P15PS02707_Solicitation_Oct_20 _2015.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

NPS, DSC Contracting Services Div

12795 W. Alameda Pkwy

P.O. Box 25287 Denver CO 80225-0287

PDS

SAME AS BOX 7

Nicole Jensen

PRPA 15029

x 10/19/2015

P15PS02707

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

14 592 calendar days and complete it within ________________ ________________ calendar days after receiving

11/23/2015

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

DOI, NPS, DSC Contracting Services 12795 W. Alameda Pkwy

P.O. Box 25287 Denver CO 80225-0287

PDS

Darrin Knapp

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 179

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

P15PS02707

1. This project is a reacquisition to complete contract P12PC00807, PRPK 581, Upgrade Grounds

Infrastructure.

2. The Contractor shall perform the design-build construction project in accordance with the terms and conditions contained herein.

3. This project has been classified at the

"Secret" level.

Karen La Bouff Kind, Contracting Officer -

(303)969-2181

Nicole Jensen, Contract Specialist - (303)987-6778

Doug Denk, Contracting Officer's

Representative(COR) - (303)969-2336

Tom Barna, COR - (202)219-0019

Lydia Creager, Alternate COR - (303)987-6855

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

Solicitation

P15PS02707

Document No.

PRPA 15029

Document Title

Upgrade Grounds Infrastructure

TABLE OF CONTENTS

SECTION B – SUPPLIES OR SERVICES AND PRICE/ COSTS

B.1 CONTRACT PRICE SCHEDULE AND INSTRUCTIONS

SECTION C – DESCRIPTION/ SPECIFICATIONS/ STATEMENT OF WORK

C.1 STATEMENT OF WORK/PROJECT SPECIFICATIONS

C.2 DSC-42 DOCUMENT STANDARDS - DESIGN-BUILD MARCH 2002

SECTION E – INSPECTION AND ACCEPTANCE

E.2 52.246-4 -- INSPECTION OF SERVICES -- FIXED-PRICE

E.2 52.246-12 INSPECTION OF CONSTRUCTION (AUGUST 1996)

SECTION F – DELIVERIES OR PERFORMANCE

F.1 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APRIL 1984) 14

F.2 52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

F.3 52.211-13 TIME EXTENSIONS (SEPT 2000)

F.4 52.242-17 GOVERNMENT DELAY OF WORK (APRIL 1984)

SECTION G – CONTRACT ADMINISTRATION DATA

G.1 1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

G.2 DIAPR 2010-14 CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM (JUL

2010)

G.3 DIAPR 2011-04 ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS—INVOICE

PROCESSING PLATFORM (IPP) (APRIL 2013)

SECTION H – SPECIAL CONTRACT REQUIREMENTS

H.1 KEY PERSONNEL

H.2 UNAUTHORIZED USE OF THE U.S. SECRET SERVICE NAME

H.3 CONDUCT OF OPERATIONS

H.4 WAGE RATES

SECTION I – CONTRACT CLAUSES

I.1 1452.203-70 RESTRICTIONS ON ENDORSEMENTS – DEPARTMENT OF INTERIOR (JUL

1996)

I.2 1452.204-70 RELEASE OF CLAIMS – DEPARTMENT OF INTERIOR (JUL 1996)

I.3 1452.215-70 EXAMINATION OF RECORDS BY THE DEPARTMENT OF INTERIOR (APR 1984) ..

I.4 1452.228-70 LIABILITY INSURANCE (JUL 1996)

I.5 1452.236-70 PROHIBITION AGAINST USE OF LEAD-BASED PAINT—DEPARTMENT OF THE

INTERIOR (JUL 1996)

I.6 52.202-1 DEFINITIONS (NOV 2013)

I.7 52.203-3 GRATUITIES (APR 1984)

I.8 52.203-5 COVENANT AGAINST CONTINGENT FEES (MAY 2014)

I.9 52.203-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE GOVERNMENT (SEPT

2006)

I.10 52.203-7 ANTI-KICKBACK PROCEDURES (MAY 2014)

I.11 52.203-8 CANCELLATION, RESCISSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR

IMPROPER ACTIVITY (MAY 2014)

I.12 52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (MAY 2014) .

I.13 52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS

(OCT 2010)

I.14 52.203-13 CONTRACTOR CODE OF BUSINESS ETHICS AND CONDUCT (APRIL 2010)

I.15 52.203-14 DISPLAY OF HOTLINE POSTER(S) (DECEMBER 2007)

I.16 52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS AND REQUIREMENT TO

INFORM EMPLOYEE OF WHISTLEBLOWER RIGHTS (APR 2014)

I.17 52.204-2 SECURITY REQUIREMENTS (AUG 1996) ALTERNATE II (APR 1984)

I.18 52.204-4 PRINTED OR COPIED DOUBLE-SIDED ON POSTCONSUMER CONTENT PAPER ... 42

I.19 52.204-9 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR PERSONNEL (JAN 2011) 42

I.20 52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT

AWARDS (JULY 2013)

I.21 52.204-12 DATA UNIVERSAL NUMBERING SYSTEM NUMBER MAINTENANCE (DEC 2012) .. 44

I.22 52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (JUL 2013)

I.23 52.204-14 SERVICE CONTRACT REPORTING REQUIREMENTS (JAN 2014)

I.24 52.204-18 COMMERCIAL AND GOVERNMENT ENTITY CODE MAINTENANCE (JUL 2015)

I.25 52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND

CERTIFICATIONS (DEC 2014)

I.26 52.209-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (AUG 2013)

I.27 52.209-9 UPDATES OF PUBLICLY AVAILABLE INFORMATION REGARDING RESPONSIBILITY

MATTERS (JUL 2013)

I.28 52.215-2 AUDIT AND RECORDS—NEGOTIATION (OCT 2010)

I.29 52.215-8 ORDER OF PRECEDENCE—UNIFORM CONTRACT FORMAT (OCT 1997)

I.30 52.215-10 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR PRICING DATA (AUG

2011)

I.31 52.215-11 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR PRICING DATA--

MODIFICATIONS (AUG 2011)

I.32 52.215-12 SUBCONTRACTOR CERTIFIED COST OR PRICING DATA (OCT 2010)

I.33 52.215-13 SUBCONTRACTOR CERTIFIED COST OR PRICING DATA—MODIFICATIONS (OCT

2010)

I.34 52.215-15 PENSION ADJUSTMENTS AND ASSET REVERSIONS (OCT 2010)

I.35 52.215-18 REVERSION OR ADJUSTMENT OF PLANS FOR POST RETIREMENT BENEFITS

(PRB) OTHER THAN PENSIONS (JUL 2005)

I.36 52.215-19 NOTIFICATION OF OWNERSHIP CHANGES (OCT 1997)

I.37 52.215-21 REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA AND DATA OTHER

THAN CERTIFIED COST OR PRICING DATA—MODIFICATIONS (OCT 2010)

I.38 52.217-5 EVALUATION OF OPTIONS (JULY 1990)

I.39 52.219-4 NOTICE OF PRICE EVALUATION FOR HUBZONE SMALL BUSINESS CONCERNS

(OCT 2014)

I.40 52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS (MAY 2014)

I.41 52.219-14 LIMITATIONS ON SUBCONTRACTING (NOV 2011)

I.42 52.219-16 LIQUIDATED DAMAGES -- SUBCONTRACTING PLAN (JAN 1999)

I.43 52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REPRESENTATION (JUL 2013)

I.44 52.222-3 CONVICT LABOR (JUNE 2003)

I.45 52.222-4 CONTRACT WORK HOURS AND SAFETY STANDARDS ACT – OVERTIME

COMPENSATION (MAY 2014)

I.46 52.222-6 CONSTRUCTION WAGE RATE REQUIRMENTS (MAY 2014)

I.47 52.222-7 WITHHOLDING OF FUNDS (MAY 2014)

I.48 52.222-8 PAYROLLS AND BASIC RECORDS (MAY 2014)

I.49 52.222-9 APPRENTICES AND TRAINEES (JULY 2005)

I.50 52.222-10 COMPLIANCE WITH COPELAND ACT REQUIREMENTS (FEB 1988)

I.51 52.222-11 SUBCONTRACTS (LABOR STANDARDS) (MAY 2014)

I.52 52.222-12 CONTRACT TERMINATION—DEBARMENT (MAY 2014)

I.53 52.222-13 COMPLIANCE WITH CONSTRUCTION WAGE RATE REQUIREMENTS AND

RELATED REGULATIONS (MAY 2014)

I.54 52.222-14 DISPUTES CONCERNING LABOR STANDARDS (FEB 1988)

I.55 52.222-15 CERTIFICATION OF ELIGIBILITY (MAY 2014)

I.56 52.222-21 PROHIBITION OF SEGREGATED FACILITIES (APR 2015)

I.57 52.222-26 EQUAL OPPORTUNITY (APR 2015)

I.58 52.222-27 AFFIRMATIVE ACTION COMPLIANCE REQUIREMENTS FOR CONSTRUCTION

(APR 2015)

I.59 52.222-30 CONSTRUCTION WAGE RATE REQUIREMENTS—PRICE ADJUSTMENT (NONE

OR SEPARATELY SPECIFIED METHOD) (MAY 2014)

I.60 52.222-35 EQUAL OPPORTUNITY FOR VETERANS (JUL 2014)

I.61 52.222-36 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (JUL 2014)

I.62 52.222-37 EMPLOYMENT REPORTS ON VETERANS (JUL 2014)

I.63 52.222-40 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR

RELATIONS ACT (DEC 2010)

I.64 52.222-50 COMBATING TRAFFICKING IN PERSONS (MAR 2015)

I.65 52.222-54 EMPLOYMENT ELIGIBILITY VERIFICATION (AUG 2013)

I.66 52.222-55 MINIMUM WAGES UNDER EXECUTIVE ORDER 13658 (DEC 2014)

I.67 52.223-2 AFFIRMATIVE PROCUREMENT OF BIOBASED PRODUCTS UNDER SERVICE AND

CONSTRUCTION CONTRACTS (SEPT 2013)

I.68 52.223-3 HAZARDOUS MATERIAL IDENTIFICATION AND MATERIAL SAFETY DATA (JAN

1997) ALTERNATE 1 (JULY 1995)

I.69 52.223-5 POLLUTION PREVENTION AND RIGHT-TO-KNOW INFORMATION (MAY 2011)

I.70 52.223-6 DRUG-FREE WORKPLACE (MAY 2001)

I.71 52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR

EPA-DESIGNATED ITEMS (MAY 2008) ALTERNATE I (MAY 2008)

I.72 52.223-12 REFRIGERATION EQUIPMENT AND AIR CONDITIONS (MAY 1995)

I.73 52.223-15 ENERGY EFFICIENCY IN ENERGY-CONSUMING PRODUCTS (DEC 2007)

I.74 52.223-17 AFFIRMATIVE PROCUREMENT OF EPA-DESIGNATED ITEMS IN SERVICE AND

CONSTRUCTION CONTRACTS (MAY 2008)

I.75 52.223-18 ENCOURAGING CONTRACTOR POLICIES TO BAN TEXT MESSAGING WHILE

DRIVING (AUG 2011)

I.76 52.225-11 BUY AMERICAN – CONSTRUCTION MATERIALS UNDER TRADE AGREEMENTS-

ALTERNATE I (MAY 2014)

I.77 52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JUNE 2008)

I.78 52.227-1 AUTHORIZATION AND CONSENT (DEC 2007)

I.79 52.227-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT

INFRIGEMENT (DEC 2007)

I.80 52.227-4 PATENT INDEMNITY -- CONSTRUCTION CONTRACTS (DEC 2007)

I.81 52.227-16 ADDITIONAL DATA REQUIREMENTS (JUNE 1987)

I.82 52.227-17 RIGHTS IN DATA--SPECIAL WORKS (DEC 2007)

I.83 52.228-2 ADDITIONAL BOND SECURITY (OCT 1997)

I.84 52.228-5 INSURANCE—WORK ON A GOVERNMENT INSTALLATION (JAN 1997)

I.85 52.228-11 PLEDGES OF ASSETS (JAN 2012)

I.86 52.228-12 PROSPECTIVE SUBCONTRACTOR REQUESTS FOR BONDS (MAY 2014)

I.87 52.228-14 IRREVOCABLE LETTER OF CREDIT (NOV 2014)

I.88 52.228-15 PERFORMANCE AND PAYMENT BONDS—CONSTRUCTION (OCT 2010)

I.89 52.229-3 FEDERAL, STATE, AND LOCAL TAXES (FEB 2013)

I.90 52.230-2 COST ACCOUNTING STANDARDS (OCT 2015)

I.91 52.230-3 DISCLOSURE AND CONSISTENCY OF COST ACCOUNTING PRACTICES (OCT

2015)

I.92 52.230-6 ADMINISTRATION OF COST ACCOUNTING STANDARDS (JUN 2010)

I.93 52.232-5 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (MAY 2014) .. 117

I.94 52.232-10 PAYMENTS UNDER FIXED-PRICE ARCHITECT-ENGINEER CONTRACTS (APR

2010)

I.95 52.232-17 INTEREST (MAY 2014)

I.96 52.232-23 ASSIGNMENT OF CLAIMS (MAY 2014)

I.97 52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (MAY 2014)

I.98 52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER-SYSTEM FOR AWARD

MANAGEMENT (JUL 2013)

I.99 52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS (JUN 2013)

I.100 52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS

SUBCONTRACTORS (DEC 2013)

I.101 52.233-1 DISPUTES (MAY 2014) ALTERNATE I (DEC 1991)

I.102 52.233-3 PROTEST AFTER AWARD (AUG 1996)

I.103 52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

I.104 52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

I.105 52.236-2 DIFFERING SITE CONDITIONS (APR 1984)

I.106 52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984) . 128

I.107 52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

I.108 52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (APR 1984)

I.109 52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991)

I.110 52.236-8 OTHER CONTRACTS (APR 1984)

I.111 52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT,

UTILITIES, AND IMPROVEMENTS (APR 1984)

I.112 52.236-10 OPERATIONS AND STORAGE AREAS (APR 1984)

I.113 52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (APR 1984)

I.114 52.236-12 CLEANING UP (APR 1984)

I.115 52.236-13 ACCIDENT PREVENTION (NOV 1991) ALTERNATE I (NOV 1991)

I.116 52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES (APR 1984)

I.117 52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

I.118 52.236-17 LAYOUT OF WORK (APR 1984)

I.119 52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997)

ALTERNATE I (APR 1984)

I.120 52.236-23 RESPONSIBILITY OF THE ARCHITECT-ENGINEER CONTRACTOR (APR 1984)

I.121 52.236-24 WORK OVERSIGHT IN ARCHITECT-ENGINEER CONTRACTS (APR 1984)

I.122 52.236-25 REQUIREMENTS FOR REGISTRATION OF DESIGNERS (JUNE 2003)

I.123 52.236-26

I.124 52.242-13 BANKRUPTCY (JULY 1995)

I.125 52.242-14 SUSPENSION OF WORK (APR 1984)

I.126 52.243-4 CHANGES (JUNE 2007)

I.127 52.243-6 CHANGE ORDER ACCOUNTING (APR 1984)

I.128 52.244-5 COMPETITION IN SUBCONTRACTING (DEC 1996)

I.129 52.244-6 SUBCONTRACTS FOR COMMERCIAL ITEMS (JUL 2014)

I.130 52.245-9 USE AND CHARGES (APR 2012)

I.131 52.246-21 WARRANTY OF CONSTRUCTION (MAR 1994) ALTERNATE 1 (APR 1984)

I.132 52.247-12 SUPERVISION, LABOR, OR MATERIALS (APR 1984)

I.133 52.248-2 VALUE ENGINEERING -- ARCHITECT-ENGINEER (MAR 1990)

I.134 52.248-3 VALUE ENGINEERING -- CONSTRUCTION (OCT 2015)

I.135 52.249-2 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE)

(APR 2012) ALTERNATE 1 (SEPT 1996)

I.136 52.249-7 TERMINATION (FIXED-PRICE ARCHITECT-ENGINEER) (APR 1984)

I.137 52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984)

I.138 52.253-1 COMPUTER GENERATED FORMS (JAN 1991)

SECTION J – LIST OF ATTACHMENTS

J.1 LIST OF ATTACHMENTS

SECTION K – REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENT OF OFFERORS . 148

K.1 52.203-2 CERTIFICATE OF INDEPENDENT PRICE DETERMINATION (APR 1985)

K.2 52.203-11 CERTIFICATION AND DISCLOSURE REGARDING PAYMENTS TO INFLUENCE

CERTAIN FEDERAL TRANSACTIONS (SEPT 2007)

K.3 52.204-6 DATA UNIVERSAL NUMBERING SYSTEM NUMBER (JUL 2013)

K.4 52.204-7 SYSTEM FOR AWARD MANAGEMENT (JUL 2013)

K.5 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAY 2014)

K.6 52.204-17 OWNERSHIP OR CONTROL OF OFFEROR (NOV 2014)

K.7 52.209-5 CERTIFICATION REGARDING RESPONSIBILITY MATTERS (APR 2010)

K.8 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JUL 2013)

K.9 52.219-1 SMALL BUSINESS PROGRAM REPRESENTATIONS (APR 2012)

K.10 52.222-22 PREVIOUS CONTRACTS AND COMPLIANCE REPORTS (FEB 1999)

K.11 52.225-25 PROHIBITION ON CONTRACTING WITH ENTITIES ENGAGING IN CERTAIN

ACTIVITIES OR TRANSACTIONS RELATING TO IRAN—REPRESENTATION AND CERTIFICATION

(DEC 2012)

K.12 52.227-15 REPRESENTATION OF LIMITED RIGHTS DATA AND RESTRICTED COMPUTER

SOFTWARE (DEC 2007)

K.13 52.230-1 COST ACCOUNTING STANDARDS NOTICES AND CERTIFICATION (OCT 2015)161

K.14 52.236-28 PREPARATION OF PROPOSALS—CONSTRUCTION (OCT 1997)

SECTION L – INSTRUCTIONS, CONDITIONS AND NOTICES TO BIDDERS

L.1 1452.215-71 USE AND DISCLOSURE OF PROPOSAL INFORMATION—DEPARTMENT OF THE

INTERIOR (APR 1984)

L.2 1452.233-2 SERVICE OF PROTEST DEPARTMENT OF THE INTERIOR (JUL 1996)

(DEVIATION)

L.3 52.204-7 SYSTEM FOR AWARD MANAGEMENT (JUL 2013)

L.4 52.215-1 INSTRUCTIONS TO OFFERORS -- COMPETITIVE ACQUISITION (JAN 2004)

L.5 52.215-20 REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA AND DATA OTHER

THAN CERTIFIED COST OR PRICING DATA (OCT 2010)

L.6 52.216-1 TYPE OF CONTRACT (APR 1984)

L.7 52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS — SECONDARY SITE OF THE

WORK (MAY 2014)

L.8 52.222-22 PREVIOUS CONTRACTS AND COMPLIANCE REPORTS (FEB 1999)

L.9 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

L.10 52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT—CONSTRUCTION MATERIALS

UNDER TRADE AGREEEMENTS-ALTERNATE I (MAY 2014)

L.11 52.228-1 BID GUARANTEE (SEP 1996)

L.12 52.233-2 SERVICE OF PROTEST (SEP 2006)

L.13 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) ALTERNATE I (FEB 1995)

L.14 52.236-28 PREPARATION OF PROPOSALS -- CONSTRUCTION (OCT 1997)

L.15 PROPOSAL PREPARATION INSTRUCTIONS

SECTION M – EVALUATION FACTORS FOR AWARD

M.1 GENERAL EVALUATION FACTORS FOR AWARD

SECTION B – SUPPLIES OR SERVICES AND PRICE/ COSTS

B.1 CONTRACT PRICE SCHEDULE AND INSTRUCTIONS

Offeror is required to submit, at a minimum, an offer that conforms to the solicitation documents with pricing for all CLINs. Failure to do so may render the proposal unacceptable. This contract is a firm fixed price. On all line items (lump-sum) provide the total firm fixed price only. For all fixed-unit-price contract line item numbers, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of errors in summations, the total of the corrected amounts govern. Round totals and extended prices to whole dollars.

CONTRACT

LINE ITEM

NUMBER

(CLIN)

CONTRACT LINE ITEM (CLI) TITLE QUANTITY UNIT OF

MEASURE UNIT PRICE TOTAL PRICE

1 South Grounds Design 1 Lump Sum

2 South Grounds Construction 1 Lump Sum

TOTAL BASE PRICE (Contract Line Item Numbers 1 & 2) ------------------------------------

3 Option A: North Grounds Design 1 Lump Sum

4 Option B: North Grounds Construction 1 Lump Sum

5A Option C: Correction of Rejected Duct Bank from EMH/TMH-306 to EMH/TMH-308 1 Lump Sum

5B Option D: Correction of Rejected Duct Bank from EMH/TMH-319 to Existing Structure 1 Lump Sum

5C Option E: Correction of Rejected Duct Bank from EMH/TMH-310 to EMH/TMH-321 to

EMH/TMH-322

1 Lump Sum

TOTAL PRICE FOR ALL OPTIONS (Contract Line Item Numbers 3, 4, 5A, 5B & 5C) --------------------------

TOTAL PROPOSED PRICE - BASE PLUS ALL OPTIONS (Contract Line Item Numbers 1 through 5) -------

All measurement and payment information is included in the Scope of Work, Section 2.0 Project Requirements

Notice: Refer to FAR Clause 52.217-5, Evaluation of Options, as prescribed in FAR 17. Offerors are required to submit, a minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of error in summation, the total of the corrected amounts govern. Round totals and extended prices to whole dollars. The Government reserves the right to award any or no options at or after the time of award. At the option of the Government, the period for exercise of options at the proposed prices shall extend 180 calendar days from the date of award. Pricing will be evaluated based on what is determined to be the best value to the Government. Options may be exercised in any combination, order, or grouping deemed in the judgment of the Contracting Officer to offer the best value to the Government.

SECTION C – DESCRIPTION/ SPECIFICATIONS/ STATEMENT OF WORK

C.1 STATEMENT OF WORK/PROJECT SPECIFICATIONS

The specifications and drawings for this acquisition are "For Official Use Only" and classified "Secret". These specifications and drawings are incorporated herein by reference. There is a list of attachments is in Section J.

C.2 DSC-42 DOCUMENT STANDARDS - DESIGN-BUILD MARCH 2002

A. Design shall be accomplished by licensed or registered design professionals in accordance with applicable codes, accepted standards and National Park Service Design Process Guidelines (Operations Manual, Part 2, Design Process). Professional registration stamps for the responsible disciplines shall be required on all final drawing sheets.

B. Drawings shall be prepared in accordance with the Denver Service Center publication "Drafting Guidelines", NPS- 10 (Drawing Requirements - Architect/Engineer Contract for Architect/Engineer Projects).

a. Format - All drawings shall be prepared on 22-inch x 34--inch standard mylar sheets in black plastic lead or black waterproof ink at the option of the A/E. Required NPS standard mylar sheets will be furnished by the Contracting Officer without charge to the A/E. Title, drawing designation, and other identification of each drawing shall be approved by the Contracting Officer.

b. Quality - all drawings shall be prepared in such manner as to facilitate 35 millimeter filming and reduced size reproduction. Detailing, lettering, spacing, line-weight, scale and other principles of technique shall be so executed as to ensure clarity and faithfulness in reduced-size reproduction, in the enlarged image as projected in 35 millimeter reading equipment, and in the "blowback" from the 35 millimeter film to a reduction identical in size to the original tracing. All letters and numerals shall be at least 1/8-inch in height, adequately spaced in single- stroke upper-case Gothic style, preferable vertical. All lines, strokes, letters and numerals shall be uniformly dense as practicable. Scale identification shall be by graphic illustration or by appropriate explanation to scale notation.

C. Specifications: All specifications prepared under this contract, including technical specifications, general requirements (provided by NPS contracting division) and a table of contents, shall be prepared in accordance with the NPS "Guide for Specifiers" which prescribes, in part, that technical specifications shall be written in accordance with the Manual of Practice written by the Construction Specifications Institute.

D. The Resource Conservation and Recovery Act (RCRA), Section 6002 and Executive Order 13101 require the purchase of Environmental Protection Agency (EPA) designated products with a required minimum recovered material content as described in an agency's Affirmative Procurement Program (APP). This list of EPA-designated products is available at http://www.epa.gov/cpg. This requirement applies to all contracts that require EPA-designated products.

When purchasing a product or products on this list without the required minimum recovered material content, a written justification based on specific exemptions is required by FAR 23.405(c). A/E firms and their consultants are required to be familiar with EPA's guidelines by developing specifications utilizing EPA's minimum recycled content standards. If products specified by the A/E under this task order do not meet EPA's guidelines, the A/E must prepare written justifications in accordance with FAR 23.405(c).

E. A/E firms shall use life-cycle cost analysis, wherever feasible and appropriate, to assist selecting in products and services. Whenever possible, cost shall be calculated over the life of the item, not just the initial, up-front cost. When comparing alternative products, the initial cost of the acquisition as well as lifetime maintenance costs, operational costs, etc., must be considered in the analysis. A product having a higher initial cost may have lower operational cost or a higher resale value and will, therefore, prove to be a better value and more cost effective compared to the alternatives.

(End of Clause)

SECTION E – INSPECTION AND ACCEPTANCE

E.2 52.246-4 -- INSPECTION OF SERVICES -- FIXED-PRICE.

(a) Definition: “Services,” as used in this clause, includes services performed, workmanship, and material furnished or utilized in the performance of services.

(b) The Contractor shall provide and maintain an inspection system acceptable to the Government covering the services under this contract. Complete records of all inspection work performed by the Contractor shall be maintained and made available to the Government during contract performance and for as long afterwards as the contract requires.

(c) The Government has the right to inspect and test all services called for by the contract, to the extent practicable at all times and places during the term of the contract. The Government shall perform inspections and tests in a manner that will not unduly delay the work.

(d) If the Government performs inspections or tests on the premises of the Contractor or a subcontractor, the Contractor shall furnish, and shall require subcontractors to furnish, at no increase in contract price, all reasonable facilities and assistance for the safe and convenient performance of these duties.

(e) If any of the services do not conform with contract requirements, the Government may require the Contractor to perform the services again in conformity with contract requirements, at no increase in contract amount. When the defects in services cannot be corrected by reperformance, the Government may --

(1) Require the Contractor to take necessary action to ensure that future performance conforms to contract requirements; and

(2) Reduce the contract price to reflect the reduced value of the services performed.

(f) If the Contractor fails to promptly perform the services again or to take the necessary action to ensure future performance in conformity with contract requirements, the Government may --

(1) By contract or otherwise, perform the services and charge to the Contractor any cost incurred by the Government that is directly related to the performance of such service; or

(2) Terminate the contract for default.

E.2 52.246-12 INSPECTION OF CONSTRUCTION (AUGUST 1996)

(a) Definition. “Work” includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not—

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer’s written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may—

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or

(2) Terminate for default the Contractor’s right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction.

However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.

(End of Clause)

SECTION F – DELIVERIES OR PERFORMANCE

F.1 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APRIL 1984)

The Contractor shall be required to (a) commence work under this contract within fourteen (14) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 592 calendar days from the Notice of Proceed date. The time stated for completion shall include final cleanup of the premises.

F.2 52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract for the specific CLIN order under a task order, the Contractor shall pay liquidated damages to the Government in the amount of $1,000.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

F.3 52.211-13 TIME EXTENSIONS (SEPT 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

F.4 52.242-17 GOVERNMENT DELAY OF WORK (APRIL 1984)

(a) If the performance of all or any part of the work of this contract is delayed or interrupted (1) by an act of the Contracting Officer in the administration of this contract that is not expressly or impliedly authorized by this contract, or

(2) by a failure of the Contracting Officer to act within the time specified in this contract, or within a reasonable time if not specified, an adjustment (excluding profit) shall be made for any increase in the cost of performance of this contract caused by the delay or interruption and the contract shall be modified in writing accordingly. Adjustment shall also be made in the delivery or performance dates and any other contractual term or condition affected by the delay or interruption. However, no adjustment shall be made under this clause for any delay or interruption to the extent that performance would have been delayed or interrupted by any other cause, including the fault or negligence of the

Contractor, or for which an adjustment is provided or excluded under any other term or condition of this contract.

(b) A claim under this clause shall not be allowed—

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved; and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the delay or interruption, but not later than the day of final payment under the contract.

SECTION G – CONTRACT ADMINISTRATION DATA

G.1 1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without prior authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

G.2 DIAPR 2010-14 CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM (JUL 2010)

(a) FAR 42.1502 directs all Federal agencies to collect past performance information on contracts. The Department of the Interior (DOI) has implemented the Contractor Performance Assessment Reporting System (CPARS) to comply with this regulation. One or more past performance evaluations will be conducted in order to record your contract performance as required by FAR 42.15.

(b) The past performance evaluation process is a totally paperless process using CPARS. CPARS is a web-based system that allows for electronic processing of the performance evaluation report. Once the report is processed, it is available in the Past Performance Information Retrieval System (PPIRS) for Government use in evaluating past performance as part of a source selection action.

(c) We request that you furnish the Contracting Officer with the name, position title, phone number, and email address for each person designated to have access to your firm's past performance evaluation(s) for the contract no later than 30 days after award. Each person granted access will have the ability to provide comments in the Contractor portion of the report and state whether or not the Contractor agrees with the evaluation, before returning the report to the Assessing Official. The report information must be protected as source selection sensitive information not releasable to the public.

(d) When your Contractor Representative(s) (Past Performance Points of Contact) are registered in CPARS, they will receive an automatically-generated email with detailed login instructions. Further details, systems requirements, and training information for CPARS is available at http://www.cpars.gov. The CPARS User Manual, registration for On Line Training for Contractor Representatives, and a practice application may be found at this site.

(e) Within 60 days after the end of a performance period, the Contracting Officer will complete an interim or final past performance evaluation and the report will be accessible at http://www.cpars.gov. Contractor Representatives may then provide comments in response to the evaluation, or return the evaluation without comment. Comments are limited to the space provided in Block 22. Your comments should focus on objective facts in the Assessing Official's narrative and should provide your views on the causes and ramifications of the assessed performance. In addition to the ratings and supporting narratives, blocks 1 - 17 should be reviewed for accuracy, as these include key fields that will be used by the Government to identify your firm in future source selection actions. If you elect not to provide comments, please acknowledge receipt of the evaluation by indicating "No comment" in Block 22, and then signing and dating Block 23 of the form. Without a statement in Block 22, you will be unable to sign and submit the evaluation http://www.cpars.gov/ http://www.cpars.gov/ back to the Government. If you do not sign and submit the CPAR within 30 days, it will automatically be returned to the Government and will be annotated: "The report was delivered/received by the contractor on (date). The contractor neither signed nor offered comment in response to this assessment." Your response is due within 30 calendar days after receipt of the CPAR.

(f) The following guidelines apply concerning your use of the past performance evaluation:

(1) Protect the evaluation as "source selection information." After review, transmit the evaluation by completing and submitting the form through CPARS. If for some reason you are unable to view and/or submit the form through CPARS, contact the Contracting Officer for instructions.

(2) Strictly control access to the evaluation within your organization. Ensure the evaluation is never released to persons or entities outside of your control.

(3) Prohibit the use of or reference to evaluation data for advertising, promotional material, preaward surveys, responsibility determinations, production readiness reviews, or other similar purposes.

(g) If you wish to discuss a past performance evaluation, you should request a meeting in writing to the Contracting

Officer no later than seven days following your receipt of the evaluation. The meeting will be held in person or via telephone or other means during your 30-day review period.

(h) A copy of the completed past performance evaluation will be available in CPARS for your viewing and for

Government use supporting source selection actions after it has been finalized.

G.3 DIAPR 2011-04 ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS—INVOICE

PROCESSING PLATFORM (IPP) (APRIL 2013)

Payment requests must be submitted electronically through the U.S. Department of the Treasury's Invoice Processing Platform (IPP).

"Payment Request” means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Condition - Commercial Items including in commercial item contracts. The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

• Pay Estimate Form – (Sample Construction Fill-In Form Provided to Contractor at the Pre-Construction Meeting) – attachment and hard copy to the Contracting Officer and the Contracting Officer’s Representative

• Schedule of Values – attachment and hard copy to the Contracting Officer and the Contracting Officer’s Representative

• Construction Project Schedule -- submitted as a hard copy to Contracting Officer and Contracting Officer’s Representative under separate cover

• Certified Payroll Records -- submitted as a hard copy to Contracting Officer under separate cover

The Contractor must use the IPP website to register, access, and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) prior to the contract award date, but no more than 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

mailto:ippgroup@bos.frb.org

SECTION H – SPECIAL CONTRACT REQUIREMENTS

H.1 KEY PERSONNEL

(a) The Contractor shall assign to this contract the following key personnel:

Project Manager – Superintendent – Safety Manager – Quality Control Supervisor – Architect / Engineer Program Manager – Architect / Engineer Electrical Engineer – Landscape Architect – Civil Engineer –

(b) During the ninety (90) calendar days of performance, the Contractor shall make no substitutions of key personnel unless the substitution is necessitated by illness, death, or termination of employment. The Contractor shall notify the Contracting Officer within 15 calendar days after the occurrence of any of these events and provide the information required by paragraph (c) below. After the initial ninety (90) calendar day period, the Contractor shall submit the information required by paragraph (c) to the Contracting Officer as least 15 days prior to making any permanent substitutions.

(c) The Contractor shall provide a detailed explanation of the circumstances necessitating the proposed substitutions, complete resumes for the proposed substitutes, and any additional information requested by the Contracting Officer. Proposed substitutes should have comparable qualifications to those of the persons being replaced. The Contracting Officer will notify the Contractor within 15 calendar days after receipt of all required information of the decision on substitutions. This clause will be modified to reflect any approved changes of key personnel.

H.2 UNAUTHORIZED USE OF THE U.S. SECRET SERVICE NAME

In accordance with 18 U.S.C. 709, any contractor, except with the written permission of the Director of the U.S. Secret Service, through the Contracting Officer for the National Park Service, who knowingly uses the words “Secret Service”, “Secret Service Uniformed Division”, “U.S.S.S”, “U.D.”, or any colorable imitation of such words or initials, in connection with or as a part of any advertisement, circular, book, pamphlet or other publication, play, motion picture, broadcast, telecast, or production, product or item, in a manner reasonably calculated to convey the impression that such advertisement, circular, book, pamphlet or other publication, product, or item, is approved, endorsed, or authorized by or associated in any manner with, the U.S. Secret Service or the U.S. Secret Service Uniformed Division shall be punishable as follows: a corporation, partnership, business trust, association, or other business entity, by fine under this title; an officer or member thereof participating or knowingly acquiescing in such violation or any individual violating this section, by a fine under this title or imprisonment for not more than one year or both.

H.3 CONDUCT OF OPERATIONS

(a) At all times the Contractor shall conduct his organization in conformance with the rules and regulations promulgated by the Secretary of the Interior for the National Park Service, and with such appropriate regulations as the Superintendent may prescribe.

(b) Work on Saturdays, Sundays, Federal holidays or at night may be performed only with the prior consent of the Contracting Officer.

(c) No signs or advertisements (except those specified herein) shall be displayed on the construction site or within the park except with approval of the Contracting Officer.

H.4 WAGE RATES

This contract includes Heavy (Heavy and Sewer and Water Line) and Highway (DC150001 10/09/2015) Davis Bacon wage rate determinations.

General Decision Number: DC150001 10/09/2015 DC1

Superseded General Decision Number: DC20140001

State: District of Columbia

Construction Types: Heavy (Heavy and Sewer and Water Line) and Highway

County: District of Columbia Statewide.

HEAVY CONSTRUCTION PROJECTS (Including Sewer and Water Lines);

HIGHWAY CONSTRUCTION PROJECTS

Note: Executive Order (EO) 13658 establishes an hourly minimum wage of $10.10 for 2015 that applies to all contracts subject to the Davis-Bacon Act for which the solicitation is issued on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.10 (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract. The EO minimum wage rate will be adjusted annually. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/02/2015 1 01/09/2015 2 03/06/2015 3 05/01/2015 4 05/08/2015 5 06/05/2015 6 06/12/2015 7 06/26/2015 8 07/03/2015 9 07/17/2015 10 08/07/2015 11 08/14/2015 12 09/11/2015 13 09/18/2015 14 10/02/2015 15 10/09/2015

ASBE0024-001 10/01/2013

Rates Fringes

Asbestos Worker/Heat and Frost Insulator Includes the application of all insulating materials, protective coverings, coatings and finishes to all types of mechanical systems..........$ 33.13 13.76

ASBE0024-002 10/09/2013

Rates Fringes

HAZARDOUS MATERIAL HANDLER

Includes preparation, wetting, stripping, removal, scrapping, vacuuming, bagging and disposing of all insulation materials, whether they contain asbestos or not, from mechanical systems..........$ 20.86 5.46

ASBE0024-005 10/01/2013

Rates Fringes

Fire Stop Technician.............$ 26.06 5.90

Includes the application of materials or devices within or around penetrations and openings in all rated wall or floor assemblies, in order to prevent the pasage of fire, smoke of other gases.