N6660422Q0251.pdf

1300986195

PROJECT TITLE AND DESCRIPTION: Building 679 and 1320 Handicapped Door Operators

PROPOSAL DUE: 14 April 2022, 2:00 PM EST; E-mail to: Michael.N.Ouellette.civ@us.navy.mil and michael.h.broomfield.civ@us.navy.mil;

Note: This RFQ w ill be posted for few er than 30 days in accordance w ith FAR 5.203.

MAGNITUDE OF PROJECT PER FAR 36.204: Betw een $25,000 and $100,000.

METHOD OF PAYMENT: Government Purchase Card. Include any applicable surcharge fees in your quote.

THIS IS A 100% SMALL BUSINESS SET ASIDE;NAICS 238290 - Other Building Equipment Contractors; Size Standard $16,500,000.00.

IMPORTANT: PLEASE NOTE THAT TECHNICAL INFORMATION IS REQUIRED WITH SUBMISSION OF OFFER. PLEASE SEE SECTIONS L AND M.

Offerors shall complete and submit Attachment 3 FAR Provision 52.204-24 w ith proposals.

MICHAEL N OUELLETTE (401)-832-5568

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

01-Apr-2022

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

X

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________120 calendar days after receiving aw ard, notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________14 Apr 2022 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

NAVAL UNDERSEA WARFARE CENTER

MICHAEL NORMAN OUELLETTE , CODE 0221

CONTRACTS DEPARTMENT

1176 HOWELL STREET, BLDG. 1258

NEWPORT RI 02841-1708

N66604

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: 401-832-5568 TEL: FAX:

N6660422Q0251 55

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job B679 B1320 Handicapped Door Operators

FFP

B679 B1320 Handicapped Door Operatorsin accordance with the attached Specification and Drawings.

FOB: Destination

PURCHASE REQUEST NUMBER: 1300986195

PSC CD: Z1AZ

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0002 1 Job Submittals

FFP

Submittals in support of CLIN 0001. NOT SEPARATLEY PRICED.

FOB: Destination

PSC CD: Z1AZ

NET AMT

Section C - Descriptions and Specifications

CLAUSES INCORPORATED BY FULL TEXT

C-223-W002 ON-SITE SAFETY REQUIREMENTS (NAVSEA) (OCT 2018)

(a) The contractor shall ensure that each contractor employee reads any necessary safety documents within 30 days of commencing performance at any Government facility. Required safety documents can be obtained from the respective safety office. Contractors shall notify the Safety office points of contact below to report completion of the required training via email. The email shall include the contractor employee’s name, work site, and contract number.

(b) It is expected that contractor employees will have received training from their employer on hazards associated with the areas in which they will be working and know what to do in order to protect themselves. Contractors are required to adhere to the requirements of 29 CFR 1910, 29 CFR 1926 and applicable state and local requirements while in Government spaces. The contractor shall ensure that all on-site contractor work at the Government facility is in accordance with any local safety instructions as provided via the COR. The contractor shall report all work-related injuries/illnesses that occurred while working at the Government site to the COR.

(c) Contractors whose employees perform work within Government spaces in excess of 1000 hours per calendar quarter during a calendar year shall submit the data elements on OSHA Form 300A, Summary of Work Related Injuries and Illnesses, for those employees to the safety office, via the COR by 15 January for the previous calendar year, even if no work related injuries or illnesses occurred. If a contractor’s injury/illness rates are above the Bureau of Labor Statistics industry standards, a safety assessment may be performed by the Safety Office to determine if any administrative or engineering controls can be utilized to prevent further injuries/illnesses, or if any additional Personal Protective Equipment or training will be required.

(d) Any contractor employee exhibiting unsafe behavior may be removed from the Government site. Such removal shall not relieve the contractor from meeting its contractual obligations and shall not be considered an excusable delay as defined in FAR 52.249-14.

(e) The Safety Office points of contacts are as follows:

TO BE PROVIDED AT AWARD

(End of text)

C-228-H002 MINIMUM INSURANCE REQUIREMENTS (NAVSEA) (JAN 2019)

(a) In accordance with the clause(s) of this contract entitled "Insurance--Work On a Government Installation" (FAR 52.228-5) and “Liability and Insurance” (DFARS 252.217-7012), as applicable, the Contractor shall procure and maintain insurance, of at least the kinds and minimum amounts set forth below:

(i) Workers' compensation and employer’s liability coverage shall be at least $100,000, except as provided in FAR 28.307-2(a), if applicable

(ii) Bodily injury liability insurance coverage shall be written on the comprehensive form of policy of at least $500,000 per occurrence.

(iii) Automobile liability policies covering automobiles operated in the United States shall provide coverage of at least $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage. The amount of liability coverage on other policies shall be commensurate with any legal requirements of the locality and sufficient to meet normal and customary claims.

(b) To be approved by the Contracting Officer, insurance certificates must include the following cancellation policy statement: Prior to cancellation or material change in coverage, the contractor shall give 30 days written notice to the Contracting Officer.

(c) Physical work cannot begin until the insurance certificate has been approved by the Contracting Officer. Failure to provide an acceptable insurance certificate will not remove the contractor’s responsibility to meet the delivery requirements outlined in Section F and FAR 52.211-11, Liquidated Damages – Supplies, Services, or Research and Development, if applicable.

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

(a) Definition. "Work" includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not--

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer's written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may (1) by contract or otherwise, replace or correct the work and charge the cost to the Contractor or (2) terminate for default the Contractor's right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government's rights under any warranty or guarantee.

(End of clause)

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 POP 22-APR-2022 TO

30-SEP-2022

N/A N/A

FOB: Destination

0002 N/A N/A N/A N/A

CLAUSES INCORPORATED BY REFERENCE

52.247-34 F.O.B. Destination NOV 1991

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 120 days after award. The time stated for completion shall include final cleanup of the premises.

Section G - Contract Administration Data

G-232-H002 PAYMENT INSTRUCTIONS AND CONTRACT TYPE SUMMARY FOR PAYMENT

OFFICE (NAVSEA) (JUN 2018)

(a) The following table of payment office allocation methods applies to the extent indicated.

For Government Use Only

Contract/Order Payment Clause

Type of Payment Request

Su pp ly

Se rv ic e

C on st ru ct io n

Payment Office Allocation Method

52.212-4 (Alt I), Contract Terms and Conditions— Commercial Items 52.216-7, Allowable Cost and Payment 52.232-7, Payments under Time-and-Materials and Labor-Hour Contracts

Cost Voucher X X N/A Line item specific proration. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated in the same proportion as the amount of funding currently unliquidated for each ACRN on the deliverable line or deliverable subline item for which payment is requested.

52.232-1, Payments Navy Shipbuilding Invoice (Fixed Price)

X N/A N/A Line Item specific by fiscal year. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated using the oldest funds. In the event of a deliverable line or deliverable subline item with two ACRNs with the same fiscal year, those amounts will be prorated to the available unliquidated funds for that year.

52.232-1, Payments;

52.232-2, Payments under Fixed-Price Research and Development Contracts;

52.232-3, Payments under Personal Services Contracts;

52.232-4, Payments under Transportation Contracts and Transportation-Related Services Contracts; and 52.232-6, Payments under Communication Service Contracts with Common Carriers

Invoice X X N/A Line Item Specific proration. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated in the same proportion as the amount of funding currently unliquidated for each ACRN on the deliverable line or deliverable subline item for which payment is requested.

Contract/Order Payment Clause

Type of Payment Request

Su pp ly

Se rv ic e

C on st ru ct io n

Payment Office Allocation Method

52.232-5, Payments Under Fixed-Price Construction Contracts

Construction Payment Invoice

N/A N/A X Line Item specific by fiscal year. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated using the oldest funds. In the event of a deliverable line or deliverable subline item with two ACRNs with the same fiscal year, those amounts will be prorated to the available unliquidated funds for that year.

52.232-16, Progress Payments

Progress Payment*

X X N/A Contract-wide proration. Funds shall be allocated in the same proportion as the amount of funding currently unliquidated for each ACRN. Progress Payments are considered contract level financing, and the “contract price” shall reflect the fixed price portion of the contract per FAR 32.501-3.

52.232-29, Terms for Financing of Purchases of Commercial Items;

52.232-30, Installment Payments for Commercial Items

Commercial Item Financing*

X X N/A Specified in approved payment. The contracting officer shall specify the amount to be paid and the account(s) to be charged for each payment approval in accordance with FAR 32.207(b)(2) and 32.1007(b)(2).

52.232-32, Performance- Based Payments

Performance- Based Payments*

X X N/A Specified in approved payment. The contracting officer shall specify the amount to be paid and the account(s) to be charged for each payment approval in accordance with FAR 32.207(b)(2) and 32.1007(b)(2).

252.232-7002, Progress Payments for Foreign Military Sales Acquisitions

Progress Payment*

X X N/A Allocate costs among line items and countries in a manner acceptable to the Administrative Contracting Officer.

*Liquidation of Financing Payments. Liquidation will be applied by the payment office against those ACRNs which are identified by the payment instructions for the delivery payment and in keeping with the liquidation provision of the applicable contract financing clause (i.e., progress payment, performance-based payment, or commercial item financing).

(b) This procurement contains the following contract type(s):

Item Type*

0001 FFP

0002 NSP

*FFP – Firm Fixed Price NSP – Not Separately Priced

G-232-H004 GOVERNMENT PURCHASE CARD METHOD OF PAY (NAVSEA) (OCT 2018)

(a) Payment will be made via the Government Purchase Card once evidence of material receipt or service completion and an invoice are received. At the time of shipment, or completion of services, but no later than two business days after shipment, contact the individual identified below to obtain the account number to be charged. The Government Purchase Card must not be charged without first obtaining final authorization from the appropriate Government Purchase Cardholder.

(b) To facilitate delivery, clearly mark all boxes, cartons, containers and packing slips with the order number referenced on the order. Include an itemized and serialized invoice. (NOTE: these numbers can be found on the face of the order or contract.)

(c) To expedite payment, please do not include your invoice with your shipment. Please mail invoice separately to the address below. Any invoice is required for payment to be authorized using the Government Purchase Card. Current DoD and Local policy does not allow the use of third party card processing companies such as Pay Pal, PayPro, etc.

(d) Mail invoices and bankcard authorizations to:

TO BE COMPLETED AT TIME OF AWARD

G-242-H001 GOVERNMENT CONTRACT ADMINISTRATION POINTS-OF-CONTACT AND

RESPONSIBILITIES (NAVSEA) (OCT 2018)

(a) The Government reserves the right to administratively substitute any of the points of contact listed below at any time.

(b) The contracting officer is the only person authorized to change this contract or orders issued thereunder. The Contractor shall not comply with any order, direction or request of Government personnel

- that would constitute a change - unless it is issued in writing and signed by the Contracting Officer or is pursuant to specific authority otherwise included as part of this contract. If, in the opinion of the contractor, an effort outside the existing scope of this contract is requested, the contractor shall promptly comply with the Notification of Changes clause of this contract.

(c) The points of contact are as follows:

(i) The Procuring Contracting Officer (PCO) is:

Name: Michael Broomfield Address: NUWC Division Newport; Newport, RI 02841 Phone: (401)832-8469 E-mail: michael.h.broomfield.civ@us.navy.mil

(ii) The Contract Specialist is:

Name: Michael Ouellette Address: NUWC Division Newport; Newport, RI 02841 Phone: (401)832-5568 E-mail: michael.n.ouellette.civ@us.navy.mil

(iii) The Administrative Contracting Officer (ACO) is: N/A

(d) The Contracting Officer’s Representative (COR) is the contracting officer’s appointed representative for technical matters. The COR is not a contracting officer and does not have the authority to direct the accomplishment of effort which is beyond the scope of the contract or to otherwise change any contract requirements. An informational copy of the COR appointment letter, which provides a delineation of COR authority and responsibilities, will be provided upon award of this contract.

The Contracting Officer’s Representative (COR) is: N/A

(e) The Alternate Contracting Officer’s Representative (ACOR) is responsible for COR responsibilities and functions in the event that the COR is unavailable due to leave, illness, or other official business. The ACOR is appointed by the contracting officer; a copy of the ACOR appointment will be provided upon award of this contract.

The Alternate Contracting Officer’s Representative (ACOR) is: N/A

(f) The Technical Point of Contact (TPOC) is the contracting officer’s representative for technical matters when a COR is not appointed. The TPOC is responsible for technical issues of contract administration, such as providing all items of Government Furnished Information (GFI), Government Furnished Material (GFM) and Government Furnished Equipment (GFE) if specified in the contract as well as the inspection and acceptance of all contract deliverables.

The Technical Point of Contact (TPOC) is: TO BE COMPLETED AT TIME OF AWARD Name: [ * ] Address: [ *Street ] [ *City, State, Zip ] Phone: (Area Code) xxx- [xxxx]; FAX: (Area Code) xxx- [xxxx] E-mail: [ * ]

(g) The Alternate Technical Point of Contact (ATPOC) is responsible for TPOC responsibilities and functions in the event that the TPOC is unavailable due to leave, illness, or other official business.

The Alternate Technical Point of Contact (ATPOC) is: TO BE COMPLETED AT TIME OF AWARD

Address:

[ *City, State, Zip ]

(h) The Competition Advocate will review complaints from the contractors and ensure that all contractors are afforded a fair opportunity to be considered, consistent with the procedures in the contract.

The NUWCDIVNPT Competition Advocate is:

Name: Stephen Lamb Address: NUWC Division Newport; Newport, RI 02841 E-mail: stephen.a.lamb1@navy.mil

(i) The Authorized Ordering Person(s) for Per-Call Maintenance is responsible for issuing and maintaining records for any per-call orders for remedial maintenance placed under this contract. No per-call order shall be placed outside the scope of this contract and the cumulative total of all orders shall not be in excess of any not-to-exceed amount specified in the contract. Per-call orders shall not, in any way, modify any terms and conditions of the contract.

(j) The Authorized Ordering Person(s) for Per-Call Maintenance is: See (c)(i)

(k) The Contractor's point of contact for performance under this contract is: CONTRACTOR TO COMPLETE WITH

PROPOSAL

Title: [ * ] Address:

[ *Street ] [ *City, State, Zip ]

[ * ] To be completed at contract award

252.204-7006 BILLING INSTRUCTIONS (OCT 2005)

When submitting a request for payment, the Contractor shall--

(a) Identify the contract line item(s) on the payment request that reasonably reflect contract work performance; and

(b) Separately identify a payment amount for each contract line item included in the payment request.

Section H - Special Contract Requirements

PERFORMANCE ON GOVERNMENT SITE

CONTRACTOR REQUIREMENTS FOR PERFORMANCE ON A GOVERNMENT SITE (APR 2018)

(a) Control of Contractor Personnel

The contractor shall comply with the requirements of NUWCDIVNPTINST 5500.4C regarding performance at Government facilities. All persons engaged in work while on Government property shall be subject to search of their persons and vehicles at any time by the Government, and shall report any known or suspected security violations to the Security Department of the contracting activity. Assignment, transfer, and reassignment of contractor personnel shall be at the discretion of the contractor. However, the contractor shall remove from contract performance any person who endangers life, property, or national security through improper conduct.

Such removal shall not relieve the contractor from meeting its contractual obligations and shall not be considered an excusable delay as defined in FAR 52.249-14.

(b) Contract Personnel Administration

The contractor is responsible for managing its employees and guarding against any actions that are of the nature of personal services or give the perception that personal services are being provided. If the contractor feels that any actions constitute, or are perceived to constitute personal services, it is the contractor's responsibility to notify the PCO immediately in accordance with the clause FAR 52.243-7. When on-site in Government office spaces, laboratories, test facilities, or ship assets, Contractor employees shall be clearly identified as a Contractor (e.g.

utilizing Common Access Cards (CACs) and sign identifications in office spaces). In addition, Contractor employees shall identify themselves as Contractor personnel when answering telephones and sending emails.

Contractor personnel cannot lead/manage/supervise Government personnel. Contractor program /project managers/Senior Technical Representative (STR) shall be clearly identified and known as such by Government employees. As circumstances permit, periodic meetings shall be conducted between the COR and the Contractor organization program manager/project manager.

(c) Early Dismissal and Closure of Government Facilities

When a Government facility is closed or Federal employees are dismissed early (due to severe weather, security threat, security exercise, or a facility related problem) that prevents personnel from working, onsite contractor personnel regularly assigned to work at that facility shall follow the same reporting and/or departure directions given to Government personnel. The contractor shall not direct charge to the contract for such time off, but shall follow parent company policies regarding taking leave (administrative or other). Non-essential contractor personnel, who are not required to remain at or report to the facility, shall follow their parent company policy regarding whether they should go/stay home or report to another company facility. Subsequent to an early dismissal and during periods of inclement weather, onsite contractors should monitor radio and television announcements before departing for work to determine if the facility is closed or operating on a delayed arrival basis.

When Federal employees are excused from work due to a holiday or a special event (that is unrelated to severe weather, a security threat, or a facility related problem), on site contractors shall continue working established work hours or take leave in accordance with parent company policy. Those contractor employees who take leave shall not direct charge the non- working hours to the contract. Contractors are responsible for predetermining and disclosing their accounting standards, and company policy. Contractors shall follow their disclosed charging practices during the contract period of performance, and shall not follow any verbal directions to the contrary.

The Contracting Officer will make the determination of cost allowability for time lost due to facility closure in accordance with FAR, applicable Cost Accounting Standards, and the Contractor's established accounting policy.

(d) Training Requirements

(A) The contractor shall ensure that each contractor employee performing work at any NUWC Division Newport site take the following actions:

• Complete all required trainings as indicated on the following website:

https://newportalv3.nwpt.nuwc.navy.mil/10/101/Training/SitePages/TrainingWelcome.as px

• Read the documents titled “Occupational Safety and Health Information for Contractors” and “NUWC Division Newport Environmental Policy”, available at the following website, prior to performing any work:

http://www.navsea.navy.mil/Home/WarfareCenters/NUWCNewport/ContactUs/VisitorInformation.aspx

• Complete Environmental Awareness training, available at the following website, within 30 days of commencing performance:

http://www.navsea.navy.mil/Home/WarfareCenters/NUWCNewport/ContactUs/VisitorInformation.aspx

(2) The contractor shall email the following web address indicating completion of items (B) and (C) above upon completion of both: NWPT.NUWC_NPT_1023_Training@navy.mil

(e) Safety Requirements

(1) Prior to commencing any work that falls under the following areas, the contractor shall provide a complete listing of all qualified and trained employees who will perform the work on company letterhead to the Contracting Officer’s Representative, or, if no COR is assigned, to the NUWC Division Newport Safety Office:

(A) Permit required Confined Space Program

(B) Control of Hazardous Energy (Lock out / Tag out)

(C) Respiratory Protection

(D) Walking-Working Surfaces, Fall Protection Program and Scaffolding

(2) The contractor shall follow the posted provisions of the building’s Emergency Action Plan (EAP) for any mishap, incident, or emergency situation.

(3) The contractor shall report unsafe work conditions, safety hazards, and any mishaps (injury/property damage) to their supervisor, the COR, and the NUWC Division Newport Safety Office.

WAGE DETERMINATION

"General Decision Number: RI20220001 02/25/2022 Superseded General Decision Number: RI20210001 State: Rhode Island

Construction Types: Building, Heavy (Heavy and Marine) and Highway

Counties: Rhode Island Statewide.

BUILDING CONSTRUCTION PROJECTS (does not include residential construction consisting of single family homes and apartments up to and including 4 stories) HEAVY, HIGHWAY AND MARINE CONSTRUCTION

PROJECTS

Note: Contracts subject to the Davis-Bacon Act are generally required to pay at least the applicable minimum wage rate required under Executive Order 14026 or Executive Order 13658.

Please note that these Executive Orders apply to covered contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but do not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60).

|If the contract is entered |. Executive Order 14026 | |into on or after January 30, | generally applies to the | |2022, or the contract is | contract. | |renewed or extended (e.g., an |. The contractor must pay | |option is exercised) on or | all covered workers at | |after January 30, 2022: | least $15.00 per hour (or | | | the applicable wage rate | | | listed on this wage | | | determination, if it is | | | higher) for all hours | | | spent performing on the | | | contract in 2022. | |If the contract was awarded on|. Executive Order 13658 | |or between January 1, 2015 and| generally applies to the | |January 29, 2022, and the | contract. | |contract is not renewed or |. The contractor must pay all| |extended on or after January | covered workers at least | |30, 2022: | $11.25 per hour (or the | | | applicable wage rate listed| | | on this wage determination,| | | if it is higher) for all | | | hours spent performing on | | | that contract in 2022. |

The applicable Executive Order minimum wage rate will be adjusted annually. If this contract is covered by one of the Executive Orders and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must still submit a conformance request.

Additional information on contractor requirements and worker protections under the Executive Orders is available at https://www.dol.gov/agencies/whd/government-contracts.

Modification Number Publication Date 0 01/07/2022 1 01/21/2022 2 02/18/2022 3 02/25/2022

ASBE0006-006 12/01/2019

Rates Fringes

HAZARDOUS MATERIAL HANDLER

(Includes preparation, wetting, stripping, removal scrapping, vacuuming, bagging & disposing of all insulation materials, whether they contain asbestos or not, from mechanical systems)..............$ 36.60 22.40

ASBE0006-008 09/01/2021

Asbestos Worker/Insulator

Includes application of all insulating materials, protective coverings, coatings & finishes to all types of mechanical systems.$ 45.00 32.89

BOIL0029-001 01/01/2021

BOILERMAKER......................$ 45.87 29.02

BRRI0003-001 06/01/2020

Bricklayer, Stonemason, Pointer, Caulker & Cleaner.......$ 42.55 28.02

BRRI0003-002 03/01/2020

Rates Fringes

Marble Setter, Terrazzo Worker & Tile Setter.............$ 40.78 28.92

BRRI0003-003 03/01/2020

Rates Fringes

Marble, Tile & Terrazzo Finisher.........................$ 34.10 27.88

CARP0330-001 01/01/2021

CARPENTER (Includes Soft Floor Layer).....................$ 39.72 28.66 Diver Tender.....................$ 40.72 28.66

DIVER. ........................................................ $ 51.47 28.66

Piledriver. ............................................. $ 39.72 28.66

WELDER. ...................................................... $

FOOTNOTES:

40.72 28.66

When not diving or tending the diver, the diver and diver tender shall receive the piledriver rate. Diver tenders shall receive $1.00 per hour above the pile driver rate when tending the diver.

Work on free-standing stacks, concrete silos & public utility electrical power houses, which are over 35 ft. in height when constructed: $.50 per hour additional.

Work on exterior concrete shear wall gang forms, 45 ft. or more above ground elevation or on setback: $.50 per hour additional.

The designated piledriver, known as the ""monkey"": $1.00 per hour additional.

CARP1121-002 01/06/2020

MILLWRIGHT.......................$ 39.07 29.15

ELEC0099-002 06/02/2021

Rates Fringes

ELECTRICIAN......................$ 43.61 54.71%

Teledata System Installer........$ 32.71 12.57%+14.93

FOOTNOTES:

Work of a hazardous nature, or where the work height is 30

ft. or more from the floor, except when working OSHA-approved lifts: 20% per hour additional.

Work in tunnels below ground level in combined sewer outfall:

20% per hour additional.

ELEV0039-001 01/01/2022

ELEVATOR MECHANIC................$ 56.91 36.885+a+b

FOOTNOTES:

A. PAID HOLIDAYS: New Years Day; Memorial Day; Independence Day; Labor Day; Veterans' Day; Thanksgiving Day; the Friday after Thanksgiving Day; and Christmas Day.

B. Employer contributes 8% basic hourly rate for 5 years or more of service of 6% basic hourly rate for 6 months to 5 years of service as vacation pay credit.

ENGI0057-001 12/01/2021

Operating Engineer: (power plants, sewer treatment plants, pumping stations, tunnels, caissons, piers, docks, bridges, wind turbines, subterranean & other marine and heavy construction work)

GROUP 1. ......................................... $ 43.55 28.25+a GROUP 2. ......................................... $ 41.55 28.25+a GROUP 3. ......................................... $ 37.17 28.25+a GROUP 4. ......................................... $ 34.32 28.25+a GROUP 5. ......................................... $ 40.60 28.25+a GROUP 6. ......................................... $ 31.40 28.25+a GROUP 7. ......................................... $ 25.40 28.25+a GROUP 8. ......................................... $ 37.25 28.25+a GROUP 9. ......................................... $ 41.17 28.25+a

a. BOOM LENGTHS, INCLUDING JIBS:

150 feet and over + $ 2.00 180 feet and over + $ 3.00 210 feet and over + $ 4.00 240 feet and over + $ 5.00 270 feet and over + $ 7.00 300 feet and over + $ 8.00 350 feet and over + $ 9.00 400 feet and over + $10.00

a. PAID HOLIDAYS:

New Year's Day, President's Day, Memorial Day, July Fourth, Victory Day, Labor Day, Columbus Day, Veterans Day, Thanksgiving Day, Christmas Day. a: Any employee who works 3 days in the week in which a holiday falls shall be paid for the holiday.

a. FOOTNOTES:

Hazmat work: $2.00 per hour additional.

Tunnel/Shaft work: $5.00 per hour additional.

POWER EQUIPMENT OPERATORS CLASSIFICATIONS

GROUP 1: Cranes, lighters, boom trucks and derricks

GROUP 2: Digging machine, Ross Carrier, locomotive, hoist, elevator, bidwell-type machine, shot & water blasting machine, paver, spreader, graders, front end loader (3 yds.

and over), vibratory hammer & vacuum truck, roadheaders, forklifts, economobile type equipment, tunnel boring machines, concrete pump and on site concrete plants.

GROUP 3: Oilers on cranes.

GROUP 4: Oiler on crawler backhoe.

GROUP 5: Bulldozer, bobcats, skid steer loader, tractor, scraper, combination loader backhoe, roller, front end loader (less than 3 yds.), street and mobile-powered sweeper (3-yd. capacity), 8-ft. sweeper minimum 65 HP).

GROUP 6: Well-point installation crew.

GROUP 7: Utility Engineers and Signal Persons

GROUP 8: Heater, concrete mixer, stone crusher, welding machine, generator and light plant, gas and electric driven pump and air compressor.

GROUP 9: Boat & tug operator.

ENGI0057-002 11/01/2021

Power Equipment Operator (highway construction projects; water and sewerline projects which are incidental to highway construction projects; and bridge projects that do not span water)

GROUP 1....................$ 36.70 28.25+a GROUP 2....................$ 31.40 28.25+a GROUP 3....................$ 25.40 28.25+a GROUP 4....................$ 31.98 28.25+a GROUP 5....................$ 35.68 28.25+a GROUP 6....................$ 35.30 28.25+a GROUP 7....................$ 30.95 28.25+a GROUP 8....................$ 32.33 28.25+a GROUP 9....................$ 34.28 28.25+a

a. FOOTNOTE: a. Any employee who works three days in the week in which a holiday falls shall be paid for the holiday.

a. PAID HOLIDAYS: New Year's Day, President's Day, Memorial Day, July Fourth, Victory Day, Labor Day, Columbus Day, Veterans Day, Thanksgiving Day & Christmas Day.

POWER EQUIPMENT OPERATOR CLASSIFICATIONS

GROUP 1: Digging machine, crane, piledriver, lighter, locomotive, derrick, hoist, boom truck, John Henry's, directional drilling machine, cold planer, reclaimer, paver, spreader, grader, front end loader (3 yds. and over), vacuum truck, test boring machine operator, veemere saw, water blaster, hydro-demolition robot, forklift, economobile, Ross Carrier, concrete pump operator and boats

GROUP 2: Well point installation crew

GROUP 3: Utlity engineers and signal persons GROUP 4: Oiler on cranes GROUP 5: Combination loader backhoe, front end loader (less than 3 yds.), forklift, bulldozers & scrapers and boats

GROUP 6: Roller,skid steer loaders, street sweeper

GROUP 7: Gas and electric drive heater, concrete mixer, light plant, welding machine, pump & compressor

GROUP 8: Stone crusher GROUP 9: Mechanic & welder

ENGI0057-003 12/01/2021

BUILDING CONSTRUCTION

Rates Fringes

Power Equipment Operator

GROUP 1. ....................................... $ 42.82 28.25+a GROUP 2. ....................................... $ 40.82 28.25+a GROUP 3. ....................................... $ 40.60 28.25+a GROUP 4. ....................................... $ 36.60 28.25+a GROUP 5. ....................................... $ 33.75 28.25+a GROUP 6. ....................................... $ 39.90 28.25+a GROUP 7. ....................................... $ 39.47 28.25+a GROUP 8. ....................................... $ 36.79 28.25+a a.BOOM LENTHS, INCLUDING JIBS:

150 ft. and over: + $ 2.00 180 ft. and over: + $ 3.00 210 ft. and over: + $ 4.00 240 ft. and over: + $ 5.00 270 ft. and over: + $ 7.00 300 ft. and over: + $ 8.00 350 ft. and over: + $ 9.00 400 ft. and over: + $10.00

a. PAID HOLIDAYS: New Year's Day, President's Day, Memorial Day, July Fourth, Victory Day, Labor Day, Columbus Day, Veterans Day, Thanksgiving Day & Christmas Day. a: Any employee who works 3 days in the week in which a holiday falls shall be paid for the holiday.

a. FOOTNOTE: Hazmat work: $2.00 per hour additional.

Tunnel/Shaft work: $5.00 per hour additional.

POWER EQUIPMENT OPERATORS CLASSIFICATIONS

GROUP 1: Cranes, lighters, boom trucks and derricks.

GROUP 2: Digging machine, Ross carrier, locomotive, hoist, elevator, bidwell-type machine, shot & water blasting machine, paver, spreader, front end loader (3 yds. and over), vibratory hammer and vacuum truck

GROUP 3: Telehandler equipment, forklift, concrete pump & on-site concrete plant

GROUP 4: Fireman & oiler on cranes GROUP 5: Oiler on crawler backhoe GROUP 6: Bulldozer,skid steer loaders,bobcats, tractor, grader, scraper,combination loader backhoe, roller, front end loader (less than 3 yds.), street and mobile powered sweeper (3 yds. capacity), 8-ft. sweeper (minimum 65 hp)

GROUP 7: Well point installation crew

GROUP 8: Heater, concrete mixer, stone crusher, welding machine, generator for light plant, gas and electric driven pump & air compressor

IRON0037-001 09/16/2021

IRONWORKER.......................$ 38.21 30.58

LABO0271-001 05/30/2021

BUILDING CONSTRUCTION

LABORER

GROUP 1.....................$ 33.55 26.15

GROUP 2.....................$ 33.80 26.15

GROUP 3.....................$ 34.30 26.15

GROUP 4.....................$ 34.55 26.15

GROUP 5.....................$ 35.55 26.15

LABORERS CLASSIFICATIONS

GROUP 1: Laborer, Carpenter Tender, Mason Tender, Cement Finisher Tender, Scaffold Erector, Wrecking Laborer, Asbestos Removal [Non-Mechanical Systems]

GROUP 2: Asphalt Raker, Adzemen, Pipe Trench Bracer, Demolition Burner, Chain Saw Operator, Fence & Guard Rail Erector, Setter of Metal Forms for Roadways, Mortar Mixer, Pipelayer, Riprap & Dry Stonewall Builder, Highway Stone Spreader, Pneumatic Tool Operator, Wagon Drill Operator, Tree Trimmer, Barco-Type Jumping Tamper, Mechanical Grinder Operator

GROUP 3: Pre-Cast Floor & Roof Plank Erectors

GROUP 4: Air Track Operator, Hydraulic & Similar Self-Powered Drill, Block Paver, Rammer, Curb Setter, Powderman & Blaster

GROUP 5: Toxic Waste Remover

LABO0271-002 05/30/2021

HEAVY AND HIGHWAY CONSTRUCTION

LABORER

COMPRESSED AIR

Group 1....................$ 53.45 24.15 Group 2....................$ 50.98 24.15 Group 3....................$ 40.50 24.15

FREE AIR

Group 1....................$ 44.05 24.15 Group 2....................$ 43.05 24.15 Group 3....................$ 40.50 24.15

LABORER

Group 1....................$ 33.55 24.15 Group 2....................$ 33.80 24.15 Group 3....................$ 34.55 24.15 Group 4....................$ 27.05 24.15 Group 5....................$ 35.55 24.15

OPEN AIR CAISSON,

UNDERPINNING WORK AND

BORING CREW

Bottom Man. ................................. $ 39.55 24.15 Top Man & Laborer. .................. $ 38.60 24.15

TEST BORING

Driller. ....................................... $ 40.00 24.15 Laborer. ....................................... $ 38.60 24.15

LABORER CLASSIFICATIONS

GROUP 1: Laborer; Carpenter tender; Cement finisher tender;

Wrecking laborer; Asbestos removers [non-mechanical systems]; Plant laborer; Driller in quarries

GROUP 2: Adzeperson; Asphalt raker; Barcotype jumping tamper; Chain saw operators; Concrete and power buggy operator; Concrete saw operator; Demolition burner; Fence and guard rail erector; Highway stone spreader; Laser beam operator; Mechanical grinder operator; Mason tender; Mortar mixer; Pneumatic tool operator; Riprap and dry stonewall builder; Scaffold erector; Setter of metal forms for roadways; Wagon drill operator; Wood chipper operator;

Pipelayer; Pipe trench bracer

GROUP 3: Air track drill operator; Hydraulic and similar powered drills; Brick paver; Block paver; Rammer and curb setter; Powderperson and blaster

GROUP 4: Flagger & signaler GROUP 5: Toxic waste remover

LABORER - COMPRESSED AIR CLASSIFICATIONS

GROUP 1: Mucking machine operator, tunnel laborer, brake person, track person, miner, grout person, lock tender, gauge tender, miner: motor person & all others in compressed air

GROUP 2: Change house attendant, powder watchperson, top person on iron

GROUP 3: Hazardous waste work within the ""HOT"" zone

LABORER - FREE AIR CLASSIFICATIONS

GROUP 1: Grout person - pumps, brake person, track person, form mover & stripper (wood & steel), shaft laborer, laborer topside, outside motorperson, miner, conveyor operator, miner welder, heading motorperson, erecting operator, mucking machine operator, nozzle person, rodperson, safety miner, shaft & tunnel, steel & rodperson, mole nipper, concrete worker, form erector (wood, steel and all accessories), cement finisher (this type of work only), top signal person, bottom person (when heading is 50' from shaft), burner, shield operator and TBM operator

GROUP 2: Change house attendant, powder watchperson GROUP 3: Hazardous waste work within the ""HOT"" zone

PAIN0011-005 06/01/2021

PAINTER

Brush and Roller. ...................... $ Epoxy, Tanks, Towers, Swing Stage & Structural

36.42 22.90

Steel. ............................................. $ 38.42 22.90 Spray, Sand & Water

Blasting. ....................................... $ 39.42 22.90 Taper. ............................................. $ 37.17 22.90 Wall Coverer. .............................. $ 36.92 22.90

PAIN0011-006 06/01/2021

Rates

Fringes

GLAZIER..........................$ 39.98 22.90

FOOTNOTES:

SWING STAGE: $1.00 per hour additional.

PAID HOLIDAYS: Labor Day & Christmas Day.

PAIN0011-011 06/01/2021

Rates Fringes

Painter (Bridge Work)...........$ 54.00 22.90

PAIN0035-008 06/01/2011

Rates Fringes

Sign Painter.....................$ 24.79 13.72

PLAS0040-001 06/03/2019

BUILDING CONSTRUCTION

Rates Fringes

CEMENT MASON/CONCRETE FINISHER...$ 36.00 27.15

FOOTNOTE: Cement Mason: Work on free swinging scaffolds under 3 planks width and which is 20 or more feet above ground and any offset structure: $.30 per hour additional.

PLAS0040-002 07/01/2019

HEAVY AND HIGHWAY CONSTRUCTION

Rates Fringes

CEMENT MASON/CONCRETE FINISHER...$ 32.85 22.20

PLAS0040-003 07/01/2019

Rates Fringes

PLASTERER........................$ 37.55 27.50

PLUM0051-002 08/30/2021

Plumbers and Pipefitters.........$ 46.49 31.40

ROOF0033-004 12/01/2021

ROOFER...........................$ 40.40 29.06

SFRI0669-001 01/01/2022

Rates Fringes

SPRINKLER FITTER.................$ 47.55 27.14

SHEE0017-002 12/01/2020

Sheet Metal Worker...............$ 38.58 36.73

TEAM0251-001 05/01/2019

HEAVY AND HIGHWAY CONSTRUCTION

TRUCK DRIVER

GROUP 1. ....................................... $ 27.96 26.8525+A+B+C

GROUP 2. ....................................... $ 27.61 26.8525+A+B+C

GROUP 3. ....................................... $ 27.66 26.8525+A+B+C

GROUP 4. ....................................... $ 27.71 26.8525+A+B+C

GROUP 5. ....................................... $ 27.81 26.8525+A+B+C

GROUP 6. ....................................... $ 28.21 26.8525+A+B+C

GROUP 7. ....................................... $ 28.41 26.8525+A+B+C

GROUP 8. ....................................... $ 27.91 26.8525+A+B+C

GROUP 9. ....................................... $ 28.16 26.8525+A+B+C

GROUP 10. ....................................... $ 27.96 26.8525+A+B+C

FOOTNOTES:

A. Paid Holidays: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day and Christmas Day, plus Presidents' Day, Columbus Day, Veteran's Day & V-J Day, providing the employee has worked at least one day in the calendar week in which the holiday falls.

B. Employee who has been on the payroll for 1 year or more but less than 5 years and has worked 150 Days during the last year of employment shall receive 1 week's paid vacation; 5 to 10 years - 2 weeks' paid vacation; 10 or more years - 3 week's paid vacation.

C. Employees on the seniority list shall be paid a one hundred dollar ($100.00) bonus for every four hundred (400) hours worked, up to a maximum of five hundred dollars ($500.00)

All drivers working on a defined hazard material job site shall be paid a premium of $2.00 per hour over applicable rate.

TRUCK DRIVER CLASSIFICATIONS

GROUP 1: Pick-up trucks, station wagons, & panel trucks GROUP 2: Two-axle on low beds GROUP 3: Two-axle dump truck GROUP 4: Three-axle dump truck GROUP 5: Four- and five-axle equipment GROUP 6: Low-bed or boom trailer.

GROUP 7: Trailers when used on a double hook up (pulling 2 trailers)

GROUP 8: Special earth-moving equipment, under 35 tons GROUP 9: Special earth-moving equipment, 35 tons or over GROUP 10: Tractor trailer

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017.