Specs W9128F22B0005 2022 IDCC at Oahe.pdf

SPECIFICATIONS

(For Construction Contract)

Solicitation Number W9128F22B0005

2022 IDCC Road Rehab

Oahe Dam, SD

May 2022

US Army Corps of Engineers Omaha District

This page was intentionally left blank for duplex printing.

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK

01 12 00 CONSTRUCTION GENERAL

01 30 00.24 OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 41 26.01 24 (SOUTH DAKOTA) NPDES PERMIT REQUIREMENTS FOR STORM WATER

DISCHARGES FROM CONSTRUCTION SITES

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.00 10 QUALITY CONTROL

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 57 20.00 10 ENVIRONMENTAL PROTECTION

01 57 23.00 10 STORM WATER POLLUTION PREVENTION MEASURES

DIVISION 31 - EARTHWORK

31 00 00 EARTHWORK

31 05 19 GEOTEXTILE

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 01 16.71 COLD MILLING ASPHALT PAVING

32 01 17.16 SEALING OF CRACKS IN BITUMINOUS PAVEMENTS

32 11 23 AGGREGATE AND/OR GRADED-CRUSHED AGGREGATE BASE COURSE

32 12 16 HOT-MIX ASPHALT (HMA) FOR ROADS

32 12 36.13 ASPHALTIC SEAL AND FOG COATS

32 16 13 CONCRETE SIDEWALKS AND CURBS AND GUTTERS

32 17 24.00 10 PAVEMENT MARKINGS

32 92 19 SEEDING

DIVISION 33 - UTILITIES

33 40 00 STORM DRAINAGE UTILITIES

-- End of Project Table of Contents --

2022 IDCC Oahe Dam SD OAA4

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00

SUMMARY OF WORK

08/11

PART 1 GENERAL

1.1 WORK COVERED BY CONTRACT DOCUMENTS

1.1.1 Project Description

1.1.2 Location

1.1.2.1 SPECIFICATIONS

1.2 OCCUPANCY OF PREMISES

1.3 EXISTING WORK

1.4 LOCATION OF UNDERGROUND UTILITIES

1.4.1 Notification Prior to Excavation

1.5 WORK SCHEDULING

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

SECTION 01 11 00 Page 1

SECTION 01 11 00

SUMMARY OF WORK

08/11

PART 1 GENERAL

The following paragraphs describe the required work. The description of the work in this section is abbreviated with the details provided in the technical sections. The technical specifications are arranged by the Construction Specifications Institute (CSI) numbering system, which does not correspond with sequence in which the work has to be accomplished.

1.1 WORK COVERED BY CONTRACT DOCUMENTS

1.1.1 Project Description

This section covers the technical specification to provide all labor, materials, incidentals, and equipment to perform the work required to maintain and improve roads in the areas around the Oahe Project in the vicinity of the Oahe Dam near Pierre, SD. This list is a general summary of the required work and is not all inclusive:

1.1.2 Location

The Oahe Project is located approximately 7 miles north of Pierre, SD.

The area included in this IDCC includes the general area of the Oahe Dam and is outlined in the location map.

The exact locations will be as shown on drawings or by the Contracting Officer's Representative.

1.1.2.1 SPECIFICATIONS

TECHNICAL SPECIFICATIONS LISTED BELOW COVER THE POTENTIAL REQUIRED TYPES

OF WORK:

00 10 00 Bid Schedule

01 11 00 SUMMARY OF WORK

01 12 00 CONSTRUCTION GENERAL

01 30 00.24 OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 41 26.01 24 (SOUTH DAKOTA) NPDES PERMIT REQUIREMENTS FOR STORM WATER

DISCHARGES FROM CONSTRUCTION SITES

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.00 10 QUALITY CONTROL

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 57 20.00 10 ENVIRONMENTAL PROTECTION

01 57 23.00 10 STORM WATER POLLUTION PREVENTION MEASURES

31 00 00 EARTHWORK

31 05 19 GEOTEXTILE

32 01 16.71 COLD MILLING OF ASPHALT PAVEMENTS

32 01 17.16 SEALING OF CRACKS IN BITUMINOUS PAVEMENTS

32 11 23 AGGREGATE AND/OR GRADED-CRUSHED AGGREGATE BASE COURSE

SECTION 01 11 00 Page 2

32 12 16 HOT-MIX ASPHALT (HMA) FOR ROADS

32 12 36.13 ASPHALTIC SEAL AND FOG COATS

32 16 13 CONCRETE SIDEWALKS AND CURBS AND GUTTERS

32 17 24.00 10 PAVEMENT MARKINGS

32 92 19 SEEDING

33 40 00 STORM DRAINAGE UTILITIES

1.2 OCCUPANCY OF PREMISES

Building(s) will be occupied during performance of work under this Contract.

Before work is started, the Contractor shall arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

1.3 EXISTING WORK

In addition to "FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements":

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work shall be in a condition equal to or better than that which existed before new work started.

1.4 LOCATION OF UNDERGROUND UTILITIES

Scan the construction site with electromagnetic or sonic equipment, and mark the surface of the ground, pier deck or paved surface where existing underground utilities are discovered. Verify the elevations of existing piping, utilities,and any type of underground or encased obstruction not indicated to be specified or removed but indicated or discovered during scanning in locations to be traversed by piping, ducts, and other work to be conducted or installed.

1.4.1 Notification Prior to Excavation

Notify the Contracting Officer at least 48 hours prior to starting excavation work.

1.5 WORK SCHEDULING

Contract work will be limited to the hours of 7 AM to 5 PM - Monday thru Friday. No work will be permitted on Saturday, Sunday, or Federal Holidays.

Any work to be performed outside the designated work scheduling will have to be approved by the COR 7 days prior to work being performed.

PART 2 PRODUCTS

Not used.

SECTION 01 11 00 Page 3

PART 3 EXECUTION

Not used.

-- End of Section --

SECTION 01 11 00 Page 4

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 12 00

CONSTRUCTION GENERAL

04/07

PART 1 GENERAL

1.1 SCOPE

1.2 CONSTRUCTION RIGHT-OF-WAY

1.3 PROTECTION OF EXISTING FACILITIES AND WORKS

1.3.1 Protection of Appurtenances from Bituminous Material

Applications

1.3.2 Flood Protection Works

1.4 CARE OF WATER

1.5 DISPOSITION OF CONSTRUCTION FACILITIES

1.6 ACCESS ROADS AND HAUL ROADS

1.6.1 Access Roads

1.7 PUBLIC ROADS

1.7.1 Lane Closure

1.7.2 Traffic Control Devices

1.7.3 Temporary Traffic Control (TTC)

1.7.4 Operations

1.7.4.1 Flaggers

1.7.5 Road Closure

1.7.6 State and Federal Highways

1.7.7 State and Local Public Roads

1.7.8 City Streets

1.7.9 Utility Lines

1.8 COOPERATION WITH OTHER CONTRACTORS

1.9 SUBMITTALS

1.10 SPECIAL INSTRUCTIONS FOR PROGRESS CHARTS

1.11 WARRANTY OF CONSTRUCTION (MAR 1994)

1.12 TELEPHONE/INTERNET

1.13 PORTABLE TOILETS

1.14 FEDERAL HOLIDAYS AND WORKING HOURS

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 12 00 Page 1

SECTION 01 12 00

CONSTRUCTION GENERAL

04/07

PART 1 GENERAL

1.1 SCOPE

The work covered in this section is outlined as a statement of construction requirements common to all the work. Specific requirements for materials and installations are provided under the Technical Sections herewith. No claims for extras shall be made on account of items presumed to have been omitted from this section.

1.2 CONSTRUCTION RIGHT-OF-WAY

The Contractor will be assigned working areas or working right-of-way limits for use in the prosecution of work under this contract, subject to the SECTION 00 72 00, GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Operations and Storage Areas."

1.3 PROTECTION OF EXISTING FACILITIES AND WORKS

The Contractor shall be responsible for the protection of the work area from damage and upon completion of the work shall leave existing works in a condition equal to that which existed when the work started. All work, storage of materials, and construction plant shall be kept within the limits of the areas assigned. Prior to construction operations, the Contractor shall confer with the Contracting Officer's representative to determine the proximity of any possible under-ground obstructions, pipe or equipment which could be damaged as a result of construction operations.

Existing utility lines that are shown on the drawings or the locations are otherwise made known to the Contractor shall be protected from damage, and if damaged, shall be repaired by the Contractor at no additional expense to the Government. In the event that the Contractor damages any existing utility lines that are not shown or the locations of which have not been made known to the Contractor, the Contractor shall immediately notify the Contracting Officer. The Contracting Officer will review the information and discuss with the Contractor how to proceed. The Contractor will be responsible for the protection of structures from any structural damage during the construction operations. Roads and surfaces shall be protected from damage by the work or if damaged shall be repaired with equal materials at no additional expense to the Government. At all times the plant and work areas shall be kept in a condition conducive to safety of workmen and the public and neat in appearance. Waste or surplus materials shall not be allowed to accumulate in the construction areas.

1.3.1 Protection of Appurtenances from Bituminous Material Applications

It shall be the responsibility of the Contractor to cover and protect the surfaces of roadway appurtenances, structures and installations by approved methods in advance of any bituminous material application adjacent thereto. Damages or defacement thereof shall be corrected as directed, by and at the expense of the Contractor.

SECTION 01 12 00 Page 2

1.3.2 Flood Protection Works

In all cases where materials in the existing flood protection works are used or connected with the construction of new work under this contract, the work shall be so planned and executed that the new work shall be completed to provide protection equivalent to the existing protection as the existing protection is weakened or removed. These operating restrictions shall be followed in order that the new work may be tied in, or connected promptly, by the Contractor, with the existing facilities so as to furnish a continuous service in an emergency. These ties or connections shall be made during periods of suspended construction operations and the Contractor shall leave incompleted pipe outlets and other structures in such conditions as to not interfere with the natural drainage from areas served by these pipes or structures.

1.4 CARE OF WATER

Full responsibility for care of water shall be borne by the Contractor until completion of work under this contract. The Contractor shall provide the materials and equipment and perform all work necessary to facilitate construction and to protect the work from damage by water. The Contractor shall make the needed investigations and determinations of conditions, both existing and anticipated concerning care of water. Plans for care of water are subject to approval by the Contracting Officer prior to construction. Facilities shall be removed upon completion of the work.

1.5 DISPOSITION OF CONSTRUCTION FACILITIES

All buildings and facilities constructed by the Contractor shall be maintained in a satisfactory condition with strict observance of the rules of sanitation, safety and order as may be established by the Contracting Officer. Prior to final payment under the contract, all buildings and facilities constructed by the Contractor for the Contractor's use shall be removed from the site by the Contractor.

1.6 ACCESS ROADS AND HAUL ROADS

1.6.1 Access Roads

Access roads as required for the prosecution of the work shall be maintained (including sprinkling for dust control, safety personnel, and traffic control) within the work areas assigned to the Contractor.

Consideration shall be given to the avoidance of interference with others, safety and frequency of traffic, subject to review and approval prior to construction. Access road areas shall be restored to their original or suitable condition upon completion of this contract. The Contractor shall be responsible for repair of damage to existing roads caused by the Contractor's operation.

SECTION 01 12 00 Page 3

1.7 PUBLIC ROADS

1.7.1 Lane Closure

One lane of the road must remain open at all times. The Contractor shall determine an appropriate method for the specific Temporary Traffic Control (TTC) zone one-lane, two-ways traffic control method in accordance with MUTCD requirements. The Contractor shall furnish all necessary personnel and traffic control devices, perform routine day and night inspections of TTC elements, and maintain all furnished traffic control devices to provide safety for motorists, bicyclists, pedestrians, workers, enforcement/emergency officials, and equipment as required by MUTCD The Contractor is required to coordinate the road/lane closure with the SDDOT and USACE.

1.7.2 Traffic Control Devices

All traffic control devices (signs, arrow boards, barricades, lighting etc) by the Contractor, must conform with the U.S. Department of Transportation, Federal Highway Administration, Manual on Uniform Traffic Control Devices.

1.7.3 Temporary Traffic Control (TTC)

The Contractor shall be responsible for the safe control of traffic on all haul and access roads used primarily for the work under these specifications and at their crossings with roads used by others. The Contractor shall, at the Contractor's own expense, furnish all personnel, and traffic control devices necessary for the safe movement of all road users through or around Temporary Traffic Control zone. Traffic control plans, including a listing of equipment and its employment, shall be submitted for review and approval prior to construction.

1.7.4 Operations

When operations are being conducted near a U. S. or State Highway or when construction equipment is being used on or adjacent to such highway, the Contractor shall furnish all necessary traffic control devices and personnel to provide safe and effective movement of all road users through or around Temporary Traffic Control zone as required by MUTCD All required state and/or local permits shall be obtained at the Contractor's expense in advance and shall be provided to the COR. The highways and streets shall be kept open at all times.

1.7.4.1 Flaggers

The Contractor shall provide flaggers when:

a) Construction equipment and/or vehicles are blocking the roadway making it difficult for vehicles to pass or see or due to terrain.

b) One-way traffic is required thru a construction zone.

c) Trucks are pulling onto and/or off of a roadway or operating at a reduced speed causing a hazardous situation for drivers.

SECTION 01 12 00 Page 4

d) Anytime the Contractor feels that drivers are at risk due to Construction activity.

Flagger shall have all qualifications, high-visibility safety apparel, and appropriate hand-signaling devices in accordance with MUTCD requirements.

The flagger shall be properly trained as required by the state. The Contractor shall furnish all necessary traffic control devices to establish appropriate TTC zone when the Flagger Control is utilized.

1.7.5 Road Closure

At each location designated by the Contracting Officer and where safe operation requires the closing of roads, streets or other travel arteries leading to the work under this contract, the Contractor shall furnish all appropriate traffic control devices to provide safety for motorists, bicyclists, pedestrians, workers, enforcement/emergency officials, and equipment during construction as required by MUTCD. Arrangements for closure of roads, streets or other travel arteries shall be made by the Contractor with local State, County or City officials. The Contractor shall notify the appropriate official in writing at least ten (10) days in advance of the date desired to close a road to traffic and shall furnish a copy of the agreement and approved Temporary Traffic Control plans to the Contracting Officer prior to closure.

1.7.6 State and Federal Highways

Where the Contractor hauls across or on State or Federal highways, the Contractor shall enter into all agreements with the State Highway Commission and shall comply with any restrictions they may impose relative to load limits, care of traffic and cleanup. Such agreements shall clearly relieve the Government of any responsibility for damages resulting from hauling across or on State highways. Copies of such agreements shall be furnished to the Contracting Officer before the Contractor begins hauling on these highways.

1.7.7 State and Local Public Roads

(a) Load Limits:

The South Dakota Department of Transportation and local County Road Commissions restrict the load weights of haul vehicles using highways and county roads during the spring thaw period. The load restrictions are usually imposed from 1 April through June depending on actual weather conditions.

(b) Hauling Regulations:

Prior to start of hauling operations on public roads, the Contractor shall furnish evidence to the Contracting Officer that an agreement has been consummated with State and County officials on the use of public roads and bridges. Such agreements shall clearly relieve the Government of any responsibility for damage resulting from hauling across or on these roads.

1.7.8 City Streets

Where the Contractor intends to cross or to use city streets for haul roads the Contractor shall enter into an agreement with the City and shall comply with any restrictions the City may impose relative to load limits, care of traffic and cleanup. Such agreements shall clearly relieve the

SECTION 01 12 00 Page 5

Government of any responsibility for damage resulting from hauling across or on these highways. A copy of all such agreements shall be furnished the Contracting Officer before the Contractor begins hauling in city streets.

1.7.9 Utility Lines

It shall be the responsibility and obligation of the Contractor to make all arrangements with the affected companies for the necessary moving and alterations of utility lines and the continuation of service during construction as covered by the plans and specifications.

1.8 COOPERATION WITH OTHER CONTRACTORS

The Contractor shall cooperate and coordinate work with that of the State and others working in the area during the life of this contract. The Contractor shall coordinate work with others to avoid undue interference and shall conduct operations, other than approved required access, within the limits of the assigned construction area or construction right-of-way limits. The Contractor shall cooperate with others as necessary in the interest of timely completion of all work and in the event of disagreement the decision of the Contracting Officer shall be final.

1.9 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Progress Charts; G-PO

Construction Right-of-Way

(Right-of-Way Agreements)

State and Federal Highways

(Agreements for hauling on highways)

State and Local Public Roads

SECTION 01 12 00 Page 6

(Agreements for hauling on roads)

Temporary Traffic Control (TTC); G, PO

SD-02 Shop Drawings

Care of Water; G-PO

SD-11 Closeout Submittals

Warranty of Construction

(List of warranties with copy of each)

1.10 SPECIAL INSTRUCTIONS FOR PROGRESS CHARTS

To be submitted in accordance with the SECTION 00 72 00, GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Schedule for Construction Contracts" shall indicate the required data for each of the principal features of the work. Contract changes or modifications will not include extensions of time unless the updated progress chart shows that the contract completion date is delayed due to the affect of the change on one or more principal features of the work.

1.11 WARRANTY OF CONSTRUCTION (MAR 1994)

(a) In addition to any other warranties in this contract, the Contractor warrants, except as provided in paragraph (i) of this clause, that work performed under this contract conforms to the contract requirements and is free of any defect in equipment, material, or design furnished, or workmanship performed by the Contractor or any subcontractor or supplier at any tier.

(b) This warranty shall continue for a period of 1 year from the date of final acceptance of the work. If the Government takes possession of any part of the work before final acceptance, this warranty shall continue for a period of 1 year from the date the Government takes possession.

(c) The Contractor shall remedy at the Contractor's expense any failure to conform, or any defect. In addition, the Contractor shall remedy at the Contractor's expense any damage to Government-owned or controlled real or personal property, when that damage is the result of--

(1) The Contractor's failure to conform to contract requirements; or

(2) Any defect of equipment, material, workmanship, or design furnished.

(d) The Contractor shall restore any work damaged in fulfilling the terms and conditions of this clause. The Contractor's warranty with respect to work repaired or replaced will run for 1 year from the date of repair or replacement.

(e) The Contracting Officer shall notify the Contractor, in writing, within a reasonable time after the discovery of any failure, defect, or damage.

SECTION 01 12 00 Page 7

(f) If the Contractor fails to remedy any failure, defect, or damage within a reasonable time after receipt of notice, the Government shall have the right to replace, repair, or otherwise remedy the failure, defect, or damage at the Contractor's expense.

(g) With respect to all warranties, express or implied, from subcontractors, manufacturers, or suppliers for work performed and materials furnished under this contract, the Contractor shall--

(1) Obtain all warranties that would be given in normal commercial practice;

(2) Require all warranties to be executed, in writing, for the benefit of the Government, if directed by the Contracting Officer; and

(3) Enforce all warranties for the benefit of the Government, if directed by the Contracting Officer.

(h) In the event the Contractor's warranty under paragraph (b) of this clause has expired, the Government may bring suit at its expense to enforce a subcontractor's, manufacturer's, or supplier's warranty.

(i) Unless a defect is caused by the negligence of the Contractor or subcontractor or supplier at any tier, the Contractor shall not be liable for the repair of any defects of material or design furnished by the Government nor for the repair of any damage that results from any defect in Government-furnished material or design.

(j) This warranty shall not limit the Government's rights under the Inspection and Acceptance clause of this contract with respect to latent defects, gross mistakes, or fraud. (FAR 52.246-21)

1.12 TELEPHONE/INTERNET

The Contractor is responsible for arranging telephone/Internet service for the Contractor's trailer through the local telephone company.

1.13 PORTABLE TOILETS

Toilet facilities will not be available for Contractor's use. The Contractor shall provide and maintain portable toilets for use by the Contractor's staff . Toilet(s) shall be placed at the location directed by the Contracting Officer. To prevent overturning by high winds, all portable toilets shall be anchored down.

1.14 FEDERAL HOLIDAYS AND WORKING HOURS

The Contractor will have access to the facility for work during normal plant business hours from 0700 to 1700 hrs Monday through Friday, excluding any federally recognized holidays or observance days. The Contractor shall plan all work accordingly. These hours will be strictly adhered to unless the Government determines work outside this time is beneficial to the Government or a bilateral modification for extended

SECTION 01 12 00 Page 8 working hours is executed.

The following Federal legal holidays are observed by this installation:

New Year's Day 1 January Martin Luther King's Birthday Third Monday in January President's Day Third Monday in February Memorial Day Last Monday in May Juneteenth 19 June Independence Day 4 July Labor Day First Monday in September Columbus Day Second Monday in October Veterans Day 11 November Thanksgiving Day Fourth Thursday in November Christmas Day 25 December

If the wage determination has a discrepancy with the above list of observed Federal holidays, then the wage determination takes precedence.

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 12 00 Page 9

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

07/20

PART 1 GENERAL

1.1 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

1.2 CONTRACTOR SUPPLY AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING

CONSTRUCTION WAGE RATE REQUIREMENTS STATUTE CERTIFIED LABOR

PAYROLLS

1.3 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS

CONTRACTS

1.4 COMPLETION OF WORK

1.5 CONTRACTOR PERFORMANCE EVALUATIONS

1.6 LIQUIDATED DAMAGES-CONSTRUCTION

1.7 ANTITERRORISM (AT)/OPERATIONS SECURITY (OPSEC) PROVISIONS

1.8 CONTRACT DRAWINGS AND SPECIFICATIONS

1.8.1 SETS FURNISHED

1.9 SUBMITTALS

1.10 PAYMENT

1.10.1 PROMPT PAYMENT ACT

1.11 DAMAGE TO WORK

1.12 AVAILABILITY AND USE OF UTILITY SERVICES

1.13 QUANTITY SURVEYS

1.14 VARIATIONS IN ESTIMATED QUANTITIES - SUBDIVIDED ITEMS

1.15 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1.16 INSURANCE REQUIRED

1.17 CONTRACTOR QUALITY CONTROL (CQC)

1.18 NONDOMESTIC CONSTRUCTION MATERIALS

1.19 DAILY WORK SCHEDULES AND WEEKLY COORDINATION MEETINGS

1.20 PROFIT

1.21 LABOR CONDITIONS APPLICABLE TO TEMPORARY FACILITIES

1.22 DRAWING SCALES

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 30 00.24 Page 1

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

07/20

PART 1 GENERAL

Attachments:

1.1 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

In accordance with FAR 31.105(d)(2)(i)(b), for the predetermined schedule of construction equipment use rates, use Engineer Pamphlet (EP) 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule. Copies of each regional schedule may be obtained through the following internet site:

https://www.publications.usace.army.mil/USACE-Publications/Engineer-Pamphlets/ on pages 10 and 11 of 13.

1.2 CONTRACTOR SUPPLY AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING

CONSTRUCTION WAGE RATE REQUIREMENTS STATUTE CERTIFIED LABOR PAYROLLS

a. Use a commercially-available electronic system to process and submit certified payrolls electronically to the Government. The requirements for preparing, processing and providing certified labor payrolls are established by the Wage Rate Requirements statute.

b. Obtain and provide for all access, licenses, and other services required to provide for receipt, processing, certifying, electronically transmitting to the Government, and storing weekly payrolls and other data required for the Contractor to comply with the Wage Rate Requirements statute. Use the electronic payroll service to prepare, process, and maintain the relevant payrolls and basic records during all work under this construction contract. The electronic payroll service must be capable of preserving these payrolls and related basic records for the required three years after contract completion. Obtain and provide electronic system access to the Government, as required to comply with the Wage Rate Requirements over the duration of the construction contract.

(c) The Contractor's provision and use of an electronic payroll processing system must meet the following basic functional criteria:

(1) commercially available;

(2) compliant with appropriate Wage Rate Requirements statute payroll provisions in the FAR;

SECTION 01 30 00.24 Page 2

(3) able to accommodate the required numbers of employees and subcontractors planned to be employed under the contract;

(4) capable of producing an Excel spreadsheet-compatible electronic output of weekly payroll records for export into an Excel spreadsheet to be imported into the contractor's mode of Resident Management System 3.0;

(5) demonstrated security of data and data entry rights;

(6) ability to produce Contractor-certified electronic versions of weekly payroll data;

(7) ability to identify erroneous entries and track the data/time of all versions of the certified Wage Rate Requirements statute payrolls submitted to the government over the life of the contract;

(8) capable of generating a durable record copy in a Compact Disc (CD) or Digital Versatile Disc (DVD) and Portable Document Format (PDF) file record of data from the system database at the end of the contract closeout. This durable record copy of data from the electronic payroll processing system must be provided to the Government during contract closeout.

d. All Contractor-incurred costs related to the Contractor's provision and use of an electronic payroll processing service must be included in the Contractor's price for the overall work under the contract. The costs for compliance with the Wage Rate Requirements statute by using electronic payroll processing services must not be a separately bid or reimbursed item under this contract.

1.3 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS CONTRACTS

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS

222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

- U.S. Department of Labor Veterans’ Employment and Training Service

(VETS):

https://www.dol.gov/vets/

- Federal Veteran Employment Information: https://www.fedshirevets.gov/

- Veterans Opportunity to Work (VOW) Program:

https://www.benefits.va.gov/vow/

- U.S. Army Warrior Transition Command Employment Index:

https://wct.army.mil/modules/employers/index.html

- Hiring Our Heroes: https://www.uschamberfoundation.org/hiring-our-heroes

1.4 COMPLETION OF WORK

See Section 00 73 00 SUPPLEMENTARY CONDITIONS (SPECIAL CONTRACT

REQUIREMENTS), FAR 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF

WORK (APR 1984).

SECTION 01 30 00.24 Page 3

1.5 CONTRACTOR PERFORMANCE EVALUATIONS

See Federal Acquisition Regulation (FAR) Subpart 42.1502(e) for the requirements on past performance evaluations for construction contracts.

For construction contracts valued at or above $750,000.00, including all modifications, the USACE will evaluate Contractor's performance using the web-based Contractors Performance Assessment Reporting System (CPARS).

After the USACE drafts an evaluation (interim or final), the Contractor will have the opportunity to access, review, comment and either concur or non-concur with the evaluation in the CPARS system for a period of 60 days. Access to the CPARS system requires either specific software called PKI certification (recommended method) or a username and password. The PKI certification is a Department of Defense recommendation and to provide security in electronic transactions. The certification software could cost approximately $110 - $125 per certificate per year and may be purchased from an External Certificate Authorities (ECA) vendor. Current information about the PKI certification process and contacting vendors can be found on the web site: https://www.cpars.gov .

1.6 LIQUIDATED DAMAGES-CONSTRUCTION

See Section 00 73 00 SUPPLEMENTARY CONDITIONS (SPECIAL CONTRACT

REQUIREMENTS), FAR 52.211-12 LIQUIDATED DAMAGES-CONSTRUCTION (SEPT 2000).

1.7 ANTITERRORISM (AT)/OPERATIONS SECURITY (OPSEC) PROVISIONS

1. NOT USED.

2. Access and General Protection/Security Policy and Procedures

All Contractor and all associated sub-contractors employees shall comply with applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative). The Contractor shall also provide all information required for background checks to meet installation access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any individual facility or installation change, the Government may require changes in Contractor security matters or processes.

2.1 Submit a complete, updated and signed, list of all Contractor and subcontractor personnel, including their titles and intended working hours, who will be working on site prior to start of work. This listing shall be revised and resubmitted when personnel changes occur. (SUBMITTAL

FIO)

2.2 Personnel Risk Assessment

A minimum of seven days prior to engaging in work submit, to the CO or Project POC, a Personnel Risk Assessment (PRA) for each employee requiring authorized unescorted access to the Jobsite. The Contractor employee will only be allowed authorized unescorted physical access after the PRA is shown to and approved by the Government. (Government Security Paperwork)

SECTION 01 30 00.24 Page 4

2.3 Authorized Unescorted Access Requirements

Perform a PRA on all Contractor personnel that require authorized unescorted access to the Jobsite. Costs associated with the execution of the PRA shall be at the expense of the Contractor. The content of the PRA is defined by the requirements as follows:

a. Criminal Check - Obtain a criminal background check, completed within the last seven years of date of task order award under this contract, on all Contractor personnel that require authorized unescorted access to the Jobsite. A minimum of a 7-year criminal background check with the state patrol office shall be performed from all states of residence and employment, for the past seven years. The Project Security Officer through the Contacting Officer will approve, disapprove, or revoke authorized unescorted access to the Jobsite as a result of the seven-year background check. (Government Security Paperwork)

b. Identity Verification - Contractor employees shall provide positive verification of individual identity prior to authorized unescorted access to the Jobsite. Acceptable forms of identity verification are documents issued by a federal Government agency that include: the individual's photograph, name, and date of birth, such as a passport or military identification (ID) card. Additionally, a state issued driver's license or ID card is acceptable for identity verification.

c. The Criminal Check and Identity Verification shall be updated at least every seven years for each employee requiring authorized unescorted access to the Jobsite.

d. Escort Requirements - Contractor personnel not cleared for authorized access to the Jobsite may be escorted by Government or Contractor personnel that have authorized unescorted access to the Jobsite. All costs related to the escorting of non-cleared personnel shall be at the expense of the Contractor. Additional burden shall not be placed upon the Government to provide these escorts. Prior to access, coordination with the Project Security Officer is required, including but not limited to:

(1) Verification of identity with photo identification

(2) Name of escorting individual and verification of unescorted status

(3) Time of entry into the Jobsite

(4) Time exiting the Jobsite.

3. NOT USED

4. iWATCH and/or CorpsWatch Training

The Contractor and all associated sub-contractors shall brief all employees on the local iWATCH, Corps Watch, or See Something, Say Something program. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the COR. This training shall be completed within 30 calendar days of task order award under this contract and within 30 calendar days of new employees commencing performance with the results reported to the COR NLT 5 calendar days after task order award under this contract (submittal: iWATCH and/or CorpsWatch Training Sign In Sheets).

http://www.myarmyonesource.com/familyprogramsandservices/iwatchprogram/default.aspx

SECTION 01 30 00.24 Page 5

5. thru 12. Not Used

13. Will be Escorted in Areas Where They May be Exposed to Classified and/or Sensitive Materials and/or Sensitive or Restricted Areas All contract employees, including subcontractor employees who are not in possession of the appropriate access privileges, will be escorted in areas where they may be exposed to sensitive materials and/or sensitive or restricted areas.

14. Not Used

15. Pre-screen Candidates using E-Verify Program.

The Contractor must pre-screen Candidates using the E-verify Program (http://www.dhs.gov/E-Verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the task order award under this contract.

16. & 17 Not Used

1.8 CONTRACT DRAWINGS AND SPECIFICATIONS

1.8.1 SETS FURNISHED

The Contractor shall be responsible for making copies of all plans and specifications as needed for the duration of the contract.

1.9 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit items below in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

AT Level I Training Sign In Sheets;

Sign In Sheets for all employee training required for AT Level I Training, see OPSEC paragraphs, subparagraph 1

Security Personnel List; G-PO

Security Personnel list as described in Access and General Protection/Security Policy and Procedures see OPSEC paragraphs, subparagraph 2.1.

SECTION 01 30 00.24 Page 6 iWATCH and/or CorpsWatch Training Sign In Sheets ;

Sign In Sheets for all employee training required for iWATCH and/or CorpsWatch Training, see OPSEC paragraphs, subparagraph 4

Government Security Paperwork; G, PO See OPSEC paragraphs, subparagraph 2.2 and 2.3 for more details.

E-Verify; G, PO See OPSEC paragraphs, subparagraph 15 for more details.

1.10 PAYMENT

1.10.1 PROMPT PAYMENT ACT

Pay requests authorized in GENERAL CONDITIONS (CONTRACT CLAUSES) clause:

"Payments Under Fixed-Price Construction Contracts", will be paid pursuant to the clause, "Prompt Payment for Construction Contracts". Submit pay requests on ENG Form 93 and 93a, "Payment Estimate-Contract Performance" and "Continuation". All information and substantiation required by the identified contract clauses must be submitted with the ENG Form 93, and the required certification included on the last page of the ENG Form 93a, signed by an authorized contractor official and dated when signed. The designated billing office is the Office of the Area Engineer.

1.11 DAMAGE TO WORK

The responsibility for damage to any part of the permanent work shall be as set forth in the GENERAL CONDITIONS (CONTRACT CLAUSES) clause:

"Permits and Responsibilities." However, if, in the judgment of the Contracting Officer, any part of the permanent work performed by the Contractor is damaged by flood or earthquake, which damage is not due to the failure of the Contractor to take reasonable precautions or to exercise sound engineering and construction practices in the conduct of the work, the Contractor will make the repairs as ordered by the Contracting Officer and full compensation for such repairs will be made at the applicable contract unit or lump sum prices as fixed and established in the contract. If, in the opinion of the Contracting Officer, there are no contract unit or lump sum prices applicable to any part of such work an equitable adjustment pursuant to GENERAL CONDITIONS (CONTRACT CLAUSES) clause: "Changes," of the contract will be made as full compensation for the repairs of that part of the permanent work for which there are no applicable contract unit or lump sum prices. Except as herein provided, damage to all work (including temporary construction), utilities, materials, equipment and plant shall be repaired to the satisfaction of the Contracting Officer at the Contractor's expense, regardless of the cause of such damage.

1.12 AVAILABILITY AND USE OF UTILITY SERVICES

Use of public and private utilities will be as found available. The

SECTION 01 30 00.24 Page 7

Contractor must make his own arrangements for use of public and private utilities.

1.13 QUANTITY SURVEYS

See Section 00 73 00 SUPPLEMENTARY CONDITIONS (SPECIAL CONTRACT REQUIREMENTS) FAR 52.236.16 QUANTITY SURVEYS- Alternate I (APR 1984).

1.14 VARIATIONS IN ESTIMATED QUANTITIES - SUBDIVIDED ITEMS

See Section 00 73 00 SUPPLEMENTARY CONDITIONS (SPECIAL CONTRACT

REQUIREMENTS).

1.15 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Default:

(Fixed-Price Construction)." In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

Jan 14 Feb 12 Mar 8 Apr 4 May 4 Jun 5 Jul 3 Aug 3 Sep 3 Oct 3 Nov 5 Dec 13

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record on the RMS daily CQC

SECTION 01 30 00.24 Page 8 report, any occurrence of adverse weather and resultant impact to normally scheduled work, within 24 hours of the event. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the contractor's scheduled work day. Describe in the RMS daily CQC reports the critical path item that is being affected and provide the critical path activity number(s) from the current schedule. The COR must acknowledge and accept the agreed upon occurrence of each adverse weather delay in RMS for the delays to be considered as adverse weather delays.

At the end of each month, identify the number of actual adverse weather delay days that includes days impacted by actual adverse weather (even if adverse weather occurred in previous month), calculated chronologically from the first to the last day of each month, and recorded as full days.

If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph b. above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Default (Fixed Price Construction)". (ER 415-1-15)

1.16 INSURANCE REQUIRED

In accordance with GENERAL CONDITIONS (CONTRACT CLAUSES) clause:

"Insurance Work on a Government Installation," procure the following minimum insurance for each Task Order:

Type Amount

Workmen's Compensation and Employer's Liability Insurance $100,000

General Liability Insurance $500,000 per occurrence

Automobile Liability Insurance Bodily injury $200,000 per person and $500,000 per occurrence Property damage $ 20,000 per occurrence

(Coverages per FAR 28.307-2)

1.17 CONTRACTOR QUALITY CONTROL (CQC)

See Section 01 45 00.00 10 QUALITY CONTROL.

1.18 NONDOMESTIC CONSTRUCTION MATERIALS

The list of excepted nondomestic construction materials or their components referenced in the Buy American Construction Material Contract Clauses includes the list set forth in paragraph 25.104 of the Federal Acquisition Regulation.

1.19 DAILY WORK SCHEDULES AND WEEKLY COORDINATION MEETINGS

In order to closely coordinate work under this contract, prepare a written agenda/meeting minutes and attend a weekly coordination meeting with the Contracting Officer and Using Service at which time the Contractor must submit for coordination and approval, their proposed daily work schedule for the next two week period. Provide a copy of modifications (MODs), Serial Letters, Requests for Information (RFIs)and

SECTION 01 30 00.24 Page 9 any other information that is needed in the minutes of the meeting.

Include required temporary utility services, time and duration of interruptions, and protection of adjoining areas with the Contractor's proposed 2-week work schedule. At this meeting, the Contractor must also submit their schedule of proposed dates and times of all preparatory inspections to be performed during the next 2 weeks. All schedules shall be in developed in accordance with paragraph: PROGRESS CHARTSCoordination action by the Contracting Officer relative to these schedules will be accomplished during these weekly meetings. Daily reports must be completed and given to the Contracting Officer or Representative within 24 hours of work. All official correspondence such as serial letters and RFIs, with attachments are to be provided in one hardcopy original with original signatures and one electronic (Adobe pdf format) copy by email.

The Government will consider the correspondence to be received when the official hardcopy or electronic copy is received by the designated office.

1.20 PROFIT

a. Use the weighted guidelines method of determining profit on any equitable adjustment change order or modification issued under this contract. The profit factors must be as follows:

Factor Rate Weight Value Degree of Risk 20 See Item Relative difficulty of work 15 b. below Size of Job 15 Period of performance 15 Contractor's investment 5 Assistance by Government 5 Subcontracting 25

b. Based on the circumstances of each procurement action, each of the above factors must be weighted from .03 to .12 as indicated below. Obtain the value by multiplying the rate by the weight. The value column when totaled indicates the fair and reasonable profit percentage under the circumstances of the particular procurement.

(1) Degree of Risk. Where the work involves no risk or the degree of risk is very small, the weighting should be .03; as the degree of risk increases, the weighting should be increased up to a maximum of .12.

Lump sum items will have, generally, a higher weighted value than the unit price items for which quantities are provided. Other things to consider:

the portion of the work to be done by subcontractors, nature of work, where work is to be performed, reasonableness of negotiated costs, amount of labor included in costs, and whether the negotiation is before or after performance of work.

(2) Relative Difficulty of Work. If the work is most difficult and complex, the weighting should be .12 and should be proportionately reduced to .03 on the simplest of jobs. This factor is tied in to some extent with the degree of risk. Some things to consider: the nature of the work, by whom it is to be done, where, and what is the time schedule.

(3) Size of Job. All work not in excess of $100,000 shall be weighted at .12. Work estimated between $100,000 and $5,000,000 shall be proportionately weighted from .12 to .05.

SECTION 01 30 00.24 Page 10

(4) Periods of Performance. Jobs in excess of 24 months are to be weighted at .12. Jobs of lesser duration are to be proportionately weighted to a minimum of .03 for jobs not to exceed 30 days. No weight where additional time not required.

(5) Contractor's Investment. To be weighted from .03 to .12 on the basis of below average, average, and above average. Things to consider: amount of subcontracting, mobilization payment item, Government furnished property, equipment and facilities, and expediting assistance.

(6) Assistance by Government. To be weighted from .12 to .03 on the basis of average to above average. Things to consider: use of Government-owned property, equipment and facilities, and expediting assistance.

(7) Subcontracting. To be weighted inversely proportional to the amount of subcontracting. Where 80 percent or more of the work is to be subcontracted, the weighting is to be .03 and such weighting proportionately increased to .12 where all the work is performed by the Contractor's own forces.

1.21 LABOR CONDITIONS APPLICABLE TO TEMPORARY FACILITIES

It is the position of the Department of Defense that the Davis-Bacon Act, 40 U.S.C. 276a is applicable to temporary facilities such as job headquarters, tool yards, batch plants, borrow pits, sandpits, rock quarries, and similar operations, provided they are dedicated exclusively, or nearly so, to performance of the contract or project, and provided they are adjacent or virtually adjacent to the site of the work and are established after receipt of the proposal or bid.