N5523619Q0156.pdf

SOUTHWEST REGIONAL MAINTENANCE CENTER

STEVE HARRINGTON

USS PEARL HARBOR (LSD-52) 401 W 8TH STREET

SWRMC MAC-MO SHIPPING/RECEVING

US NAVAL STATION BLDG 31

NATIONAL CITY CA 91950

TEL: (619) 556-1746 FAX:

N5523619Q0156PR

REQUEST FOR QUOTATIONS

(THIS IS NOT AN ORDER) 1

PAGE OF PAGES

1. REQUEST NO. 2. DATE ISSUED RATING

N5523619Q0156 23-Sep-2019 5a. ISSUED BY

8. TO: NAME AND ADDRESS, INCLUDING ZIP CODE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this

Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State, and local taxes)

ITEM NO.

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e) (f)

SEE SCHEDULE

AMOUNT

% No. %

NOTE: Additional provisions and representations [ ] are [ ] are not attached.

13. NAME AND ADDRESS OF QUOTER (Street, City, County, State, and ZIP Code)

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

15. DATE OF

QUOTATION

16. NAME AND TITLE OF SIGNER (Type or print) (Include area code)

TELEPHONE NO.

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 18 (REV. 6-95)

PREVIOUS EDITION NOT USABLE Prescribed by GSA FAR (48 CFR) 53.215-1(a)

THIS RFQ X[ ] IS [ ] IS NOT A SMALL BUSINESS SET-ASIDE

6. DELIVER BY (Date)

SEE SCHEDULE

AND/OR DMS REG. 1

UNDER BDSA REG. 2

4. CERT. FOR NAT. DEF.3. REQUISITION/PURCHASE

REQUEST NO.

SOUTHWEST REGIONAL MAINTENANCE CENTER

CODE 410B 3755 BRINSER STREET, STE 1

SAN DIEGO CA 92136-5205

9. DESTINATION (Consignee and address, including ZIP Code)

7. DELIVERY

[ ]X FOB

DESTINATION

[ ] OTHER

(See Schedule)

26-Sep-2019(Date)

PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS:10.

(619)-556-2978MYLES K GASALAO

(Name and Telephone no.) (No collect calls)5b. FOR INFORMATION CALL:

d. CALENDAR DAYSc. 30 CALENDAR DAYSb. 20 CALENDAR DAYS12. DISCOUNT FOR PROMPT PAYMENT a. 10 CALENDAR DAYS

N5523619Q0156

Section A - Solicitation/Contract Form

CLOSING DATE AND TIME

The closing date and time for the subject solicitation is: 26 September 2019, 09:00AM (PST).

THE SUBJECT SOLICITATION WILL BE PROCESSED UNDER FAR PART 13.

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

CLIN

Number

1 Each

USS PEARL HARBOR (LSD-52) LLTM

FFP

Vendor shall provide 2,200 square feet of aluminum deck extruded, 6005-T5, MIL- G-18015A, Type II, 10-1/4 inch wide by 1-1/2 inch deep with punched upset punch 11/32 inch square holes 11/16 inch apart or 6061-T6 MIL-G-18015A, punched upset punch 11/32 inch square holes 11/16 inch apart in accordance with Section C contained herein. Shipping Charges included.

FOB: Destination

MFR PART NR: 6055-T5 MIL-G-18015A

PURCHASE REQUEST NUMBER: N5523619Q0156PR

ADDITIONAL MARKINGS: POC: Steve Harrington (619)-556-1746

PSC CD: 2090

NET AMT

Section C - Descriptions and Specifications

PRODUCT DESCRIPTION

1. Statement of Need and Purpose:

SWRMC Code 300 requires procurement and delivery of 2,200 square feet of aluminum deck grating, extruded, 6005-T5, MIL-G-18015A, Type II, 10-1/4 inch wide by 1-1/2 inch deep with punched upset punch 11/32 inch square holes 11/16 inch apart or 6061-T6 MIL-G-18015A, punched upset punch 11/32 inch square holes 11/16 inch apart for the USS PEARL HARBOR (LSD-52).

2. Required Delivery Date:

31 January 2020

3. Required Delivery Location:

Southwest Regional Maintenance Center (SWRMC) Attn: Steve Harrington, Project Manager, Code 330 USS Pearl Harbor (LSD-52) SWRMC MAC-MO Shipping/Receiving US Naval Station Bldg 3155-BAY17 401 W 8th Street National City, CA 91950

(619) 556-1746

4. Packaging Instructions:

Required Delivery Location/POC shall be annotated on the shipment information above.

CLAUSES INCORPORATED BY FULL TEXT

C-202-H001 ADDITIONAL DEFINITIONS–BASIC (NAVSEA) (OCT 2018)

(a) Department - means the Department of the Navy.

(b) Commander, Naval Sea Systems Command - means the Commander of the Naval Sea Systems Command of the Department of the Navy or his duly appointed successor.

(c) References to The Federal Acquisition Regulation (FAR) - All references to the FAR in this contract shall be deemed to also reference the appropriate sections of the Defense FAR Supplement (DFARS), unless clearly indicated otherwise.

(d) National Stock Numbers - Whenever the term Federal Item Identification Number and its acronym FIIN or the term Federal Stock Number and its acronym FSN appear in the contract, order or their cited specifications and standards, the terms and acronyms shall be interpreted as National Item Identification Number (NIIN) and National Stock Number (NSN) respectively which shall be defined as follows:

(1) National Item Identification Number (NIIN). The number assigned to each approved Item Identification under the Federal Cataloging Program. It consists of nine numeric characters, the first two of which are the National Codification Bureau (NCB) Code. The remaining positions consist of a seven digit non-significant number.

(2) National Stock Number (NSN). The National Stock Number (NSN) for an item of supply consists of the applicable four-position Federal Supply Class (FSC) plus the applicable nine-position NIIN assigned to the item of supply.

(End of text)

C-211-H016 SPECIFICATIONS AND STANDARDS (NAVSEA) (OCT 2018)

(a) Definitions.

(i) A "zero-tier reference" is a specification, standard, or drawing that is cited in the contract (including its attachments).

(ii) A "first-tier reference" is either: (1) a specification, standard, or drawing cited in a zero-tier reference, or (2) a specification cited in a first-tier drawing.

(b) Requirements. All zero-tier and first-tier references, as defined above, are mandatory for use. All lower tier references shall be used for guidance only unless specifically identified below.

None

C-211-H017 UPDATING SPECIFICATIONS AND STANDARDS (NAVSEA) (DEC 2018)

The contractor may request that this contract be updated to include the current version of the applicable specification or standard if the update does not affect the form, fit or function of any deliverable item or increase the cost/price of the item to the Government. The contractor should submit update requests to the Procuring Contracting Officer with copies to the Administrative Contracting Officer and cognizant program office representative for approval. The contractor shall perform the contract in accordance with the existing specifications and standards until notified of approval/disapproval of its request to update by the Procuring Contracting Officer. Any approved alternate specifications or standards will be incorporated into the contract.

C-211-H018 APPROVAL BY THE GOVERNMENT (NAVSEA) (JAN 2019)

Approval by the Government as required under this contract and applicable specifications shall not relieve the Contractor of its obligation to comply with the specifications and with all other requirements of the contract, nor shall it impose upon the Government any liability it would not have had in the absence of such approval.

Section D - Packaging and Marking

D-211-H005 IDENTIFICATION MARKING OF PARTS – ALTERNATE I (NAVSEA) (OCT 2018)

(a) For all parts not subject to the marking requirements in DFARS 252.211-7003 – Item Unique Identification and Valuation, marking shall be accomplished in accordance with the following:

(1) Parts not manufactured to Government specifications shall be marked in accordance with generally accepted commercial practice.

(2) Parts manufactured to Government specifications shall be marked as follows:

(i) Electrical Parts - that is, all parts in electrical equipment and electrical parts when used in equipment which are not electrical in nature (e.g., electric controls and motors in a hydraulic system) - shall be identified and marked in accordance with MIL-STD-1285D(2) dated 22 June 2018, or, where MIL-STD-1285D(2) does not cover such a part, in accordance with MIL-STD-130N(1) dated 16 November 2012. Requirements of MIL-STD-1686C dated 25 October 1995 for Electrostatic Discharge Control shall be addressed.

(ii) Electronic Parts - that is, all parts in electronic equipment and electronic parts when used in equipment which are not electronic in nature (e.g., electronic fuel controls in some engines) - shall be identified and marked in accordance with Requirement 67 of MIL-HDBK-454B dated 15 April 2007 with Notice 1 dated 12 December 2012. Requirements of MIL-STD-1686C for Electrostatic Discharge Control shall be addressed.

(iii) Parts other than electrical or electronic parts (as described above) shall be identified and marked in accordance with MIL-STD-130N(1).

(b) In cases where parts are so small as not to permit identification marking as provided above, such parts shall be appropriately coded so as to permit ready identification.

(End of Text)

D-246-H003 WARRANTY NOTIFICATION FOR ITEM(S) 0001—ALTERNATE I (NAVSEA) (MAY 2019)

The Contractor shall apply a permanent warranty notification stamping or marking on each warranted deliverable end item and its container in accordance with MIL-STD-129R with Change 1 dated 24 May 2018 and MIL-STD- 130N(1) dated 16 November 2012. The notification shall be placed in close proximity to other required stamping or markings so as to be easily readable by personnel. The warranty notification shall read:

THIS ITEM WARRANTED UNDER CONTRACT N55236-19-______ TO CONFORM TO DESIGN,

MANUFACTURING, AND PERFORMANCE REQUIREMENTS AND BE FREE FROM DEFECTS IN

MATERIAL AND WORKMANSHIP FOR 90 DAYS FROM DATE OF ACCEPTANCE. IF ITEM IS

DEFECTIVE NOTIFY CONTRACTOR AND PCO.

(End of Text)

D-247-H005 MARKING AND PACKING LIST(S) – ALTERNATE I (NAVSEA) (OCT 2018)

(a) Marking. Shipments, shipping containers and palletized unit loads shall be marked in accordance with MIL- STD-129R with Change 1 dated 24 May 2018.

(b) Packing List(s). A packing list (DD Form 250 Material Inspection and Receiving Report may be used) identifying the contents of each shipment, shipping container or palletized unit load shall be provided by the Contractor with each shipment in accordance with the above cited MIL-STD. When a contract line item identified under a single stock number includes an assortment of related items such as kit or set components, detached parts or accessories, installation hardware or material, the packing list(s) shall identify the assorted items.

Where DD Form 1348-1 or DD Form 1348-1A is applicable and an assortment of related items is included in the shipping container, a packing list identifying the contents shall be furnished.

(c) Master Packing List. In addition to the requirements in paragraph (b) above, a master packing list shall be prepared where more than one shipment, shipping container or palletized unit load comprise the contract line item being shipped. The master packing list shall be attached to the number one container and so identified.

(d) Part Identification. All items within the kit, set, installation hardware or material shall be suitably segregated and identified within the unit pack(s) or shipping container by part number and/or national stock number. Refer to the above cited MIL-STD for marking of assorted (related-unrelated) items.

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.246-2 Inspection Of Supplies--Fixed Price AUG 1996

E-246-H016 INSPECTION AND ACCEPTANCE OF F.O.B. DESTINATION DELIVERIES (NAVSEA) (OCT 2018)

Item(s) 0001 - Inspection and acceptance shall be made at destination by a representative of the Government.

E-246-H022 INSPECTION AND TEST RECORDS NAVSEA JAN 2019

Inspection and test records shall, as a minimum, indicate the nature of the observations, number of observations made, and the number and type of deficiencies found. Data included in inspection and test records shall be complete and accurate, and shall be used for trend analysis and to assess corrective action and effectiveness. The data shall, on request, be identified and made available for on-site review by the Contracting Officer or designated Government representative.

End of text

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 31-JAN-2020 1 SOUTHWEST REGIONAL MAINTENANCE

CENTER

STEVE HARRINGTON

USS PEARL HARBOR (LSD-52) 401 W 8TH

STREET

SWRMC MAC-MO SHIPPING/RECEVING

US NAVAL STATION BLDG 31

NATIONAL CITY CA 91950

(619) 556-1746 FOB: Destination

N55236

52.242-15 Stop-Work Order AUG 1989 52.242-17 Government Delay Of Work APR 1984 52.247-34 F.O.B. Destination NOV 1991 52.247-48 F.O.B. Destination--Evidence Of Shipment FEB 1999

F-242-H001 CONTRACTOR NOTICE REGARDING LATE DELIVERY (NAVSEA) (OCT 2018)

In the event the contractor anticipates or encounters difficulty in complying with the contract delivery schedule or date, the contractor shall immediately notify, in writing, the Contracting Officer and the cognizant Contract Administration Services Office, if assigned. The notice shall give the pertinent details; however, such notice shall not constitute a waiver by the Government of any contract delivery schedule, or of any rights or remedies provided by law or under this contract.

Section G - Contract Administration Data

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) Definitions. As used in this clause—

“Department of Defense Activity Address Code (DoDAAC)” is a six position code that uniquely identifies a unit, activity, or organization.

“Document type” means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

“Local processing office (LPO)” is the office responsible for payment certification when payment certification is done external to the entitlement system.

“Payment request” and “receiving report” are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232- 7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall—

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items—

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

Inspection: Destination – N55262 Acceptance: Destination – N55262

Invoice and Receiving Report Combo (FFP Supply)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

Inspection: Destination – N55262 Acceptance: Destination – N55262

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

[Note: The Contractor may use a WAWF “combo” document type to create some combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC N68732 Issue By DoDAAC N55262

Admin DoDAAC N55262 Inspect By DoDAAC N55262 Ship To Code N55262 Ship From Code N/A Mark For Code N/A Service Approver (DoDAAC) N55262 Service Acceptor (DoDAAC) N55262 Accept at Other DoDAAC N/A LPO DoDAAC N55262 DCAA Auditor DoDAAC TBD Other DoDAAC(s) N/A

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

Steve Harrington , (619) 556-1746, email: steven.harrington@navy.mil

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

SWRMC WAWF POC: Mr. Charles Pierce, (619)556-2291, e-mail: charles.w.pierce1@navy.mil

SWRMC WAWF ACCEPTOR: Steve Harrington , (619) 556-1746, email: steven.harrington@navy.mil

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

(End of clause)

G-232-H002 PAYMENT INSTRUCTIONS AND CONTRACT TYPE SUMMARY FOR PAYMENT

OFFICE (NAVSEA) (JUN 2018)

(a) The following table of payment office allocation methods applies to the extent indicated.

For Government Use Only

Contract/Order Payment Clause

Type of Payment Request

Su pp ly

Se rv ic e

C on st ru ct io n

Payment Office Allocation Method

52.212-4 (Alt I), Contract Terms and Conditions— Commercial Items 52.216-7, Allowable Cost and Payment 52.232-7, Payments under Time-and-Materials and Labor-Hour Contracts

Cost Voucher X X N/A Line item specific proration. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated in the same proportion as the amount of funding currently unliquidated for each ACRN on the deliverable line or deliverable subline item for which payment is requested.

52.232-1, Payments Navy Shipbuilding Invoice (Fixed Price)

X N/A N/A Line Item specific by fiscal year. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated using the oldest funds. In the event of a deliverable line or deliverable subline item with two ACRNs with the same fiscal year, those amounts will be prorated to the available unliquidated funds for that year.

52.232-1, Payments;

52.232-2, Payments under Fixed-Price Research and Development Contracts;

52.232-3, Payments under Personal Services Contracts;

52.232-4, Payments under Transportation Contracts and Transportation-Related Services Contracts; and 52.232-6, Payments under Communication Service Contracts with Common Carriers

Invoice X X N/A Line Item Specific proration. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated in the same proportion as the amount of funding currently unliquidated for each ACRN on the deliverable line or deliverable subline item for which payment is requested.

Contract/Order Payment Clause

Type of Payment Request

Su pp ly

Se rv ic e

C on st ru ct io n

Payment Office Allocation Method

52.232-5, Payments Under Fixed-Price Construction Contracts

Construction Payment Invoice

N/A N/A X Line Item specific by fiscal year. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated using the oldest funds. In the event of a deliverable line or deliverable subline item with two ACRNs with the same fiscal year, those amounts will be prorated to the available unliquidated funds for that year.

52.232-16, Progress Payments

Progress Payment*

X X N/A Contract-wide proration. Funds shall be allocated in the same proportion as the amount of funding currently unliquidated for each ACRN. Progress Payments are considered contract level financing, and the “contract price” shall reflect the fixed price portion of the contract per FAR 32.501-3.

52.232-29, Terms for Financing of Purchases of Commercial Items;

52.232-30, Installment Payments for Commercial Items

Commercial Item Financing*

X X N/A Specified in approved payment. The contracting officer shall specify the amount to be paid and the account(s) to be charged for each payment approval in accordance with FAR 32.207(b)(2) and 32.1007(b)(2).

52.232-32, Performance- Based Payments

Performance- Based Payments*

X X N/A Specified in approved payment. The contracting officer shall specify the amount to be paid and the account(s) to be charged for each payment approval in accordance with FAR 32.207(b)(2) and 32.1007(b)(2).

252.232-7002, Progress Payments for Foreign Military Sales Acquisitions

Progress Payment*

X X N/A Allocate costs among line items and countries in a manner acceptable to the Administrative Contracting Officer.

*Liquidation of Financing Payments. Liquidation will be applied by the payment office against those ACRNs which are identified by the payment instructions for the delivery payment and in keeping with the liquidation provision of the applicable contract financing clause (i.e., progress payment, performance-based payment, or commercial item financing).

(b) This procurement contains the following contract type(s):

Item Type*

CLIN 0001 FP

*FP – Fixed Price

G-242-H001 GOVERNMENT CONTRACT ADMINISTRATION POINTS-OF-CONTACT AND

RESPONSIBILITIES (NAVSEA) (OCT 2018)

a) The Government reserves the right to administratively substitute any of the points of contact listed below at any time.

1. The contracting officer is the only person authorized to change this contract or orders issued thereunder. The Contractor shall not comply with any order, direction or request of Government personnel - that would constitute a change - unless it is issued in writing and signed by the Contracting Officer or is pursuant to specific authority otherwise included as part of this contract. If, in the opinion of the contractor, an effort outside the existing scope of this contract is requested, the contractor shall promptly comply with the Notification of Changes clause of this contract.

2. The points of contact are as follows:

i. The Procuring Contracting Officer (PCO) is:

Roderick Rioveros 3755 Brinser Street San Diego, CA 92136

(619) 556-2309 roderick.rioveros@navy.mil

ii. The Contract Specialist is:

Myles Gasalao

San Diego, CA 92136

(619) 556-2978 Myles.gasalao@navy.ml

3. The Technical Point of Contact (TPOC) is the contracting officer’s representative for technical matters when a COR is not appointed. The TPOC is responsible for technical issues of contract administration, such as providing all items of Government Furnished Information (GFI), Government Furnished Material (GFM) and Government Furnished Equipment (GFE) if specified in the contract as well as the inspection and acceptance of all contract deliverables.

i. The Technical Point of Contact (TPOC) is:

Steven Harrington SWRMC Code 330 steven.harrington@navy.mil

(619) 556-2632

b) The Contractor's point of contact for performance under this contract is:

Roderick Rioveros

San Diego, CA 92136

(619) 556-2309 roderick.rioveros@navy.mil

G-242-H002 HOURS OF OPERATION AND HOLIDAY SCHEDULE (NAVSEA) (OCT 2018)

(a) The policy of this activity is to schedule periods of reduced operations or shutdown during holiday periods.

Deliveries will not be accepted on Saturdays, Sundays or Holidays except as specifically requested by the Southwest Regional Maintenance Center. All goods or services attempted to be delivered on a Saturday, Sunday or Holiday without specific instructions from the Contracting Officer or his duly appointed representative will be returned to the contractor at the contractor’s expense with no cost or liability to the U.S. Government.

(b) The federal Government observes the following holidays:

HOLIDAYS*

New Year's Day Martin Luther King's Birthday Presidential Inauguration Day (Washington DC metro area only) President's Day Memorial Day Independence Day Labor Day Columbus Day Veteran's Day Thanksgiving Day Christmas Day

* Except for the Presidential Inauguration Day, if the actual date falls on a Saturday, the holiday will be observed the preceding Friday. If the holiday falls on a Sunday, the observance shall be on the following Monday.

The actual date of observance for each of the above holidays, for a specific calendar year, may be obtained from the OPM website at OPM.GOV or by using the following direct link: https://www.opm.gov/policy-data-oversight/snow-dismissal-procedures/federal-holidays/#url.

(c) Delayed Opening, Early Dismissal and Closure of Government Facilities. When a Government facility has a delayed opening, is closed or Federal employees are dismissed early (due to severe weather, security threat, security exercise, or a facility related problem) that prevents personnel from working, onsite contractor personnel regularly assigned to work at that facility shall follow the same reporting and/or departure directions given to Government personnel. The contractor shall not direct charge to the contract for such time off, but shall follow parent company policies regarding taking leave (administrative or other). Non-essential contractor personnel, who are not required to remain at or report to the facility, shall follow their parent company policy regarding whether they should go/stay home or report to another company facility. Subsequent to an early dismissal, delayed opening, or during periods of inclement weather, onsite contractors should monitor the OPM website as well as radio and television announcements before departing for work to determine if the facility is closed or operating on a delayed arrival basis.

(d) When Federal employees are excused from work due to a holiday or a special event (that is unrelated to severe weather, a security threat, or a facility related problem), on site contractors shall continue working established work hours or take leave in accordance with parent company policy. Those contractor employees who take leave shall not direct charge the non-working hours to the contract. Contractors are responsible for predetermining and disclosing their charging practices for early dismissal, delayed openings, or closings in accordance with the FAR, applicable cost accounting standards, and the company’s established policy and procedures. Contractors shall follow their disclosed charging practices during the contract period of performance, and shall not follow any verbal directions to the contrary. The Contracting Officer will make the determination of cost allowability for time lost due to facility closure in accordance with FAR, applicable Cost Accounting Standards, and the Contractor's established accounting policy and procedures.

(e) If you intend to visit the Contracts Office, it is advised that you call for an appointment at least 24 hours in advance.

(f) The hours of operation are as follows:

AREA FROM TO

SWRMC MAC-MO SHIPPING 0700 1500

US NAVAL STATION BLDG 31

NATIONAL CITY CA 91950

(g) All deliveries to the Receiving Officer, shall be made Monday through Friday from 0700 to 1500 , local time.

Deliveries will not be accepted after 1500. No deliveries will be accepted on federal government holidays.

Section I - Contract Clauses

52.203-19 Prohibition on Requiring Certain Internal Confidentiality

Agreements or Statements

JAN 2017

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law

FEB 2016

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.243-1 Changes--Fixed Price AUG 1987 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7009 Limitations on the Use or Disclosure of Third-Party Contractor Reported Cyber Incident Information

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

OCT 2016

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.225-7001 Buy American And Balance Of Payments Program-- Basic DEC 2017 252.225-7002 Qualifying Country Sources As Subcontractors DEC 2017 252.225-7048 Export-Controlled Items JUN 2013 252.232-7010 Levies on Contract Payments DEC 2006 252.247-7023 Transportation of Supplies by Sea APR 2014

52.213-4 TERMS AND CONDITIONS--SIMPLIFIED ACQUISITIONS (OTHER THAN COMMERCIAL

ITEMS) (AUG 2019).

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(iii) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (AUG 2019) (Section 889(a)(1)(A) of Pub. L. 115-232).

(iv) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

(v) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(vi) 52.222-26, Equal Opportunity (SEPT 2016) (E.O. 11246).

(vii) 52.225-13, Restrictions on Certain Foreign Purchases (JUN 2008) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(viii) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(ix) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78 (19 U.S.C. 3805 note).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (APR 1984).

(ii) 52.232-8, Discounts for Prompt Payment (FEB 2002).

(iii) 52.232-11, Extras (APR 1984).

(iv) 52.232-25, Prompt Payment (JAN 2017).

(v) 52.232-39, Unenforceability of Unauthorized Obligations (JUN 2013).

(vi) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (DEC 2013).

(vii) 52.233-1, Disputes (MAY 2014).

(viii) 52.244-6, Subcontracts for Commercial Items (AUG 2019).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (MAR 2016) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)).

(b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2018) (Pub. L. 109-282) (31 U.S.C. 6101 note) (Applies to contracts valued at $30,000 or more).

(ii) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (Jan 2018) (E.O. 13126). (Applies to contracts for supplies exceeding the micro-purchase threshold).

(iii) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment Exceeding $15,000 (MAY 2014) (41 U.S.C. chapter 65) (Applies to supply contracts over $15,000 in the United States, Puerto Rico, or the U.S. Virgin Islands).

(iv) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212) (applies to contracts of $150,000 or more).

(v) 52.222-36, Equal Employment for Workers with Disabilities (JUL 2014) (29 U.S.C. 793) (Applies to contracts over $15,000, unless the work is to be performed outside the United States by employees recruited outside the United States). (For purposes of this clause, ``United States'' includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.)

(vi) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212) (Applies to contracts of $150,000 or more).

(vii) 52.222-41, Service Contract Labor Standards (AUG 2018) (41 U.S.C. chapter 67) (Applies to service contracts over $2,500 that are subject to the Service Contract Labor Standards statute and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S.

Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf).

(viii)(A) 52.222-50, Combating Trafficking in Persons (JAN 2019) (22 U.S.C. chapter 78 and E.O. 13627) (Applies to all solicitations and contracts).

(B) Alternate I (MAR 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (DEC 2015) (Executive Order 13658) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)).

(x) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia.))

(xi) 52.223-5, Pollution Prevention and Right-to-Know Information (MAY 2011) (E.O. 13423) (Applies to services performed on Federal facilities).

(xii) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (June, 2016) (E.O. 13693)(applies to contracts for products as prescribed at FAR 23.804(a)(1)).

(xiii) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (June, 2016) (E.O. 13693) (Applies to maintenance, service, repair, or disposal of refrigeration equipment and air conditioners).

(xiv) 52.223-15, Energy Efficiency in Energy-Consuming Products (DEC 2007) (42 U.S.C. 8259b) (Unless exempt pursuant to 23.204, applies to contracts when energy-consuming products listed in the ENERGY STAR ® Program or Federal Energy Management Program (FEMP) will be--

(A) Delivered;

(B) Acquired by the Contractor for use in performing services at a Federally-controlled facility;

(C) Furnished by the Contractor for use by the Government; or

(D) Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance).

(xv) 52.223-20, Aerosols (June, 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons as a propellant or as a solvent; or contracts for maintenance or repair of electronic or mechanical devices).

(xvi) 52.223-21, Foams (June, 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent;

or contracts for construction of buildings or facilities.

(xvii) 52.225-1, Buy American--Supplies (MAY 2014) (41 U.S.C. chapter 67) (Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold and the acquisition--

(A) Is set aside for small business concerns; or

(B) Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $25,000).

(xviii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (MAY 2014) (42 U.S.C. 1792) (Applies to contracts greater than $25,000 that provide for the provision, the service, or the sale of food in the United States).

(xix) 52.232-33, Payment by Electronic Funds Transfer--System for Award Management (OCT 2018) (Applies when the payment will be made by electronic funds transfer (EFT) and the payment office uses the System for Award Management (SAM) as its source of EFT information.)

(xx) 52.232-34, Payment by Electronic Funds Transfer--Other than System for Award Management (JUL 2013) (Applies when the payment will be made by EFT and the payment office does not use the SAM database as its source of EFT information.)

(xxi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (FEB 2006) (46 U.S.C. App. 1241) (Applies to supplies transported by ocean vessels (except for the types of subcontracts listed at 47.504(d).)

(2) Listed below are additional clauses that may apply:

(i) 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (June, 2016) (Applies to contracts when the contractor or a subcontractor at any tier may have Federal contract information residing in or transiting through its information system.

(ii) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Oct 2015) (Applies to contracts over $35,000).

(iii) 52.211-17, Delivery of Excess Quantities (SEP 1989) (Applies to fixed-price supplies).

(iv) 52.247-29, F.o.b. Origin (FEB 2006) (Applies to supplies if delivery is f.o.b. origin).

(v) 52.247-34, F.o.b. Destination (NOV 1991) (Applies to supplies if delivery is f.o.b. destination).

(c) FAR 52.252-2, Clauses Incorporated by Reference (FEB 1998). This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

FAR at http://www.arnet.gov/far DFARS at http://www.acq.osd.mil/dp/dars/dfars.html

(d) Inspection/Acceptance. The Contractor shall tender for acceptance only those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. The Government must exercise its postacceptance rights--

(1) Within a reasonable period of time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(e) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(f) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges that the Contractor can demonstrate to the satisfaction of the Government, using its standard record keeping system, have resulted from the termination.

The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred that reasonably could have been avoided.

(g) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(h) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JULY 2013)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The

Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code - assigned to contract number .

(Contractor to sign and date and insert authorized signer's name and title).

52.223-11 OZONE-DEPLETING SUBSTANCES AND HIGH GLOBAL WARMING POTENTIAL

HYDROFLUOROCARBONS (JUN 2016)

(a) Definitions. As used in this clause--

Global warming potential means how much a given mass of a chemical contributes to global warming over a given time period compared to the same mass of carbon dioxide. Carbon dioxide's global warming potential is defined as 1.0.

High global warming potential hydrofluorocarbons means any hydrofluorocarbons in a particular end use for which EPA's Significant New Alternatives Policy (SNAP) program has identified other acceptable alternatives that have lower global warming potential. The SNAP list of alternatives is found at 40 CFR part 82, subpart G, with supplemental tables of alternatives available at (http://www.epa.gov/snap/).

Hydrofluorocarbons means compounds that only contain hydrogen, fluorine, and carbon.

Ozone-depleting substance means any substance the Environmental Protection Agency designates in 40 CFR part 82 as--

(1) Class I, including, but not limited to, chlorofluorocarbons, halons, carbon tetrachloride, and methyl chloroform;

or

(2) Class II, including, but not limited to, hydrochlorofluorocarbons.

(b) The Contractor shall label products that contain or are manufactured with ozone-depleting substances in the manner and to the extent required by 42 U.S.C. 7671j (b), (c), (d), and (e) and 40 CFR part 82, subpart E, as follows:

Warning: Contains (or manufactured with, if applicable) *_______, a substance(s) which harm(s) public health and environment by destroying ozone in the upper atmosphere.

* The Contractor shall insert the name of the substance(s).

(c) Reporting. For equipment and appliances that normally each contain 50 or more pounds of hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons, the Contractor shall--

(1) Track on an annual basis, between October 1 and September 30, the amount in pounds of hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons contained in the equipment and appliances delivered to the Government under this contract by--

(i) Type of hydrofluorocarbon (e.g., HFC-134a, HFC-125, R-410A, R-404A, etc.);

(ii) Contract number; and

(iii) Equipment/appliance;

(2) Report that information to the Contracting Officer for FY16 and to www.sam.gov, for FY17 and after--

(i) Annually by November 30 of each year during contract performance; and

(ii) At the end of contract performance.

(d) The Contractor shall refer to EPA's SNAP program (available at http://www.epa.gov/snap) to identify alternatives. The SNAP list of alternatives is found at 40 CFR part 82, subpart G, with supplemental tables available at http://www.epa.gov/snap.

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any…