RFP 25-1370 PK Buttress No. 8 Conduit Relocation Services.pdf

Request for Proposals

8/14/2025 RFP No. 25-1370

Dear Prospective Respondent:

Statements of Qualifications hereafter referred to Request for Proposals (RFP or Proposal(s)) will be received by the Purchasing Agent or other designee of the Brazos River Authority no later than 10:00 AM, Tuesday, September 16, 2025 for PK Buttress No. 8 Conduit Relocation Services. All qualified firms including Small, Minority, Women Owned Businesses and Historically Underutilized Businesses are encouraged to submit proposals in response to this request.

Proposals must be submitted and received no later than the due date and time specified. Any Proposal received later than the specified time, shall not be considered. The BRA is NOT responsible for ensuring the delivery of Proposals.

Refer to Section 15. Delivery of Proposal Submittals for instructions on submitting a response to this solicitation.

Proposal must be clearly identified as follows on the outside of the sealed physical submission. The BRA shall not be responsible for submissions that are not properly identified. Proper identification of Respondent’s proposal is the sole responsibility of the Respondent and failure to do so may result in the submission not being included in the proposal opening:

RFP TITLE: PK Buttress No. 8 Conduit Relocation Services

RFP NO: 25-1370

RFP DUE DATE: 10:00 AM, Tuesday, September 16, 2025

The BRA shall have the right to accept or reject any or all Proposals, or any part thereof, and to waive any technicalities in the interest of the BRA.

BRA will evaluate all relevant, health, safety and business factors on all solicitations to determine when to initiate a notice to proceed on all projects, delivery of goods and/or services or procurement of construction related services to best attempt to balance BRA needs and to protect the health and safety of BRA employees, the employees of respondents and the public at large.

Sincerely, Victor Venegas Purchasing Agent

4600 Cobbs Drive • Waco, Texas 76710 254-761-3166

RFP No. 25-1370 PK Buttress No. 8 Conduit Relocation Services Page 2 of 12

SUPPLIER DIVERSITY PURCHASING POLICY

The Brazos River Authority (BRA) will ensure that purchases of equipment, materials, supplies, and/or services conform with Texas Procurement law as applicable to the BRA, are cost effective, and contribute to the competitiveness of the BRA and its customers.

Procurement activities will be conducted in an open and fair manner with equal opportunity provided to all qualified parties. The BRA will provide equal contracting opportunities as provided by all applicable State and Federal laws to small business enterprises, Historically Underutilized Businesses and Disadvantaged Business enterprises.

GENERAL INSTRUCTIONS TO RESPONDENTS

The Work consists of the furnishing of all labor, materials, services, equipment, and appliances required for the delivery and the supplying of products and/or services as described herein and in the contract documents.

1. PROPOSAL SUBMISSION: Proposals must be received no later than the Proposal opening date and time specified above. All Proposals received after closing time will not be considered.

A. To be considered as eligible, a Respondent shall have complied with all legal requirements to permit them to operate in the State of Texas.

B. Proposals must be submitted electronically, mailed or hand delivered to be considered.

2. WITHDRAWAL OF PROPOSALS: No Proposal may be withdrawn for a period of ninety (90) days after Proposal opening, except by: 1) mutual consent of the BRA and Respondent; or 2) a previously submitted Proposals may be withdrawn upon written request received from Respondent prior to time established for receipt of Proposals.

3. SIGNATURE ON PROPOSALS: To be valid, Proposals must be signed by an authorized person. By such signature, Respondent agrees to strictly abide by the terms, conditions, and Scope of Services embodied in this Request for Proposal.

4. EXAMINATION OF PROPOSAL DOCUMENTS: Before submitting a Proposal, all Respondents shall examine the complete Proposal documents, including Proposal Notice, Instruction to Respondent, and Scope of Services, all of which are part of the Proposal documents.

5. ADDENDA: Unless otherwise stated in the Proposal, answers to all questions, inquiries, and request for additional information will be issued in the form of Addenda. During the Proposal period, prospective Respondent may be advised by Addenda of additions, deletions from, or changes in the requirements of the Proposal documents. The BRA will not be responsible for the authenticity or correctness of oral interpretations of the Proposal documents or for information obtained in any other manner than through the media of Addenda. Receipt of each Addendum shall be acknowledged by the Respondent.

Any questions concerning this Proposal should be submitted on https://www.bidnetdirect.com/texas/brazosriverauthority no later than five (5) days prior to the opening of the Proposal. This is to allow the BRA sufficient time to respond to inquiries and provide information to all interested Respondents by Addendum. Unless otherwise stated in the Proposal, Addenda will be posted on https://www.bidnetdirect.com/texas/brazosriverauthority .

Respondent is responsible for checking https://www.bidnetdirect.com/texas/brazosriverauthority for updates and Addenda until the time at which the submission is due. Failure to respond to all requirements, including those Addenda, shall be grounds for rejection of your Proposal.

6. TAXATION: The BRA is exempt under the Texas Sales Tax and Use Tax Laws, and the Respondent shall not include such taxes in the Proposal.

7. QUALIFICATION OF RESPONDENTS: The BRA reserves the right to reject any Proposal if the evidence submitted by, or investigation of, such Respondent fails to satisfy the BRA that such

Respondent is properly qualified to carry out the obligations of the contract and to complete the Services contemplated herein.

Conditional Proposals will not be accepted.

8. CONSIDERATION OF PROPOSALS: Unless stated otherwise in the Advertisement or Request for Proposal, the properly identified Proposals received on time will be opened publicly and only the names of the Respondent will be read aloud. Respondents are invited to be present.

9. COMPLIANCE WITH SCOPE OF SERVICES AND RIGHT OF

SELECTION: The Respondent shall abide by and comply with the true intent of the scope of services and not take advantage of any unintentional error or omission.

10. DEVIATION FROM SCOPE OF SERVICES: All deviations from the scope of services must be noted in detail by the Respondent, in writing, at the time of submittal of the formal Proposal. The absence of a written list of deviations at the time of submittal of the Proposal will be considered acceptance of the Scope of Services as written.

Any deviations from the Scope of Services as written not previously submitted, as required by the above, will be grounds for rejection of the material and/or item when delivered.

In case of ambiguity or lack of clarity, the BRA reserves the right to consider the most advantageous Proposal or reject the Proposal.

11. REPRESENTATIONS: By execution and submission of this Proposal, the Respondent hereby represents and warrants to the BRA that Respondent has read and understands the Proposal Documents and this Proposal is made in accordance with the Proposal Documents.

12. INDEMNIFICATION:

THE RESPONDENT SHALL COMPLY WITH THE REQUIREMENTS

OF ALL APPLICABLE LAWS, RULES, AND REGULATIONS AND

SHALL EXONERATE, INDEMNIFY AND HOLD HARMLESS THE

BRA FROM ANY AND ALL LIABILITY OR DAMAGES RESULTING

FROM FAILURE TO DO SO.

IN ADDITION, THE RESPONDENT AGREES TO INDEMNIFY,

KEEP, SAVE AND HOLD THE BRA HARMLESS FROM ANY AND

ALL ACTIONS, LIABILITIES, DAMAGES, JUDGMENTS, COSTS

AND EXPENSES INCLUDING REASONABLE ATTORNEY’S FEES,

IN CASE AN ACTION IS FILED OR DOES IN ANY WAY ACCRUE

AGAINST THE BRA, ITS OFFICIALS, OFFICERS, AND

EMPLOYEES IN CONSEQUENCE OF THE AWARDED CONTRACT

FOR ANY NEGLIGENT ACT OR OMISSION OF THE RESPONDENT

IN THE PROVISION OF SERVICES UNDER THE AWARDED

CONTRACT, OR THAT MAY RESULT FROM THE CARELESSNESS

OR LACK OF SKILL OF THE RESPONDENT OR THE

RESPONDENT’S OFFICERS, AGENT, CONTRACTORS, ASSIGNS

OR EMPLOYEES. IN THE EVENT A JUDGMENT IS RECOVERED

AGAINST THE BRA FOR ANY SUCH LIABILITY, COSTS OR

EXPENSES, SUCH JUDGMENT SHALL BE CONCLUSIVE

AGAINST THE RESPONDENT.

IT IS SPECIFICALLY UNDERSTOOD AND AGREED BY THE

RESPONDENT THAT SUCH INDEMNITY IS INDEMNITY BY THE

RESPONDENT TO INDEMNIFY AND PROTECT THE BRA FROM

https://www.bidnetdirect.com/texas/brazosriverauthority https://www.bidnetdirect.com/texas/brazosriverauthority

RFP No. 25-1370 PK Buttress No. 8 Conduit Relocation Services Page 3 of 12

LIABILITY, CLAIMS, SUITS, LOSSES, DAMAGES OR CAUSES OF

ACTION DUE TO THE RESPONDENT’S NEGLIGENCE, ERROR OR

OMISSION.

13. CRITERIA FOR AWARD: The BRA will select the most highly qualified Respondent on the basis of demonstrated competence and qualifications and then attempt to negotiate with that Respondent a contract at a fair and reasonable price. If a satisfactory contract cannot be negotiated with the most highly qualified Respondent, the BRA will select the next most highly qualified Respondent and attempt to negotiate a contract with that Respondent at a fair and reasonable price. The criteria is stated in section 11 of the RFP.

14. TERMINATION: The awarded contract may be terminated at any time by the BRA, in BRA’s sole discretion, for any cause or for convenience without penalty or liability. Upon receipt of such notice, the supplier shall immediately discontinue all services and actions.

The BRA shall pay the Respondent promptly the accrued and unpaid amounts due for services to the date of termination, to the extent the services are approved by the BRA.

15. CHANGE OF CONTRACT PRICE:

The agreed upon contract price shall not be exceeded without the prior written consent of the BRA and may only be modified by a written amendment to the contract executed by both BRA and Respondent.

16. PAYMENT: Unless otherwise specified, payment for services and/or product will be processed within thirty (30) days from invoice date and acceptance of Services and/or product. Invoices presented for payment must be submitted in accordance with instructions contained on the purchase order including reference to purchase order number and submittal to the correct address for processing. Unit price on invoice shall be in two (2) decimal places only, i.e., $ .XX.

The BRA has set a goal to have as much paperwork submitted electronically. Respondents are asked to submit invoices electronically to the following Accounts Payable email address:

accounts.payable@brazos.org. Respondents who use the electronic service should not mail the original invoice.

17. CONFIDENTIALITY OF DOCUMENTS: The BRA is subject to the Texas Public Information Act (PIA). Any information submitted to the BRA by a Respondent shall be considered non-confidential and available to the public, except as follows:

In the event a Respondent considers a specific portion of their Proposal to be confidential and subject to an exception to disclosure under the PIA, such portion must be clearly identified and marked "CONFIDENTIAL". Do not mark an entire Proposal confidential, as this is not in conformance with the PIA and is not acceptable. Only the specific portion or portions of the Proposal that the Respondent considers to be confidential pursuant to the PIA should be marked. IF

AN ENTIRE PROPOSAL IS MARKED CONFIDENTIAL, THE BRA

WILL NOT TREAT ANY PORTION OF THE PROPOSAL AS

CONFIDENTIAL AND THE PROPOSAL MAY BE REJECTED AS

NON-CONFORMING. The BRA will honor notations of confidentiality made in accordance with this paragraph and decline to release such information initially. However, final determination of whether a particular portion of a Proposal may in fact be withheld pursuant to the PIA will be made by the Texas Attorney General or a court of competent jurisdiction.

In the event a public information request is received for a portion of a Proposal that has been marked confidential, the BRA shall ask the affected Respondent if the information may be released. If the release is agreed to, the BRA shall release the information.

If the release is denied, the matter shall be referred to the Texas Attorney General's Office in accordance with the process set forth in the PIA. The Respondent shall be fully and solely responsible for submitting arguments and evidence within the statutory timeframes to the Texas Attorney General’s Office regarding its claim of confidentiality. The BRA will NOT submit arguments on behalf of the Respondent.

The Texas Attorney General's office shall rule on the matter. In the event that it is determined by opinion or order of the Texas Attorney General or a court of competent jurisdiction that such information may not be withheld, then such information will be made available to the requester. If it is determined that the information may be withheld, BRA will withhold the information from the requestor.

Pricing information contained in Proposals or contracts is not considered confidential under the PIA and will be disclosed without making a request to the Texas Attorney General.

18. NO PRICE: The selection of the Selected Respondent under this RFP shall be in accordance with Chapter 2254 of the Texas Local Government Code. Do not include any price information within the submittal. Any submittal containing any price information will be automatically disqualified.

RFP No. 25-1370 PK Buttress No. 8 Conduit Relocation Services Page 4 of 12

REQUEST FOR PROPOSALS

PK BUTTRESS NO. 8 CONDUIT RELOCATION SERVICES

RFP NO. 25-1370

SUBMITTAL SCHEDULE

Requests for Proposals are posted on the BidNet Direct website at and prospective Respondents should visit the site for potential updates to Proposal requirements.

Thursday, August 14, 2025

RFP is available to download at

Two (2) Pre-Proposal meeting times will be held.

First Non-Mandatory meeting time: 10:00 AM Tuesday, August 26th 2025.

Second Non-Mandatory meeting time: 1:00 PM Tuesday, August 26th 2025.

On-Site Pre-Bid Meeting Location:

Brazos River Authority- Possum Kingdom 301 Observation Point Road Graford, TX 76449

4:00 PM, Friday, September 5, Last date and time to ask questions or request additional information. Please submit your questions at

4:00 PM, Tuesday, September 9, Post response to questions received as of the deadline or as soon thereafter, as an Addendum on

10:00 AM, Tuesday, September 16, Proposals are due.

11:00 AM Tuesday, September 16, Proposals will be opened virtually at the link below……………………………..

https://youtube.com/live/KT1_bv3pltI?feature=share

Local Time Prevailing.

https://www.bidnetdirect.com/texas/brazosriverauthority https://youtube.com/live/KT1_bv3pltI?feature=share

RFP No. 25-1370 PK Buttress No. 8 Conduit Relocation Services Page 5 of 12

RFP NO. 25-1370

1. General

The purpose of this Request for Proposal (RFP) is to obtain information from engineering Firms as to their qualifications to perform structural and electrical engineering services at Morris Sheppard Dam.

Morris Sheppard Dam, owned and operated by the Brazos River Authority (BRA), was designed by Ambursen Engineering Corporation and constructed in 1941 to form the Possum Kingdom Lake Reservoir. Morris Sheppard Dam is located in Palo Pinto County, approximately 25 miles northwest of Mineral Wells, Texas. Possum Kingdom Lake has a normal pool (El. 999 ft-msl) storage capacity of approximately 538,139 acre-feet and the spillway structure consists of nine (9) roof-weir gates.

Buttress No 8 is an approximately exposed height of 120 feet and has an elevator shaft connected to it to access different levels of the dam. There is electrical conduit embedded into the concrete and also on the surface of the concrete throughout the buttress.

During maintenance activities, electrical conduit embedded into the concrete of Buttress No 8 was found to be deteriorating. The BRA plans to reroute the electrical and replace where necessary. The BRA also plans to install new electrical boxes throughout Buttress No 8. The rerouting of the electrical conduit will also require concrete coring and or cuts to get the electrical conduit to new electrical boxes. The BRA would also like to map out any remaining electrical conduit that can be found embedded in the concrete of buttress No 8 for future use and reference. Furthermore, the BRA would like to find the root cause (if possible) for the electrical conduit deteriorating.

2. Scope of Services

The following is a nonexclusive overview of possible professional services that may be required:

Assessment of the current electrical conduit in Buttress No. 8 and find the root cause of the current electrical conduit condition.

Reroute the electrical conduit to new electrical boxes throughout Buttress No 8.

Cut and or core into concrete in Buttress No 8 to allow the electrical conduit into new electrical boxes.

Map out the remaining electrical conduit found in the concrete of Buttress No. 8 Structural and Electrical Engineering Services required to support the above tasks.

Bidding/Contract Administration Services (if needed) Construction Contract Administration Services (if needed) Construction Phase Engineering Services (if needed) Resident Project Representative (RPR) Services (if needed)

RFP No. 25-1370 PK Buttress No. 8 Conduit Relocation Services Page 6 of 12

3. Information Required in the RFP Submittal - Tab Format

The BRA specifically requests succinct submittals tailored to the general and discipline-specific scopes of services summarized above. Each response should describe in sufficient detail the relevance of the individual team member’s expertise and experience to the specific requirements of the project. All submittals become the property of the BRA. Each submittal shall include the information requested below. Please limit each submittal to no more than 15-20 pages (not including resumes and required forms)

FAILURE TO SUBMIT ANY OF THE REQUESTED INFORMATION MAY BE GROUNDS

FOR REJECTION OF PROPOSAL OR DELAY ISSUANCE OF A PURCHASE

ORDER/CONTRACT.

Tab A: Include the following:

(1) Date your company was established and a brief history; number of employees; provide number and location of offices.

(2) Provide name, title and office location of person who will be the principal contact for the BRA and the billing location if different.

(3) Describe the types of organizations that your company typically serves and general nature of the work.

(4) A list and description of similar services completed within the last five years under your current company name or any other company name similar in nature to this solicitation.

This should include the name, the location, a brief description of Scope of Services, and a contact name and telephone number of a reference for each client. List litigation that your company has been a party to in the last five (5) years, under your current company name or any other company name. Include only litigation that involves business units in your company that are proposed for performing services under this

RFP.

(5) List all such litigation involving owners and/or general contractors. To be fully responsive, provide the level of detail in the attached example, as well as a name and phone number to contact an authorized representative of your company in the event that the BRA needs to clarify your response. Failure to be fully responsive will be sufficient grounds for the BRA to disqualify your company.

(6) Have you ever defaulted, failed to complete a contract or had a contract terminated by the other party? If so, where and why? Provide name and telephone number of the other party.

(7) Please provide the contact information including the email address of the person responsible for providing proof of insurance.

RFP No. 25-1370 PK Buttress No. 8 Conduit Relocation Services Page 7 of 12

Tab B: Include the following:

1. Provide a summary of Firm’s experience in providing structural engineering consultation and analyses for and in successfully resolving structural issues.

2. Provide a summary of Firm’s experience in providing electrical engineering consultation and analyses for and in successfully resolving electrical issues.

3. Provide a summary of Firm’s experience designing and implementing structural and electrical investigations, assessments, monitoring programs and designs for hydraulic structures and facilities. Experience with major civil works structures and foundation elements should be documented.

4. Describe innovative methods and/or technologies pertinent to major civil works structures and foundation elements that are available to complete the work required with which your firm is familiar. Provide a list of projects to which the innovative methods and/or technologies have been applied. Include contact information for project owner(s).

5. Provide names and technical qualifications of the personnel that will be utilized by the Firm that will conduct assessments, make recommendations or serve a principal engineer or project manager.

6. Provide the identification of the person proposed by the Firm to serve as the point of contact for scope of services development and negotiations.

7. Provide a detailed description of the Firm’s quality control methodology for structural engineering and electrical engineering services.

8. Provide a description of the Firm’s ability to complete projects without significant cost escalations or overrun.

9. Provide a description of the Firm’s ability to meet current and long-term workloads and staff’s ability to develop and meet schedules, milestone dates, and deadlines on an as needed basis.

10. Provide the firm’s professional registrations and the identification of the project manager and team members with their professional licenses and qualifications to perform the proposed professional services in the State of Texas.

11. Provide resumes for team members associated with the project.

Tab C: Include the following:

(1) Complete and submit the attached W-9 form, or if foreign entity submit the appropriate tax document information.

(2) Complete and submit the attached “Conflicts of Interest Questionnaire [CIQ]” form.

(3) Complete and submit the “Acknowledgment of Request for Proposals and Receipt of

Addenda” form. Respondent is required to complete, sign and submit this form with Respondent’s Proposal. Failure to complete, sign and submit this form with Respondent’s Proposal will disqualify the entire Proposal as non-responsive.

(4) Complete and submit the Non-Collusion Affidavit form.

(5) HUB Subcontracting Plan

4. RFP Inquiries

All inquiries, including clarifying questions, related to this RFP shall only be directed to the Purchasing Agent via https://www.bidnetdirect.com/texas/brazosriverauthority The Purchasing Agent will direct any inquiries to the appropriate BRA staff, a response will be issued and if warranted, an Addendum will be posted on the BidNet Direct site. Failure to adhere to this restriction during the advertising, evaluation, and selection phases will result in the rejection of a Respondent’s Proposal.

RFP No. 25-1370 PK Buttress No. 8 Conduit Relocation Services Page 8 of 12

5. Hub Subcontracting Plan

This solicitation requires a HUB Subcontracting Plan to be completed and submitted. The HUB Subcontracting Plan is attached to this solicitation. If you have any questions regarding the HUB Subcontracting Plan please contact Bryan Gray Purchasing Manager / HUB Coordinator at bryan.gray@Brazos.org.

6. Hub Subcontracting Plan Instructions

If you will not be subcontracting any portion of the contract and will be fulfilling the entire contract with your own resources (i.e., employees, supplies, materials and/or equipment), follow the instructions on the HUB Subcontracting Plan Checklist, first page of the HUB Plan included in this solicitation.

Section 1 - Respondent and Requisition Information

Section 2 a. - No, I will not be subcontracting any portion of the contract, and I will be fulfilling the entire contract with my own resources.

Section 3 - Self Performing Justification Section 4 – Affirmation (Remember to sign Section 4)

If you are subcontracting any work please follow the instructions on the HUB Subcontracting Plan Checklist, first page of the HUB Plan included in this solicitation.

As the BRA endeavors to make a good faith effort to utilize HUBs in contracting for this project, this project does not have a HUB goal.

7. Respondent’s Past Performance

BRA will consider Respondent’s past performance and may conduct reference checks with other entities regarding past performance. BRA may examine Respondent’s performance including, but not limited to:

the Comptroller of Public Accounts Statewide Procurement Division Vendor Performance Tracking System, notices of termination, cure notices, assessments of liquidated damages, litigation, audit reports, repeated negative performance, records of repeated non-responsiveness to performance issues, and non-renewals of contracts. Such sources of Respondent performance may include any governmental entity, whether an agency or political subdivision of the State of Texas, another state, or the Federal government. Further, BRA may initiate such examinations of Respondent performance based upon media reports. Any such investigations shall be at the sole discretion of BRA, and any negative findings, as determined by BRA, may result in non-award to Respondent.

8. Conflict of Interest

Pursuant to Chapter 176 of the Local Government Code, any person or agent of a person who contracts or seeks to contract for the sale or purchase of property, goods, or services with a local government entity (i.e., Brazos River Authority) must disclose in the Conflicts of Interest Questionnaire Form ("CIQ") the person's affiliation or business relationship that might cause a conflict of interest with the local government entity. By law, the CIQ must be filed with the BRA Records Management Officer no later than seven (7) days after the date the person begins contract discussions or negotiations with the BRA, or submits an application or response to a Request for Proposals, correspondence, or another writing related to a potential agreement with the BRA. Updated Questionnaires must be filed in conformance with Chapter 176.

mailto:bryan.gray@Brazos.org Bryan Gray Added a line

RFP No. 25-1370 PK Buttress No. 8 Conduit Relocation Services Page 9 of 12

A copy of the CIQ is attached. If you have any questions about compliance, please consult your own legal counsel. Compliance is the individual responsibility of each person or agent of a person who is subject to the filing requirement. An offense under Chapter 176 carries a penalty up to a Class A misdemeanor.

9. Disclosure of Interested Parties

Pursuant to Section 2252.908 of the Government Code, the selected Firm in contracts for the sale or purchase of property, goods, or services with a local government entity (i.e., BRA) anticipated to have a value of at least $250,000/$500,000 must submit a Disclosure of Interested Parties Form to the local government entity that discloses all persons at the Selected Firm who have a controlling interest in the selected Firm or who actively participated in facilitating the contract or negotiating the terms of the contract.

The requirements of Section 2252.908 of the Government Code are subject to change, and if you have any questions about compliance, please consult your own legal counsel.

https://www.ethics.state.tx.us/whatsnew/elf_info_form1295.htm

10. Term of Agreement

The term of this Contract shall be for a period of one (1) year, commencing on the Effective Date, and may be renewed by subsequent agreement of the parties for up to four (4) additional one (1) year periods, for a total potential term of five (5) years.

11. Selection Process

Proposals will be evaluated and scored based on the factors listed below.

1. Respondent Qualification - Specified professional license or certification - Copy of current license or certificate applicable to specified profession or trade;

2. Respondent Experience - Specified number of projects of similar size and scope - Detailed information regarding project size, dollar amount and scope of project for each individual project and any additional information necessary to evaluate vendor experience;

3. Ability to perform the contract or provide the service promptly, or in the time required, without delay or interference;

4. Respondent’s Proposed Plan for Providing Services.

12. Contract

The executed contract between BRA and the selected Respondent shall be a BRA standard form contract for Professional Services. Contract terms are not subject to modification and Respondent will be expected to execute the contract in substantially the form provided. Respondent should not base a proposal on an expectation that BRA will modify its contract terms.

https://www.ethics.state.tx.us/whatsnew/elf_info_form1295.htm

RFP No. 25-1370 PK Buttress No. 8 Conduit Relocation Services Page 10 of 12

Compensation for services provided under the professional services contract to be entered into with the selected Firm will be based on time and materials up to a total mutually agreeable not-to-exceed amount. Individual tasks under the contract will also be billed on a time and material basis up to a not-to-exceed amount for such task.

The BRA reserves the right to award contract(s) without any negotiations and reserves the right to not make awards. The BRA reserves the right to conduct studies and other investigations as necessary to evaluate any submittal. Submission of a proposal confers no legal right upon any Respondent.

The decision of BRA, or its designee with regard to the above, shall be administratively final. BRA, in its sole discretion, may waive administrative deficiencies and/or minor technicalities in submittals received.

13. Insurance Requirements

The Respondent shall, at Respondent’s sole expense, maintain insurance coverage as determined acceptable to the BRA. The Respondent must obtain the following minimum insurance requirements and provide proof to the BRA prior to entering into a contract:

General Liability Insurance:

Bodily Injury $ 500,000 per occurrence Property Damage $ 1,000,000 per occurrence Aggregate $ 2,000,000

Professional Liability:

$1,000,000 per occurrence/$2,000,000 aggregate

Workers’ Compensation:

Statutory

Automobile Liability: $ 1,000,000 per claim / aggregate

Employers’ Liability

$ 1,000,000 policy limit

Pollution Liability

$ 1,000,000 per claim / aggregate

Before beginning any work under this agreement, the Respondent is required to register with myCOItracking.com and upload documentation that meets the insurance requirements outlined in this agreement. Work WILL NOT commence until the certificate of insurance is approved as compliant. The Respondent must add registration@myCOItracking.com and certificaterequest@myCOIsolution.com to their safe sender list to ensure receipt of essential communications from myCOI. If any issues arise during registration, please contact the myCOItracking support team at (317) 759-9426.

RFP No. 25-1370 PK Buttress No. 8 Conduit Relocation Services Page 11 of 12

14. Recycled and Recyclable Products

The BRA encourages the use of recycled products and products that may be recycled or reused.

15. Delivery of Proposal Submittals

Proposals may be submitted in one of the following manners:

Electronic Transmission. Electronic submittals will be received on the following platform. BidNet Direct requires you to register at no charge.

Drop Box Submission Prior to Proposal Submission Deadline: Hand delivery of one sealed, clearly identified original signed paper copy submission may be received up to the proposal submission deadline contained in the solicitation at the Brazos River Authority, 4600 Cobbs Drive, Waco, TX. 76710, utilizing the secure drop box located near of the office building. The BRA shall not be responsible for submissions that are not properly identified. Proper identification of Respondent’s proposal is the sole responsibility of the Respondent and failure to do so may result in the submission not being included in the proposal opening.

Mail-In Delivery: Mailed by commercial carrier, overnight or express mail, one sealed clearly identified original signed paper copy submission may be accepted by the Purchasing Agent or other designee up to the proposal submission deadline contained in the solicitation at the Brazos River Authority 4600 Cobbs Drive, Waco, TX. 76710. The BRA shall not be responsible for submissions that are not properly identified. Proper identification of Respondent’s proposal is the sole responsibility of the Respondent and failure to do so may result in the submission not being included in the proposal opening.

RFP No. 25-1370 PK Buttress No. 8 Conduit Relocation Services Page 12 of 12

RFP NO. 25-1370

ACKNOWLEDGMENT OF REQUEST FOR PROPOSALS AND

RECEIPT OF ADDENDA

RESPONDENT MUST ACKNOWLEDGE RECEIPT OF THIS REQUEST FOR PROPOSALS

AND ADDENDA BY SIGNING BELOW AND SUBMITTING THIS ACKNOWLEDGEMENT

WITH YOUR PROPOSAL. FAILURE TO SIGN THIS ACKNOWLEDGEMENT WILL

DISQUALIFY THE PROPOSAL AS NON-RESPONSIVE. SIGNATURE MAY BE DIGITAL,

ELECTRONIC OR HANDWRITTEN.

This acknowledgement shall become part of your response and the subsequent contract documents if applicable.

ACKNOWLEDGMENT OF REQUEST FOR PROPOSALS:

Respondent hereby acknowledges that it has received and read the Request for Proposals and all Addenda, and that this Proposal is made in accordance with the provisions thereof.

Respondent acknowledges that this Proposal meets or exceeds all terms, requirements, conditions, and/or specifications set forth in the Request for Proposals and Addenda, and exceptions or deviations from such terms, requirements, conditions, and/or specifications, if any, have been clearly and conspicuously identified as such in the Proposal.

Does your company have ten (10) or more full time employees? Check one box only.

YES NO

Name of Firm (Respondent)

Signature – Authorized Representative

Printed Name

Date

E-mail Address

Telephone Number

CONFLICT OF INTEREST QUESTIONNAIRE

For vendor doing business with local governmental entity

FORM CIQ

OFFICE USE ONLY

Date Received

This questionnaire reflects changes made to the law by H.B. 23, 84th Leg., Regular Session.

This questionnaire is being filed in accordance with Chapter 176, Local Government Code, by a vendor who has a business relationship as defined by Section 176.001(1-a) with a local governmental entity and the vendor meets requirements under Section 176.006(a).

By law this questionnaire must be filed with the records administrator of the local governmental entity not later than the 7th business day after the date the vendor becomes aware of facts that require the statement to be filed. See Section 176.006(a-1), Local Government Code.

A vendor commits an offense if the vendor knowingly violates Section 176.006, Local Government Code. An offense under this section is a misdemeanor.

1 Name of vendor who has a business relationship with local governmental entity.

Check this box if you are filing an update to a previously filed questionnaire. (The law requires that you file an updated completed questionnaire with the appropriate filing authority not later than the 7th business day after the date on which you became aware that the originally filed questionnaire was incomplete or inaccurate.)

3 Name of local government officer about whom the information is being disclosed.

Name of Officer

4 Describe each employment or other business relationship with the local government officer, or a family member of the officer, as described by Section 176.003(a)(2)(A). Also describe any family relationship with the local government officer.

Complete subparts A and B for each employment or business relationship described. Attach additional pages to this Form CIQ as necessary.

A. Is the local government officer or a family member of the officer receiving or likely to receive taxable income, other than investment income, from the vendor?

Yes No

B. Is the vendor receiving or likely to receive taxable income, other than investment income, from or at the direction of the local government officer or a family member of the officer AND the taxable income is not received from the local governmental entity?

Yes No

5 Describe each employment or business relationship that the vendor named in Section 1 maintains with a corporation or other business entity with respect to which the local government officer serves as an officer or director, or holds an

Check this box if the vendor has given the local government officer or a family member of the officer one or more gifts as described in Section 176.003(a)(2)(B), excluding gifts described in Section 176.003(a-1).

Signature of vendor doing business with the governmental entity Date ownership interest of one percent or more.

Form provided by Texas Ethics Commission www.ethics.state.tx.us Revised 1/1/2021

Revised 1/1/2021Form provided by Texas Ethics Commission www.ethics.state.tx.us

CONFLICT OF INTEREST QUESTIONNAIRE

For vendor doing business with local governmental entity

A complete copy of Chapter 176 of the Local Government Code may be found at http://www.statutes.legis.state.tx.us/ Docs/LG/htm/LG.176.htm. For easy reference, below are some of the sections cited on this form.

Local Government Code § 176.001(1-a): "Business relationship" means a connection between two or more parties based on commercial activity of one of the parties. The term does not include a connection based on:

(A) a transaction that is subject to rate or fee regulation by a federal, state, or local governmental entity or an agency of a federal, state, or local governmental entity;

(B) a transaction conducted at a price and subject to terms available to the public; or

(C) a purchase or lease of goods or services from a person that is chartered by a state or federal agency and that is subject to regular examination by, and reporting to, that agency.

Local Government Code § 176.003(a)(2)(A) and (B):

(a) A local government officer shall file a conflicts disclosure statement with respect to a vendor if:

(2) the vendor:

(A) has an employment or other business relationship with the local government officer or a family member of the officer that results in the officer or family member receiving taxable income, other than investment income, that exceeds $2,500 during the 12-month period preceding the date that the officer becomes aware that

(i) a contract between the local governmental entity and vendor has been executed;

or

(ii) the local governmental entity is considering entering into a contract with the vendor;

(B) has given to the local government officer or a family member of the officer one or more gifts that have an aggregate value of more than $100 in the 12-month period preceding the date the officer becomes aware that:

(i) a contract between the local governmental entity and vendor has been executed; or

(ii) the local governmental entity is considering entering into a contract with the vendor.

Local Government Code § 176.006(a) and (a-1)

(a) A vendor shall file a completed conflict of interest questionnaire if the vendor has a business relationship with a local governmental entity and:

(1) has an employment or other business relationship with a local government officer of that local governmental entity, or a family member of the officer, described by Section 176.003(a)(2)(A);

(2) has given a local government officer of that local governmental entity, or a family member of the officer, one or more gifts with the aggregate value specified by Section 176.003(a)(2)(B), excluding any gift described by Section 176.003(a-1); or

(3) has a family relationship with a local government officer of that local governmental entity.

(a-1) The completed conflict of interest questionnaire must be filed with the appropriate records administrator not later than the seventh business day after the later of:

(1) the date that the vendor:

(A) begins discussions or negotiations to enter into a contract with the local governmental entity; or

(B) submits to the local governmental entity an application, response to a request for proposals or bids, correspondence, or another writing related to a potential contract with the local governmental entity; or

(2) the date the vendor becomes aware:

(A) of an employment or other business relationship with a local government officer, or a family member of the officer, described by Subsection (a);

(B) that the vendor has given one or more gifts described by Subsection (a); or

(C) of a family relationship with a local government officer.

Revised May 2007

NON-COLLUSION AFFIDAVIT

STATE OF TEXAS §

COUNTY OF ________ §

By the signature below, the signatory for the bidder certifies that neither he nor the firm, corporation, partnership or institution represented by the signatory or anyone acting for the firm bidding this project has violated the antitrust laws of this State, codified at

Section 15.01, et seq., Texas Business and Commerce Code, or the Federal antitrust laws, nor communicated directly or indirectly the bid made to any competitor or any other person engaged in the same line of business, nor has the signatory or anyone acting for the firm, corporation or institution submitting a bid committed any other act of collusion related to the development and submission of this bid proposal.

Signature:

Printed Name:

Title:

Company:

Date:

SUBSCRIBED and sworn to before me the undersigned authority by the of, on behalf of said bidder.

Notary Public in and for the State of Texas

My commission expires: ____________

EXAMPLE RESPONSE TO LITIGATION HISTORY QUESTION

Date Parties Nature/Description of Litigation Outcome 2010 XYZ, Inc. v. Owner Owner brought suit against XYZ, Inc.

claiming flawed design of a concrete pad.

XYZ, Inc.

Nonsuited

2011 XYZ, Inc. v. Owner XYZ, Inc. retained to design bike path, the path collapsed in construction and owner sued XYZ, Inc. and contractor

Settled

2012 XYZ, Inc. v. Contractor Contractor claimed XYZ, Inc. negligent on a project where Contractor was constructing a tower and the tower allegedly incorporated incorrect materials. XYZ, Inc. disputes the allegations.

Ongoing

Rev. 2/17

HUB Subcontracting Plan (HSP)

QUICK CHECKLIST

While this HSP Quick Checklist is being provided to merely assist you in readily identifying the sections of the HSP form that you will need to complete, it is very important that you adhere to the instructions in the HSP form and instructions provided by the contracting agency.

If you will be awarding all of the subcontracting work you have to offer under the contract to only Texas certified HUB vendors, complete:

Section 2 a. - Yes, I will be subcontracting portions of the contract.

Section 2 b. - List all the portions of work you will subcontract, and indicate the percentage of the contract you expect to award to Texas certified HUB vendors.

Section 2 c. - Yes Section 4 - Affirmation GFE Method A (Attachment A) - Complete an Attachment A for each of the subcontracting opportunities you listed in Section 2 b.

If you will be subcontracting any portion of the contract to Texas certified HUB vendors and Non-HUB vendors, and the aggregate percentage of all the subcontracting work you will be awarding to the Texas certified HUB vendors with which you do not have a continuous contract* in place for more than five (5) years meets or exceeds the HUB Goal the contracting agency identified in the “Agency Special Instructions/Additional Requirements”, complete:

Section 1 - Respondent and Requisition Information Section 2 a. - Yes, I will be subcontracting portions of the contract.

Section 2 b. - List all the portions of work you will subcontract, and indicate the percentage of the contract you expect to award to Texas certified HUB vendors and Non-HUB vendors.

Section 2 c. - No Section 2 d. - Yes Section 4 - Affirmation GFE Method A (Attachment A) - Complete an Attachment A for each of the subcontracting opportunities you listed in Section 2 b.

If you will be subcontracting any portion of the contract to Texas certified HUB vendors and Non-HUB vendors or only to Non-HUB vendors, and the aggregate percentage of all the subcontracting work you will be awarding to the Texas certified HUB vendors with which you do not have a continuous contract* in place for more than five (5) years does not meet or exceed the HUB Goal the contracting agency identified in the “Agency Special Instructions/Additional Requirements”, complete:

Section 2 a. - Yes, I will be subcontracting portions of the contract.

Section 2 b. - List all the portions of work you will subcontract, and indicate the percentage of the contract you expect to award to Texas certified HUB vendors and Non-HUB vendors.

Section 2 c. - No Section 2 d. - No Section 4 - Affirmation GFE Method B (Attachment B) - Complete an Attachment B for each of the subcontracting opportunities you listed in Section 2 b.

If you will not be subcontracting any portion of the contract and will be fulfilling the entire contract with your own resources (i.e., employees, supplies, materials and/or equipment), complete:

Section 2 a. - No, I will not be subcontracting any portion of the contract, and I will be fulfilling the entire contract with my own resources.

Section 3 - Self Performing Justification Section 4 - Affirmation

*Continuous Contract: Any existing written agreement (including any renewals that are exercised) between a prime contractor and a HUB vendor, where the HUB vendor provides the prime contractor with goods or service, to include under the same contract for a specified period of time. The frequency the HUB vendor is utilized or paid during the term of the contract is not relevant to whether the contract is considered continuous. Two or more contracts that run concurrently or overlap one another for different periods of time are considered by CPA to be individual contracts rather than renewals or extensions to the original contract. In such situations the prime contractor and HUB vendor are entering (have entered) into “new” contracts.

HUB Subcontracting Plan (HSP)

In accordance with Texas Gov’t Code §2161.252, the contracting agency has determined that subcontracting opportunities are probable under this contract. Therefore, all respondents, including State of Texas certified Historically Underutilized Businesses (HUBs) must complete and submit this State of Texas HUB Subcontracting Plan (HSP) with their response to the bid requisition (solicitation).

NOTE: Responses that do not include a completed HSP shall be rejected pursuant to Texas Gov’t Code §2161.252(b).

The HUB Program promotes equal business opportunities for economically disadvantaged persons to contract with the State of Texas in accordance with the goals specified in the 2009 State of Texas Disparity Study. The statewide HUB goals defined in 34 Texas Administrative Code (TAC) §20.284 are:

• 11.2 percent for heavy construction other than building contracts,

• 21.1 percent for all building construction, including general contractors and operative builders’ contracts,

• 32.9 percent for all special trade construction contracts,

• 23.7 percent for professional services contracts,

• 26.0 percent for all other services contracts, and

• 21.1 percent for commodities contracts.

- - Agency Special Instructions/Additional Requirements - -

Respondent (Company) Name:

Point of Contact:

State of Texas VID #:

Bid Open Date:

SECTION 1: RESPONDENT AND REQUISITION INFORMATION

(mm/dd/yyyy)

- Yes - No a.

b.

c.

In accordance with 34 TAC §20.285(d)(1)(D)(iii), a respondent (prime contractor) may demonstrate good faith effort to utilize Texas certified HUBs for its subcontracting opportunities if the total value of the respondent’s subcontracts with Texas certified HUBs meets or exceeds the statewide HUB goal or the agency specific HUB goal, whichever is higher. When a respondent uses this method to demonstrate good faith effort, the respondent must identify the HUBs with which it will subcontract. If using existing contracts with Texas certified HUBs to satisfy this requirement, only the aggregate percentage of the contracts expected to be subcontracted to HUBs with which the respondent does not have a continuous contract* in place for more than five (5) years shall qualify for meeting the HUB goal. This limitation is designed to encourage vendor rotation as recommended by the 2009 Texas Disparity Study.

E-mail Address:

Is your company a State of Texas certified HUB?

Requisition #:

Phone #:

Fax #:

- Yes, I will be subcontracting portions of the contract. (If Yes, complete Item b of this SECTION and continue to Item c of this SECTION.)

- Yes (If Yes, continue to SECTION 4 and complete an “HSP Good Faith Effort - Method A (Attachment A)” for each of the subcontracting opportunities you listed.)

- No (If No, continue to Item d, of this SECTION.)

- Yes (If Yes, continue to SECTION 4 and complete an “HSP Good Faith Effort - Method A (Attachment A)” for each of the subcontracting opportunities you listed.)

- No (If No, continue to SECTION 4 and complete an “HSP Good Faith Effort - Method B (Attachment B)” for each of the subcontracting opportunities you listed.)

Non-HUBs

HUBs

Enter your company’s name here: Requisition #:

SECTION 2: RESPONDENT's SUBCONTRACTING INTENTIONS

After dividing the contract work into reasonable lots or portions to the extent consistent with prudent industry practices, and taking into consideration the scope of work to be performed under the proposed contract, including all potential subcontracting opportunities, the respondent must determine what portions of work, including contracted staffing, goods and services will be subcontracted. Note: In accordance with 34 TAC §20.282, a “Subcontractor” means a person who contracts with a prime contractor to work, to supply commodities, or to contribute toward completing work for a governmental entity.

a. Check the appropriate box (Yes or No) that identifies your subcontracting intentions:

b. List all the portions of work (subcontracting opportunities) you will subcontract.