Sol_140R6020Q0082.pdf

SEE ADDENDUMIS CHECKED

CODE 18a. PAYMENT WILL BE MADE BY

CODE

FACILITYCODE

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN OFFER

OFFEROR

R66

PO Box 1630 Wyoming Area Office Great Plains Region Bureau of Reclamation

CODE 16. ADMINISTERED BYCODE

X

X

X

332618

SIZE STANDARD:

100.00 % FOR:SET ASIDE:UNRESTRICTED ORR60

RFPIFB

10. THIS ACQUISITION ISCODE

RFQ

14. METHOD OF SOLICITATION

13b. RATING

NAICS:

SMALL BUSINESS

08/26/2020 1600 MT

08/12/2020

307-261-5619Audrey Whetham (No collect calls)

INFORMATION CALL:

FOR SOLICITATION 8. OFFER DUE DATE/LOCAL TIMEb. TELEPHONE NUMBER a. NAME

4. ORDER NUMBER3. AWARD/ 6. SOLICITATION

140R6020Q0082

5. SOLICITATION NUMBER

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS 1. REQUISITION NUMBER PAGE OF

1 65 0040488244OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, & 30

Mills WY 82644

TELEPHONE NO.

17a. CONTRACTOR/

Alcova WY 82620 22122 South Kortes Road Alcova Power Plant Bureau of Reclamation

15. DELIVER TO

Billings MT 59107 PO Box 36900 Regional Office Great Plains Region

9. ISSUED BY

7.

2. CONTRACT NO.

EFFECTIVE DATE

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK BELOW

ISSUE DATE

DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

11.

SEE SCHEDULE

12. DISCOUNT TERMS

THIS CONTRACT IS A

RATED ORDER UNDER

DPAS (15 CFR 700)

13a.

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

HUBZONE SMALL

BUSINESS

8(A)

Bureau of Reclamation

WOMEN-OWNED SMALL BUSINESS

(WOSB) ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

24.

AMOUNT

23.

UNIT PRICE

22.

UNIT

21.

QUANTITY

20.

SCHEDULE OF SUPPLIES/SERVICES

19.

ITEM NO.

Legacy Doc #: BOR Delivery: 04/01/2021

00010 Cable Bus Unit 1 118 to KX1A 1 EA

00020 Cable Bus Unit 2 218 to KX2A 1 EA Continued ...

(Use Reverse and/or Attach Additional Sheets as Necessary)

HEREIN, IS ACCEPTED AS TO ITEMS:

X

XX

DATED

Wendy M. New

. YOUR OFFER ON SOLICITATION (BLOCK 5),

INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE SET FORTH

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND DELIVER

ARE

ARE

31c. DATE SIGNED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER (Type or print)

ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY ADDITIONAL

SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1, 52.212-4. FAR 52.212-3 AND 52.212-5 ARE ATTACHED. ADDENDA

26. TOTAL AWARD AMOUNT (For Govt. Use Only)

OFFER

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA - FAR (48 CFR) 53.212

ARE NOT ATTACHED.

ARE NOT ATTACHED.

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

30b. NAME AND TITLE OF SIGNER (Type or print)

30a. SIGNATURE OF OFFEROR/CONTRACTOR

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

25. ACCOUNTING AND APPROPRIATION DATA

29. AWARD OF CONTRACT:

REF.

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE

32c. DATE 32b. SIGNATURE OF AUTHORIZED GOVERNMENT REPRESENTATIVE

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED:

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

40. PAID BY39. S/R VOUCHER NUMBER38. S/R ACCOUNT NUMBER

37. CHECK NUMBER

FINALPARTIAL

36. PAYMENT

FINALPARTIAL

35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER33. SHIP NUMBER

COMPLETE

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

42d. TOTAL CONTAINERS42c. DATE REC'D (YY/MM/DD)

42b. RECEIVED AT (Location)

42a. RECEIVED BY (Print)

41c. DATE41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

STANDARD FORM 1449 (REV. 2/2012) BACK

24.

AMOUNT

23.

UNIT PRICE

22.

UNIT

21.

QUANTITY

20.

SCHEDULE OF SUPPLIES/SERVICES

19.

ITEM NO.

00030 Supply Cable 1 EA

32f. TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT REPRESENTATIVE

65 2 of

Statement of Work for Replacement of the Medium Voltage Cables at the Alcova Power Plant

pg. 1 of 8 pgs.

1) References:

(a) American Society of Mechanical Engineers (ASME)

(i) ASME Y14.1-2005(2010) Decimal Inch Drawing Sheet Size and Format

(ii) ASME BPVC-IX 2007 Boiler and Pressure Vessel Code, Section IX

– Welding and Brazing Qualifications

(b) Institute of Electrical and Electronic Engineers (IEEE)

(i) IEEE 315-1975(1993) Graphic Symbols for Electrical and Electronics

Diagrams (Including Reference Designation Letters)

(ii) IEEE C37.2-2008 Electrical Power System Device Function Numbers, Acronyms, and Contact Designations (iii)IEEE Y32.9-1972(1989) Graphic Symbols for Electrical Wiring and

Layout Diagrams Used in Architecture and Building Construction

(iv) IEEE C2-2007 National Electrical Safety Code (NESC)

(v) IEEE 80-2000 Safety in AC Substation Grounding

(vi) IEEE 81-1983 Measuring Earth Resistivity, Ground Impedance, and Earth

Surface Potentials of a Ground System

(vii) IEEE 142-2007 Grounding of Industrial and Commercial Power

Systems

(viii) IEEE 837-2002 Qualifying Permanent Connections Used in

Substation Grounding

(ix) IEEE 48-1996(2003) Alternating-Current Cable Terminations 2.5 kV

Through 765 kV

(x) IEEE 386-2006 Separable Insulated Connectors Systems for Power

Distribution Systems Above 600 V.

(xi) IEEE 400.2-2004 Field Testing of Shielded Power Cable Systems

Using Very Low Frequency

(xii) IEEE 422-1986 Design and Installation of Cable Systems in

Power Generating Stations.

(xiii) IEEE 525-2007 Design and Installation of Cable Systems in

Substations.

(xiv) IEEE C37.20.1 Metal-Enclosed Low-Voltage (1000 Vac and below, 3200 Vdc and below) Power Circuit Breaker Switchgear

(c) National Electrical Manufacturers Association (NEMA)

(i) NEMA ICS 1-2000(2008) Industrial Control and Systems: General Requirements

pg. 2 of 8 pgs.

(ii) NEMA WC 74-2006 5-46 KV Shielded Power cable for Use in the Transmission and Distribution of Electric Energy

(d) ASTM International (ASTM)

(i) ASTM A 123/A 123M-08 Zinc (Hot-Dip Galvanized) Coatings on Iron and Steel Products

(ii) ASTM A 153/A 153M-05 Zinc Coatings (Hot-Dip) on Iron and Steel

Hardware

1. ASTM B 8-04 Concentric-Lay-Stranded Copper Conductors, Hard, Medium-Hard, or Soft (iii)ASTM B 3-01(2007) Soft or Annealed Copper Wire

(iv) ASTM B 228-04 Concentric-Lay-Stranded Copper-Clad Steel

Conductors

(v) ASTM B 496-04 Compact Round Concentric-Lay-Stranded Copper

Conductors

(e) National Fire Protection Association (NFPA)

(i) NFPA 70-2020 National Electrical Code (NEC)

(f) Underwriters Laboratories (UL)

(i) UL 467-2004 Grounding and Bonding Equipment

(ii) UL 486A-486B-2003 Wire Connectors

(g) Association of Edison Illuminating Companies (AEIC)

(i) AEIC CS8-07 Extruded Dielectric Shielded Power Cables Rated 5

Through 46 kV

2) Fabricate and supply Cable Bus system to run between breaker 118 and transformer

KX1A meeting all the following requirements:

a) 8,000V

b) Continuous current-carrying capacity 1920 amperes.

c) 3phase

d) 60 Hertz

e) Stranded copper cables

f) Basic impulse insulation level (BIL) of 95 kV at 5,370 feet.

g) Approximate length 146’

h) Capable of withstanding a through-fault current of 29,037 asymmetrical amperes (three-phase fault) for approximately 0.005 seconds.

i) Include all accessories required for complete installation. No Asbestos or Lead containing materials may be used.

pg. 3 of 8 pgs.

j) Outdoor bus sections will be exposed to sun and will be subject to temperatures ranging from minus 15 degrees C to plus 30 degrees C.

k) All connection hardware shall be manufacturer’s standard and included in bid price. (U.S.

Bureau of Reclamation (USBR) preference is for bronze bolts, with silicon bronze nuts, washers, and Belleville washers.)

l) Contact surfaces of joints and connections of conductors shall be silver-to-silver.

m) Support insulated 3-phase bus inside housing with appropriate insulating supports.

n) Bus and housing connections shall have slotted holes to allow enough adjustments of connections to permit proper installation and alignment. Provision shall be made for expansion and contraction caused by specified temperature range, and for minimizing vibration under operating conditions. Expansion joints shall not require sliding contacts.

Connectors or splices shall be constructed so there will be no electrolytic effects.

o) Provide all required field splices and connections complete with hardware. Provide suitable re-useable rubber (silicone) insulating covers for all connection joints, including flexible interface connections at the transformer and at the switchgear end of the bus duct assembly. No cold or heat shrinkable products are allowed on the primary conductors inside the bus duct.

p) Bus Duct assembly (metal enclosure) will have the following design criteria:

i) All connections between bus duct segments will be weatherproof.

ii) Removable access covers at bus duct section connections shall be provided so entire panels need not be removed for inspection.

iii) Finish of the cable bus enclosure, mounting supports, deck penetration sealing plates/flanges shall be manufacturer’s standard finish. The color shall be: ANSI 61 gray

q) Bus Termination connections will meet the following criteria:

i) Connectors will attach directly to the X-bushing terminal paddles on the top end, and to bus work in the unit breakers cubicles on the bottom end.

r) See the following drawings for routing

i) 144-D-3977 Alcova Switchyard (Transformer Area Equipment & Grounding Plans)

ii) 144-D-3994 Alcova Power Plant (Transformer Area – Foundations Location Plan)

iii) 144-D-4003 Alcova Power Plant (General Arrangement Floors-EL.5348.92 and EL.

5350.17)

iv) 144-D-4091 Alcova Switchyard (Transformer Area Sections and Details)

v) 144-D-4099 Alcova Power Plant (Transformer Area Tunnels and Trenches)

(i) 144M-703-49-5 Metal clad SWGR Indoor Horizontal Draw out

vi) Route

vii) Transformer

3) Fabricate and supply Cable Bus system to run between breaker 218 and transformer KX2A meeting all the following requirements:

a) 8,000V

b) Continuous current-carrying capacity 1920 amperes.

c) 3phase

d) 60 Hertz

pg. 4 of 8 pgs.

e) Stranded copper cables

f) Basic impulse insulation level (BIL) of 95 kV at 5,370 feet.

g) Approximate length 159’

h) Capable of withstanding a through-fault current of 39,037 asymmetrical amperes (three-phase fault) for approximately 0.005 seconds.

i) Include all accessories required for complete installation. No Asbestos or Lead containing materials may be used.

j) Outdoor bus sections will be exposed to sun and will be subject to temperatures ranging from minus 15 degrees C to plus 30 degrees C.

k) All connection hardware shall be manufacturer’s standard and included in bid price.

(USBR preference is for bronze bolts, with silicon bronze nuts, washers, and Belleville washers.)

l) Contact surfaces of joints and connections of conductors shall be silver-to-silver.

m) Support insulated 3-phase bus inside housing with appropriate insulating supports.

n) Bus and housing connections shall have slotted holes to allow enough adjustments of connections to permit proper installation and alignment. Provision shall be made for expansion and contraction caused by specified temperature range, and for minimizing vibration under operating conditions. Expansion joints shall not require sliding contacts.

Connectors or splices shall be constructed so there will be no electrolytic effects.

o) Provide all required field splices and connections complete with hardware. Provide suitable re-useable rubber (silicone) insulating covers for all connection joints, including flexible interface connections at the transformer and at the switchgear end of the bus duct assembly. No cold or heat shrinkable products are allowed on the primary conductors inside the bus duct.

p) Bus Duct assembly (metal enclosure) will have the following design criteria:

i) All connections between bus duct segments will be weatherproof.

ii) Removable access covers at bus duct section connections shall be provided so entire panels need not be removed for inspection.

iii) Finish of the cable bus enclosure, mounting supports, deck penetration sealing plates/flanges shall be manufacturer’s standard finish. The color shall be: ANSI 61 gray

q) Bus Termination connections will meet the following criteria:

i) Connectors will attach directly to the X-bushing terminal paddles on the top end, and to bus work in the unit breakers cubicles on the bottom end.

r) See the following drawings for routing

i) 144-D-3977 Alcova Switchyard (Transformer Area Equipment & Grounding Plans)

ii) 144-D-3994 Alcova Power Plant (Transformer Area – Foundations Location Plan)

iii) 144-D-4003 Alcova Power Plant (General Arrangement Floors-EL.5348.92 and EL.

5350.17)

iv) 144-D-4091 Alcova Switchyard (Transformer Area Sections and Details)

v) 144-D-4099 Alcova Power Plant (Transformer Area Tunnels and Trenches)

(i) 144M-703-49-5 Metal clad SWGR Indoor Horizontal Draw out

vi) Route

pg. 5 of 8 pgs.

vii) Transformer

4) Supply cable, termination kits and compression lugs to run between breaker 118 and disconnect 113 meeting all the following requirements:

a) 8,000V

b) Continuous current-carrying capacity 88 amperes.

c) 3phase

d) 60 Hertz

e) Stranded copper cables

f) Basic impulse insulation level (BIL) of 95 kV at 5,370 feet.

g) Approximate length 110’

h) Capable of withstanding a through-fault current of 3,716 asymmetrical amperes (double-line to ground fault fault) for approximately 2.6 seconds.

i) Temperature rating of the cable shall be 90 degrees C.

j) Include all accessories required for complete installation. No Asbestos or Lead containing materials may be used.

k) All connection hardware shall be included in bid price. (USBR preference is for bronze bolts, with silicon bronze nuts, washers, and Belleville washers.)

l) See the following drawings for routing

i) 144-D-4003 Alcova Power Plant (General Arrangement Floors-EL.5348.92 and EL.

5350.17)

ii) 144M-703-49-5 Metal clad SWGR Indoor Horizontal Draw out

5) A design submittal will be required after award and before fabrication can begin. Bids should include pricing for submittals.

6) All bus provided shall have successfully passed factory design and production testing in accordance with ANSI C37.23. Copies of all documentation from tests performed during construction, quality assurance and acceptance shall be provided for review before any payment is made.

7) Complete design and assembly drawings will be provided with the shipment of materials.

a) All drawings will be in USBR format and conform to USBR standards

i) Drawings, general:

(1) Device designations and symbols:

(a) Conform to IEEE 315, IEEE C37.2, IEEE Y32.9, and NEMA ICS-1.

(b) As indicated on Standard Drawings 104-D-757 and 104-D-1150.

(2) Size: D-size prints as defined in ASME Y14.1 made from original drawings.

(3) Indicate changes on revised drawings to distinguish them from previous submittals. Describe reasons for significant changes in submittal letters.

pg. 6 of 8 pgs.

ii) Approval Drawings in Government Format:

(1) Drawings, general:

(a) Device designations and symbols:

(i) Conform to IEEE 315, IEEE C37.2, IEEE Y32.9, and NEMA ICS-1.

(ii) As indicated on Standard Drawings 104-D-757 and 104-D-1150.

(b) Size: D-size prints as defined in ASME Y14.1 made from original drawings.

(c) Indicate changes on revised drawings to distinguish them from previous versions of the drawing. Describe reasons for significant changes.

(2) Approval Drawings in Government Format:

(a) Furnish with Government title block and in form as indicated on Standard

Drawing 40-D-7102.

(b) Government will provide specific title block information when drawings are submitted.

(c) Government may revise conductor or device designations on Contractor’s drawings when drawings are approved at no change in contract price or completion time.

(3) Schematic Diagrams:

(a) In accordance with Standard Drawing 104-D-1150.

(b) Format:

(i) Vertical ladder diagram form.

(ii) Label rungs with sequential numbers starting with number 1.

(iii)Locate rung numbers adjacent and to left of associated rung.

(iv) Provide unique rung numbers for each circuit.

(c) Conductor designations: As indicated on drawings.

(d) Indicate device terminal designations.

(e) Indicate functional operation.

(f) Describe unusual or nonstandard operation.

(g) Indicate ratings and/or values of devices.

(h) Indicate cross-referencing between other schematics and wiring diagrams.

(i) Conductor designations: As indicated on drawings or as developed by

Contractor. Contractor-developed conductor designations shall consist of:

(i) Circuit prefix

(ii) Rung number

pg. 7 of 8 pgs.

(iii)Unique rung wire letter such as 5P15C (“5”-Unit Number, “P”- Protection Circuit, “15”-Rung Number, “C”-Unique Rung Wire Letter).

(4) Wiring Diagram Drawings:

(i) Match with schematic diagram drawings.

(ii) Indicate point-to-point wiring in accordance with Standard Drawing 104-

D-1165.

(iii)Indicate equipment as mounted on back, side, swing, and door panels.

Show panel as viewed from wiring side of panel.

(iv) Identify each item of equipment with designation indicated on schematic diagram.

(v) Indicate wiring of devices and items of equipment including terminal number.

(vi) Indicate cables, cable and individual wire designations, and connections to external circuits. Government will show cables, cable and individual wire designations, and connections when wiring diagrams are first submitted for approval. Provide room on drawings for Government to add cables.

(vii) Cable designations: Like designations on Standard Drawing 104-D-1165.

(viii) Show no more than one panel per drawing.

(5) Sample Wiring Diagram: Sample of actual wiring diagram that will be submitted as check print and final drawing.

(6) Approval Drawings and Data in Manufacturer’s Format:

(a) General: Furnish with manufacturer’s standard format, except as noted below.

(b) Equipment Layout Drawings:

(i) Indicate dimensions of equipment.

(ii) Indicate location of devices and items of equipment including nameplates, terminal blocks, wiring ducts, bus, conduit entries, and other features in their relative physical location.

(iii)Indicate method of securing equipment to deck, floor, or wall.

(iv) Identify each device and item of equipment with a bill of material reference number.

(7) Bill of Material List:

(i) Provide information on manufacturer, style, type, rating, quantity, and other identifying information for each device or item of equipment.

(ii) Provide unique reference number for each device or item of equipment listed on bill of material.

pg. 8 of 8 pgs.

(8) Nameplate Lists: Provide information on type of material, size, and engraved lettering.

(9) Manufacturer’s Technical Catalog Data:

(i) Provide technical data for each device or item of equipment.

(ii) Include manufacturer’s name and address; catalog number, type, style, or model number; electrical ratings; and dimensions.

(iii)Where several items are listed on same sheet, indicate items being submitted for approval.

(iv) Demonstrate proposed device or item of equipment meets specifications requirements.

(v) Mark catalog data sheet with appropriate bill of material (BOM) item number.

(vi) Assemble catalog data sheet into one enclosing cover with bill of material

(BOM) index,

(10) Check Prints:

(a) Schematic and wiring diagrams which indicate “As Built” condition of equipment at time of shipment.

(b) Mark with changes and revisions made during installation and checkout of equipment.

(c) Maintain separate, identical set of prints for use in preparing final drawings.

8) Test Reports:

a) Typed, 8 1/2- by 11-inch sheets.

b) Certified.

c) Submit multi-page reports in bound folder or three-ring binder.

d) Operation and Maintenance Instructions Books:

i) Electronic copies:

(1) Adobe Acrobat (.pdf) format on CD-ROM discs.

(2) Conform to print copies.

(3) Bookmark file(s) to aid in navigating.

ii) Provide following items:

(1) Index sheet at front of each book which provides page or index tab number information for each device or item of equipment in book.

(2) Manufacturer’s operation and maintenance procedures; installation details, as necessary; and catalog data sheets for each device or item of equipment.

(3) List of recommended spare parts and components.

pg. 9 of 8 pgs.

(4) Complete parts lists for all replacement parts.

(5) Copies of all factory test reports.

(6) Copies of bills of materials

(7) Copies of all drawings.

(8) Revised to reflect approval comments

9) Installation will be completed by local forces under the guidance of the manufacturer’s on-site representative.

10) Installation will start on 1/5/2021.

11) Manufacturer’s representative will need to be on-site during the installation between

07:00 and 17:30 MST.

12) Installation must be completed by 4/1/2021.

13) All parts will carry a 5-year manufacturer’s warranty starting on the day the

Government accepts delivery of all the finished products.

F - Deliveries or Performance 52.242-15 Stop Work Order (Aug 1989) 52.247-34 F.o.b. Destination (Nov 1991) G - Contract Administration Data DOI - AAAP 0028 Electronic Invoicing and Payment Requirements - Invoice Processing Platform (IPP) (Apr 2013) H - Special Contract Requirements GP-7 Site Security (Feb 2004) I - Contract Clauses 52.252-2 Clauses Incorporated by Reference 52.204-21 Basic Safeguarding of Covered Contractor Information Systems (Jun 2016) 52.212-5 Contract Terms and Conditions Required to Implement Statutes or Executive Order Commercial...

Items (Jun 2020) 52.219-6 Notice of Total Small Business Set-Aside (Deviation 2019-01) (Jul 2019) 1452.228-70 Liability Insurance (July 1996) WBR 1452.223-81 Safety and Health - Bureau of Reclamation WBR 1452.237-80 Security Requirements - Bureau of Reclamation J - List of Documents, Exhibits and Other Attachments K - Representations, Certifications, and Other Statements of Bidders 52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment (Dec 2019) 52.212-3 Offeror Representations and Certifications - Commercial Items (Jun 2020) 52.225-18 Place of Manufacture (Aug 2018) WBR 1452.223-82 Protecting Federal Employees and the Public from Exposure to Tobacco Smoke in the...

Workplace - Bureau of Reclamation (Oct 1998) L - Instructions,Conditions, and Notices to Bidders 52.204-7 System for award Management (Oct 2018) 52.204-16 Commercial and Government Entity Code Reporting (Jul 2016) 52.204-22 Alternative Line Item Proposal (Jan 2017) 52.212-1 Instructions to Offerors - Commercial Items (Deviation) (Jun 2020) 1452.215-71 Use and Disclosure of Proposal Information - Department of the Interior (Apr 1984) M - Evaluation Factors for Award 52.212-2 Evaluation - Commercial Items (Oct 2014) WBR 1452.225-82 Notice of World Trade Organization Government Procurement Agreement Evaluations Bureau of Reclamation (May 2005)

F - Deliveries or Performance

52.242-15 Stop-Work Order (AUG 1989)

(a) The Contracting Officer may, at any time, by written order to the Contractor, require the Contractor to stop all, or any part, of the work called for by this contract for a period of 90 days after the order is delivered to the Contractor, and for any further period to which the parties may agree. The order shall be specifically identified as a stop-work order issued under this clause. Upon receipt of the order, the Contractor shall immediately comply with its terms and take all reasonable steps to minimize the incurrence of costs allocable to the work covered by the order during the period of work stoppage. Within a period of 90 days after a stop-work order is delivered to the Contractor, or within any extension of that period to which the parties shall have agreed, the Contracting Officer shall either -

(1) Cancel the stop-work order; or

(2) Terminate the work covered by the order as provided in the Default, or the Termination for Convenience of the Government, clause of this contract.

(b) If a stop-work order issued under this clause is canceled or the period of the order or any extension thereof expires, the Contractor shall resume work. The Contracting Officer shall make an equitable adjustment in the delivery schedule or contract price, or both, and the contract shall be modified, in writing, accordingly, if -

(1) The stop-work order results in an increase in the time required for, or in the Contractor's cost properly allocable to, the performance of any part of this contract; and

(2) The Contractor asserts its right to the adjustment within 30 days after the end of the period of work stoppage; provided, that, if the Contracting Officer decides the facts justify the action, the Contracting Officer may receive and act upon a proposal submitted at any time before final payment under this contract.

(c) If a stop-work order is not canceled and the work covered by the order is terminated for the convenience of the Government, the Contracting Officer shall allow reasonable costs resulting from the stop-work order in arriving at the termination settlement.

(d) If a stop-work order is not canceled and the work covered by the order is terminated for default, the Contracting Officer shall allow, by equitable adjustment or otherwise, reasonable costs resulting from the stop-work order.

(End of clause)

52.247-34 F.o.b. Destination (JAN 1991)

(a) The term f.o.b. destination, as used in this clause, means -

(1) Free of expense to the Government, on board the carrier's conveyance, at a specified delivery point where the consignee's facility (plant, warehouse, store, lot, or other location to which shipment can be made) is located; and

(2) Supplies shall be delivered to the destination consignee's wharf (if destination is a port city and supplies are for export), warehouse unloading platform, or receiving dock, at the expense of the Contractor. The Government shall not be liable for any delivery, storage, demurrage, accessorial, or other charges involved before the actual delivery (or "constructive placement" as defined in carrier tariffs) or the supplies to the destination, unless such charges are caused by an act or order of the Government acting in its contractual capacity. If rail carrier is used, supplies shall be delivered to the specified unloading platform of the consignee.

If motor carrier (including "piggyback") is used, supplies shall be delivered to truck tailgate at the unloading platform of the consignee, except when the supplies delivered meet the requirements of Item 568 of the National Motor Freight Classification for "heavy or bulky freight." When supplies meeting the requirements of the referenced Item 568 are delivered, unloading (including movement to the tailgate) shall be performed by the consignee, with assistance from the truck driver, if requested. If the contractor uses rail carrier or freight forwarder for less than carload shipments, the contractor shall ensure that the carrier will furnish tailgate delivery, when required, if transfer to truck is required to complete delivery to consignee.

(b) The Contractor shall -

(1)(i) Pack and mark the shipment to comply with contract specifications; or

(ii) In the absence of specifications, prepare the shipment in conformance with carrier requirements;

(2) Prepare and distribute commercial bills of lading;

(3) Deliver the shipment in good order and condition to the point of delivery specified in the contract;

(4) Be responsible for any loss of and/or damage to the goods occurring before receipt of the shipment by the consignee at the delivery point specified in the contract;

(5) Furnish a delivery schedule and designate the mode of delivering carrier; and

(6) Pay and bear all charges to the specified point of delivery.

(End of clause)

G - Contract Administration Data

DOI – AAAP 0028 Electronic Invoicing and Payment Requirements - Invoice Processing Platform (IPP) (April 2013)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor.

To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

• The Contractor shall submit an electronic copy of the actual invoice to Audrey Whetham at awhetham@usbr.gov. Once the Government has received and accepted the line items on the purchase order, then the Contract Specialist will sign the invoice and send to the vendor to submit the signed invoice into IPP for payment processing.

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3 - 5 business days of the contract award date.

Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Local Clause) http://www.ipp.gov/ mailto:awhetham@usbr.gov mailto:ippgroup@bos.frb.org

H - Special Contract Requirements

GP-7 Site Security (Feb 2004)

(a) At least 10 days prior to arriving at the worksite, the contractor shall submit a list to the Contracting Officer (CO) of the names of all contractor employees that will be on-site initially. Additional employee names must be provided to CO prior to additional employees arriving on-site. The list(s) must include a legible photocopy of each employee's driver's license. In the absence of a driver's license, provide an alternate source of official identification that includes: First, Middle, Last Name; date and place of birth; and place of residence. All contractor employees must be U.S. citizens or have a valid Immigrant Visa Number, Permanent Resident Card or Resident Alien Card authorizing them to work in the U.S.

(b) The contractor is hereby notified of the following:

The Government may perform background checks on any or all workers. If the Government performs background checks, workers shall be required to submit additional personal and work history information.

The Government may deny access to any worker at any time, based on information discovered during the background check. Information related to criminal matters (e.g., outstanding arrest warrants) that is discovered during a background check will be reported to the appropriate authorities.

(c) At least 10 days prior to arriving at the worksite, the contractor shall submit an initial list to CO of all contractor vehicles to be brought to the worksite. A supplemental list shall be provided to CO before additional vehicles are brought on-site. For each vehicle the list shall include the year, make, model and color; and license plate numbers and state of issuance when applicable.

(d) Reclamation will provide keys and/or locks to gates and doors, etc. as necessary for contractor personnel to access points within the scope of this project. Any duplication of keys or substitution of locks is strictly prohibited. Contractor shall be accountable to secure and return all keys and/or locks provided by the Government, and shall immediately notify the CO of the loss or misplacement of any provided key and/or lock.

(e) All drawings, plans, and other sensitive documents issued to the contractor shall remain under their direct control at all times. These sensitive documents shall not be reproduced or copied or further distributed without approval from CO.

(f) All firearms and dangerous weapons are prohibited in Federal facilities for all persons not specifically authorized by Title 18, United States Code, Section 930. A license to carry a concealed firearm issued under state law is not an exception to this prohibition. This prohibition shall apply to all areas within the construction worksite and contractor use area.

(g) In case of an emergency situation, the contractor shall follow emergency instructions provided by CO.

(h) Unless exempted by CO, the contractor shall comply with all security requirements already in place at the site, i.e., those security requirements that have been adopted as standard operating procedures at the site.

(i) The contractor shall report to the CO all incidents of criminal and/or suspicious activity observed by their employees on or adjacent to the construction site.

(j) Reclamation reserves the right to change or modify security requirements as mandated by the Office of Homeland Security and/or as deemed necessary by Reclamation security staff.

(k) Any violations of Reclamation security requirements and/or restrictions may result in Reclamation denying the contractor personnel access to the worksite.

(l) Cost - Include cost incurred for General Security Requirements in prices offered in the schedule for other items of work. In the event Reclamation changes of modifies these requirements after the contract is in place, increased Contractor costs will be paid for under the Contract Change Clause.

(m) Contractor shall notify the CO at least 24 hours in advance of any material delivery to worksite. Material may only be delivered to areas approved by CO.

I - Contract Clauses

52.252-2 Clauses Incorporated by Reference. (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): FAR Clauses - https://www.acquisition.gov/far/

Clause Title Date 52.204-13 System for Award Management Maintenance Oct 2018 52.204-18 Commercial and Government Entity Code Maintenance Aug 2020 52.204-19 Incorporation by Reference of Representations and Certifications Dec 2014 52.209-3 First Article Approval – Contractor Testing Alternate II Sept 1989 52.212-4 Contract Terms and Conditions – Commercial Items Oct 2018 52.232-1 Payments Apr 1984 52.232-39 Unenforceability of Unauthorized Obligations Jun 2013 52.232-40 Providing Accelerated Payments to Small Business Subcontractors Dec 2013 52.233-1 Disputes May 2014 52.243-1 Changes-Fixed-Price Aug 1987 52.246-2 Inspection of Supplies-Fixed Price Aug 1996 52.246-15 Certificate of Conformance Apr 1984 52.246-18 Warranty of Supplies of a Complex Nature Alternate IV Apr 1984 52.249-1 Termination for Convenience of the Government (Fixed-Price) (Short Form) Apr 1984 52.249-8 Default (Fixed-Price Supply and Service Apr 1984

(End of clause)

52.204-21 Basic Safeguarding of Covered Contractor Information Systems (JUN 2016)

(a) Definitions. As used in this clause-

Covered contractor information system means an information system that is owned or operated by a contractor that processes, stores, or transmits Federal contract information.

Federal contract information means information, not intended for public release, that is provided by or generated for the Government under a contract to develop or deliver a product or service to the Government, but not including information provided by the Government to the public (such as on public Web sites) or simple transactional information, such as necessary to process payments.

https://www.acquisition.gov/far/

Information means any communication or representation of knowledge such as facts, data, or opinions, in any medium or form, including textual, numerical, graphic, cartographic, narrative, or audiovisual (Committee on National Security Systems Instruction (CNSSI) 4009).

Information system means a discrete set of information resources organized for the collection, processing, maintenance, use, sharing, dissemination, or disposition of information (44 U.S.C. 3502).

Safeguarding means measures or controls that are prescribed to protect information systems.

(b) Safeguarding requirements and procedures. (1) The Contractor shall apply the following basic safeguarding requirements and procedures to protect covered contractor information systems. Requirements and procedures for basic safeguarding of covered contractor information systems shall include, at a minimum, the following security controls:

(i) Limit information system access to authorized users, processes acting on behalf of authorized users, or devices (including other information systems).

(ii) Limit information system access to the types of transactions and functions that authorized users are permitted to execute.

(iii) Verify and control/limit connections to and use of external information systems.

(iv) Control information posted or processed on publicly accessible information systems.

(v) Identify information system users, processes acting on behalf of users, or devices.

(vi) Authenticate (or verify) the identities of those users, processes, or devices, as a prerequisite to allowing access to organizational information systems.

(vii) Sanitize or destroy information system media containing Federal Contract Information before disposal or release for reuse.

(viii) Limit physical access to organizational information systems, equipment, and the respective operating environments to authorized individuals.

(ix) Escort visitors and monitor visitor activity; maintain audit logs of physical access; and control and manage physical access devices.

(x) Monitor, control, and protect organizational communications (i.e., information transmitted or received by organizational information systems) at the external boundaries and key internal boundaries of the information systems.

(xi) Implement subnetworks for publicly accessible system components that are physically or logically separated from internal networks.

(xii) Identify, report, and correct information and information system flaws in a timely manner.

(xiii) Provide protection from malicious code at appropriate locations within organizational information systems.

(xiv) Update malicious code protection mechanisms when new releases are available.

(xv) Perform periodic scans of the information system and real-time scans of files from external sources as files are downloaded, opened, or executed.

(2) Other requirements. This clause does not relieve the Contractor of any other specific safeguarding requirements specified by Federal agencies and departments relating to covered contractor information systems generally or other Federal safeguarding requirements for controlled unclassified information (CUI) as established by Executive Order 13556.

(c) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (c), in subcontracts under this contract (including subcontracts for the acquisition of commercial items, other than commercially available off-the-shelf items), in which the subcontractor may have Federal contract information residing in or transiting through its information system.

(End of clause)

52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders - Commercial Items (JUL 2020)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (Aug 2019) (Section 889(a)(1)(A) of Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015).

(5) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).

(6) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Public Laws 108-77 and 108-78 ( 19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

__ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (June 2020), with Alternate I (Oct 1995) ( 41U.S.C.4704 and 10 U.S.C. 2402).

__ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Jun 2020) (41 U.S.C. 3509)).

__ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

__ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Jun 2020) (Pub. L.

109-282) ( 31 U.S.C. 6101 note).

https://www.acquisition.gov/content/52203-19-prohibition-requiring-certain-internal-confidentiality-agreements-or-statements#i52_203-19 https://www.acquisition.gov/content/52204-23-prohibition-contracting-hardware-software-and-services-developed-or-provided-kaspersky-lab-and-other-covered-entities#id189A70O0P1N https://www.acquisition.gov/content/52204-25-prohibition-contracting-certain-telecommunications-and-video-surveillance-services-or-equipment#id1989I600I4C https://www.acquisition.gov/content/52209-10-prohibition-contracting-inverted-domestic-corporations#i1062680 https://www.acquisition.gov/content/52233-3-protest-after-award#i1048661 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/content/52233-4-applicable-law-breach-contract-claim#i1048698 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/content/52203-6-restrictions-subcontractor-sales-government#i1063319 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/content/52203-13-contractor-code-business-ethics-and-conduct#i1063504 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/content/52203-15-whistleblower-protections-under-american-recovery-and-reinvestment-act-2009#i1063607 https://www.acquisition.gov/content/52204-10-reporting-executive-compensation-and-first-tier-subcontract-awards#i1064087 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section6101&num=0&edition=prelim

__ (5) [Reserved].

__ (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div.

C).

__ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

__ (8) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Jun 2020) (31 U.S.C. 6101 note).

__ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Oct 2018) (41 U.S.C. 2313).

__ (10) [Reserved]

__ (11)

(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Mar 2020) (15 U.S.C. 657a).

__ (ii) Alternate I (Mar 2020) of 52.219-3.

__ (12)

(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Mar 2020) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

__ (ii) Alternate I (Mar 2020) of 52.219-4

__ (13) [Reserved]

-X- (14)

(i) 52.219-6, Notice of Total Small Business Set-Aside (Mar 2020) of 52.219-6 (15 U.S.C. 644).

__ (ii) Alternate I (Mar 2020) of 52.219-6 .

__ (15)

(i) 52.219-7, Notice of Partial Small Business Set-Aside (Mar 2020) (15 U.S.C. 644).

__ (ii) Alternate I (Mar 2020) of 52.219-7.

__ (16) 52.219-8, Utilization of Small Business Concerns (Oct 2018) (15 U.S.C. 637(d)(2) and (3)).

__ (17)

(i) 52.219-9, Small Business Subcontracting Plan (Jun 2020) (15 U.S.C. 637(d)(4)).

__ (ii) Alternate I (Nov 2016) of 52.219-9.

__ (iii) Alternate II (Nov 2016) of 52.219-9.

https://www.acquisition.gov/content/52204-14-service-contract-reporting-requirements#i1064214 https://www.acquisition.gov/content/52204-15-service-contract-reporting-requirements-indefinite-delivery-contracts#i1064243 https://www.acquisition.gov/content/52209-6-protecting-government%E2%80%99s-interest-when-subcontracting-contractors-debarred-suspended-or-proposed-debarment#i1062590 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section6101&num=0&edition=prelim https://www.acquisition.gov/content/52209-9-updates-publicly-available-information-regarding-responsibility-matters#i1062651 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title41-section2313&num=0&edition=prelim https://www.acquisition.gov/content/52219-3-notice-hubzone-set-aside-or-sole-source-award#i1057314 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title15-section637a&num=0&edition=prelim https://www.acquisition.gov/content/52219-3-notice-hubzone-set-aside-or-sole-source-award#i1057314 https://www.acquisition.gov/content/52219-4-notice-price-evaluation-preference-hubzone-small-business-concerns#i1057352 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/content/52219-4-notice-price-evaluation-preference-hubzone-small-business-concerns#i1057352 https://www.acquisition.gov/content/52219-6-notice-total-small-business-set-aside#i1057393 https://www.acquisition.gov/content/52219-6-notice-total-small-business-set-aside#i1057393 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/content/52219-6-notice-total-small-business-set-aside#i1057393 https://www.acquisition.gov/content/52219-7-notice-partial-small-business-set-aside#i1057419 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/content/52219-7-notice-partial-small-business-set-aside#i1057419 https://www.acquisition.gov/content/52219-8-utilization-small-business-concerns#i52_219-8 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/content/52219-9-small-business-subcontracting-plan#i52_219-9 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/content/52219-9-small-business-subcontracting-plan#i52_219-9 https://www.acquisition.gov/content/52219-9-small-business-subcontracting-plan#i52_219-9

__ (iv)Alternate III (Jun 2020) of 52.219-9.

__ (v)Alternate IV (Jun 2020) of 52.219-9

__ (18)

(i) 52.219-13, Notice of Set-Aside of Orders (Mar 2020) (15 U.S.C. 644(r)).

(ii) Alternate I (Mar 2020) of 52.219-13.

__ (19) 52.219-14, Limitations on Subcontracting (Mar 2020) (15 U.S.C. 637(a)(14)).

__ (20) 52.219-16, Liquidated Damages-Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)).

__ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Mar 2020) (15 U.S.C. 657f).

-X- (22)

(i) 52.219-28, Post Award Small Business Program Rerepresentation (May 2020) (15 U.S.C. 632(a)(2))

(ii) Alternate I (MAR 2020) of 52.219-28.

__ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Mar 2020) (15 U.S.C. 637(m)).

__ (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Mar2020) (15 U.S.C. 637(m)).

__ (25) 52.219-32, Orders Issued Directly Under Small Business Reserves (Mar 2020) (15 U.S.C. 644(r)).

__ (26) 52.219-33, Nonmanufacturer Rule (Mar 2020) (15U.S.C. 637(a)(17)).

-X- (27) 52.222-3, Convict Labor (Jun 2003) (E.O.11755).

-X- (28) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Jan2020) (E.O.13126).

-X- (29) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

-X- (30)

(i) 52.222-26, Equal Opportunity (Sep 2016) (E.O.11246).

__ (ii) Alternate I (Feb 1999) of 52.222-26.

__ (31)

(i) 52.222-35, Equal Opportunity for Veterans (Jun 2020) (38 U.S.C. 4212).

__ (ii) Alternate I (Jul 2014) of 52.222-35.

https://www.acquisition.gov/content/52219-9-small-business-subcontracting-plan#i52_219-9 https://www.acquisition.gov/content/52219-9-small-business-subcontracting-plan#i52_219-9 https://www.acquisition.gov/content/52219-13-notice-set-aside-orders#i1057715 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/content/52219-13-notice-set-aside-orders#i1057715 https://www.acquisition.gov/content/52219-14-limitations-subcontracting#i1057730 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/content/52219-16-liquidated-damages-subcontracting-plan#i1057758 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/content/52219-27-notice-service-disabled-veteran-owned-small-business-set-aside#i1057823 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/content/52219-28-post-award-small-business-program-rerepresentation#i1057874 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/content/52219-28-post-award-small-business-program-rerepresentation#i1057874 https://www.acquisition.gov/content/52219-29-notice-set-aside-or-sole-source-award-economically-disadvantaged-women-owned-small-business-concerns#i1057902 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3…