Statement_of_Work.pdf

REHABILITATION OF THE COE VISITOR

CENTER, COMFORT STATION, AND

ORIENTATION PAVILION

EVERGLADES NATIONAL PARK

Homestead, Florida

PMIS #: EVER 218241 & 218239

FINAL SPECIFICATIONS

NATIONAL PARK SERVICE

April 28, 2017

Document No. 160/132079

EVER – 218239 / 218241 TABLE OF CONTENTS - 1

TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

NOT USED

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 011100 – SUMMARY OF WORK

SECTION 013100 – PROJECT MANAGEMENT AND COORDINATION

SECTION 013216 – CONSTRUCTION SCHEDULE

SECTION 013323 – SUBMITTAL PROCEDURES

SECTION 013523 – SAFETY REQUIREMENTS

SECTION 014000 – QUALITY REQUIREMENTS

SECTION 015000 – TEMPORARY FACILITIES AND CONTROLS

SECTION 016700 – PRODUCT REQUIREMENTS

SECTION 017329 – CUTTING AND PATCHING

SECTION 017340 – EXECUTION

SECTION 017419 – CONSTRUCTION WASTE MANAGEMENT AND DISPOSAL

SECTION 017700 – CLOSEOUT PROCDEURES

SECTION 017823 – OPERATIONS AND MAINTENANCE DATA

DIVISION 02 - EXISTING CONDITIONS

DIVISION 03 - CONCRETE

DIVISION 04 - MASONRY

DIVISION 05 - METALS

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

SECTION 061000 – ROUGH CARPENTRY

SECTION 061600 – SHEATHING

SECTION 067300 – COMPOSITE DECKING

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

SECTION 072100 – THERMAL INSULATION

SECTION 072500 – WEATHER BARRIERS

EVER – 218239 / 218241 TABLE OF CONTENTS - 2

SECTION 074130 – STANDING-SEAM METAL ROOF PANELS

SECTION 074600 – FIBER CEMENT SIDING

SECTION 079200 – JOINT SEALANTS

DIVISION 08 - OPENINGS

DIVISION 09 - FINISHES

SECTION 099110 – EXTERIOR PAINTING

DIVISION 10 - SPECIALTIES

SECTION 107113.13 – ACCORDION STORM SHUTTERS

DIVISION 11 - EQUIPMENT

DIVISION 12 - FURNISHINGS

DIVISION 13 - SPECIAL CONSTRUCTION

DIVISION 14 - CONVEYING EQUIPMENT

DIVISION 21 - FIRE SUPPRESSION

DIVISION 22 - PLUMBING

DIVISION 23 - HEATING, VENTILATING, AND AIR-CONDITIONING (HVAC)

DIVISION 26 - ELECTRICAL

SECTION 260510 – ELECTRICAL SUBMITTALS

EVER – 218239 / 218241 TABLE OF CONTENTS - 3

SECTION 264100 – FACILITY LIGHTNING PROTECTION

DIVISION 27 - COMMUNICATIONS

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

DIVISION 31 - EARTHWORK

DIVISION 32 - EXTERIOR IMPROVEMENTS

DIVISION 33 - UTILITIES

EVER – 218239 / 218241 01 11 00 - 1

SUMMARY OF WORK

SECTION 01 11 00 - SUMMARY OF WORK

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes the following:

1. Work covered by the Contract Documents.

2. Work phases.

3. Work under other contracts.

4. Government Furnished Materials.

5. Contractor use of premises.

6. Public use of site.

7. Occupancy requirements for buildings.

8. Work Restrictions.

9. Special Construction Requirements.

1.2 WORK COVERED BY CONTRACT DOCUMENTS

A. Project Location: Coe Visitor Center, Everglades National Park.

B. The Work consists of the following:

1. The Work includes the rehab of the Coe Visitor Center, Visitor Restrooms and Orientation Pavilion including new fiber cement siding, new decking, new accordion hurricane shutters, new roofing and lightening protection over the Restrooms and Orientation Pavilion.

C. Project will be constructed under a single prime contract.

1.3 CONTRACTOR USE OF SITE

A. General: Contractor shall have limited use of the site for construction operations.

Limit use of the premises to areas within the Contract limits indicated. Do not disturb portions of the Project site beyond the areas in which the Work is indicated.

1. Limits: Confine construction operations to the Coe Visitor Center, Restrooms and Orientation Pavilion area.

B. Storage of Materials: Confine storage of materials to the laydown area.

C. Laydown area to be in the Coe Visitor Center parking area as indicated on drawings. Laydown area shall be protected with orange construction fencing around perimeter. A dumpster and port-john shall be located within the laydown area.

D. Preservation of Natural Features:

EVER – 218239 / 218241 01 11 00 - 2

1. Prevent damage to natural surroundings. Restore damaged areas, repairing or replacing damaged trees and plants, at no additional expense to the Government.

2. Provide temporary barriers to protect existing trees and plants and root zones.

3. Do not remove, injure, or destroy trees or other plants without prior approval. Consult with Contracting Officer and remove agreed-on roots and branches that interfere with construction.

4. Do not fasten ropes, cables, or guys to existing trees.

5. Carefully supervise excavating, grading, filling, and other construction operations near trees to prevent damage.

E. Driveways and Entrances: Keep driveways and entrances serving premises clear and available to Government, Government's employees, and emergency vehicles at all times. Do not use these areas for parking or storage of materials.

1. Schedule deliveries to minimize use of driveways and entrances.

2. Schedule deliveries to minimize space and time requirements for storage of materials and equipment on-site.

F. Construction Camp: Establishment of a camp within the park will not be permitted.

G. Hauling Restrictions: Comply with all legal load restrictions in the hauling of materials. Load restrictions on park roads are identical to the state load restrictions with such additional regulations as may be imposed by the Park Superintendent. Information regarding rules and regulations for vehicular traffic on park roads may be obtained from the Office of the Park Superintendent. A special permit will not relieve Contractor of liability for damage which may result from moving of equipment.

1.4 PUBLIC USE OF SITE

A. Contractor shall at all times conduct his operations to ensure the least inconvenience to the public. Building and Road closures will be permitted, when required, upon specific approval of the NPS COR for a maximum of one hour.

1.5 OCCUPANCY REQUIRMENTS FOR BUILIDINGS

A. Existing Buildings

1. Full Government Occupancy: Government will occupy the premises during entire construction period. Cooperate with Government during construction operations to minimize conflicts and facilitate Government usage. Perform the Work so as not to interfere with Government’s operations. Maintain existing exits, unless otherwise indicated.

a. Maintain access to existing walkways, corridors, and other adjacent occupied or used facilities. Do not close or obstruct walkways, EVER – 218239 / 218241 01 11 00 - 3 corridors, or other occupied or used facilities without written permission from the Contracting Officer (CO).

b. Maintain existing building in a weather tight condition throughout construction period. Repair damage caused by construction operations. Protect building, contents and occupants during construction period.

1.6 WORK RESTRICTIONS

A. On-Site Work Hours: Work shall be generally performed during normal business working hours of 7:00 a.m. to 5:00 p.m., Monday through Friday, except when otherwise indicated.

1. Early Morning, Weekend or National Holiday Hours: No hours will be permitted without consent of the Contracting Officer’s Representative.

B. Existing Utilities

1. Existing Utilities: Notify Contracting Officer and utility companies of proposed locations and times for excavation.

2. Contractor shall be responsible for locating and preventing damage to known utilities. If damage occurs, repair utility at no additional expense to the Government.

3. If damage occurs to an unknown utility, repair utility. An equitable adjustment will be made in accordance with the Changes clause of the contract.

C. Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by Government or others unless permitted under the following conditions and then only after arranging to provide temporary utility services according to requirements indicated:

1. Notify Contracting Officer not less than two days in advance of proposed utility interruptions.

2. Do not proceed with utility interruptions without Contracting Officer’s written permission.

3. Hours for Utility Shutdowns: To be coordinated with Contracting Officer’s Representative.

D. Nonsmoking Building: Smoking is not permitted within the building or within 25 feet of entrances, operable windows, or outdoor air intakes.

EVER – 218239 / 218241 01 11 00 - 4

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 11 00

EVER – 218239 / 218241 01 27 00 - 1

CONSTRUCTION SCHEDULE

SECTION 01 27 00 – DEFINITION OF CONTRACT LINE ITEMS

PART 1 - GENERAL

1.1 SUMMARY

A. The intent of this section is to explain, in general, what is and what is not included in a contract line item, and the limits or cut-off points where one item ends and another begins.

B. If no contract line item exists for a portion of the work, include the costs in a related item.

PART 2 - (NOT USED)

PART 3 - EXECUTION

3.1 LIST OF CONTRACT LINE ITEMS

A. Contract Line Item No. 0001 Base Bid- Rehab Coe Visitor Center

1. This item consist of all work required to complete repairs to the Coe Visitor Center, in accordance with the drawing and specifications.

2. Measurement for payment will be Lump Sum.

3. Payment will be made at the contract lump sum price.

B. Contract Line Item No. 0002 Add Alternate 1 – Rehab Coe Comfort Station & Orientation Pavilion.

1. This item consist of all work required to complete repairs to the Coe Comfort Station and Orientation Pavilion, in accordance with the drawing and specifications.

2. Measurement for payment will be Lump Sum.

3. Payment will be made at the contract lump sum price.

END OF SECTION 01 27 00

EVER – 218239 / 218241 013100 - 1

SECTION 01 31 00 - PROJECT MANAGEMENT AND COORDINATION

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes administrative provisions for coordinating construction operations on Project including, but not limited to, the following:

1. Construction Coordination.

2. Submittals

3. Coordination Drawings.

4. Requests for Information (RFIs).

5. Project meetings.

6. Environmental Coordination.

7. Permits

B. Related Requirements:

1. Section 01 32 16 “Construction Schedule” for preparing and submitting Contractor’s construction schedule.

2. Section 01 73 40 “Execution” for procedures for coordinating general installation and field-engineering services, including establishment of benchmarks and control points.

3. Section 01 77 00 “Closeout Procedures” for coordinating closeout of the Contract.

1.2 CONSTRUCTION COORDINATION

A. Coordination: Coordinate construction operations included in different Sections of the Specifications to ensure efficient and orderly installation of each part of the Work. Coordinate construction operations, included in different Sections, which depend on each other for proper installation, connection, and operation.

1. Schedule construction operations in sequence required to obtain the best results where installation of one part of the Work depends on installation of other components, before or after its own installation.

2. Coordinate installation of different components with other Contractors to ensure maximum accessibility for required maintenance, service, and repair.

3. Make adequate provisions to accommodate items scheduled for later installation.

4. Where availability of space is limited, coordinate installation of different components to ensure maximum performance and accessibility for

EVER – 218239 / 218241 013100 - 2

required maintenance, service, and repair of all components, including mechanical and electrical.

B. Prepare memoranda for distribution to each party involved, outlining special procedures required for coordination. Include such items as required notices, reports, and list of attendees at meetings.

C. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction activities and activities of other contractors to avoid conflicts and to ensure orderly progress of the Work.

Such administrative activities include, but are not limited to, the following:

1. Preparation of Contractor's Construction Schedule.

2. Preparation of the Schedule of Values.

3. Installation and removal of temporary facilities and controls.

4. Delivery and processing of submittals.

5. Progress meetings.

6. Pre-installation conferences.

7. Project closeout activities.

1.3 SUBMITTALS

A. Division 01 documents: The following items shall be submitted a minimum of one week prior to the Preconstruction Conference. Contracting Officer will notify Contractor of tentative date for the Pre-Construction Conference.

1. Letter designating Project Superintendent.

2. Construction Schedule.

3. A comprehensive breakdown of the Schedule of Values.

4. Accident Prevention Plan.

5. A list of Subcontractors for this project.

6. Written statements from subcontractors certifying compliance with applicable labor standard clauses.

7. Satisfactory evidence of liability insurance coverage and workman’s compensation for the Contactor and all subcontractors.

8. Waste Management Plan.

9. Quality Control Plan.

B. All items listed must be provided to the Contracting Officer before the Pre- Construction Conference is held. If all of these documents have not been received one week prior to the scheduled Pre-Construction Conference date, the conference will be cancelled, Notice to Proceed will not be issued, and the Contracting Officer will consider other contractual remedies. Work shall not commence until written Notice to Proceed has been issued.

EVER – 218239 / 218241 013100 - 3

1.4 REQUESTS FOR INFORMATION (RFIs)

A. General: Immediately on discovery of the need for additional information or interpretation of the Contract Documents, Contractor shall prepare and submit an RFI utilizing the form created on the NPS/DSC SharePoint Project website.

1. COR will not respond to RFIs submitted by other entities controlled by Contractor.

2. Coordinate and submit RFIs in a prompt manner to avoid delays in the work.

B. Content of the RFI: Include a detailed, legible description of item needing information or interpretation and the following:

1. RFI number, numbered sequentially.

2. Date.

3. RFI subject.

4. Specification Section number and title and related paragraphs, as appropriate.

5. Drawing number and detail references, as appropriate.

6. Field dimensions and conditions, as appropriate.

7. Contractor's suggested resolution. If Contractor's suggested resolution impacts the Contract Time or the Contract Sum, Contractor shall state impact in the RFI.

8. Contractor's signature.

9. Requested date for response.

10. Attachments: Include sketches, descriptions, measurements, photos, Product Data, Shop Drawings, coordination drawings, and other information necessary to fully describe items needing interpretation.

a. Include dimensions, thicknesses, structural grid references, and details of affected materials, assemblies, and attachments on attached sketches.

C. Contracting Officer’s Representative Action: COR will review each RFI, determine action required, and respond. COR will determine the critical nature of each RFI and issue a response accordingly.

1. The following are not considered to be RFIs and will receive no action:

a. Requests for approval of submittals.

b. Requests for approval of substitutions.

c. Requests for approval of Contractor's means and methods.

d. Requests for coordination information already indicated in the

Contract Documents.

e. Requests for adjustments in the Contract Time or the Contract Sum.

f. Requests for interpretation of Architect's actions on submittals.

g. Incomplete RFIs or inaccurately prepared RFIs.

EVER – 218239 / 218241 013100 - 4

2. COR's action may include a request for additional information, in which case time for response will date from time of receipt of additional information.

3. COR's action on RFIs may result in the need for a change to the Contract Time or the Contract Sum. All contract changes will be processed following the terms and conditions of the contract.

D. All users will be required to have the following software packages:

1. Internet Explorer version 7 or later.

2. Adobe Acrobat Professional (Pro) version 9 or later

1.5 PROJECT MEETINGS

A. Preconstruction Conference: Before start of construction, Contracting Officer will arrange an on-site meeting with Contractor. The meeting agenda will include the following as a minimum:

1. Roles & Responsibilities/ Lines of Authority.

2. Park rules and regulations.

3. Jobsite Safety.

4. Resolution of comments on required Division 01 documents.

5. Coordination of Subcontractors.

6. Labor law application.

7. Modifications.

8. Payments to Contractor.

9. Payroll reports.

10. Contract time.

11. Liquidated damages.

12. Contractor Performance Evaluation.

13. Display of Hotline posters.

14. Notice to proceed.

15. Correspondence procedures.

16. NPS/DSC SharePoint Project website.

17. Acceptance/rejection of work.

18. Progress meetings.

19. Submittal procedures.

B. Progress Meetings: The Contracting Officer will schedule weekly meetings with the Contractor.

1. Attendees: In addition to Government Representatives, each Contractor, Subcontractor, supplier, and other entity concerned with current progress or involved in planning, coordination, or performance of future activities shall be represented at these meetings. All participants at the meeting shall be familiar with the Project and authorized to conclude matters relating to the Work.

EVER – 218239 / 218241 013100 - 5

2. Agenda: Review and correct or approve minutes of previous progress meeting. Review other items of significance that could affect progress.

The meeting agenda will include the following:

a. Approval of minutes of previous meetings.

b. Submittal status.

c. Review of off-site fabrication and delivery schedules.

d. Requests for information (RFI) and other issues.

e. Modifications.

f. Work in progress and projected.

1) Status of required inspections (Special Inspections, Accessibility, etc.)

g. Inspections of work in progress and projected (Special inspections,

h. Construction Schedule update (provide updated CPM).

i. Status of Project Record Drawings and O&M manuals.

j. Other business relating to work.

k. Permit requirements.

C. Preinstallation Conferences: Conduct a preinstallation conference at Project site before each construction activity that requires coordination with other construction.

1. Attendees: Installer and representatives of manufacturers and fabricators involved in or affected by the installation and its coordination or integration with other materials and installations that have preceded or will follow, shall attend the meeting. Advise CO of scheduled meeting dates.

2. Agenda: Review progress of other construction activities and preparations for the particular activity under consideration, including requirements for the following:

a. Contract Documents.

b. Options.

c. Related RFIs.

d. Related Change Orders.

e. Purchases.

f. Deliveries.

g. Submittals.

h. Review of mockups.

i. Possible conflicts.

j. Compatibility requirements.

k. Time schedules.

l. Weather limitations.

m. Manufacturer's written instructions.

n. Warranty requirements.

o. Compatibility of materials.

p. Acceptability of substrates.

q. Temporary facilities and controls.

r. Space and access limitations.

s. Regulations of agency(ies) with jurisdiction.

EVER – 218239 / 218241 013100 - 6

t. Testing and inspecting requirements.

u. Installation procedures.

v. Coordination with other work.

w. Required performance results.

x. Protection of adjacent work.

y. Protection of construction and personnel.

3. Record significant conference discussions, agreements, and disagreements, including required corrective measures and actions.

4. Reporting: Distribute minutes of the meeting to each party present and to other parties requiring information.

5. Do not proceed with installation if the conference cannot be successfully concluded. Initiate whatever actions are necessary to resolve impediments to performance of the Work and reconvene the conference at earliest feasible date.

1.6 ENVIRONMENTAL COORDINATION

A. Contractor’s Environmental Manager: Designate an on-site party responsible for overseeing the Contractor’s conformance to environmental goals for the project and implementing procedures for environmental protection.

1. Qualifications: Minimum 3 years Construction experience on projects of similar size and scope; with environmental procedures similar to those of this project; familiarity with Environmental Management Systems (EMSs) such as ISO 14001; must be familiar with environmental regulations applicable to construction operations.

2. Responsibilities: Responsibilities shall include:

a. Compliance with applicable Federal, State, and local environmental regulations, including maintaining required documentation.

b. Implementation of the Waste Management Plan (WMP).

c. Present an overview of environmental issues and summarize site specific procedures relating to management plans at the Preconstruction conference.

d. Training for Contractor personnel in accordance with their position requirements.

e. Monitoring and documentation of environmental procedures.

B. Perform project quality control in accordance with requirements specified in Related Sections, including:

1. Quality Requirements.

2. Regulatory Requirements.

3. Noise & Acoustics Management.

4. Construction Waste Management.

EVER – 218239 / 218241 013100 - 7

C. Contractor’s Environmental Training Program: Contractor shall provide environmental training for workers performing work on the project site. Training shall include the following:

1. Overview of environmental issues related to the building industry.

2. Overview of environmental issues related to the Project.

3. Review of site specific procedures and management plans:

a. Construction Waste Management.

b. Noise & Acoustics Management.

4. Compliance with environmental regulations: As specified in Regulatory Requirements. Submit Contractor 40 CFR employee training records upon request of Contracting Officer.

D. Provide documentation for environmental procedures as specified herein and in accordance with approved Waste Management Plan, IAQ Management Plan, and Storm Water Pollution Prevention Plan.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 31 00

EVER – 218239 / 218241 01 32 16 - 1

SECTION 01 32 16 – CONSTRUCTION SCHEDULE

PART 1 - GENERAL

1.1 SUMMARY

A. This Section consists of Construction Schedule requirements including but not limited to the following:

1. Schedule of Values

2. Construction Schedule Requirements.

3. Construction Schedule Updates.

4. Time Impact Analysis.

B. Purpose: The purpose of the Construction Schedule is to ensure adequate planning, coordination, scheduling, and reporting during execution of the work by the Contractor. The Construction Schedule will assist the Contractor and Contracting Officer in monitoring the progress of the work, evaluating proposed changes, and processing the Contractor's monthly progress payment.

1.2 DEFINITIONS

A. Activity: A discrete part of a project that can be identified for planning, scheduling, monitoring, and controlling the construction project. Activities included in a construction schedule consume time and resources.

1. Critical activities are activities on the critical path. They must start and finish on the planned early start and finish times.

2. Predecessor Activity: An activity that precedes another activity in the network.

3. Successor Activity: An activity that follows another activity in the network.

B. Cost Loading: The allocation of the Schedule of Values for the completion of an activity as scheduled. The sum of costs for all activities must equal the total Contract Sum, unless otherwise approved by the Contracting Officer.

C. CPM: Critical path method, which is a method of planning and scheduling a construction project where activities are arranged based on activity relationships. Network calculations determine when activities can be performed and the critical path of Project.

D. Critical Path: The longest connected chain of interdependent activities through the network schedule that establishes the minimum overall Project duration and contains no float.

E. Float: The measure of leeway in starting and completing an activity.

EVER – 218239 / 218241 01 32 16 - 2

1. Float: Float is not for the exclusive use or benefit of either the Government or the Contractor but is jointly owned.

2. Free float is the amount of time an activity can be delayed without adversely affecting the early start of the successor activity.

3. Total float is the measure of leeway in starting or completing an activity without adversely affecting the planned Project completion date.

F. Resource Loading: The allocation of manpower and equipment necessary for the completion of an activity as scheduled.

G. Fragnet: A partial or fragmentary network that breaks down activities into smaller activities for greater detail.

1.3 SUBMITTALS

A. Electronic Copies: All schedules and reports submitted by email to the NPS COR, provided in the native electronic file format. It is the intent of the Government to limit the number of printed reports to only those reports determined by the project team to be essential.

B. Schedule of Values: After contract award and before the Pre-Construction conference submit a schedule of dollar values based on the Contract Price Schedule.

C. Construction Baseline Schedule: After contract award and before the Pre- Construction conference, submit two paper copies of baseline schedule, large enough to show entire schedule for entire construction period.

D. Construction Schedule Updates: On or before the 7th day preceding the progress payment request date, submit estimates of the percent completion of each schedule activity and necessary supporting data. Provide two paper copies.

E. Construction Schedule Revisions and Time Impact Analysis: For each Construction Schedule revision submit two paper copies of a Time Impact Analysis. Each Time Impact Analysis shall include a Fragmentary Network (Fragnet), incorporated into the currently accepted Construction Schedule, demonstrating how the Contractor proposes to incorporate a modification, change, delay, or Contractor request.

1.4 QUALITY ASSURANCE

A. The Contractor shall meet with the Contracting Officer on the day of the preconstruction conference to go over the following:

1. Review software limitations, content and format for reports.

2. Verify availability of qualified personnel needed to develop and update schedule.

EVER – 218239 / 218241 01 32 16 - 3

3. Discuss constraints, including phasing, work stages, interim milestones and partial Government occupancy.

4. Review delivery dates for Government-furnished products.

5. Review schedule for work of separate Government contracts.

6. Review time required for review of submittals and re-submittals.

7. Review requirements for tests and inspections by independent testing and inspecting agencies.

8. Review time required for completion and startup procedures.

9. Review time required for obtaining and activating permits.

10. Review and finalize list of construction activities to be included in schedule.

11. Review baseline schedule comments, resolve issues and progress on incorporating them

12. Review procedures for updating schedule.

13. Discuss reporting requirements and establish a protocol for naming and transmitting electronic schedules.

1.5 COORDINATION

A. Coordinate preparation and processing of schedules and reports with performance of construction activities and with scheduling and reporting of separate Contractors.

B. Coordinate Construction Baseline Schedule with the Schedule of Values, list of subcontracts, Submittals Schedule, progress reports, payment requests, and other required schedules and reports.

1. In developing the Construction Baseline Schedule, ensure that the Subcontractor’s work at all tiers, as well as the prime Contractor’s work, is included and coordinated.

2. Secure time commitments for performing critical elements of the Work from parties involved.

3. Coordinate each construction activity in the network with other activities and schedule them in proper sequence.

PART 2 - PRODUCTS

2.1 SCHEDULE OF VALUES

A. Breakdown each lump-sum item into component work activities used in the schedule, for which progress payments may be requested. The work activities broken out within the schedule of values shall be integrated into and made a logical part of the construction baseline schedule submitted under this specification. The total costs for the component work activities shall equal the contract price for that lump-sum item. The Contracting Officer may request data to verify accuracy of dollar values. Include mobilization, general condition costs, overhead and profit in the total dollar value of unit price items and in the

EVER – 218239 / 218241 01 32 16 - 4

component work activities for each lump-sum item. Do not include mobilization, general condition costs, overhead or profit as a separate item.

B. Do not break down unit price items. Use only the contract price for unit price items.

C. The total cost of all items shall equal the contract price. The Schedule of Values will form the basis for progress payments.

D. An acceptable Schedule of Values shall be agreed upon by the Contractor and Contracting Officer before the first progress payment is processed.

2.2 CONSTRUCTION SCHEDULE REQUIREMENTS

A. Construction Baseline Schedule: Prepare Construction Baseline Schedule using a computerized, resource-loaded, time-scaled CPM network analysis diagram for the Work.

1. Develop and finalize Construction Baseline Schedule so it can be accepted for use no later than 30 days after date established for the Notice of Award.

a. Failure to include any work item required for performance of this Contract shall not excuse Contractor from completing all work within applicable completion dates, regardless of Governments acceptance of the schedule.

2. Establish procedures for monitoring and updating Construction Baseline Schedule and for reporting progress. Coordinate procedures with progress meeting and payment request dates.

B. Construction Baseline Schedule Preparation: Prepare a list of all activities required to complete the Work. Using the preliminary CPM network diagram, prepare a skeleton network to identify probable critical paths.

1. Activities: Indicate the estimated duration, sequence requirements, and relationship of each activity in relation to other activities.

2. Critical Path Activities: Identify critical path activities, including those for interim completion dates. Scheduled start and completion dates shall be consistent with Contract milestone dates.

3. Processing: Process data to produce output data on a computer-drawn, time-scaled network. Revise data, reorganize activity sequences, and reproduce as often as necessary to produce the CPM schedule within the limitations of the Contract Time.

4. The Construction Baseline Schedule as developed shall show the sequence and interdependence of activities required for complete performance of the work. Ensure all work sequences are logical and the Construction Baseline Schedule shows a coordinated plan of the work.

Baseline schedule must be saved and not modified. Actuals will then be recorded and compared to saved baseline.

EVER – 218239 / 218241 01 32 16 - 5

5. Resource loading of each activity shall include all personnel by labor category and equipment type and capacity proposed to complete the activity in the duration shown.

6. Consider seasonal weather conditions in planning and scheduling all work influenced by high and low ambient temperatures, wind, or precipitation to ensure completion of all work within the contract time.

7. Time Frame: Proposed duration assigned to each activity shall be the Contractor's best estimate of time required to complete the activity considering the scope and resources planned for the activity.

a. An early finish date may be shown but the late finish date must be the same date as the last day of the contract period. An early completion schedule must contain the following:

1) Insert an activity titled “Project Float” as a successor to the last activity in the early project completion schedule network.

2) Add a milestone titled “Contract End Date” as a successor to the activity “Project Float”.

3) Add duration to the activity “Project Float” as required so the milestone “Contract End Date” equals the last day of the Contract Period.

b. Contract completion date shall not be changed by submission of a schedule that shows an early completion date.

c. The Contractor shall limit use of lead or lag duration’s between schedule activities.

d. Project Calendars: Develop and incorporate the following calendars:

1) Administrative Calendar: Include a calendar that is based on a 7 day week to be used on any activities that are based on calendar days. Apply this calendar to administrative tasks or any other tasks that are not affected by non-working days (Federal Holidays, weather, etc.).

2) Project Calendar: Include a calendar that is based on the planned work week for the project. Include Federal Holidays, weekends, and any other non-work days indicated in the contract documents. Apply this calendar to activities which are not anticipated to be affected by weather.

3) Weather Calendar: Utilize the Project Calendar and show anticipated normal downtime related to weather as non-working time. Weather days shall be based on data for the local area from a reliable source like the National Oceanic and Atmospheric Administration (NOAA), National Park Service records, or source acceptable to the Contracting Officer.

Apply this calendar to activities that are anticipated to be affected by weather.

e. Activity Duration: Define activities so no activity is longer than 15 days, except for non-construction activities including mobilization, EVER – 218239 / 218241 01 32 16 - 6 shop drawings and submittals, fabrication and delivery of materials and equipment.

f. Submittal Review Time: Include review and re-submittal times indicated. Coordinate submittal review times in Construction Baseline Schedule.

g. Substantial Completion: Allow time for Government administrative procedures necessary for certification of Substantial Completion.

(For more information, refer to Division 01 Specification 01 77 00 Closeout Procedures.)

8. Constraints: Include constraints and work restrictions indicated in the Contract Documents and as follows in schedule, and show how the sequence of the Work is affected.

a. Phasing: Arrange list of activities on schedule by phase.

b. Work under More Than One Contract: Include a separate activity for each contract.

c. Work Restrictions: Show the effect of the following items on the schedule:

1) Coordination with existing construction.

2) Limitations of continued occupancies.

3) Uninterruptible services.

4) Partial occupancy before Substantial Completion.

5) Use of premises restrictions.

6) Provisions for future construction.

7) Seasonal variations.

8) Environmental control.

9) Permit provisions.

d. Work Stages: Indicate important stages of construction for each major portion of the Work.

1) Subcontract awards.

2) Submittals.

3) Purchases.

4) Fabrication.

5) Sample testing.

6) Deliveries.

7) Installation.

8) Tests and inspections.

9) Adjusting.

10) Curing.

11) Building flush-out.

9. Milestones: Include milestones indicated in the Contract Documents in schedule, including, but not limited to, the Notice to Proceed, Substantial Completion.

C. Joint Review, Revision, and Acceptance:

EVER – 218239 / 218241 01 32 16 - 7

1. Within seven calendar days of receipt of the Contractor's proposed Construction Baseline Schedule, the Contracting Officer and Contractor shall meet for joint review, correction, or adjustment of the initial Construction Baseline Schedule. Any areas which, in the opinion of the Contracting Officer, conflict with timely completion of the project shall be subject to revision by the Contractor.

2. Within seven calendar days after the joint review between the Contractor and Contracting Officer, the Contractor shall revise and resubmit the Construction Baseline Schedule in accordance with agreements reached during the joint review.

3. In the event the Contractor fails to define any element of work, activity, or logic, and the Contracting Officer review does not detect this omission or error, such omission or error, when discovered by the Contractor or Contracting Officer, shall be corrected by the Contractor within seven calendar days and shall not affect the contract period.

4. Upon acceptance of the Construction Baseline Schedule by the Contracting Officer, save the schedule as a baseline and update on a monthly basis. The construction schedule update will be used to evaluate the Contractor's monthly applications for payment based upon information developed at the monthly Construction Schedule update meeting.

D. Recovery Schedule: When periodic schedule update indicates the Work is 14 or more calendar days behind the current accepted schedule, a separate recovery schedule indicating means by which Contractor intends to regain compliance with the schedule must also be submitted. Indicate changes to working hours, working days, crew sizes, and equipment required to achieve compliance, and date by which recovery will be accomplished.

E. Computer Software: Prepare schedules using a program that has been developed specifically to manage construction schedules.

1. Use Microsoft Project, Primavera, or Meridian Prolog for current Windows operating system.

PART 3 - EXECUTION

3.1 CONSTRUCTION SCHEDULE UPDATES

A. Progress Meeting Updates: Provide a 2 week look-ahead schedule, derived from the currently accepted schedule, before each weekly progress meeting.

Utilize the look-ahead schedule to facilitate and take notes on discussions held during the progress meeting.

B. Monthly Schedule Updates:

1. General: Update the Construction Schedule on a monthly basis to reflect actual construction progress and activities throughout the entire contract period and until project substantial completion. The status date of each

EVER – 218239 / 218241 01 32 16 - 8

schedule update shall be the 7th day preceding the progress payment request date.

2. Procedure: The Contractor shall meet with the Contracting Officer each month at a Construction Schedule update meeting to review actual progress made through the status date of the Construction Schedule update, including dates activities were started and/or completed and the percentage of work completed on each activity started and/or completed.

3. Reports: Concurrent with making revisions to schedule, prepare tabulated reports showing the following:

a. Identification of activities that have changed.

b. Changes in early and late start dates.

c. Changes in early and late finish dates.

d. Changes in activity durations in workdays.

e. Changes in the critical path.

f. Changes in total float or slack time.

g. Changes in the Contract Time.

4. Narrative: The report shall include a brief description of the actual progress made during the update period; actual and potential delaying activities; any impediments to progress; issues related to inclement weather; progress toward established milestones and project float. The report shall include a brief description of the work anticipated to be performed in the next month. Any minor revisions to the schedule should be identified so they can be evaluated and accepted or rejected.

5. As the Work progresses, indicate Actual Completion percentage for each activity.

6. If the schedule update shows a late finish date after the contract completion date, at a minimum, include the following in the narrative with your submission:

a. Any known delays.

b. Actions that will be taken to get back on schedule.

c. Pending modifications.

d. Impediments or constraints affecting progress.

7. Progress Payments: The monthly updating of the currently accepted Construction Schedule shall be an integral part of the process upon which progress payments will be made under this contract. If the Contractor fails to provide schedule updates or revisions, then a portion of the monthly payment may be retained until such corrections have been made.

C. Distribution: Distribute copies of accepted schedule to Contracting Officer, Contracting Officers Representative, Construction Management Representative, Subcontractors, testing and inspecting agencies, and other parties identified by Contractor with a need-to-know schedule responsibility.

1. Post copies in Project meeting rooms and temporary field offices.

EVER – 218239 / 218241 01 32 16 - 9

2. When revisions are made, distribute updated schedules to the same parties and post in the same locations. Delete parties from distribution when they have completed their assigned portion of the Work and are no longer involved in performance of construction activities.

D. Construction Schedule Revisions:

1. Required Revisions: If, as a result of the monthly schedule update, it appears the currently accepted Construction Schedule no longer represents the actual prosecution and progress of the work, the Contracting Officer will request, and the Contractor shall submit, a revision to the Construction Schedule. The Contractor may also request reasonable revisions to the currently accepted Construction Schedule in the event the Contractor's planning for the work is revised. If the Contractor desires to make changes, the Contractor shall notify the Contracting Officer in writing, stating the reason for the proposed revision.

Accepted revisions will be incorporated into the currently accepted Construction Schedule for the next monthly schedule update.

2. Procedure: If revision to the currently accepted Construction Schedule is contemplated, the Contractor or Contracting Officer shall so advise the other in writing at least seven calendar days prior to the next monthly schedule update meeting, describing the revision and reasons for the revision. Government-requested revisions will be presented in writing to the Contractor, who shall respond in writing within seven calendar days.

3. Reports: Concurrent with making revisions to schedule, prepare tabulated reports showing the following:

a. Identification of activities that have changed.

b. Changes in early and late start dates.

c. Changes in early and late finish dates.

d. Changes in activity durations in workdays.

e. Changes in the critical path.

f. Changes in total float or slack time.

3.2 TIME IMPACT ANALYSIS FOR CONTRACT MODIFICATIONS CHANGES DELAYS AND

CONTRACTOR REQUESTS:

1. Requirements: When contract modifications or changes are initiated, delays are experienced, or the Contractor desires to revise the currently accepted Construction Schedule, the Contractor shall submit to the Contracting Officer a written time impact analysis illustrating the influence of each modification, change, delay, or Contractor request on the contract time.

2. Time Extensions: Activity delays, which result in projecting a late completion date, shall not automatically mean that an extension of the contract time is warranted or due the Contractor. It is possible that a modification, change, or delay will not affect existing critical path activities or cause non-critical activities to become critical. A modification, change, or delay may result in only absorbing a part of the

EVER – 218239 / 218241 01 32 16 - 10

available total float that may exist within an activity chain of the Schedule, thereby not causing any effect on the contract time. Time extensions will be granted in accordance with the terms of the contract.

3. Extension of the contract time will be granted only to the extent the equitable time adjustments to the activity or activities affected by the modification, change, or delay exceeds the total (positive or zero) float available on a particular activity.

4. Procedure: Each time impact analysis shall be submitted within the time period stated in a request for proposal, or the time period designated under the clauses entitled Changes or Default. In cases where the Contractor does not submit a written request for extension of time and a time impact analysis within the designated time, it is mutually agreed that the particular modification, change, delay, or Contractor request does not require an extension of the contract time. Upon acceptance, the time impact analysis shall be incorporated into the currently accepted Construction Schedule at the next monthly schedule update.

5. Contract Modifications: For each proposed contract modification and concurrent with its submission, prepare a time-impact analysis using fragnets to demonstrate the effect of the proposed change on the overall Construction Schedule.

END OF SECTION 01 32 16

EVER – 218239 / 218241 01 33 23 - 1

SUBMITTAL PROCEDURES

SECTION 01 33 23 - SUBMITTAL PROCEDURES

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes administrative and procedural requirements for submitting Shop Drawings, Product Data, Samples, and other submittals.

1.2 DEFINITIONS

A. Action Submittals: Written, graphic information, and physical samples that require Government’s responsive action.

B. Informational Submittals: Written information that does not require Government’s responsive action. Submittals may be rejected for not complying with the requirements.

C. File Transfer Protocol (FTP): Communications protocol that enables transfer of files to and from another computer over a network and that serves as the basis for standard Internet protocols. An FTP site is a portion of a network located outside of network firewalls within which internal and external users are able to access files.

D. Portable Document Format (PDF): An open standard file format licensed by Adobe Systems used for representing documents in a device-independent and display resolution-independent fixed-layout document format.

1.3 GENERAL SUBMITTAL PROCEDURES

A. General: Prepare and submit submittals required by individual Specification Sections. Types of submittals are indicated in individual specific sections.

1. Contracting Officer reserves the right to require submittals in addition to those called for in individual sections.

B. Coordination: Coordinate preparation and processing of submittals with performance of construction activities. Review them for legibility, accuracy, completeness, and compliance with Contract Documents.

1. Coordinate each submittal with fabrication, purchasing, testing, delivery, other submittals, and related activities that require sequential activity.

2. Coordinate transmittal of different types of submittals for related parts of the Work so processing will not be delayed because of need to review submittals concurrently for coordination.

EVER – 218239 / 218241 01 33 23 - 2

a. Contracting Officer reserves the right to withhold action on a submittal requiring coordination with other submittals until related submittals are received.

C. Processing Time: Allow enough time for submittal review, including time for re-submittals, as follows. Time for review shall commence when submittal is received by the NPS COR. When the Contracting Officer has completed their review, an e-mail notification will be sent to the Contractor indicating the submittal has been processed. No extension of the Contract Time will be authorized because of failure to transmit submittals enough in advance of the Work to permit processing, including re-submittals.

1. Action Submittals

a. Initial Review: Allow 10 days for initial review of each submittal. Allow additional time if coordination with subsequent submittals is required.

b. Re-submittal Review: Allow 10 days for review of each re-submittal.

2. Informational submittals

a. Review: Allow 10 days for review of each submittal.

D. Approved Equals:

1. For each item proposed as an “approved equal,” submit supporting data, including:

a. Drawings and samples as appropriate.

b. Comparison of the characteristics of the proposed item with that specified.

c. Changes required in other elements of the work because of the substitution.

d. Name, address, and telephone number of vendor.

e. Manufacturer’s literature regarding installation, operation, and maintenance, including schematics for electrical and hydraulic systems, lubrication requirements, and parts lists. Describe availability of maintenance service, and state source of replacement materials.

2. A request for approval constitutes a representation that Contractor:

a. Has investigated the proposed item and determined that it is equal or superior in all respects to that specified.

b. Will provide the same warranties for the proposed item as for the item specified.

c. Has determined that the proposed item is compatible with interfacing items.

d. Will coordinate the installation of an approved item and make all changes required in other elements of the work because of the substitution.

EVER – 218239 / 218241 01 33 23 - 3

e. Waives all claims for additional expenses that may be incurred as a result of the substitution.

E. Electronic Submittals: Identify and incorporate information in each electronic submittal file as follows:

1. CM-SPE Transmittal Form: All submittals shall be transmitted using National Park Service form CM-SPE form. The form will be provided by NPS. No action will be taken on a submittal item unless accompanied by the CM- SPE transmittal form.

a. Complete the general information at the top of the form.

b. Provide all required information based on the submittal type

c. Attach all related documents.

d. Sign the CM-SPE form in the contractor section at the bottom of the form, and select “submit” when complete.

2. Physical samples: Deliver the physical samples to the CO (or designee) on site for processing. All comments and actions will be documents.

F. Identification: Submittal number or other unique identifier, including revision identifier.

1. Submittal number shall use a sequential number (e.g., .001). Re-submittals shall include an alphabetic suffix after another decimal point (e.g., .001.A).

G. Re-submittals: Make re-submittals using the same process used with the initial submittal.

1. Note date and content of previous submittal.

2. Note date and content of revision in the title block on the CM-SPE and clearly indicate the extent of revision.

3. Re-submit submittals until they are marked “Approved” or “Approved with notations”.

H. Distribution: Furnish copies of final submittals to manufacturers, subcontractors, suppliers, fabricators, installers, and others as necessary for performance of construction activities.

I. Use for Construction: Use only final submittals with mark indicating “Approved” or…