SPMYM222Q1124 AMEND 1.pdf

N4523A20677900

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

This is issued to extend offer due date to 03/22/2022 at 1000AM PST and to change delivery date as determining factor for aw ard consideration due to urgency of need All other terms and conditions remain the same

1. CONTRACT ID CODE PAGE OF PAGES

J 1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 18-Mar-2022

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X SPMYM222Q1124

X 9B. DATED (SEE ITEM 11)

12-Mar-2022

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

18-Mar-2022

CODE

DLA MARITIME PUGET SOUND

ATTN: RICHARD KEY

467 W STREET

BREMERTON WA 98314

SPMYM2 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

SPMYM222Q1124

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 1449 - CONTINUATION SHEET

SOLICITATION/CONTRACT FORM

The required response date/time has changed from 16-Mar-2022 10:00 AM to 22-Mar-2022 10:00 AM.

SUPPLIES OR SERVICES AND PRICES

CLIN 0001

The CLIN extended description has changed from:

2" THK X 12" W X 16' LG,ROUGH, FULL SAWN, FIRE-RETARDANTWOOD, SOFT, DOUGLAS FIR,

GRADE-DENSE PREMIUM/#1 IAW WCLIB (48 PIECES TO A SLING) MIL-L-19140E TY-2 CAT-

2Manufacturer's Name:__________________________________________ Brand_______________________________________________________ No:_________________________________________________________NSN: 00-551-9860 DOC:

2067-7900A. LUMBER AND PLYWOOD, FIRE-RETARDANT TREATED MIL-L-19140E Amendment 02 01/29/97B. TY-2, WEATHER RESISTANT IAW 1.2.1C. CATEGORY-2, NAVAL SHIPBUILDING AND REPAIR IAW 1.2.2D. 2" THK X 12" W X 16 LG, ROUGH FULL SAWNE. N/AF. 19% IAW PARA 3.12, GRADE- DENSE, PREMIUM #1G. N/AH. MARKING- IAW PARA 3.13.2 FOR CATEGORY-2I. N/AJ.

VERIFICATION INFORMATION IS REQUIRED AND IS TO ACCOMPANY MATERIAL

To:

2" THK X 12" W X 16' LG,ROUGH, FULL SAWN, FIRE-RETARDANTWOOD, SOFT, DOUGLAS FIR,

GRADE-DENSE PREMIUM/#1 IAW WCLIB (48 PIECES TO A SLING) MIL-L-19140E TY-2 CAT-

2DELIVERY DATE IS DETERMINING FACTOR FOR AWARD CONSIDERATIONManufacturer's Name:__________________________________________ Brand_______________________________________________________ No:_________________________________________________________NSN: 00-551-9860 DOC:

2067-7900A. LUMBER AND PLYWOOD, FIRE-RETARDANT TREATED MIL-L-19140E Amendment 02 01/29/97B. TY-2, WEATHER RESISTANT IAW 1.2.1C. CATEGORY-2, NAVAL SHIPBUILDING AND REPAIR IAW 1.2.2D. 2" THK X 12" W X 16 LG, ROUGH FULL SAWNE. N/AF. 19% IAW PARA 3.12, GRADE- DENSE, PREMIUM #1G. N/AH. MARKING- IAW PARA 3.13.2 FOR CATEGORY-2I. N/AJ.

VERIFICATION INFORMATION IS REQUIRED AND IS TO ACCOMPANY MATERIAL

DELIVERIES AND PERFORMANCE

The following Delivery Schedule item for CLIN 0001 has been changed from:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

SPMYM222Q1124

25-MAR-2022 35,712 PUGET SOUND NAVAL SHIPYARD

RECEIVING OFFICER PSNS

BLDG 514

1400 FARRAGUT AVE

N4523A

BREMERTON WA 98314-5001

360-476-7640 FOB: Destination

N4523A

To:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

31-MAR-2022 35,712 PUGET SOUND NAVAL SHIPYARD

RECEIVING OFFICER PSNS

BLDG 514

1400 FARRAGUT AVE

N4523A

BREMERTON WA 98314-5001

360-476-7640 FOB: Destination

N4523A

(End of Summary of Changes)