Sol_P15PS00430.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

0040195404

NPS, MWR - MWRO MABO

601 Riverfront Drive

Omaha NE 68102

PMH

Nicholas Murray 402-661-1698

102/09/2015

P15PS00430

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

This is a Request for Proposal (RFP) for roof surface replacement at Fort Larned

National Historic Site, Fort Larned, KS in accordance with the scope of work provided dated 01-08-2015.

The work of this contract includes installing new roof and Bat exclusion material on

Shops Building HS 3 including but not limited to:

Removal and disposal of existing cedar shingles, ridge boards

Removal of Apron, Counter and Step flashing and vent stack flashing.

Temporary removal, salvage and reinstallation of existing lightening protection system.

Selective fascia and rake molding repairs.

Install new cedar ridge boards on ridges

Installation of new lead coated copper metal flashing

Installation of new fire retardant cedar shingle roofs

Selective masonry demolition

This requirement has been set-aside as for HUBZone Certified small business pursuant to The Historically Underutilized Business Zone (HUBZone) Act of 1997 (15 U.S.C. 631 note) created the HUBZone Program

Continued ...

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

10 90 calendar days and complete it within ________________ ________________ calendar days after receiving

03/09/2015

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

NPS, MWR - MWRO MABO

601 Riverfront Drive

Omaha NE 68102

PMH

DIANA VANDERZANDEN

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 48

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

P15PS00430

Type of Contract: Firm Fixed

CONTRACTING POC: Nicholas M Murray, (402)

661-1698 email: nicholas_m_murray@nps.gov

SITE VISIT: An organized site visit is tentatively scheduled for March 03, 2015, 10:00am for both parties

THIS IS NOT THE GOVERNMENT ESTIMATE. In

Accordance with FAR 36.204, the magnitude of this project is between $25,000 and $100,000.

NAICS: 238160 (Commercial and Institutional

Building Construction)

Construction Duration: Estimated at 90 days

REQUIRED BONDS: This project is subject to the

Davis-Bacon Act. Bonds will be required as follows: Bid Guarantee - 20% of the contract price. Payment and Performance bonds - (forms

SF25 and SF25a) 100% of the contract price.

Required Submission Documents:

1-Completed Line Item Schedule

2-Signed SF1442

3-Itemized breakdown for each Line item to include labor hours, material, overhead and profit.

ALL QUESTIONS WILL BE PRESENTED TO THE CONTRACT

SPECIALIST ON THIS PROJECT, NOT THE PARK. READ

ALL AREAS IN THE TABLE OF CONTENT

Suggested COR: WCHAPMAN

Delivery: 06/30/2015

Delivery Location Code: 0009060370

NPS, MWR, Fort Larned NHS

1767 KS Hwy. 156

Larned KS 67550-9321 US

FOB: Destination

Period of Performance: 04/01/2015 to 06/30/2015

00010 Replace wood shingle roof

Continued ...

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

4 48

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

P15PS00430

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

P15PS00430 Replace Shingle Roof-FOLS Page 5 of 48

A - Solicitation/Contract Form B - Supplies or Services/Prices C - Description/Specifications E - Inspection and Acceptance

52.246-12 Inspection of Construction. (APR 1996) 52.246-13 Inspection - Dismantling, Demolition, or Removal of Improvements. (AUG 1996)

F - Deliveries or Performance

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK APRIL 1984

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION - SEPTEMBER 2000

52.211-13 TIME EXTENSIONS SEPTEMBER 2000

52.242-14 SUSPENSION OF WORK APRIL 1984

G - Contract Administration Data

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

DOI TEXT MESSAGING Prohibition on Text Messaging and Using Electronic Equipment Supplied by the Government while Driving (October 2009) SUBPART 42.15 CONTRACTOR PERFORMANCE INFORMATION (DIAPR) 2010-14, Amendment

52.232-99, PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS

SUBCONTRACTORS

DOI Electronic Invoicing and Payment Requirements - Invoice Processing Platform (IPP) (September 2011)

H - Special Contract Requirements I - Contract Clauses

52.252-02 CLAUSES INCORPORATED BY REFERENCE FEBRUARY 1998

52.202-1 Definitions. (NOV 2013) 52.203-03 Gratuities April 1984 52.203-5 Covenant Against Contingent Fees. (MAY 2014) 52.203-7 Anti-Kickback Procedures. (MAY 2014) 52.203-10 Price or Fee Adjustment for Illegal or Improper Activity (January 1997) 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards February 2012 52.209-06 Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment December 2010 52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984) 52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984) - Alternate I (APR 1984) 52.222-01 Notice to the Government of Labor Disputes February 1997 52.222-03 Convict Labor June 2003 52.222-06 Davis-Bacon Act July 2005 52.222-07 Withholding of Funds February 1988 52.222-08 Payrolls and Basic Records June 2010 52.222-09 Apprentices and Trainees July 2005 52.222-10 Compliance with Copeland Act Requirements February 1988 52.222-11 Subcontracts (Labor Standards) July 2005 52.222-12 Contract Termination-Debarment February 1988 52.222-13 Compliance with Davis-Bacon and Related Act Regulations February 1988 52.222-14 Disputes Concerning Labor Standards February 1988 52.222-15 Certification of Eligibility February 1988 52.222-19 Child Labor- Cooperation with Authorities and Remedies March 2012 52.222-21 Prohibition of Segregated Facilities February 1999 52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction. (FEB 1999) 52.222-06 Davis-Bacon Act July 2005 52.222-07 Withholding of Funds February 1988 52.222-08 Payrolls and Basic Records June 2010 52.222-09 Apprentices and Trainees July 2005

P15PS00430 Replace Shingle Roof-FOLS Page 6 of 48

52.222-10 Compliance with Copeland Act Requirements February 1988 52.222-11 Subcontracts (Labor Standards) July 2005 52.222-12 Contract Termination-Debarment February 1988 52.222-13 Compliance with Davis-Bacon and Related Act Regulations February 1988 52.222-14 Disputes Concerning Labor Standards February 1988 52.222-15 Certification of Eligibility February 1988 52.222-16 Approval of Wage Rates 52.222-26 Equal Opportunity March 2007 52.222-27 Affirmative Action Compliance Requirements for Construction February 1999 52.222-30 – Construction Wage Rate Requirements—Price Adjustment (None or Separately Specified Method) 52.222-31 – Construction Wage Rate Requirements—Price Adjustment (Percentage Method) 52.222-32 -- Construction Wage Rate Requirements—Price Adjustment (Actual Method) 52.222-33 Notice of Requirement for Project Labor Agreement May 2010 52.222-34 Project Labor Agreement May 2010 52.222-36 Affirmative Action For Workers with Disabilities October 2010 52.222-50 Combating Trafficking in Persons. (FEB 2009) 52.223-05 Pollution Prevention and Right-to-Know Information May 2011 52.223-06 Drug-Free Workplace May 2001 52.223-15 Energy Efficiency in Energy-Consuming Products December 2007 52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. (AUG 2011) 52.225-13 Restrictions on Certain Foreign Purchases. (JUN 2008) 52.232-27 Prompt payment for construction contracts. (MAY 2014) 52.232-39 Unenforceability of Unauthorized Obligations. (JUN 2013) 52.233-3 Protest after Award. (AUG 1996) 52.233-4 Applicable Law for Breach of Contract Claim. (OCT 2004) 52.244-6 Subcontracts for Commercial Items. (OCT 2014) 52.225-13 Restrictions on Certain Foreign Purchases June 2008 52.226-01 Utilization of Indian Organizations and Indian-Owned Economic Enterprises June 2000 52.227-01 Authorization and Consent December 2007 52.227-02 Notice and Assistance Regarding Patent and Copy Infringement December 2007 52.227-04 Patent Indemnity-Construction Contracts December 2007 52.227-05 Waiver of Indemnity April 1984 52.228-01 Bid Guarantee September 1996 52.228-02 Additional Bond Security October 1997 52.228-05 Insurance - Work on a Government Installation January 1997 52.228-11 Pledges of Assets January 2012 52.228-14 Irrevocable Letter of Credit December 1999 52.229-3 Federal, State, and Local Taxes. (FEB 2013) 52.230-06 Administration of Cost Accounting Standards June 2010 52.232-5 Payments Under Fixed-Price Construction Contracts. (MAY 2014) 52.232-16 Progress Payments. (APR 2012) 52.232-05 Payments under Fixed-Price Construction Contracts September 2002 52.232-16 Progress Payments. (APR 2012) - Alternate I (MAR 2000) 52.232-23 Assignment of Claims January 1986 52.232-25 Prompt Payment October 2008 52.232-27 Prompt Payment for Construction Contracts October 2008 52.232-33 Payment by Electronic Funds Transfer-Central Contractor Registration October 2003 52.232-34 Payment by Electronic Funds Transfer--Other than Central Contractor Registration May 1999 52.232-35 Designation of Office for Government Receipt of Electronic Funds Transfer Information May 52.232-40 – Providing Accelerated Payments to Small Business Subcontractors. (Dec 2013) 52.233-04 Applicable Law for Breach of Contract Claim October 2004

52.233-03 PROTEST AFTER AWARD AUGUST 1996

P15PS00430 Replace Shingle Roof-FOLS Page 7 of 48

52.236-02 Differing Site Conditions April 1984 52.236-03 Site Investigation and Conditions Affecting the Work April 1984 52.236-5 Material and Workmanship. (APR 1984) 52.236-6 Superintendence by the Contractor. (APR 1984) 52.236-7 Permits and Responsibilities. (NOV 1991) 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements. (APR 1984) 52.236-11 Use and Possession Prior to Completion. (APR 1984) 52.236-12 Cleaning Up. (APR 1984) 52.236-13 Accident Prevention. (NOV 1991) 52.236-14 Availability and Use of Utility Services. (APR 1984) 52.236-17 Layout of Work April 1984 52.236-26 Preconstruction Conference February 1995 52.246-21 Warranty of Construction March 1994 52.249-02 Alt I Termination for Convenience of the Government (Fixed-Price) (May 2004) - Alternate I

1452.203- 70 RESTRICTIONS ON ENDORSEMENTS - DEPARTMENT OF INTERIOR

1452.204-70 RELEASE OF CLAIMS - DEPARTMENT OF INTERIOR JULY 1996

1452.225-70 USE OF FOREIGN CONSTRUCTION MATERIALS – DEPARTMENT OF THE

INTERIOR JULY 1996

1452.228-70 Liability Insurance (JUL 1996) 1452.236-70 Prohibition Against Use of Lead-based Paint (JUL 1996)

J - List of Documents, Exhibits and Other Attachments List of Documents, Exhibits, and Other Attachments

K - Representations, Certifications, and Other Statements of Bidders 52.223-4 Recovered Material Certification. (MAY 2008) 52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-Representation and Certifications. (DEC 2012) 52.236-28 Preparation of Proposals - Construction. (OCT 1997)

52.203-11 CERTIFICATION AND DISCLOSURE REGARDING PAYMENT TO INFLUENCE

CERTAIN FEDERAL TRANSACTIONS SEP 2007

52.204-8 Annual Representations and Certifications (Jan 2014)

52.209-05 CERTIFICATION REGARDING RESPONSIBILITY MATTERS - APRIL 2010

52.222-22 PREVIOUS CONTRACTS AND COMPLIANCE REPORTS - FEBRUARY 1999

L - Instructions,Conditions, and Notices to Bidders DS 52.204-06 DATA UNIVERSAL NUMBERING SYSTEM (DUNS) NUMBER – December 2012 .46 52.204-7 Central Contractor Registration. (DEC 2012)

52.216-01 TYPE OF CONTRACT APRIL 1984

52.222-05 DAVIS-BACON ACT-SECONDARY SITE OF THE WORK -JULY 2005

52.233-2 Service of Protest. (SEP 2006) 52.236-1 Performance of Work by the Contractor. (APR 1984)

52.236-27 SITE VISIT (CONSTRUCTION) - FEBRUARY 1995

M - Evaluation Factors for Award

P15PS00430 Replace Shingle Roof-FOLS Page 8 of 48

A - Solicitation/Contract Form

B - Supplies or Services/Prices

Replacement of Shingle Roof -FOLS

Estimated Item No Description Quantity Unit TOTAL 0001 DIV 1-Remove and replace 1 L.S. $______________________ defective board roof sheeting As per the specifications, wage rates, and any amendments

0002 DIV 2-Temporary removal 1 L.S. $______________________ and storage of lightening protection system As per the specifications, wage rates, and any amendments

0003 DIV 3-Remove and dispose of 1 L.S. $______________________ existing cedar shingles and replace with new 24-inch fire retardant cedar shingles.

As per the specifications, wage rates, and any amendments

0004 DIV 6-Install new roof vent system. 1 L.S. $______________________ Install additional eave sheeting and, ice roof dam barrier.

As per the specifications, wage rates, and any amendments

0005 DIV 7-Remove and replace 1 L.S. $______________________ defective fascia, flashing and install bat exclusion material As per the specifications, wage rates, and any amendments

00006 DIV 10 Specialties 1 L.S. $______________________ (i.e. Lightening protection, Asbestos, Bats and industrial hygiene) As per the specifications, wage rates, and any amendments

0007 Miscellaneous 1 L.S. $______________________ (i.e. Overhead, Profit, and Bonding) as per the specifications, wage rates, and any amendments

Grand Total: $________________________

Note:

(1) The government requires a breakdown of cost for each Line Item. A total price will be inserted on the

P15PS00430 Replace Shingle Roof-FOLS Page 9 of 48 line for each Line Item. Ina separate document the government requires you to breakout each Line Item total to show your Materials, Labor, Overhead, Profit cost, insurance; all in one document. Then submit it with your proposal.

(2) Prices must be entered for all items of the schedule. Additions will be subject to verification by the Government.

The Government may issue the Notice to Proceed (NTP) via e-mail or Facsimile (FAX) or by other

READ ALL AREAS IN THE TABLE OF CONTENT

Note: There is a possibility that this project could be delayed due to weather conditions during the winter season; PROPOSE AND PLAN APPROPRIATELY.

C - Description/Specifications

Project work consists of:

Installing new roof and Bat exclusion material on Shops Building HS 3 including but not limited to Removal and disposal of existing cedar shingles, ridge boards Removal of Apron, Counter and Step flashing and vent stack flashing.

Temporary removal, salvage and reinstallation of existing lightening protection system.

Selective fascia and rake molding repairs.

Install new cedar ridge boards on ridges Installation of new lead coated copper metal flashing Installation of new fire retardant cedar shingle roofs Selective masonry demolition

In accordance with the HARD COPY SPECIFICATIONS AND DRAWINGS provided to the contractor.

Note: Green Procurement

To the extent that the construction services provided by the Contractor require provision of any of these types of products, the Contractor is expected to provide the green type of product unless that type of product is not available competitively within a reasonable time, at a reasonable price, is not life cycle cost efficient in the case of energy consuming products, or does not meet reasonable performance standards.

The clauses at FAR 52.223-2, Affirmative Procurement of Biobased Products under Service and Construction Contracts, 52.223-15, Energy Efficiency in Energy Consuming Products, and 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts, require the use of products that have biobased content, are energy efficient, or have recycled content.

P15PS00430 Replace Shingle Roof-FOLS Page 10 of 48

E - Inspection and Acceptance

52.246-12 Inspection of Construction. (APR 1996)

52.246-13 Inspection - Dismantling, Demolition, or Removal of Improvements. (AUG 1996)

F - Deliveries or Performance

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK APRIL 1984

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 90 days. The time stated for completion shall include final cleanup of the premises.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION - SEPTEMBER 2000

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $222.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.211-13 TIME EXTENSIONS SEPTEMBER 2000

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

(End of clause)

52.242-14 SUSPENSION OF WORK APRIL 1984

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting

P15PS00430 Replace Shingle Roof-FOLS Page 11 of 48

Officer's failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

G - Contract Administration Data

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

Authorities and Delegations (SEP 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum.

The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph

(d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

P15PS00430 Replace Shingle Roof-FOLS Page 12 of 48

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

(End of clause)

DOI TEXT MESSAGING Prohibition on Text Messaging and Using Electronic Equipment Supplied by the Government while Driving (October 2009)

Prohibition on Text Messaging and Using Electronic Equipment Supplied by the Government while Driving (October 2009)

Executive Order 13513 , Federal Leadership On Reducing Text Messaging While Driving , was signed by President Barack Obama on October 1, 2009 (Ref: http://edocket.access.gpo.gov/2009/pdf/E9-24203.pdf).

This Executive Order introduces a Federal Government-wide prohibition on the use of text messaging while driving on official business or while using Government-supplied equipment. Additional guidance enforcing the ban will be issued at a later date. In the meantime, please adopt and enforce policies that immediately bans text messaging while driving company-owned or rented vehicles, government owned or leased vehicles, or while driving privately owned vehicles while on official government business or when performing any work for or on behalf of the government.

(End of Clause)

SUBPART 42.15 CONTRACTOR PERFORMANCE INFORMATION (DIAPR) 2010-14,

Amendment 1

CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM (JULY 2010)

(a) FAR 42.1502 directs all Federal agencies to collect past performance information on contracts. The Department of the Interior (DOI) has implemented the Contractor Performance Assessment Reporting System (CPARS) to comply with this regulation. One or more past performance evaluations will be conducted in order to record your contract performance as required by FAR 42.15.

(b) The past performance evaluation process is a totally paperless process using CPARS. CPARS is a web-based system that allows for electronic processing of the performance evaluation report. Once the report is processed, it is available in the Past Performance Information Retrieval System (PPIRS) for Government use in evaluating past performance as part of a source selection action.

(c) We request that you furnish the Contracting Officer with the name, position title, phone number, and email address for each person designated to have access to your firm's past performance evaluation(s) for the contract no later than 30 days after award. Each person granted access will have the ability to provide comments in the Contractor portion of the report and state whether or not the Contractor agrees with the evaluation, before returning the report to the Assessing Official. The report information must be protected as source selection sensitive information not releasable to the public.

(d) When your Contractor Representative(s) (Past Performance Points of Contact) are registered in CPARS, they will receive an automatically-generated email with detailed login instructions. Further details, systems requirements, and training information for CPARS is available at http://www.cpars.csd.disa.mil/. The CPARS User Manual, registration for On Line Training for Contractor Representatives, and a practice application may be found at this site.

P15PS00430 Replace Shingle Roof-FOLS Page 13 of 48

(e) Within 60 days after the end of a performance period, the Contracting Officer will complete an interim or final past performance evaluation, and the report will be accessible at http://www.cpars.csd.disa.mil/.

Contractor Representatives may then provide comments in response to the evaluation, or return the evaluation without comment. Comments are limited to the space provided in Block 22. Your comments should focus on objective facts in the Assessing Official's narrative and should provide your views on the causes and ramifications of the assessed performance. In addition to the ratings and supporting narratives, blocks 1 - 17 should be reviewed for accuracy, as these include key fields that will be used by the Government to identify your firm in future source selection actions. If you elect not to provide comments, please acknowledge receipt of the evaluation by indicating "No comment" in Block 22, and then signing and dating Block 23 of the form. Without a statement in Block 22, you will be unable to sign and submit the evaluation back to the Government. If you do not sign and submit the CPAR within 30 days, it will automatically be returned to the Government and will be annotated: "The report was delivered/received by the contractor on (date). The contractor neither signed nor offered comment in response to this assessment." Your response is due within 30 calendar days after receipt of the CPAR.

(f) The following guidelines apply concerning your use of the past performance evaluation:

(1) Protect the evaluation as "source selection information." After review, transmit the evaluation by completing and submitting the form through CPARS. If for some reason you are unable to view and/or submit the form through CPARS, contact the Contracting Officer for instructions.

(2) Strictly control access to the evaluation within your organization. Ensure the evaluation is never released to persons or entities outside of your control.

(3) Prohibit the use of or reference to evaluation data for advertising, promotional material, preaward surveys, responsibility determinations, production readiness reviews, or other similar purposes.

(g) If you wish to discuss a past performance evaluation, you should request a meeting in writing to the Contracting Officer no later than seven days following your receipt of the evaluation. The meeting will be held in person or via telephone or other means during your 30-day review period.

(h) A copy of the completed past performance evaluation will be available in CPARS for your viewing and for Government use supporting source selection actions after it has been finalized.

(End of notice)

52.232-99, PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS

SUBCONTRACTORS

This clause implements the temporary policy provided by OMB Policy Memorandum M-12-16, Providing Prompt Payment to Small Business Subcontractors, dated July 11, 2012.

Upon receipt of accelerated payments from the Government, the contractor is required to make accelerated payments to small business subcontractors to the maximum extent practicable after receipt of a proper invoice and all proper documentation from the small business subcontractor.

Include the substance of this clause, including this paragraph (b), in all subcontracts with small business concerns.

The acceleration of payments under this clause does not provide any new rights under the Prompt Payment Act.

(End of Clause)

P15PS00430 Replace Shingle Roof-FOLS Page 14 of 48

DOI Electronic Invoicing and Payment Requirements - Invoice Processing Platform (IPP) (September 2011)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor.

To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice: ATTACHED INVOICE REQUIERED

The Contractor must use the IPP website to register, access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in CCR) will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Template)

CONTRACT MANAGEMENT

(a). Contracting Officer responsible for this contract:

Diana Vanderzanden National Park Service 601 Riverfront Drive Omaha, NE 68102 Telephone Number: 402-661-1660 Email: Diana_Vanderzanden@nps.gov

Contracting Officer responsible for this contract:

Nicholas M Murray National Park Service 601 Riverfront Drive Omaha, NE 68102 Telephone Number: 402-661-1660 Email: Nicholas_M_Murray@nps.gov

P15PS00430 Replace Shingle Roof-FOLS Page 15 of 48

(b) The Contracting Officer (CO) is the only person authorized to approve changes or modify any of the requirements under this contract and notwithstanding any provisions contained elsewhere in this contract, the said authority remains solely with the CO. In the event the contractor effects any such change at the direction of any person other than the CO, the change will be considered made without authority and no adjustment will be made in the contract price to cover increase in costs incurred as a result thereof.

(c) Contractual problems, of any nature, which might occur during the life of the contract, must be handled in conformance with very specific public laws and regulations (e.g., Federal Acquisition Regulation), and must be referred to the CO for resolution. Only the CO is authorized to formally resolve such problems. Therefore, the contractor is hereby directed to bring all such contractual problems to the immediate attention of the CO.

(d) Any request for contract changes/modifications shall be submitted to the CO.

(e) The contractor and the Government may agree to perform a no-cost field change. Field changes are made when the change appears to be mutually beneficial to all parties and would not require changing the negotiated line items. An example of a field change is: rerouting planned location of a sidewalk to avoid a tree (when quantities are not changed). All field changes must be approved by the CO prior to execution.

(f) All correspondence concerning this contract, such as requests for information, explanation of terms, and contract interpretation, shall be submitted to the CO.

Key Personnel:

(a) The Contractor shall assign to this contract the following key personnel:

Site Superintendent/Project Manager

(b) During the first 15 days of performance, the Contractor shall make no substitutions of key personnel unless the substitution is necessitated by illness, death, or termination of employment.

The Contractor shall notify the Contracting Officer within 15 calendar days after the occurrence of any of these events and provide the information required by paragraph (c) below. After the initial 15-day period, the Contractor shall submit the information required by paragraph (c) to the Contracting Officer as least 15 days prior to making any permanent substitutions.

(c) The Contractor shall provide a detailed explanation of the circumstances necessitating the proposed substitutions, complete resumes for the proposed substitutes, and any additional information requested by the Contracting Officer. Proposed substitutes should have comparable qualifications to those of the persons being replaced. The Contracting Officer will notify the Contractor within 15 calendar days after receipt of all required information of the decision on substitutions.

P15PS00430 Replace Shingle Roof-FOLS Page 16 of 48

FINAL PAYMENT

Final payment will be made only after receipt of all payrolls to include subcontractors, SF 1413 Statement of Acknowledgement for each subcontractor, project schedule, updated progress reports, material submittals, test reports, as-built drawings, and release of claims. Contractor must provide a signed copy of the 'Release of Claims' to the Contract Administrator upon submittal of final invoice.

REMITTANCE ADDRESS

If the remittance address is different from the mailing address, enter the remittance address below. Failure to provide this information may impact payment.

AVAILABILITY OF UTILITIES SERVICES

Notwithstanding the provisions of contract clause FAR 52.236-14, Availability and Use of Utility Services, all reasonable required amounts of water, gas, electricity, etc., essential to contract performance shall be made available, at no cost to the contractor, from existing systems, outlets, and supplies. All temporary connections, outlets, and distribution lines as may be required will be installed by the contractor at the contractor's own expense.

UTILITIES CONSERVATION

The contractor will be required to participate in government energy conservation programs. For the purpose of this contract, utilities such as water, electricity, etc., will be furnished by the government at no cost to the contractor. Long distance and Defense Switched Network (DSN) telephone services will not be provided.

OCCUPATIONAL SAFETY AND HEALTH ACT (OSHA) INSPECTIONS

The contractor shall be subject to no notice inspections under OCCUPATIONAL SAFETY AND HEALTH ACT (OSHA) program by inspectors of the Department of Labor.

FEDERAL RECOGNIZED LEGAL HOLIDAYS

The following legal holidays are observed by the National Park Service:

New Year Day 1 January Martin Luther King Birthday 3rd Monday in January Presidents Day 3rd Monday in February Memorial Day Last Monday in May Independence Day 4 July

P15PS00430 Replace Shingle Roof-FOLS Page 17 of 48

Labor Day 1st Monday in September Columbus Day 2nd Monday in October Veterans Day 11 November Thanksgiving Day 4th Thursday in November Christmas 25 December

Note: Any of the above holidays falling on a Saturday will be observed on the preceding Friday;

holiday falling on Sunday will be observed on the following Monday.

H - Special Contract Requirements

I - Contract Clauses

52.252-02 CLAUSES INCORPORATED BY REFERENCE FEBRUARY 1998

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://www.acquisition.gov/far/

OR

http://farsite.hill.af.mil

52.202-1 Definitions. (NOV 2013)

When a solicitation provision or contract clause uses a word or term that is defined in the Federal Acquisition Regulation (FAR), the word or term has the same meaning as the definition in FAR

2.101 in effect at the time the solicitation was issued, unless-

(a) The solicitation, or amended solicitation, provides a different definition;

(b) The contracting parties agree to a different definition;

(c) The part, subpart, or section of the FAR where the provision or clause is prescribed provides a different meaning; or

(d) The word or term is defined in FAR Part 31, for use in the cost principles and procedures.

(End of clause)

52.203-03 Gratuities April 1984

52.203-5 Covenant Against Contingent Fees. (MAY 2014)

52.203-7 Anti-Kickback Procedures. (MAY 2014)

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity (January 1997)

P15PS00430 Replace Shingle Roof-FOLS Page 18 of 48

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards February 2012

52.209-06 Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment December 2010

52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984)

52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984) - Alternate I (APR 1984)

52.222-01 Notice to the Government of Labor Disputes February 1997

52.222-03 Convict Labor June 2003

52.222-06 Davis-Bacon Act July 2005

52.222-07 Withholding of Funds February 1988

52.222-08 Payrolls and Basic Records June 2010

52.222-09 Apprentices and Trainees July 2005

52.222-10 Compliance with Copeland Act Requirements February 1988

52.222-11 Subcontracts (Labor Standards) July 2005

52.222-12 Contract Termination-Debarment February 1988

52.222-13 Compliance with Davis-Bacon and Related Act Regulations February 1988

52.222-14 Disputes Concerning Labor Standards February 1988

52.222-15 Certification of Eligibility February 1988

52.222-19 Child Labor- Cooperation with Authorities and Remedies March 2012

52.222-21 Prohibition of Segregated Facilities February 1999

52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction. (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for Minority Participation for Each Trade

5.7

Goals for Female Participation for Each Trade

P15PS00430 Replace Shingle Roof-FOLS Page 19 of 48

6.9

These goals are applicable to all the Contractor's construction work performed in the covered area.

If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction," and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the-

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is [Contracting Officer shall insert description of the geographical areas where the contract is to be performed, giving the state, county, and city].

(End of provision)

P15PS00430 Replace Shingle Roof-FOLS Page 20 of 48

52.222-06 Davis-Bacon Act July 2005

52.222-07 Withholding of Funds February 1988

52.222-08 Payrolls and Basic Records June 2010

52.222-09 Apprentices and Trainees July 2005

52.222-10 Compliance with Copeland Act Requirements February 1988

52.222-11 Subcontracts (Labor Standards) July 2005

52.222-12 Contract Termination-Debarment February 1988

52.222-13 Compliance with Davis-Bacon and Related Act Regulations February 1988

52.222-14 Disputes Concerning Labor Standards February 1988

52.222-15 Certification of Eligibility February 1988

52.222-16 Approval of Wage Rates.

52.222-26 Equal Opportunity March 2007

52.222-27 Affirmative Action Compliance Requirements for Construction February 1999

52.222-30 – Construction Wage Rate Requirements—Price Adjustment (None or Separately Specified Method)

52.222-31 – Construction Wage Rate Requirements—Price Adjustment (Percentage Method)

52.222-32 -- Construction Wage Rate Requirements—Price Adjustment (Actual Method)

52.222-33 Notice of Requirement for Project Labor Agreement May 2010

52.222-34 Project Labor Agreement May 2010

52.222-36 Affirmative Action For Workers with Disabilities October 2010

52.222-50 Combating Trafficking in Persons. (FEB 2009)

52.223-05 Pollution Prevention and Right-to-Know Information May 2011

52.223-06 Drug-Free Workplace May 2001

52.223-15 Energy Efficiency in Energy-Consuming Products December 2007

52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. (AUG 2011)

52.225-13 Restrictions on Certain Foreign Purchases. (JUN 2008)

52.232-27 Prompt payment for construction contracts. (MAY 2014)

52.232-39 Unenforceability of Unauthorized Obligations. (JUN 2013)

P15PS00430 Replace Shingle Roof-FOLS Page 21 of 48

52.233-3 Protest after Award. (AUG 1996)

52.233-4 Applicable Law for Breach of Contract Claim. (OCT 2004)

52.244-6 Subcontracts for Commercial Items. (OCT 2014)

52.225-13 Restrictions on Certain Foreign Purchases June 2008

52.226-01 Utilization of Indian Organizations and Indian-Owned Economic Enterprises June 2000

52.227-01 Authorization and Consent December 2007

52.227-02 Notice and Assistance Regarding Patent and Copy Infringement December 2007

52.227-04 Patent Indemnity-Construction Contracts December 2007

52.227-05 Waiver of Indemnity April 1984

52.228-01 Bid Guarantee September 1996

52.228-02 Additional Bond Security October 1997

52.228-05 Insurance - Work on a Government Installation January 1997

52.228-11 Pledges of Assets January 2012

52.228-14 Irrevocable Letter of Credit December 1999

52.229-3 Federal, State, and Local Taxes. (FEB 2013)

52.230-06 Administration of Cost Accounting Standards June 2010

52.232-5 Payments Under Fixed-Price Construction Contracts. (MAY 2014)

52.232-16 Progress Payments. (APR 2012)

The Government will make progress payments to the Contractor when requested as work progresses, but not more frequently than monthly, in amounts of $2,500 or more approved by the Contracting Officer, under the following conditions:

(a) Computation of amounts. (1) Unless the Contractor requests a smaller amount, the Government will compute each progress payment as 80 percent of the Contractor's total costs incurred under this contract whether or not actually paid, plus financing payments to subcontractors (see paragraph (j) of this clause), less the sum of all previous progress payments made by the Government under this contract. The Contracting Officer will consider cost of money that would be allowable under FAR 31.205-10 as an incurred cost for progress payment purposes.

(2) The amount of financing and other payments for supplies and services purchased directly for the contract are limited to the amounts that have been paid by cash, check, or other forms of payment, or that are determined due and will be paid to subcontractors-

(i) In accordance with the terms and conditions of a subcontract or invoice; and

(ii) Ordinarily within 30 days of the submission of the Contractor's payment

P15PS00430 Replace Shingle Roof-FOLS Page 22 of 48 request to the Government.

(3) The Government will exclude accrued costs of Contractor contributions under employee pension plans until actually paid unless-

(i) The Contractor's practice is to make contributions to the retirement fund quarterly or more frequently; and

(ii) The contribution does not remain unpaid 30 days after the end of the applicable quarter or shorter payment period (any contribution remaining unpaid shall be excluded from the Contractor's total costs for progress payments until paid).

(4) The Contractor shall not include the following in total costs for progress payment purposes in paragraph (a)(1) of this…