SPMYM4-21-Q-0175.pdf

DLA DISTRIBUTION

GOVERNMENT REPRESENTATIVE

RECEIVING DEPT, CODE Z0S

667 SAFEGUARD ST, BLDG 167-1

JBPHH HI 96860-5033

TEL: 808-473-8000 X4961 FAX:

N322531053B855

REQUEST FOR QUOTATIONS

(THIS IS NOT AN ORDER) 1

PAGE OF PAGES

1. REQUEST NO. 2. DATE ISSUED RATING

SPMYM421Q0175 22-Sep-2021 5a. ISSUED BY

8. TO: NAME AND ADDRESS, INCLUDING ZIP CODE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this

Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State, and local taxes)

ITEM NO.

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e) (f)

SEE SCHEDULE

AMOUNT

% No. %

NOTE: Additional provisions and representations [ ] are [ ] are not attached.

13. NAME AND ADDRESS OF QUOTER (Street, City, County, State, and ZIP Code)

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

15. DATE OF

QUOTATION

16. NAME AND TITLE OF SIGNER (Type or print) (Include area code)

TELEPHONE NO.

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 18 (REV. 6-95)

PREVIOUS EDITION NOT USABLE Prescribed by GSA FAR (48 CFR) 53.215-1(a)

THIS RFQ X[ ] IS [ ] IS NOT A SMALL BUSINESS SET-ASIDE

6. DELIVER BY (Date)

SEE SCHEDULE

AND/OR DMS REG. 1

UNDER BDSA REG. 2

4. CERT. FOR NAT. DEF.3. REQUISITION/PURCHASE

REQUEST NO.

DLA MARITIME PEARL HARBOR

ADINA CRAIG

COMPETITIVE SOURCING

667 SAFEGUARD ST.

JBPHH HI 96860-5033

9. DESTINATION (Consignee and address, including ZIP Code)

7. DELIVERY

[ ]X FOB

DESTINATION

[ ] OTHER

(See Schedule)

24-Sep-2021(Date)

PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS:10.

808 473-8000 X7350ADINA M. CRAIG

(Name and Telephone no.) (No collect calls)5b. FOR INFORMATION CALL:

d. CALENDAR DAYSc. 30 CALENDAR DAYSb. 20 CALENDAR DAYS12. DISCOUNT FOR PROMPT PAYMENT a. 10 CALENDAR DAYS

SPMYM421Q0175

Section SF 30 - BLOCK 14 CONTINUATION PAGE

IMPORTANT RFQ INFO

**Trade Agreements apply and the vendor shall list the country of origin for each item**

PURCHASING AGENT: Adina Craig TEL: 808-473-8000 x7350

E-MAIL: adina.craig@dla.mil adina.craig@navy.mil FAX: 808-471-1030

*THIS SOLICICTAION WILL BE EVALUATED BASED ON PRICE, DELIVERY, AND/OR PAST

PERFORMANCE*

THE DOD AND NAVY REQUIRE PAPERLESS DISTRIBUTION OF PURCHASE ORDERS,

CONTRACTS, AND MODIFICATIONS. PLEASE PROVIDE YOUR E-MAIL ADDRESS BELOW:

PLEASE PROVIDE THE FOLLOWING INFORMATION SO YOUR COMPANY CAN BE ENTERED INTO

OUR COMPUTER SYSTEM

CAGE Code (Commercial & Government Entity No.) _____________ DUNS (Dun & Bradstreet) No. _________________________ SAM (System for Award Management) Yes No (circle one)

TAX ID NO. (TIN) _________________________

WITHOUT THE ABOVE INFORMATION AN ORDER MAY NOT BE AWARDED AND YOUR QUOTE

MAY NOT BE FAIRLY EVALUATED. PLEASE CALL 808-473-8000 EXT 5204 WITH ANY

QUESTIONS.

The Contractor shall be registered in the SAM database prior to submitting an invoice and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

The SAM registration shall be for the same name and address identified on the contract, with its associated CAGE code and DUNS or DUNS+4.

Contractors may obtain information on registration and annual confirmation requirements via the SAM accessed through https://www.acquisition.gov or by calling 866-606-8220, or 334-206-7828 for international calls.

Unless otherwise provided in the Schedule, offers may not be submitted for quantities less than those specified. The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit prices offered, unless the offeror specified otherwise in the offer.

THE FOLLOWING INFORMATION MUST BE PROVIDED OR YOUR QUOTE MAY NOT BE

ACCEPTED.

Provide your best delivery schedule:

Estimated delivery to Pearl Harbor days weeks months

Business size (in accordance with Federal Government Standards)

□ Small □ Large □ Woman-Owned □ Disadvantaged □ Other

Prompt Payment Terms_______% _______Days NET ______

If on GSA Contract: [ ] GSA Contract #____________________Expiration Date: ______

IF PRICING IS ON “OR EQUAL” BRAND, PLEASE PROVIDE COPY OF

LITERATURE/SPECIFICATIONS, MAKE AND MODEL OF ITEM BEING OFFERED.

VENDOR SHALL COMPLETE AND RETURN THE FOLLOWING PRICE INFORMATION: PRICES ARE

BASED ON (Check one or more)

(1) [ ] Commercial catalog/published price list number _______________ date_________page________. ATTACH APPLICABLE CATALOG/PRICE LIST PAGE.

Note: If quoted prices exceeds catalog/published price, explain

(2) Unpublished or internal Price List No. ______________

State means of verification:

Prices audited and approved by DCAA/DCASR ______________________ Last audit was on ________________________ (date).

(3) Sales history of this item for at least the last 12 months:

Government Commercial Sales dollar Volume:

Quantity of units sold:

Unite Price:

Contract number:

Award date:

METHOD OF PAYMENT IS GOVERNMENT PURCHASE CARD:

FAR Clause 52.232-36 is applicable to this solicitation. Please note that the Government wide purchase card will be used as the method of payment for supplies and/or services procured under this solicitation. If you are not able to accept payment by credit card, please provide reason(s) below:

METHOD OF PAYMENT IS WIDE AREA WORK FLOW (WAWF)

DFAR Clause 252.232-7003 (MAR 2008) ELECTRONIC SUBMISSION OF PAYMENT REQUEST AND RECEIVING REPORTS is applicable to this solicitation. Please note that the WAWF (Wide Area Work Flow) will be used as the method of payment for supplies and/or services procured under this solicitation. Information regarding WAWF is available on the internet at https://wawf.eb.mil. If you are not able to accept payment by WAWF please provide the reason(s) below:

SHIPPING INFO

**FAILURE TO PROVIDE PROPER CERTIFICATION WILL CAUSE PHNSY/IMF

QA INSPECTION TEAM TO REJECT THE MATERIAL AND DELAY PAYMENT**

INQUIRIES REGARDING PAYMENT OF INVOICES / STATEMENTS MAY BE

DIRECTED TO DFAS CLEVELAND – CUSTOMER SERVICE SECTION @ 1-800-756-4571

OPTION 2, OPTION 4; OR PHNSY/IMF CODE 610.4 FAX: 808-471-5031 OR E-MAIL:

PRLH_PHNS_C630_CONTRACTS@NAVY.MIL

VENDOR TO PACK THE CERTIFICATION IN THE BOXES/PCKS AND ALSO SEND A

COPY TO THE CONTRACTING OFFICER VIA EMAIL adina.craig@dla.mil OR VIA FAX:

808-471-1030

VENDOR TO MARK BOXES/PKGS WITH THE FOLLOWING INFORMATION:

PURCHASE ORDER NO: SPMYM4-21-P-XXXX (ASSIGNED AFTER AWARD)

REQN NO: EACH BOXED/PACKAGE SHOULD BE MARKED WITH THE MILSTIP

OF THE ITEM IN WHICH IS PACKED.

WITHOUT THIS INFORMATION MATERIAL CANNOT BE PROCESSED WHEN

RECEIVED AND WILL INDICATE NON DELIVERY IN PEARL HARBORS SYSTEM.

CONTRACTOR MAY BE PENALIZED FOR LATE DELIVERY.

DLA LAND AND MARYTIME PEARL HARBOR CODE HMD-A POC:

Purchasing Agent: Adina Craig E-mail: adina.craig@dla.mil adina.craig@navy.mil

Tel: 808-473-8000 ext. 7350

FAX: 808-471-1030

ALL MODIFICATION REQUESTS MUST BE IN WRITING & FAXED OR E-MAILED

TO THE BUYER LISTED ABOVE.

The contractor shall be registered in the SAM database prior to submitting an invoice and through final payment of an contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting in the referenced solicitation.

The SAM registration shall be the same name and address identified on the contract, with it associated CAGE code and DUNS or DUNS +4

Contractors may obtain information on registration and annual confirmation requirement via the SAM accessed through https://www.acquisition.gov or by calling 866-606-8220, or 334-206-7828 for international calls.

CLAUSES INCORPORATED BY REFERENCE

252.232-7006 Wide Area WorkFlow Payment Instructions DEC 2018 252.232-7009 Mandatory Payment by Governmentwide Commercial

Purchase Card

MAY 2018

CLAUSES INCORPORATED BY FULL TEXT

52.204-24 REPRESENTATION REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES OR EQUIPMENT (OCT 2020)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in paragraph (c)(1) in the provision at 52.204-26, Covered Telecommunications Equipment or Services-- Representation, or in paragraph (v)(2)(i) of the provision at 52.212-3, Offeror Representations and Certifications- Commercial Items. The Offeror shall not complete the representation in paragraph (d)(2) of this provision if the Offeror has represented that it "does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services" in paragraph (c)(2) of the provision at 52.204-26, or in paragraph (v)(2)(ii) of the provision at 52.212-3.

(a) Definitions. As used in this provision-

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services."

(d) Representations. The Offeror represents that--

(1) It [] will, [] will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds "will" in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that--

It [] does, [] does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds "does" in paragraph (d)(2) of this section.

(e) Disclosures.

(1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded "will" in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded "does" in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(End of provision)

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 125 Reel

POLY FILM, WOVEN FR

FFP

WOVEN POLYOLEFIN FILAMENT, 72" WIDE X 100 FT LONG,

FIRE/FLAME RETARDANT PER NFPA 701 (OR ASTM E-84) W/FR

MARKED ON MATERIAL OR PACKAGING.

TEAR STRENGTH (TONGUE-12LBF/TRAPEZOIDAL-25LBF)

WATERPROOF, WHITE, PACKING PER ASTM 3951

FOB: Destination

NSN: 5640-LL-L19-6591

MILSTRIP: N322531053B855

MFR PART NR: 61005X411FR

PURCHASE REQUEST NUMBER: N322531053B855

PROJECT: 6P1

PSC CD: 5640

NET AMT

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 30-OCT-2021 125 DLA DISTRIBUTION

GOVERNMENT REPRESENTATIVE

RECEIVING DEPT, CODE Z0S

667 SAFEGUARD ST, BLDG 167-1

JBPHH HI 96860-5033

808-473-8000 X4961 FOB: Destination

N32253

Section G - Contract Administration Data

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2016 52.204-13 System for Award Management Maintenance OCT 2016 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-2 Prohibition on Contracting with Inverted Domestic Corporations--Representation

NOV 2015

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.211-5 Material Requirements AUG 2000 52.211-14 Notice Of Priority Rating For National Defense, Emergency

Preparedness, and Energy Program Use

APR 2008

52.211-17 Delivery of Excess Quantities SEP 1989 52.212-1 Instructions to Offerors--Commercial Items JAN 2017 52.212-4 Contract Terms and Conditions--Commercial Items JAN 2017 52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.219-28 Post-Award Small Business Program Rerepresentation JUL 2013 52.222-3 Convict Labor JUN 2003 52.222-19 Child Labor -- Cooperation with Authorities and Remedies OCT 2016 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-50 Combating Trafficking in Persons MAR 2015 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.247-34 F.O.B. Destination NOV 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7004 Alt A System for Award Management Alternate A FEB 2014 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

OCT 2016

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.225-7001 Buy American And Balance Of Payments Program-- Basic (Dec 2016)

DEC 2016

252.225-7002 Qualifying Country Sources As Subcontractors DEC 2016 252.225-7041 Correspondence in English JUN 1997 252.225-7048 Export-Controlled Items JUN 2013 252.227-7015 Technical Data--Commercial Items FEB 2014 252.227-7037 Validation of Restrictive Markings on Technical Data SEP 2016 252.232-7010 Levies on Contract Payments DEC 2006

252.243-7001 Pricing Of Contract Modifications DEC 1991 252.244-7000 Subcontracts for Commercial Items JUN 2013 252.246-7003 Notification of Potential Safety Issues JUN 2013 252.247-7023 Transportation of Supplies by Sea APR 2014

CLAUSES INCORPORATED BY FULL TEXT

CONTRACTOR RETENTION OF TRACEABILITY DOCUMENTATION

(a) This clause applies whenever the Contractor is not the manufacturer of the item(s) to be furnished.

(b)(1) The Contractor shall retain evidence to document that items furnished under this contract conform to contract requirements. Evidence will generally include information tracing the items back to the manufacturing source or its authorized distributor. At a minimum, evidence shall be sufficient to establish the identity of the item, its manufacturing source, and conformance to the item description.

(2) Examples of traceability documentation include, but are not limited to, the following:

(i) Purchase order(s)/invoice(s) between manufacturer(s)/distributor(s), identifying part number (and/or technical data package (TDP) with revision level) and quantities;

(ii) Original equipment manufacturer (OEM) or approved/qualified source’s packing slips, identifying part number (and/or TDP with revision level) and quantities;

(iii) OEM or approved/qualified source’s certification, identifying part number (and/or TDP with revision level) and quantities; and/or

(iv) OEM or approved/qualified source’s identifiable standard packaging, with part number (and/or

TDP with revision level) cited on the package.

(3) The Contractor shall be responsible for the assurance of type, kind, count, and condition. Preservation, packing, packaging, and marking shall be in accordance with contractual requirements.

(4) The Contractor shall provide documentation of traceability for review—

(i) Upon request by the Contracting Officer at any time prior to or after award;

(ii) At time of Government source inspection, if applicable; and/or

(iii) During random or directed post-award audits.

(5) The Contractor shall retain documentation in accordance with this clause for 5 years after final payment under this contract.

c) The Offeror/Contractor shall provide documentation of traceability for review—

(1) Upon request by the Contracting Officer at any time prior to or after award;

(2) At time of Government source inspection, if applicable; and/or

(3) During random or directed post-award audits.

(d) Traceability documentation shall, at a minimum, include the following:

(1) If the Offeror/Contractor is an authorized dealer/distributor for an approved source for the specific item being procured by the Government, the following requirements apply:

(i) The Offeror/Contractor shall maintain at least one of the following:

(A) A copy of its current dealer/distributorship agreement;

(B) A letter of authorization from the approved source; or

(C) A link to an official website maintained by the approved source, which shall clearly identify the Offeror as an authorized dealer/distributor.

(ii) By submission of documentation described in subparagraph (d)(1)(i) of this clause, the Offeror/Contractor represents that:

(A) The dealer/distributor relationship with the approved source applies to the specific item being procured by the Government; and

(B) If the Contractor’s dealer/distributor status with the approved source changes after award, the

Contractor shall promptly notify the Contracting Officer. Failure to provide such notification is grounds for cancellation of award or termination for default/cause, as applicable.

(2) If the Offeror/Contractor is not an authorized dealer/distributor for an approved source for the specific item being procured by the Government, the following requirements apply:

(i) If the Offeror/Contractor identified the offered item as “not in stock/not currently owned by the Offeror" or "not yet manufactured," the Offeror/Contractor shall—

(A) Maintain a verifiable quotation from the approved source, or from an authorized dealer/distributor for the approved source.

(B) Include the following information in its quotation:

(1) The item part number or designation, which shall be provided in sufficient detail to document that the item being quoted is the same as the item being procured by the Government;

(2) The quantity, which shall be sufficient to satisfy the solicitation requirement;

(3) The unit price quoted by the approved source, or by the authorized dealer/distributor for the approved source;

(4) The date of the quotation; and

(5) The name and phone number of the representative of the approved source, or of the authorized dealer/distributor for the approved source.

(C) The quotation shall be on the letterhead of the approved source, or of an authorized dealer/distributor for the approved source; or an electronic quotation, which shall be clearly identifiable as coming to the Offeror/Contractor from the approved source, or from an authorized dealer/distributor for the approved source.

(D) If the offered items are obtained from an authorized dealer/distributor for the approved source, the Offeror/Contractor shall maintain the information described in subparagraph (d)(1)(i) of this clause to document the authorized dealer/distributor arrangement; and the terms in subparagraph (d)(1)(ii) of this clause shall apply.

(ii) If the Offeror/Contractor identified the offered item as “shipped” or “in stock/currently owned by the Offeror,” the following requirements apply:

(A) The Offeror/Contractor shall maintain one of the following documents:

(1) The invoice received by the Offeror/Contractor from the approved source, or from an authorized dealer/distributor for the approved source; or

(2) The packing slip that accompanied the shipment to the Offeror/ Contractor from the approved source, or from an authorized dealer/distributor for the approved source. The packing slip shall include a packing slip number. (If no packing slip number was provided, the Offeror/Contractor shall obtain and maintain written documentation from the approved source, or from the authorized dealer/distributor for the approved source, verifying the packing slip number. Such documentation shall include the name and address of the approved source, or of the authorized dealer/distributor for the approved source; the date of the correspondence; and the name and phone number of the representative of the approved source, or of the authorized dealer/distributor for the approved source, who provided the information.)

(B) The documentation furnished in accordance with subparagraph (c)(2)(ii)(A) of this clause shall include the following:

(1) Date;

(2) the name and address of the approved source, or of the authorized dealer/distributor for the approved source;

(3) the name and phone number of the representative of the approved source, or of the authorized dealer/distributor for the approved source;

(4) the item part number or designation, which shall be provided in sufficient detail to document that the item provided to the Contractor is the same as the item being procured by the Government;

(5) the quantity, which shall be sufficient to satisfy the solicitation requirement;

(6) the unit price charged by the approved source, or by the authorized dealer/distributor for the approved source; and

(7) the Offeror’s/Contractor’s name and address.

(C) If the offered items are obtained directly from an authorized dealer or distributor, the

Offeror/Contractor shall maintain the information described in subparagraph (d)(1)(i) of this clause to document the authorized dealer/distributor arrangement; and the terms in subparagraph (d)(1)(ii) of this clause shall apply.

(3) If the offered items are not obtained directly from an approved source, or from an authorized dealer/distributor of an approved source, the Offeror/Contractor shall maintain documentation, as described in subparagraph (d)(2) of this clause, sufficient to establish the complete line of ownership or distribution from the approved source, or from an authorized dealer/distributor for the approved source, to the Offeror/Contractor.

(e) The Contracting Officer determines the acceptability and sufficiency of documentation or other evidence, at his or her sole discretion. If the Contracting Officer finds the evidence to be unacceptable, or if the Contractor fails to retain or provide the requested evidence, the award may be cancelled or contract may be terminated for cause/default, as applicable.

(f) At the Contracting Officer’s discretion, documentation of traceability provided by the Contractor, in accordance with provisions in the solicitation and/or clauses included in this contract, may be used to determine the acceptability of documentation retained in accordance with this clause.

(g) Notwithstanding any documentation provided by the Offeror prior to purchase order issuance/contract award, the Government reserves the right to require additional documentation attesting to the authenticity of the material at any time before or after contract delivery.

(h) If the solicitation states inspection and acceptance shall take place at destination, the Government reserves the right to change the place of inspection and acceptance to origin and to invoke 52.246-9004, Product Verification Testing, at time of award, with no increase in the awarded unit price.

(i) The Contractor shall be responsible for the assurance of type, kind, count, and condition. Preservation, packing, packaging, and marking shall be in accordance with contractual requirements.

(j) The Contractor shall retain documentation in accordance with this clause for 5 years after final payment under this contract.

(End of Clause)

SUBSTITUTION OF ITEM AFTER AWARD

When the purchase order text (POT) identifies supplies by manufacturer's name, commercial and Government Entity (CAGE) code , and part number, the specified item(s) are the only item(s) acceptable under this contract. The Contractor may not substitute a different item after award.

PHYSICAL ITEM IDENTIFICATION/BARE ITEM MARKING – DLA LAND AND MARITIME

Unless authorized by exclusions listed below, all items shall be marked as specified in military standard (MIL-STD) 130N. The following DLA Land and Maritime supplemental marking requirements shall take precedence in case of conflict with MIL-STD-130N.

DLA Land and Maritime Exclusion:

(a) Unless the design control document specifically cites other marking requirements, the item will be considered too small to mark under the conditions listed below (however, 52.211-9035, Marking Requirements, applies):

(1) For federal supply classes (FSCs) 5905, 5910, 5935, 5961, 5962, and 5999, items smaller than .100 inch in diameter and .250 inch in length or .100 inch square X .250 inch in length, exclusive of wire leads, will not be marked.

(2) Other FSCs managed by DLA Land and Maritime will not be marked if the item is smaller than .250 inch in diameter X .500 inch long or .250 inch square X .500 inch long, exclusive of wire leads.

(3) Restrictions (1) and (2) above will not preclude marking of items of smaller dimensions if it is the manufacturers or vendor's standard practice to do so.

(b) No other physical item marking exclusions are authorized unless specified by MIL-STD-130N.

52.212-2 EVALUATION--COMMERCIAL ITEMS (OCT 2014)

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:

1. PRICE

2. TECHNICALLY ACCEPTABLE

3. DELIVERY

(b) Options. The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the Government to exercise the option(s).

(c) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL ITEMS (JAN 2017)

ALTERNATE I (OCT 2014)

The offeror shall complete only paragraphs (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal . If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision--

“Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means--

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: ``Guidance for Executive Order 13673, `Fair Pay and Safe Workplaces' ''. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are--

(1) Department of Labor Wage and Hour Division (WHD) for--

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(v) The Family and Medical Leave Act; and

(vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for--

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for--

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for--

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

“Forced or indentured child labor” means all work or service—

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation,” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of ``labor laws''.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except—

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate—

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology—

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically—

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

“Service-disabled veteran-owned small business concern”—

(1) Means a small business concern—

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern, consistent with 13 CFR 124.1002,” means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Veteran-owned small business concern” means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans(as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Women-owned business concern” means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

“Women-owned small business concern” means a small business concern --

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127),” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: ``Administrative merits determination'', ``Arbitral award or decision'', paragraph (2) of ``Civil judgment'', ``DOL Guidance'', ``Enforcement agency'', ``Labor compliance agreement'', ``Labor laws'', and ``Labor law decision''. The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(b)

(1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAMwebsite.

(2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representation and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications—Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ___ . [Offeror to identify the applicable paragraphs at (c) through (u) of this provision that the offeror has completed for the purposes of this solicitation only, if any. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.]

(c) Offerors must complete the following representations when the resulting contract is to be performed in the United States or its outlying areas. Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a small business concern.

(2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a veteran-owned small business concern.

(3) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a service-disabled veteran-owned small business concern.

(4) Small disadvantaged business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.]The offeror represents that it [ ___ ] is, [ ___ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(5) Women-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.]The offeror represents that it [ ___ ] is, [ ___ ] is not a women-owned small business concern.

Note: Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold.

(6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that—

(i) It [ ___ ] is, [ ___ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture.