N6649821Q0098.pdf

NAVAL SURFACE WARFARE CENTER PHILA

CHRIS SHAFFER

NSWC PHILADELPHIA DIVISION

NSLC DETACHMENT

1601 LANGLEY AVE BLDG 542

PHILADELPHIA PA 19112

TEL: 215-897-3067 FAX:

1300910626

REQUEST FOR QUOTATIONS

(THIS IS NOT AN ORDER) 1

PAGE OF PAGES

1. REQUEST NO. 2. DATE ISSUED RATING

N6449821Q0098 28-Apr-2021

5a. ISSUED BY

8. TO: NAME AND ADDRESS, INCLUDING ZIP CODE

IMPO RTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this

Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State, and local taxes)

ITEM NO.

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e) (f)

SEE SCHEDULE

AMOUNT

% No. %

NO TE: Additional provisions and representations [ ] are [ ] are not attached.

13. NAME AND ADDRESS OF QUOTER (Street, City, County, State, and ZIP Code)

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

15. DATE OF

QUOTATION

16. NAME AND TITLE OF SIGNER (Type or print) ( Include area code)

TELEPHONE NO.

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 18 (REV. 6-95)

PREVIOUS EDITION NOT USABLE Prescribed by GSA

FAR (48 CFR) 53.215-1(a)

THIS RFQ [ ] IS X[ ] IS NOT A SMALL BUSINESS SET-ASIDE

6. DELIVER BY (Date)

SEE SCHEDULE

AND/OR DMS REG. 1

UNDER BDSA REG. 2

4. CERT. FOR NAT. DEF.3. REQUISITION/PURCHASE

REQUEST NO.

NAVAL SURFACE WARFARE CENTER PHILA

CODE 0223, SHAWN WATERS

215-897-1828, SHAWN.M.WATERS@NAVY.MIL

5001 SOUTH BROAD STREET

PHILADELPHIA PA 19112

9. DESTINATION (Consignee and address, including ZIP Code)

7. DELIVERY

[ ]X FOB

DESTINATION

[ ] OTHER

(See Schedule)

31-May-2021(Date)

PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS:10.

215-897-1828SHAWN M WATERS

(Name and Telephone no.) (No collect calls)5b. FOR INFORMATION CALL:

d. CALENDAR DAYSc. 30 CALENDAR DAYSb. 20 CALENDAR DAYS12. DISCOUNT FOR PROMPT PAYMENT a. 10 CALENDAR DAYS

N6449821Q0098

Section A - Solicitation/Contract Form

CONTINUATION SHEET

Standard Form (SF) 1449 – Solicitation / Contract / Order for Commercial Items

(CONTINUATION SHEET)

1. Block 8

Offer Due Date / Local Time: 31 May 2021 by 3:00 P.M. Local Time

EMAIL OFFERS ARE AUTHORIZED

Emailed Offers shall be sent to: shawn.m.waters@navy.mil

FACSIMILE OFFERS ARE NOT AUTHORIZED

2. Block 17a: Offeror’s assigned DUNS Number: ___________________________.

Offeror’s CAGE CODE: ________________________.

3. Are you registered in System for Award Management (SAM)?

( ) YES ( ) NO

You will not be eligible for award if you are not registered in the System for Award Management (SAM). If you have previously registered, make sure that your registration has not expired.

~NOTE: Offeror’s should ensure that all clauses, certifications, and representations within this solicitation have been accurately completed.

NOTE:

This procurement will be completed by utilizing the provided drawings sent via safe.apps.mil.

VERY IMPORTANT: The vendor must certify their agreement to these terms and conditions of the solicitation by signing and dating page one (1) of form SF1449.

mailto:jillian.randazzo@navy.mil

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 2 Each

CMBRE MDS

FFP

CMBRE Main Disconnect Switch (400Hz) - Please reference drawing 8603792

FOB: Destination

NSN: 20901021756699

VENDOR PART NR: 100001620978-0010

PURCHASE REQUEST NUMBER: 1300910626

PSC CD: 6110

NET AMT

0002 5 Each

CMBRE SDS

FFP

CMBRE Secondary Disconnect Switch (400Hz) - Please reference drawing

8603793

FOB: Destination

NSN: 20901021756700

VENDOR PART NR: 100001620978-0010

0003 5 Each

CMBRE PDB

FFP

CMBRE Power Drop Box (400Hz) - Please reference drawing 8603794

FOB: Destination

NSN: 20901021756701

VENDOR PART NR: 100001620978-0010

0004 3 Each

DMLGB MDS

FFP

DMLGB Main Disconnect Switch (60Hz) - Please reference drawing 8603795

FOB: Destination

NSN: 20901021756702

VENDOR PART NR: 100001620978-0010

0005 5 Each

DMLGB SDS

FFP

DMLGB Secondary Disconnect Switch (60Hz) - Please reference drawing

8603796

FOB: Destination

NSN: 20901021756703

VENDOR PART NR: 100001620978-0010

0006 5 Each

DMLGB PDB

FFP

DMLGB Power Drop Box (60Hz) - Please reference drawing 8603797

FOB: Destination

NSN: 20901021756704

VENDOR PART NR: 100001620978-0010

CDRL A001

FFP

CDRL A001 - Test Report

FOB: Destination

Section C - Descriptions and Specifications

BENCH TEST PROCEDURE

TEST PROCEDURE FOR COMMON MUNITIONS BIT/REPROGRAMING EQUIPMENT ( CAMBRE )

FOR 440 VAC 400 HZ POWER SYSTEM.

1. HOOK UP CABLING BETWEEN THE MAIN DISCONNECT, THE SECONDARY

DISCONNECT AND THE POWER DROPBOX. MAKE SURE THAT YOU BOND ALL THE

BOXES TOGETHER AND THAT THEY ARE GROUNDED AT THE SOURCE.

2. HOOK UP THE SECONDARY OF THE 480/208/120 VAC TRANSFORMER TO THE INPUT

TERMINAL BOARD TB1-1, TB1-2, TB1-3 AND TB1-4 IN THE SECONDARY DISCONNECT

BOX.

3. HOOK UP THE PRIMARY 440/208/120 VAC TRANSFORMER TO THE OUTPUT TERMINAL

BOARD OF THE MAIN DISCONNECT TB2-1, TB2-2 AND TB2-3.

4. HOOK THE 440 VAC PLUG TO THE INPUT TERMINAL BOARD TB1-1, TB1-2 AND TB1-3 IN

THE MAIN DISCONNECT BOX.

5. HOOK UP THE 208/120 VAC 400 HZ TEST BOX BY PLUGGING IN CANNON PLUG TO THE

POWER DROP BOX AND PLUGGING THE 2 ANDERSON PLUGS TO LOAD BANK. RUN A

120 VAC EXTENSION CORD FOR THE COOLING FAN ON THE LOAD BANK . TURN THE

TOGGLE SWITCH ON THE SIDE OF THE TEST BOX TO THE ON POSITION.

6. NEXT STEP IS TO TURN THE TOGGLE SWITCH ON THE LOAD BANK TO THE 220 VAC

POSITION AND TURN ONE OF THE TOGGLE SWITCHES TO 5KVA ON AND MAKE SURE

THAT THE REST ARE IN THE OFF POSITION.

7. NEXT STEP IS TO RE-VERIFY HOOK UP AND MAKE SURE THAT YOU HAVE SAFETY

BOUNDRIES MARKED AND ROPED OFF. YOU ARE NOW READY FOR TESTING.

8. PLUG IN 440VAC PLUG TO RECEPTACLE AND TURN SWITCH TO THE ON POSITION.

9. PUSH THE ON BUTTON ON THE SECONDARY DISCONNECT AND YOU SHOULD HERE

THE MAIN CONTACT CLOSE IN THE MAIN DISCONNECT AND THE POWER AVAILABLE

LIGHT SHOULD BE ILLUMINATED ON THE START PUSH BUTTON. (THE TRANSFORMER

SHOULD ALSO BE HUMMING AT THIS TIME AS IT SHOULD BE ENERGIZED. IF THIS

DOES NOT HAPPEN CHECK HOOK UP AND MAIN POWER SUPPLY TO 440 VAC

RECEPTACLE.

10. NEXT STEP IS TO PRESS THE TEST BUTTON ON THE SECONDARY DISCONNECT AND

THE MAIN CONTACTOR IN THE MAIN DISCONNECT SHOULD OPEN AND THE POWER

AVAILABLED LIGHT ON THE PUSH BUTTON WILL GO OUT.

11. REPEAT STEP #9.

12. THE NEXT STEP IS TO PUSH THE ON PUSH BUTTON ON THE POWER DROP BOX AND

NOTHING SHOULD HAPPEN. (THIS TEST IS TO MAKE SURE THE KEY SWITCH IS

OPERATING CORRECTLY).

13. THE NEXT STEP IS TURN THE KEY SWITCH ON THE POWER DROP BOX TO THE ON

POSITION.

14. THEN PUSH THE ON BUTTON ON THE PWER DROP BOX AND LOAD BANK SHOULD

START OPERATING AT THIS TIME AS YOU SHOULD HAVE APPLIED 208/120 VAC AT

THIS TIME AND YOU ARE SIMULATING NORMAL OPERATION. (CHECK THE VOLTAGE

AND HZ AT THE LOAD BANK TEST POINTS VERIFYING THAT IT IS 120 VAC 60 HZ 3

PHASE POWER.)

15. THE NEXT STEP IS TO PUSH THE TEST BUTTON AND THE LOAD BANK SHOULD STOP

OPERATING WHILE THE BUTTON IS PRESSED BUT WHEN YOU LET OFF THE BUTTON

THE HEAT GUN SHOULD START OPERATING AGAIN.

16. THE LAST STEP IS TO PUSH IN THE E-STOP BUTTON AND EVERYTHING SHOULD SHUT

DOWN.

17. AT THIS TIME THE TEST IS COMPLETE AND YOU WILL HAVE TO RELEASE THE E-STOP

TEST PROCEDURE FOR COMMON MUNITIONS BIT/REPROGRAMING EQUIPMENT ( CAMBRE )

FOR 120 VAC 60 HZ POWER SYSTEM.

1. HOOK UP CABLING BETWEEN THE MAIN DISCONNECT, THE SECONDARY

DISCONNECT AND THE POWER DROPBOX. MAKE SURE THAT YOU BOND ALL THE

BOXES TOGETHER AND THAT THEY ARE GROUNDED AT THE SOURCE.

2. HOOK UP THE SECONDARY OF THE 480/120 VAC TRANSFORMER TO THE INPUT

TERMINAL BOARD TB1-1 AND TB1-2 IN THE SECONDARY DISCONNECT BOX.

3. HOOK UP THE PRIMARY 440/120 VAC TRANSFORMER TO THE OUTPUT TERMINAL

BOARD OF THE MAIN DISCONNECT TB2-1 AND TB2-2.

4. HOOK THE 440 VAC PLUG TO THE INPUT TERMINAL BOARD TB1-1 AND TB1-2 IN THE

MAIN DISCONNECT BOX.

5. HOOK UP THE 120 VAC 60 HZ TEST BOX BY PLUGGING IN CANNON PLUG TO THE

POWER DROP BOX.

6. PLUG IN A HEAT GUN TO 12O VAC OUTLET ON TEST BOX AND TURN THE HEAT GUN

TO ON POSITION.

7. NEXT STEP IS TO RE-VERIFY HOOK UP AND MAKE SURE THAT YOU HAVE SAFETY

BOUNDRIES MARKED AND ROPED OFF. YOU ARE NOW READY FOR TESTING.

8. PLUG IN 440VAC PLUG TO RECEPTACLE AND TURN SWITCH TO THE ON POSITION.

9. PUSH THE ON BUTTON ON THE SECONDARY DISCONNECT AND YOU SHOULD HERE

THE MAIN CONTACT CLOSE IN THE MAIN DISCONNECT AND THE GREEN LIGHT

SHOULD BE ILLUMINATED ON THE START PUSH BUTTON. (THE TRANSFORMER

SHOULD ALSO BE HUMMING AT THIS TIME AS IT SHOULD BE ENERGIZED. IF THIS

DOES NOT HAPPEN CHECK HOOK UP AND MAIN POWER SUPPLY TO 440 VAC

RECEPTACLE.

10. NEXT STEP IS TO PRESS THE TEST BUTTON ON THE SECONDARY DISCONNECT AND

THE MAIN CONTACTOR IN THE MAIN DISCONNECT SHOULD OPEN AND RED LIGHT ON

THE PUSH BUTTON WILL LIGHT.

11. REPEAT STEP #9.

12. THE NEXT STEP IS TURN THE KEY SWITCH ON THE POWER DROP BOX.

13. THEN PUSH THE ON BUTTON ON THE PWER DROP BOX AND HEAT GUN SHOULD

START OPERATING AT THIS TIME AS YOU SHOULD HAVE APPLIED 120 VAC AT THIS

TIME AND YOU ARE SIMULATING NORMAL OPERATION. (CHECK THE VOLTAGE AND

HZ AT THE RECEPTACLE PLUG VERIFYING THAT IT IS 120 VAC 60 HZ).

14. THE NEXT STEP IS TO PUSH THE TEST BUTTON AND THE HEAT GUN SHOULD STOP

OPERATING WHILE THE BUTTON IS PRESSED BUT WHEN YOU LET OFF THE BUTTON

THE HEAT GUN SHOULD START OPERATING AGAIN.

15. THE LAST STEP IS TO PUSH IN THE E-STOP BUTTON AND EVERYTHING SHOULD SHUT

DOWN.

16. AT THIS TIME THE TEST IS COMPLETE AND YOU WILL HAVE TO RELEASE THE E-STOP

STATEMENT OF WORK

CMBRE Boxes Procurement

1.0 Objective

1.1 NSWCPD was funded for the procurement of CMBRE (Common Munitions BIT Reprogramming Equipment) boxes for LHD 7. These boxes are provided as GFE (Government Furnished Equipment) to the installation activity, which is usually a shipyard. These boxes need to be manufactured and assemble.

The contractor shall procure all parts for the manufacture and assembly process, for which they will be provided drawings as GFI. There are twenty five (25) boxes in total that need to be made for LHD 7 as detailed in section 2.0.

2.0 Technical Requirements

2.1 Requested material in this SAP will ultimately be used as GFE for an installation on LHD 7. The contractor shall be responsible for the procurement of all necessary parts for the manufacturing and assembly, manufacture and assemble the boxes, and conduct a bench test per attachment 1 to prove proper operation of each box described in section 2.2.

2.2 Parts

Item Number

Part Name Product Info Part Number Quantity

1 CMBRE Main Disconnect Switch (400Hz)

XXX 8603792 2

2 CMBRE Secondary Disconnect Switch (400Hz)

XXX 8603793 5

3 CMBRE Power Drop Box (400Hz)

XXX 8603794 5

4 DMLGB Main Disconnect Switch (60Hz)

XXX 8603795 3

5 DMLGB Secondary Disconnect Switch (60Hz)

XXX 8603796 5

6 DMLGB Power Drop Box (60Hz)

XXX 8603797 5

3.0 Delivery Requirements

3.1 NSWCPD will require the awarded contractor to deliver the parts to Naval Surface Warfare Center Philadelphia Division (NSWCPD)

3.1.1 The shipping address for NSWCPD is as follows:

Chris Shaffer Building 542 1601 Langley Avenue Philadelphia, PA 19112

3.2 Contractor shall provide a test report (A001) to prove all equipment was bench tested and operates satisfactorily at time of delivery.

3.3 The completed boxes listed in section 2.2 along with required test reports shall delivered by 1 SEP 2021.

4.0 Technical Point of Contact (TPOC)

4.1 The TPOC for this delivery order is Chris Shaffer, Naval Surface Warfare

Center - Code 443, Phone (215) 897-3067, Email chris.shaffer@navy.mil

4.2 The secondary TPOC for this delivery order is Steve Peta, Naval Surface

Warfare Center -Code 443, Phone (215) 897-8203, Email steve.peta@navy.mil

CLAUSES INCORPORATED BY FULL TEXT

C-202-H001 ADDITIONAL DEFINITIONS–BASIC (NAVSEA) (OCT 2018)

(a) Department - means the Department of the Navy.

(b) Commander, Naval Sea Systems Command - means the Commander of the Naval Sea Systems Command of the

Department of the Navy or his duly appointed successor.

(c) References to The Federal Acquisition Regulation (FAR) - All references to the FAR in this contract shall be deemed to also reference the appropriate sections of the Defense FAR Supplement (DFARS), unless clearly indicated otherwise.

(d) National Stock Numbers - Whenever the term Federal Item Identification Number and its acronym FIIN or the term Federal Stock Number and its acronym FSN appear in the contract, order or their cited specifications and standards, the terms and acronyms shall be interpreted as National Item Identification Number (NIIN) and National

Stock Number (NSN) respectively which shall be defined as follows:

(1) National Item Identification Number (NIIN). The number assigned to each approved Item

Identification under the Federal Cataloging Program. It consists of nine numeric characters, the first two of which are the National Codification Bureau (NCB) Code. The remaining positions consist of a seven digit non-significant number.

(2) National Stock Number (NSN). The National Stock Number (NSN) for an item of supply consists of the applicable four-position Federal Supply Class (FSC) plus the applicable nine-position NIIN assigned to the item of supply.

(End of text)

C-204-H001 USE OF NAVY SUPPORT CONTRACTORS FOR OFFICIAL CONTRACT FILES (NAVSEA)

(OCT 2018)

(a) NAVSEA may use a file room management support contractor, hereinafter referred to as "the support contractor", to manage its file room, in which all official contract files, including the official file supporting this procurement, are retained. These official files may contain information that is considered a trade secret, proprietary, business sensitive or otherwise protected pursuant to law or regulation, hereinafter referred to as “protected information”. File room management services consist of any of the following: secretarial or clerical support; data entry; document reproduction, scanning, imaging, or destruction; operation, management, or maintenance of paper-based or electronic mail rooms, file rooms, or libraries; and supervision in connection with functions listed herein.

(b) The cognizant Contracting Officer will ensure that any NAVSEA contract under which these file room management services are acquired will contain a requirement that:

(1) The support contractor not disclose any information;

(2) Individual employees are to be instructed by the support contractor regarding the sensitivity of the official contract files;

(3) The support contractor performing these services be barred from providing any other supplies and/or services, or competing to do so, to NAVSEA for the period of performance of its contract and for an additional three years thereafter unless otherwise provided by law or regulation; and,

(4) In addition to any other rights the contractor may have, it is a third party beneficiary who has the right of direct action against the support contractor, or any person to whom the support contractor has released or disclosed protected information, for the unauthorized duplication, release, or disclosure of such protected information.

(c) Execution of this contract by the contractor is considered consent to NAVSEA's permitting access to any information, irrespective of restrictive markings or the nature of the information submitted, by its file room management support contractor for the limited purpose of executing its file room support contract responsibilities.

(d) NAVSEA may, without further notice, enter into contracts with other contractors for these services. Contractors should enter into separate non-disclosure agreements with the file room contractor. Contact the Procuring

Contracting Officer for contractor specifics. However, any such agreement will not be considered a prerequisite before information submitted is stored in the file room or otherwise encumber the government.

C-211-H016 SPECIFICATIONS AND STANDARDS (NAVSEA) (OCT 2018)

(a) Definitions.

(i) A "zero-tier reference" is a specification, standard, or drawing that is cited in the contract (including its attachments).

(ii) A "first-tier reference" is either: (1) a specification, standard, or drawing cited in a zero-tier reference, or (2) a specification cited in a first-tier drawing.

(b) Requirements. All zero-tier and first-tier references, as defined above, are mandatory for use. All lower tier references shall be used for guidance only unless specifically identified below.

None

C-211-H018 APPROVAL BY THE GOVERNMENT (NAVSEA) (JAN 2019)

Approval by the Government as required under this contract and applicable specifications shall not relieve the

Contractor of its obligation to comply with the specifications and with all other requirements of the contract, nor shall it impose upon the Government any liability it would not have had in the absence of such approval.

C-215-H002 CONTRACTOR PROPOSAL (NAVSEA) (OCT 2018)

(a) Performance of this contract by the Contractor shall be conducted and performed in accordance with the detailed obligations to which the Contractor committed itself in Proposal dated in response to Solicitation No.

N6449821Q0098.

(b) The technical volume(s) of the Contractor's proposal is(are) hereby incorporated by reference and made subject to the "Order of Precedence" (FAR 52.215-8) clause of this contract. Under the "Order of Precedence" clause, the technical volume(s) of the Contractor's proposal referenced herein is (are) hereby designated as item (f) of the clause, following

"the specifications" in the order of precedence.

C-227-H006 DATA REQUIREMENTS (NAVSEA) (OCT 2018)

The data to be furnished hereunder shall be prepared in accordance with the Contract Data Requirements List, DD Form

1423, Exhibit(s) A001, attached hereto.

(End of Text)

C-227-H014 PROTECTION OF DEPARTMENT OF NAVY TRADEMARKS - BASIC (NAVSEA) (JAN 2021)

(a) The contractor shall not assert any claim, in any jurisdiction, based on trademark or other name or design-based causes of action that are based on rights the contractor believes it has in the term(s) [contracting officers shall list terms(s) (typically the assigned nomenclature, or portions thereof)] (the “Designation(s)”), against the Government or others authorized by the Government to use the Designation(s) (including the word(s), name, symbol, or design) acting within the scope of such authorization (i.e. claims for trademark infringement, dilution, trade dress infringement, unfair competition, false advertising, palming off, passing off, or counterfeiting). Such authorization shall be implied by the award of a Government contract to any party for the manufacture, production, distribution, use, modification, maintenance, sustainment, or packaging of the products and services identified under this contract, and the scope of such implied authorization is defined as the use of the Designation(s) in performance under such contract by the prime contractor and its subcontractors and suppliers at any tier. In all other cases, the scope of the authorization will be defined by the Government in writing.

(b) The contractor shall notify the contracting officer at least 30 days before asserting rights in, or filing an application to register, any one of the Designation(s) in any jurisdiction within the United States. Any such notification shall be in writing and shall identify the Designation(s) (including the word(s), name, symbol, or design), provide a statement as to its intended use(s) in commerce, and list the particular classes of goods or services in which registration will be sought.

C-233-H001 DOCUMENTATION OF REQUESTS FOR EQUITABLE ADJUSTMENT--BASIC (NAVSEA) (OCT

2018)

(a) For the purposes of this special contract requirement, the term "change" includes not only a change that is made pursuant to a written order designated as a "change order" but also (1) an engineering change proposed by the

Government or by the Contractor and (2) any act or omission to act on the part of the Government in respect of which a request is made for equitable adjustment.

(b) Whenever the Contractor requests or proposes an equitable adjustment of $100,000 or more per vessel in respect to a change made pursuant to a written order designated as a "change order" or in respect to a proposed engineering change and whenever the Contractor requests an equitable adjustment in any amount in respect to any other act or omission to act on the part of the Government, the proposal supporting such request shall contain the following information for each individual item or element of the request:

(1) A description (i) of the work required by the contract before the change, which has been deleted by the change, and (ii) of the work deleted by the change which already has been completed. The description is to include a list of components, equipment, and other identifiable property involved. Also, the status of manufacture, procurement, or installation of such property is to be indicated. Separate description is to be furnished for design and production work.

Items of raw material, purchased parts, components and other identifiable hardware, which are made excess by the change and which are not to be retained by the Contractor, are to be listed for later disposition;

(2) Description of work necessary to undo work already completed which has been deleted by the change;

(3) Description of work not required by the terms hereof before the change, which is substituted or added by the change. A list of components and equipment (not bulk materials or items) involved should be included. Separate descriptions are to be furnished for design work and production work;

(4) Description of interference and inefficiencies in performing the change;

(5) Description of each element of disruption and exactly how work has been, or will be disrupted:

(i) The calendar period of time during which disruption occurred, or will occur;

(ii) Area(s) aboard the vessel where disruption occurred, or will occur;

(iii) Trade(s) disrupted, with a breakdown of manhours for each trade;

(iv) Scheduling of trades before, during, and after period of disruption;

(v) Description of measures taken to lessen the disruptive effect of the change;

(6) Delay in delivery attributable solely to the change;

(7) Other work attributable to the change;

(8) Supplementing the foregoing, a narrative statement of the direct "causal" relationship between any alleged

Government act or omission and the claimed consequences therefor, cross-referenced to the detailed information provided as required above; and

(9) A statement setting forth a comparative enumeration of the amounts "budgeted" for the cost elements, including the material costs, labor hours and pertinent indirect costs, estimated by the Contractor in preparing its initial and ultimate proposal(s) for this contract, and the amounts claimed to have been incurred and/or projected to be incurred corresponding to each such "budgeted cost" elements.

(c) Each proposal in excess of $100,000 submitted in support of a claim for equitable adjustment under any requirement of this contract shall, in addition to the information required by paragraph (b) hereof, contain such information as the

Contracting Officer may require with respect to each individual claim item.

(d) It is recognized that individual claims for equitable adjustment may not include all of the factors listed in paragraph

(b) above. Accordingly, the Contractor is required to set forth in its proposal information only with respect to those factors which are comprehended in the individual claim for equitable adjustment. In any event, the information furnished hereunder shall be in sufficient detail to permit the Contracting Officer to cross-reference the claimed increased costs, or delay in delivery, or both, as appropriate, submitted pursuant to paragraph (c) of this requirement, with the information submitted pursuant to paragraph (b) hereof.

C-247-H001 PERMITS AND RESPONSIBILITIES (NAVSEA) (DEC 2018)

The Contractor shall, without additional expense to the Government, be responsible for obtaining any necessary licenses and permits for complying with any applicable Federal, State, and Municipal laws, codes, and regulations for shipping and transportation including, but not limited to, any movement over public highways of overweight/over dimensional materials.

Section D - Packaging and Marking

D-211-H001 PACKAGING OF DATA (NAVSEA) (OCT 2018)

Data to be delivered by Integrated Digital Environment (IDE) or other electronic media shall be as specified in the contract.

All unclassified data to be shipped shall be prepared for shipment in accordance with best commercial practice.

Classified reports, data, and documentation shall be prepared for shipment in accordance with National Industrial

Security Program Operating Manual (NISPOM), DOD 5220.22-M dated 28 February 2006 incorporating Change 2 dated 18 May 2016.

D-246-H002 WARRANTY NOTIFICATION FOR ITEM(S) 0001-0006—BASIC (NAVSEA) (OCT 2018)

The Contractor shall apply a permanent warranty notification stamping or marking on each warranted deliverable end item and its container. The notification shall be placed in close proximity to other required stamping or markings so as to be easily readable by personnel. The warranty notification shall read:

THIS ITEM WARRANTED UNDER CONTRACT TBD TO CONFORM TO DESIGN,

MANUFACTURING, AND PERFORMANCE REQUIREMENTS AND BE FREE FROM DEFECTS IN

MATERIAL AND WORKMANSHIP FOR 13 MONTHS FROM DATE OF ACCEPTANCE. IF ITEM IS

DEFECTIVE NOTIFY TPOC AND PCO.

D-247-H002 PACKAGING OF SUPPLIES—BASIC (NAVSEA) (DEC 2020)

Item(s) 0001-0006 The supplies furnished hereunder shall be packaged in accordance with ASTM-D-3951-18, Standard

Practice for Commercial Packing.

D-247-W001 PROHIBITED PACKING MATERIALS (NAVSEA) (OCT 2018)

The use of asbestos, excelsior, newspaper or shredded paper (all types including waxed paper, computer paper and similar hygroscopic or non-neutral material) is prohibited. In addition, the use of yellow wrapping or packaging material is prohibited except where used for the containment of radioactive material. Loose fill polystyrene is prohibited for shipboard use.

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

0002 Destination Government Destination Government

0003 Destination Government Destination Government

0004 Destination Government Destination Government

0005 Destination Government Destination Government

0006 Destination Government Destination Government

0007 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.246-16 Responsibility For Supplies APR 1984

E-246-H013 INSPECTION AND ACCEPTANCE OF DATA (NAVSEA) (OCT 2018)

Inspection and acceptance of all data shall be as specified on the attached Contract Data Requirements List(s), DD Form

1423.

E-246-H016 INSPECTION AND ACCEPTANCE OF F.O.B. DESTINATION DELIVERIES (NAVSEA) (OCT

2018)

Item(s) 0001-0006 - Inspection and acceptance shall be made at destination by a representative of the Government.

E-246-W002 CERTIFICATE OF COMPLIANCE (NAVSEA) (OCT 2018)

(a) A certification of material shall be provided by the Contractor, one (1) copy to accompany the shipment (in the packing list envelope) and (l) copy mailed to arrive at time of receipt of the shipment. Mark all certificates to the attention of Code 00Q.

(b) The certificate shall state compliance of material with drawing specification and contract/order requirements. The certificate shall as a minimum state the company name, contract/order number, drawing or specification number, and date. The certificate shall state, above the signature of a legally authorized representative of the company, the following:

This certification concerns a matter within the jurisdiction of an agency of the United States and the making of a false, fictitious, or fraudulent certification may render the maker subject to prosecution under Title 18, United

States Code, Section 1001.

(c) Failure to provide certification at the time of shipment may result in material being rejected and returned at the contractor's expense.

(d) The certificate shall read as follows:

I certify that on ______ [insert date], the ____ [insert Contractor’s name] furnished the supplies called for by the Order/Contract No._____ via ____ [Carrier] on ________ [identify the bill of lading or shipping document] in accordance with all applicable requirements. I further certify that the supplies or services are of the quality specified and conform in all respects with the contract requirements, including specifications, drawings, preservation, packaging, packing, marking requirements, and physical item identification (part number), and are in the quantity shown on this document.

Date of Execution: ________________________________

Signature: _______________________________________

Typed Name: ____________________________________

Title: ___________________________________________

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 01-SEP-2021 2 NAVAL SURFACE WARFARE CENTER

PHILA

CHRIS SHAFFER

NSWC PHILADELPHIA DIVISION

NSLC DETACHMENT

1601 LANGLEY AVE BLDG 542

PHILADELPHIA PA 19112

215-897-3067

N64498

0002 01-SEP-2021 5 (SAME AS PREVIOUS LOCATION)

0003 01-SEP-2021 5 (SAME AS PREVIOUS LOCATION)

0004 01-SEP-2021 3 (SAME AS PREVIOUS LOCATION)

0005 01-SEP-2021 5 (SAME AS PREVIOUS LOCATION)

0006 01-SEP-2021 5 (SAME AS PREVIOUS LOCATION)

0007 N/A N/A N/A N/A

52.211-17 Delivery of Excess Quantities SEP 1989

52.242-15 Stop-Work Order AUG 1989

52.242-17 Government Delay Of Work APR 1984

F-247-H001 DELIVERY OF DATA (NAVSEA) (OCT 2018)

All data to be furnished under this contract shall be delivered prepaid to the destination(s) and at the time(s) specified on the Contract Data Requirements List(s), DD Form 1423.

Section G - Contract Administration Data

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) Definitions. As used in this clause—

“Department of Defense Activity Address Code (DoDAAC)” is a six position code that uniquely identifies a unit, activity, or organization.

“Document type” means the type of payment request or receiving report available for creation in Wide Area

WorkFlow (WAWF).

“Local processing office (LPO)” is the office responsible for payment certification when payment certification is done external to the entitlement system.

“Payment request” and “receiving report” are defined in the clause at 252.232-7003, Electronic Submission of

Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-

7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall—

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training

Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data

Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items— https://www.sam.gov/ https://wawf.eb.mil/ https://wawf.eb.mil/

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting

Officer.

COMBO

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the

Contracting Officer.

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC N64500

Issue By DoDAAC N64498

Admin DoDAAC** N64498

Inspect By DoDAAC N64498

Ship To Code N64498

Ship From Code ____

Mark For Code ____

Service Approver (DoDAAC) ____

Service Acceptor (DoDAAC) ____

Accept at Other DoDAAC ____

LPO DoDAAC ____

DCAA Auditor DoDAAC ____

Other DoDAAC(s) ____

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition

Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity’s

WAWF point of contact.

Kimberly Villano

Kimberly.villano@navy.mil

215-897-2433

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

G-232-H002 PAYMENT INSTRUCTIONS AND CONTRACT TYPE SUMMARY FOR PAYMENT

OFFICE (NAVSEA) (JUN 2018)

(a) The following table of payment office allocation methods applies to the extent indicated.

mailto:Kimberly.villano@navy.mil

For Government Use Only

Contract/Order Payment

Clause

Type of Payment

Request

S u p p ly

S er v ic e

C o n st ru ct io n

Payment Office

Allocation Method

52.212-4 (Alt I), Contract

Terms and Conditions—

Commercial Items

52.216-7, Allowable Cost and Payment

52.232-7, Payments under

Time-and-Materials and

Labor-Hour Contracts

Cost Voucher X X N/A Line item specific proration. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated in the same proportion as the amount of funding currently unliquidated for each

ACRN on the deliverable line or deliverable subline item for which payment is requested.

52.232-1, Payments Navy

Shipbuilding

Invoice (Fixed

Price)

X N/A N/A Line Item specific by fiscal year. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated using the oldest funds. In the event of a deliverable line or deliverable subline item with two ACRNs with the same fiscal year, those amounts will be prorated to the available unliquidated funds for that year.

52.232-1, Payments;

52.232-2, Payments under

Fixed-Price Research and

Development Contracts;

52.232-3, Payments under

Personal Services Contracts;

52.232-4, Payments under

Transportation Contracts and

Transportation-Related

Services Contracts; and

52.232-6, Payments under

Communication Service

Contracts with Common

Carriers

Invoice X X N/A Line Item Specific proration. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated in the same proportion as the amount of funding currently unliquidated for each

ACRN on the deliverable line or deliverable subline item for which payment is requested.

Contract/Order Payment

Clause

Type of Payment

Request

S u p p ly

S er v ic e

C o n st ru ct io n

Payment Office

Allocation Method

52.232-5, Payments Under

Fixed-Price Construction

Contracts

Construction

Payment Invoice

N/A N/A X Line Item specific by fiscal year. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated using the oldest funds. In the event of a deliverable line or deliverable subline item with two ACRNs with the same fiscal year, those amounts will be prorated to the available unliquidated funds for that year.

52.232-16, Progress

Payments

Progress

Payment*

X X N/A Contract-wide proration. Funds shall be allocated in the same proportion as the amount of funding currently unliquidated for each ACRN. Progress Payments are considered contract level financing, and the “contract price” shall reflect the fixed price portion of the contract per FAR

32.501-3.

52.232-29, Terms for

Financing of Purchases of

Commercial Items;

52.232-30, Installment

Payments for Commercial

Items

Commercial Item

Financing*

X X N/A Specified in approved payment. The contracting officer shall specify the amount to be paid and the account(s) to be charged for each payment approval in accordance with FAR 32.207(b)(2) and

32.1007(b)(2).

52.232-32, Performance-

Based Payments

Performance-

Based Payments*

X X N/A Specified in approved payment. The contracting officer shall specify the amount to be paid and the account(s) to be charged for each payment approval in accordance with FAR 32.207(b)(2) and

32.1007(b)(2).

252.232-7002, Progress

Payments for Foreign

Military Sales Acquisitions

Progress

Payment*

X X N/A Allocate costs among line items and countries in a manner acceptable to the

Administrative Contracting Officer.

*Liquidation of Financing Payments. Liquidation will be applied by the payment office against those ACRNs which are identified by the payment instructions for the delivery payment and in keeping with the liquidation provision of the applicable contract financing clause (i.e., progress payment, performance-based payment, or commercial item financing).

(b) This procurement contains the following contract type(s):

FP – Fixed Price

G-232-H005 SUPPLEMENTAL INSTRUCTIONS REGARDING INVOICING (NAVSEA) (JAN 2019)

(a) For other than firm fixed priced contract line item numbers (CLINs), the Contractor agrees to segregate costs incurred under this contract/task order (TO), as applicable, at the lowest level of performance, either at the sub line item number (SLIN) or CLIN level, rather than at the total contract/TO level, and to submit invoices reflecting costs incurred at that level. Supporting documentation in Wide Area Workflow (WAWF) for invoices shall include summaries of work charged during the period covered as well as overall cumulative summaries by individual labor categories, rates, and hours (both straight time and overtime) invoiced; as well as, a cost breakdown of other direct costs (ODCs), materials, and travel, by technical instruction (TI), SLIN, or CLIN level. For other than firm fixed price subcontracts, subcontractors are also required to provide labor categories, rates, and hours (both straight time and overtime) invoiced; as well as, a cost breakdown of ODCs, materials, and travel invoiced. Supporting documentation may be encrypted before submission to the prime contractor for WAWF invoice submittal.

Subcontractors may email encryption code information directly to the Contracting Officer and Contracting Officer

Representative (COR). Should the subcontractor lack encryption capability, the subcontractor may also email detailed supporting cost information directly to the Contracting Officer and COR; or other method as agreed to by the Contracting Officer.

(b) Contractors submitting payment requests and receiving reports to WAWF using either Electronic Data

Interchange (EDI) or Secure File Transfer Protocol (SFTP) shall separately send an email notification to the COR and Contracting Officer on the same date they submit the invoice in WAWF. No payments shall be due if the contractor does not provide the COR and Contracting Officer email notification as required herein.

G-242-H001 GOVERNMENT CONTRACT ADMINISTRATION POINTS-OF-CONTACT AND

RESPONSIBILITIES (NAVSEA) (OCT 2018)

(a) The Government reserves the right to administratively substitute any of the points of contact listed below at any time.

(b) The contracting officer is the only person authorized to change this contract or orders issued thereunder. The Contractor shall not comply with any order, direction or request of Government personnel

- that would constitute a change - unless it is issued in writing and signed by the Contracting Officer or is pursuant to specific authority otherwise included as part of this contract. If, in the opinion of the contractor, an effort outside the existing scope of this contract is requested, the contractor shall promptly comply with the Notification of Changes clause of this contract.

(c) The points of contact are as follows:

(i) The Procuring Contracting Officer (PCO) is:

Jillian Randazzo

Contract Specialist

Naval Sea Systems Command (NAVSEA)

Naval Surface Warfare Center Philadelphia Division

5001 South Broad Street

Philadelphia, PA 19112-5083

Phone: 215-897-2235

Cell: 267-990-6035

Email: jillian.randazzo@navy.mil

(ii) The Contract Specialist is:

Shawn Waters

Contract Specialist

Naval Sea Systems Command (NAVSEA)

Naval Surface Warfare Center Philadelphia Division

5001 South Broad Street

Philadelphia, PA 19112-5083

Phone: 215-897-1828

Cell: 267-990-6169

Email: shawn.m.waters@navy.mil

(iii) The Administrative Contracting Officer (ACO) is:

n/a

(d) The Contracting Officer’s Representative (COR) is the contracting officer’s appointed representative for technical matters. The COR is not a contracting officer and does not have the authority to direct the accomplishment of effort which is beyond the scope of the contract or to otherwise change any contract requirements. An informational copy of the COR appointment letter, which provides a delineation of COR authority and responsibilities, will be provided upon award of this contract.

The Contracting Officer’s Representative (COR) is:

(e) The Alternate Contracting Officer’s Representative (ACOR) is responsible for COR responsibilities and functions in the event that the COR is unavailable due to leave, illness, or other official business. The ACOR is appointed by the contracting officer; a copy of the ACOR appointment will be provided upon award of this contract.

The Alternate Contracting Officer’s Representative (ACOR) is:

(f) The Technical Point of Contact (TPOC) is the contracting officer’s representative for technical matters when a COR is not appointed. The TPOC is responsible for technical issues of contract administration, such as providing all items of Government Furnished Information (GFI), Government Furnished Material

(GFM) and Government Furnished Equipment (GFE) if specified in the contract as well as the inspection and acceptance of all contract deliverables.

The Technical Point of Contact (TPOC) is:

TBD

(g) The Alternate Technical Point of Contact (ATPOC) is responsible for TPOC responsibilities and functions in the event that the TPOC is unavailable due to leave, illness, or other official business.

The Alternate Technical Point of Contact (ATPOC) is:

(h) The Ombudsman will review complaints from the contractors and ensure that all contractors are afforded a fair opportunity to be considered, consistent with the procedures in the contract.

The Ombudsman is:

(i) The Authorized Ordering Person(s) for Per-Call Maintenance is responsible for issuing and maintaining records for any per-call orders for remedial maintenance placed under this contract. No per-call order shall be placed outside the scope of this contract and the cumulative total of all orders shall not be in excess of any not-to-exceed amount specified in the contract. Per-call orders shall not, in any way, modify any terms and conditions of the contract.

(j) The Authorized Ordering Person(s) for Per-Call Maintenance is:

(k) The Contractor's point of contact for performance under this contract is:

Name: [ * ]

Title: [ * ]

Address:

[ *Street ]

[ *City, State, Zip ]

Phone: (Area Code) xxx- [xxxx]; FAX: (Area Code) xxx- [xxxx]

E-mail: [ * ]

[ * ] To be completed at contract award

G-242-H002 HOURS OF OPERATION AND HOLIDAY SCHEDULE (NAVSEA) (OCT 2018)

(a) The policy of this activity is to schedule periods of reduced operations or shutdown during holiday periods.

Deliveries will not be accepted on Saturdays, Sundays or Holidays except as specifically requested by the [insert activity name]. All goods or services attempted to be delivered on a Saturday, Sunday or Holiday without specific instructions from the Contracting Officer or his duly appointed representative will be returned to the contractor at the contractor’s expense with no cost or liability to the U.S. Government.

(b) The federal Government observes the following holidays:

HOLIDAYS*

New Year's Day

Martin Luther King's Birthday

Presidential Inauguration Day (Washington DC metro area only)

President's Day

Memorial Day

Independence Day

Labor Day

Columbus Day

Veteran's Day

Thanksgiving Day

Christmas Day

* Except for the Presidential Inauguration Day, if the actual date falls on a Saturday, the holiday will be observed the preceding Friday. If the holiday falls on a Sunday, the observance shall be on the following Monday.

The actual date of observance for each of the above holidays, for a specific calendar year, may be obtained from the

OPM website at OPM.GOV or by using the following direct link: https://www.opm.gov/policy-data-oversight/snow-dismissal-procedures/federal-holidays/#url.

(c) Delayed Opening, Early Dismissal and Closure of Government Facilities. When a Government facility has a delayed opening, is closed or Federal employees are dismissed early (due to severe weather, security threat, security exercise, or a facility related problem) that prevents personnel from working, onsite contractor personnel regularly assigned to work at that facility shall follow the same reporting and/or departure directions given to Government personnel. The contractor shall not direct charge to the contract for such time off, but shall follow parent company policies regarding taking leave (administrative or other). Non-essential contractor personnel, who are not required to remain at or report to the facility, shall follow their parent company policy regarding whether they should go/stay home or report to another company facility. Subsequent to an early dismissal, delayed opening, or during periods of inclement weather, onsite contractors should monitor the OPM website as well as radio and television announcements before departing for work to determine if the facility is closed or operating on a delayed arrival basis.

(d) When Federal employees are excused from work due to a holiday or a special event (that is unrelated to severe weather, a security threat, or a facility related problem), on site contractors shall continue working established work hours or take leave in accordance with parent company policy. Those contractor employees who take leave shall not direct charge the non-working hours to the contract. Contractors are responsible for predetermining and disclosing their charging practices for early dismissal, delayed openings, or closings in accordance with the FAR, applicable cost accounting standards, and the company’s established policy and procedures. Contractors shall follow their disclosed charging practices during the contract period of performance, and shall not follow any verbal directions to the contrary. The Contracting Officer will make the determination of cost allowability for time lost due to facility closure in accordance with FAR, applicable Cost Accounting Standards, and the Contractor's established accounting policy and procedures.

(e) If you intend to visit the Contracts Office, it is advised that you call for an appointment at least 24 hours in advance.

(f) The hours of operation are as follows:

AREA FROM TO

NSWCPD 0800 1500

(g) All deliveries to the Receiving Officer, Building 542; 1601 Langley Ave Philadelphia, PA 19112, shall be made

Monday through Friday from 0800 to 1500, local time. Deliveries will not be accepted after 1500. No deliveries will be accepted on federal government holidays.

G-242-W001 CONTRACT ADMINISTRATION FUNCTIONS (NAVSEA) (OCT 2018)

(a) In accordance with FAR 42.302(a) all functions listed are delegated to the ACO except the following items to be retained by the PCO:

https://www.opm.gov/policy-data-oversight/snow-dismissal-procedures/federal-holidays/#url https://www.opm.gov/policy-data-oversight/snow-dismissal-procedures/federal-holidays/#url

All functins retained by PCO

(b) In accordance with FAR 42.302(b), the following additional functions are delegated to the ACO:

All functins retained by PCO

Section I - Contract Clauses

52.204-2 Security Requirements MAR 2021

52.204-13 System for Award Management Maintenance OCT 2018

52.204-18 Commercial and Government Entity Code Maintenance AUG 2020

52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-10 Prohibition on Contracting With Inverted Domestic

Corporations

NOV 2015

52.211-5 Material Requirements AUG 2000

52.219-4 (Dev) Notice of Price Evaluation Preference for HUBZone Small

Business Concerns (DEVIATION 2020-O0008)

MAR 2020

52.222-19 (Dev) Child Labor - Cooperation with Authorities and Remedies

(DEVIATION 2020-O0019)

JUL 2020

52.222-51 Exemption from Application of the Service Contract Labor

Standards to Contracts for Maintenance, Calibration, or

Repair of Certain Equipment--Requirements

MAY 2014

52.222-53 Exemption from Application of the Service Contract Labor

Standards to Contracts for Certain Services--Requirements

MAY 2014

52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

JUN 2020

52.227-1 Authorization and Consent JUN 2020

52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

JUN 2020

52.232-23…