall apply for approving a waiver or a portion thereof of a First Article Test.

[End of Provision]

L-3 DELETED 52.209-4008 CAUTION CONCERNING THE PRICING OF FIRST ARTICLE APPROVAL APR/1986

(TACOM)

6 6