N3904019R0007.pdf

CODE

(Hour)

PAGE(S)

until 05:00 PM local time 01 May 2019

X

A X B X C X D

EX

X

G F 38 - 42

43 - 44 X H michael.l.mccluskey1@navy.mil

RATING PAGE OF PAGES

7. ISSUED BY

(Date)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

Previous Edition is Unusable 33-134 STANDARD FORM 33 (REV. 9-97)

Prescribed by GSA FAR (48 CFR) 53.214(c)

1 44

(If other than Item 7)

15A. NAME 16. NAME AND TITLE OF PERSON AUTHORIZED TO

AND

ADDRESS

SIGN OFFER (Type or print)

OF

OFFEROR

AMENDMENT NO. DATE

15B. TELEPHONE NO (Include area code) 17. SIGNATURE15C. CHECK IF REMITTANCE ADDRESS

IS DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

18. OFFER DATE

1. THIS CONTRACT IS A RATED ORDER

UNDER DPAS (15 CFR 700)

2. CONTRACT NO.

N39040 8. ADDRESS OFFER TO

See Item 7

9. Sealed offers in original and 1 copies for furnishing the supplies or services in the Schedule will be received at the place specified in Item 8, or if handcarried, in the depository located in

CAUTION - LATE Submissions, Modifications, and Withdrawals: See Section L, Provision No. 52.214-7 or 52.215-1. All offers are subject to all terms and

Building 156, PNS, Kittery,ME conditions contained in this solicitation.

10. FOR INFORMATION

CALL:

A. NAME (NO COLLECT CALLS)

MICHAEL L MCCLUSKEY 207-438-6819

11. TABLE OF CONTENTS

SOLICITATION/ CONTRACT FORM

SUPPLIES OR SERVICES AND PRICES/ COSTS

2 - 3

X I CONTRACT CLAUSES

DESCRIPTION/ SPECS./ WORK STATEMENT

PACKAGING AND MARKING

4 - 15

J LIST OF ATTACHMENTS

INSPECTION AND ACCEPTANCE

DELIVERIES OR PERFORMANCE

17 - 18

X K

REPRESENTATIONS, CERTIFICATIONS AND

OTHER STATEMENTS OF OFFERORS

CONTRACT ADMINISTRATION DATA 20 - 27 X

SPECIAL CONTRACT REQUIREMENTS

OFFER (Must be fully completed by offeror) 28 - 30 M

L INSTRS., CONDS., AND NOTICES TO OFFERORS

EVALUATION FACTORS FOR AWARD

NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause No. 52.232-8)

14. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments

AMENDMENT NO. DATE

to the SOLICITATION for offerors and related documents numbered and dated):

FACILITY

12. In compliance with the above, the undersigned agrees, if this offer is accepted within calendar days (60 calendar days unless a different period

SOLICITATION, OFFER AND AWARD

X

(X) SEC. DESCRIPTION (X) SEC. DESCRIPTION PAGE(S)

PART I - THE SCHEDULE

26. NAME OF CONTRACTING OFFICER (Type or print) 27. UNITED STATES OF AMERICA 28. AWARD DATE

EMAIL:TEL: (Signature of Contracting Officer)

CODE CODE

B. TELEPHONE (Include area code) C. E-MAIL ADDRESS

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION:

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c)( ) (4 copies unless otherwise specified)

23. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

24. ADMINISTERED BY (If other than Item 7) CODE 25. PAYMENT WILL BE MADE BY CODE

PART IV - REPRESENTATIONS AND INSTRUCTIONS

PART III - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

31 - 37

PART II - CONTRACT CLAUSES

PORTSMOUTH NAVAL SHIPYARD

CODE 410

KITTERY ME 03904

207-438-5253

FAX:

TEL:

FAX:

TEL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SOLICITATION

6. REQUISITION/PURCHASE NO.

N3904019RC90370

5. DATE ISSUED

18 Apr 2019

4. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

[ X ]

3. SOLICITATION NO.

N3904019R0007

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job CO/H2 Field Service

FFP

Field Services for the installation and repair work of the CO/H2 Scrubber and Burner system on a Los-Angeles Class Submarine in accordance with Statement of Work in Section C.

NOTE: The requirements in DFARS 252.211-7003, Item Identification and Valuation, are applicable for this line item. The contractor shall provide DoD unique identification or a DoD recognized unique identification equivalent.

FOB: Destination

MILSTRIP: N3904019RC90370

PURCHASE REQUEST NUMBER: N3904019RC90370

NET AMT

0002 1 Job CO/H2 Material

FFP

Material cost for the installation and repair of the CO/H2 Scrubber and Burner system of a Los-Angeles class Submarine in accordance with the Statement of Work in Section C NOTE: The requirements in DFARS 252.211-7003, Item Identification and Valuation, are applicable for this line item. The contractor shall provide DoD unique identification or a DoD recognized unique identification equivalent.

FOB: Destination

NET AMT

0003 1 Job CO/H2 Travel Expenses

COST

Travel Expenses for work of CLIN 0001. Two trips to include the transportation, lodging, meals, and incidental expenses in accordance with FAR 31.205-46 Travel Costs and Joint Travel Regulations (JTR) FOB: Destination

ESTIMATED COST

CLAUSES INCORPORATED BY FULL TEXT

B-231-H001 TRAVEL COSTS (NAVSEA) (OCT 2018)

(a) Except as otherwise provided herein, the Contractor shall be reimbursed for its actual travel costs in accordance with FAR 31.205-46. The travel costs to be reimbursed shall be those costs for which the Contractor has maintained appropriate documentation and which have been determined to be allowable, allocable, and reasonable by the Procuring Contracting Officer, Administrative Contracting Officer, or their duly authorized representative.

(b) Reimbursable travel costs include only that travel performed from the Contractor's facility to the worksite, in and around the worksite, and from the worksite to the Contractor's facility.

(c) Relocation costs and travel costs incidental to relocation are allowable to the extent provided in FAR 31.205-35;

however, Procuring Contracting Officer approval shall be required prior to incurring relocation expenses and travel costs incidental to relocation.

(d) The Contractor shall not be reimbursed for the following daily local travel costs:

(i) travel at U.S. Military Installations where Government transportation is available,

(ii) travel performed for personal convenience/errands, including commuting to and from work, and

(iii) travel costs incurred in the replacement of personnel when such replacement is accomplished for the Contractor's or employee's convenience.

(End of text)

Section C - Descriptions and Specifications

C

Performance Work Statement

References.

Installation shall be in accordance with Scrubber NAVSEA Technical Manual S9515-AK-MMO-010 & Burner

Technical Manual NAVSEA S9515-AS-MMM-010.

Based on inspections accomplished by CEPEDA Associates and the repair recommendations by SUBMEPP, the work specified below is to be accomplished on the SSN 751 USS San Juan Scrubber/Burners at New London Connecticut by CEPEDA Associates.

Description Scrubber

# 1 Scrubber

# 2 Scrubber Material- new unless otherwise noted

Boiler Assembly- Refurbished-21312-EA01-4815 X X Heat Exchanger X X

Level Sensors X X

Level Control Cables X X

Level Control Units X X Control Panel Master Switches X X Heater Box- Refurbished X X Absorber Packing X X 5hp Motor- Refurbished with NEW Pulley X X Absorber Level Gages X X Flex Hoses X X CO2 Flow Meters X X Ground Straps X X V-12 X N/A Compressor- 21312-EA01-4802 X X 3hp Motor and MEA Pump- Refurbished- 21312-EA01-4832 X X Machinery Mounts MEA and Comp Bed X X

Burner Material- new unless otherwise noted Burner #1 Burner #2 Refurbished Bypass Ducts X X Refurbished 2hp Motors X X Refurbished Heater Boxes X X Replace Wire #3 in Control Panel- 21312-EE01-6985 & 6986 X X

Work and Repair Criteria

Shipboard installation and repair work shall be in accordance with Scrubber Technical Manual NAVSEA S9515- AK-MMO-010& RI 5320-012-0668, Burner Technical Manual NAVSEA S9515-AS-MMM-010 & RI 5320-021- 0658. Shipboard testing shall be in accordance with HME tests 532-5228 CO2 Removal System Simulated Operation and 532-5208 CO/H2 Burner (Mark IV-E) Operational Test. Shop repair accomplished at CEPEDA Associates in Louisville, Kentucky, shall be in accordance with SUBMEPP Refurbishment Instruction No. 5320- 012-0657 & 5320-012-0656.

Shipment of Material

The contractor, CEPEDA Associates, will transport all “A” & “F” condition material required for shipboard repair to the work site.

Security Requirements

All contractor personnel must be US citizens of good standing, able to obtain security clearances required to work in the ship's Engine Room at the applicable shipyard.

At a minimum, all personnel providing services related to this order shall be United States citizens and shall possess a Department of Defense final-adjudicated Personal Security Clearance at the secret level, in accordance with DD Form 254 for performance on this requirement. Failure of ability of a worker or supervisor to obtain a shipyard badge (i.e. minimum final secret clearance) will be cause for the shipyard to refuse acceptance of individual.

Contractors shall have DBIDS credentials for access to Subbase New London. Contractors and any subcontractors shall submit contract DD-254 to the applicable Shipyard’s Security Department for access requirement verification prior to arrival.

Contractors/subcontractors shall submit Visit Requests via the Joint Personnel Adjudication System (JPAS) for visitor clearance verification. Visit requests submitted by other means will not be accepted without Facility Security Officer signed verification as to the level of security clearance granted to each employee on the visit request.

C-202-H001 ADDITIONAL DEFINITIONS–BASIC (NAVSEA) (OCT 2018)

(a) Department - means the Department of the Navy.

(b) Commander, Naval Sea Systems Command - means the Commander of the Naval Sea Systems Command of the Department of the Navy or his duly appointed successor.

(c) References to The Federal Acquisition Regulation (FAR) - All references to the FAR in this contract shall be deemed to also reference the appropriate sections of the Defense FAR Supplement (DFARS), unless clearly indicated otherwise.

(d) National Stock Numbers - Whenever the term Federal Item Identification Number and its acronym FIIN or the term Federal Stock Number and its acronym FSN appear in the contract, order or their cited specifications and standards, the terms and acronyms shall be interpreted as National Item Identification Number (NIIN) and National Stock Number (NSN) respectively which shall be defined as follows:

(1) National Item Identification Number (NIIN). The number assigned to each approved Item Identification under the Federal Cataloging Program. It consists of nine numeric characters, the first two of which are the National Codification Bureau (NCB) Code. The remaining positions consist of a seven digit non-significant number.

(2) National Stock Number (NSN). The National Stock Number (NSN) for an item of supply consists of the applicable four-position Federal Supply Class (FSC) plus the applicable nine-position NIIN assigned to the item of supply.

C-204-H001 USE OF NAVY SUPPORT CONTRACTORS FOR OFFICIAL CONTRACT FILES (NAVSEA)

(OCT 2018)

(a) NAVSEA may use a file room management support contractor, hereinafter referred to as "the support contractor", to manage its file room, in which all official contract files, including the official file supporting this procurement, are retained. These official files may contain information that is considered a trade secret, proprietary, business sensitive or otherwise protected pursuant to law or regulation, hereinafter referred to as “protected information”. File room management services consist of any of the following: secretarial or clerical support; data entry; document reproduction, scanning, imaging, or destruction; operation, management, or maintenance of paper-based or electronic mail rooms, file rooms, or libraries; and supervision in connection with functions listed herein.

(b) The cognizant Contracting Officer will ensure that any NAVSEA contract under which these file room management services are acquired will contain a requirement that:

(1) The support contractor not disclose any information;

(2) Individual employees are to be instructed by the support contractor regarding the sensitivity of the official contract files;

(3) The support contractor performing these services be barred from providing any other supplies and/or services, or competing to do so, to NAVSEA for the period of performance of its contract and for an additional three years thereafter unless otherwise provided by law or regulation; and,

(4) In addition to any other rights the contractor may have, it is a third party beneficiary who has the right of direct action against the support contractor, or any person to whom the support contractor has released or disclosed protected information, for the unauthorized duplication, release, or disclosure of such protected information.

(c) Execution of this contract by the contractor is considered consent to NAVSEA's permitting access to any information, irrespective of restrictive markings or the nature of the information submitted, by its file room management support contractor for the limited purpose of executing its file room support contract responsibilities.

(d) NAVSEA may, without further notice, enter into contracts with other contractors for these services. Contractors should enter into separate non-disclosure agreements with the file room contractor. Contact the Procuring Contracting Officer for contractor specifics. However, any such agreement will not be considered a prerequisite before information submitted is stored in the file room or otherwise encumber the government.

C-211-H001 ACCESS TO THE VESSEL(S) (NAVSEA) (OCT 2018)

Officers, employees and associates of other prime Contractors with the Government and their subcontractors, shall, as authorized by the Supervisor, have, at all reasonable times, admission to the plant, access to the vessel(s) where and as required, and be permitted, within the plant and on the vessel(s) required, to perform and fulfill their respective obligations to the Government. The Contractor shall make reasonable arrangements with the Government or Contractors of the Government, as shall have been identified and authorized by the Supervisor to be given admission to the plant and access to the vessel(s) for office space, work areas, storage or shop areas, or other facilities and services, necessary for the performance of the respective responsibilities involved, and reasonable to their performance.

C-211-H016 SPECIFICATIONS AND STANDARDS (NAVSEA) (OCT 2018)

(a) Definitions.

(i) A "zero-tier reference" is a specification, standard, or drawing that is cited in the contract (including its attachments).

(ii) A "first-tier reference" is either: (1) a specification, standard, or drawing cited in a zero-tier reference, or (2) a specification cited in a first-tier drawing.

(b) Requirements. All zero-tier and first-tier references, as defined above, are mandatory for use. All lower tier references shall be used for guidance only unless specifically identified below.

None

C-211-H017 UPDATING SPECIFICATIONS AND STANDARDS (NAVSEA) (DEC 2018)

The contractor may request that this contract be updated to include the current version of the applicable specification or standard if the update does not affect the form, fit or function of any deliverable item or increase the cost/price of the item to the Government. The contractor should submit update requests to the Procuring Contracting Officer with copies to the Administrative Contracting Officer and cognizant program office representative for approval. The contractor shall perform the contract in accordance with the existing specifications and standards until notified of approval/disapproval of its request to update by the Procuring Contracting Officer. Any approved alternate specifications or standards will be incorporated into the contract.

C-211-H018 APPROVAL BY THE GOVERNMENT (NAVSEA) (JAN 2019)

Approval by the Government as required under this contract and applicable specifications shall not relieve the Contractor of its obligation to comply with the specifications and with all other requirements of the contract, nor shall it impose upon the Government any liability it would not have had in the absence of such approval.

C-222-H001 ACCESS TO THE VESSELS BY NON-U.S. CITIZENS (NAVSEA) (OCT 2018)

(a) No person not known to be a U.S. citizen shall be eligible for access to naval vessels, work sites and adjacent areas when said vessels are under construction, conversion, overhaul, or repair, except upon a finding by COMNAVSEA or his designated representative that such access should be permitted in the best interest of the United States. The Contractor shall establish procedures to comply with this requirement and NAVSEAINST

5510.3 ( ).

(b) If the Contractor desires to employ non-U.S. citizens in the performance of work under this contract or agreement that requires access as specified in paragraph (a) of this requirement, approval must be obtained prior to access for each contract or agreement where such access is required. To request such approval for non-U.S. citizens of friendly countries, the Contractor shall submit to the cognizant Contract Administration Office (CAO), an Access Control Plan (ACP) which shall contain as a minimum, the following information:

(1) Badge or Pass oriented identification, access, and movement control system for non-U.S. citizen employees with the badge or pass to be worn or displayed on outer garments at all times while on the Contractor's facilities and when performing work aboard ship.

(i) Badges must be of such design and appearance that permits easy recognition to facilitate quick and positive identification.

(ii) Access authorization and limitations for the bearer must be clearly established and in accordance with applicable security regulations and instructions.

(iii) A control system, which provides rigid accountability procedures for handling lost, damaged, forgotten or no longer required badges, must be established.

(iv) A badge or pass check must be performed at all points of entry to the Contractor's facilities or by a site supervisor for work performed on vessels outside the Contractor's plant.

(2) Contractor's plan for ascertaining citizenship and for screening employees for security risk.

(3) Data reflecting the number, nationality, and positions held by non-U.S. citizen employees, including procedures to update data as non-U.S. citizen employee data changes, and pass to cognizant CAO.

(4) Contractor's plan for ensuring subcontractor compliance with the provisions of the Contractor's ACP.

(5) These conditions and controls are intended to serve as guidelines representing the minimum requirements of an acceptable ACP. They are not meant to restrict the Contractor in any way from imposing additional controls necessary to tailor these requirements to a specific facility.

(c) To request approval for non-U.S. citizens of hostile and/or communist-controlled countries (listed in Department of Defense Industrial Security Manual, DOD 5220.22-M or available from cognizant CAO), Contractor shall include in the ACP the following employee data: name, place of birth, citizenship (if different from place of birth), date of entry to U.S., extenuating circumstances (if any) concerning immigration to U.S., number of years employed by Contractor, position, and stated intent concerning U.S. citizenship. COMNAVSEA or his designated representative will make individual determinations for desirability of access for the above group. Approval of ACP's for access of non-U.S. citizens of friendly countries will not be delayed for approval of non-U.S. citizens of hostile communist-controlled countries. Until approval is received, Contractor must deny access to vessels for employees who are non- U.S. citizens of hostile and/or communist-controlled countries.

(d) The Contractor shall fully comply with approved ACPs. Noncompliance by the Contractor or subcontractor serves to cancel any authorization previously granted, in which case the Contractor shall be precluded from the continued use of non-U.S. citizens on this contract or agreement until such time as the compliance with an approved ACP is demonstrated and upon a determination by the CAO that the Government's interests are protected. Further, the Government reserves the right to cancel previously granted authority when such cancellation is determined to be in the Government's best interest. Use of non-U.S. citizens, without an approved ACP or when a previous authorization has been canceled, will be considered a violation of security regulations. Upon confirmation by the CAO of such violation, this contract, agreement or any job order issued under this agreement may be terminated or default in accordance with the clause entitled "Default (Fixed-Price Supply And Service)" (FAR 52.249-8), "Default (Fixed-Price Research And Development)" (FAR 52.249-9) or "Termination (Cost Reimbursement)" (FAR 52.249- 6), as applicable.

(e) Prime Contractors have full responsibility for the proper administration of the approved ACP for all work performed under this contract or agreement, regardless of the location of the vessel, and must ensure compliance by all subcontractors, technical representatives and other persons granted access to U.S. Navy vessels, adjacent areas, and work sites.

(f) In the event the Contractor does not intend to employ non-U.S. citizens in the performance of the work under this contract, but has non-U.S. citizen employees, such employees must be precluded from access to the vessel and its work site and those shops where work on the vessel's equipment is being performed. The ACP must spell out how non-U.S. citizens are excluded from access to contract work areas.

(g) The same restriction as in paragraph (f) above applies to other non-U.S. citizens who have access to the Contractor's facilities (e.g., for accomplishing facility improvements, from foreign crewed vessels within its facility, etc.) except that, with respect to access to the vessel and worksite, the restrictions shall not apply to uniformed U.S.

Navy personnel who are non-U.S. citizens and who are either assigned to the ship or require access to the ship to perform their duties.

C-223-H002 SAFETY, HEALTH AND FIRE REQUIREMENTS FOR SHIP REPAIR (NAVSEA) (JAN 2019)

(a) Attention of the Contractor is directed to the Occupational Safety and Health Act of 1970 (29 USC 651-678), and to the Safety and Health Regulations for Ship Repairing (29 CFR 1915), promulgated under Public Law 85-742, amending Section 41 of the Longshoremen's and Harbor Workers' Compensation Act (33 USC 941), and adopted by the Department of Labor as occupational safety or health standards under Section 6(a) of the Occupational Safety and Health Act of 1970 (See 29 CFR 1910.13). These regulations apply to all ship repair and related work, as defined in the regulations performed under this contract on the navigable waters of the United States including any dry dock and marine railway. Nothing contained in this contract shall be construed as relieving the Contractor from any obligations which it may have for compliance with the aforesaid regulations.

(b) SAFETY INSPECTOR/FIRE MARSHAL: In addition to the safety standards provided in the specifications, the contractor is responsible for providing an experienced Safety Inspector/Fire Marshal who will accomplish daily inspections of the Contractor's entire work area on the ship, together with the Contracting Office’s Safety Representative. This Inspector or Fire Marshal shall not be one of the Contractor's supervisors or superintendents normally assigned to the ship and shall be identified in the contractor’s approved Safety Plan.

(c) PERSONAL PROTECTIVE EQUIPMENT: Whenever work is performed aboard U.S. Naval Ships or vessels at piers or dry docks of a Naval Shipyard or Naval Station, Contractor employees (including management personnel) shall have and use at all times the following personal protective equipment:

(1) Protective hard hats that meet the following specifications:

(i) Protective helmets purchased after July 5, 1994 shall comply with ANSI Z89.1-1986, "American National Standard for Personnel Protection-Protective Headwear for Industrial Workers-Requirements," or shall be demonstrated by the Contractor to be equally effective.

(ii) Protective helmets purchased before July 5, 1994 shall comply with ANSI Standard "American National Standard Safety requirements for Industrial Head Protection," Z89.1-1969, or shall be demonstrated by the employer to be equally effective. [Ref. 29 CFR 1910.135 Head Protection]

(2) Approved type Plano or prescription glasses meeting the following specifications:

(i) Protective eye and face devices purchased after July 5, 1994 shall comply with ANSI standard Z87.1- 1989, "American National Standard Practice for Occupational and Educational Eye and Face Protection", or shall be demonstrated by the employer to be equally effective.

(ii) Protective eye and face devices purchased before July 5, 1994 shall comply with ANSI "USA standard for Occupational and Educational Eye and Face Protection", Z87.1-1968, or shall be demonstrated by the employer to be equally effective. [Ref. 29 CRF 1910.133 Protective eye and face devices.]

(3) Safety toe shoes, with built-in protective toe box that meet the following specifications:

(i) Protective footwear purchased after July 5, 1994 shall comply with ANSI Standard Z41-1991, "American National Standard for Personal Protection-Protective Footwear", or shall be demonstrated by the employer to be equally effective.

(ii) Protective footwear purchased before July 5, 1994 shall comply with the ANSI standard "USA Standard for Men's Safety Toe Footwear", Z41.1 1967, or shall be demonstrated by the employer to be equally effective [Ref. 29 CFR 1910.136 Protective eye and face devices.]

C-223-H003 EXCLUSION OF MERCURY (NAVSEA) (MAR 2019)

(a) Definitions. As used in this text:

Article means a manufactured item other than a fluid or particle: (i) which is formed to a specific shape or design during manufacture; (ii) which has end use function(s) dependent in whole or in part upon its shape or design during end use; and (iii) which under normal conditions of use does not release more than very small quantities, e.g., minute or trace amounts of a hazardous chemical, and does not pose a physical hazard or health risk to employees.

Boundary of containment means a continuous tight seal (barrier) to prevent the release of functional mercury during normal operation and maintenance. Examples include the exterior of a fluorescent lamp, glass capsule of a mercury switch, and container for mercury reagents. A double boundary of containment consists of two independent seals.

Functional mercury means mercury or mercury compound(s) contained in equipment that is required for the equipment to operate properly, such as that found in mercury switches, fluorescent lamps, flat-panel monitors, thermostats, thermostat probes, small coin type batteries, barometers, and dental amalgams.

Hardware means any article, container, piece of material, individual part, subassembly, assembly, component, or system to which mercury control requirements apply.

Mercury-free means hardware that does not contain functional mercury and is not contaminated by mercury or mercury compounds.

Portable means items that are frequently transported during normal operation. Desk lamps, shop lights, and hand-held instruments are considered portable, while bulbs in stationary light fixtures are not. In general, items that require transport only during maintenance, installation, and removal of the items are not considered portable.

(b) The Contractor, and all subcontractors and vendors, shall ensure that mercury or mercury containing compounds are not intentionally added to, or come in direct contact with, hardware or supplies furnished under this contract.

(1) The Contractor shall ensure that mercury and mercury compounds are not taken onboard naval vessels by Contractor, subcontractor, or vendor personnel except for functional mercury used in batteries, dental amalgams, fluorescent lamps, flat-panel monitors, required instruments, sensors or controls, weapon systems, and chemical analysis reagents specified by the Naval Sea Systems Command (NAVSEA).

(2) Portable fluorescent lamps and portable instruments containing elemental mercury must be shock-proof in accordance with MIL-DTL-901E entitled Requirements for Shock Tests, H.I. (High Impact) Shipboard Machinery, Equipment, and Systems and have mercury enclosed by a double boundary of containment. Some devices with liquid crystal display (LCD) screens utilize a fluorescent bulb backlight to illuminate the LCD screen.

No additional restrictions or controls apply to devices with LCD screens; however, the Contractor shall remove the LCD screen and seal it in plastic following any evidence that the backlight failed.

(3) For Submarines, any use of mercury containing items must be approved as required by the Nuclear Powered Submarine Atmosphere Control Manual (S9510-AB-ATM-010/U) Volume 1.

(4) The Contractor shall ensure that mercury and mercury compounds do not contact hardware surfaces in systems covered by NAVSEA Manual NAVSEA 0989-064-3000 entitled Cleanliness Requirements for Nuclear Propulsion Plant Maintenance and Construction, submarine air systems, level I systems per NAVSEA Publication 0948-LP-045-7010, NAVSEA Material Control Standard, or the submarine safety program (SUBSAFE) surfaces during maintenance or repair. Such hardware is designated as mercury-free. The Contractor shall ensure that all other hardware that could be structurally degraded by contamination with elemental mercury or reactive mercury compounds is separated from it by sufficient distance, or boundaries of containment that effectively prevents contact in all but the most extreme circumstances.

(5) The Contractor shall check any hardware surfaces in the above systems which are known or suspected to have come in contact with mercury or mercury compounds for evidence of structural degradation and external mercury contamination. The existence of external mercury contamination can be determined following MIL-STD-2041D entitled Control of Detrimental Materials.

(6) The presence of mercury in a product may be determined by checking product labeling on material safety data sheets or safety data sheets. Chemical analysis is not required.

(7) The Contractor shall dispose of any mercury and mercury compounds in accordance with OPNAV Manual (OPNAV M-5090.1) entitled Environmental Readiness Program Manual of 10 January 2014.

(8) If the use of mercury or mercury compounds cannot be avoided, a risk assessment and waiver request, if required, must be performed and submitted per the NAVSEA Hazardous Material Avoidance Process (T9070-AL- DPC-020/077-2). For systems covered by the NAVSEA Manual NAVSEA 0989-064-3000 entitled Cleanliness Requirements for Nuclear Propulsion Plant Maintenance and Construction, submit the risk assessment and waiver request, if required to Nuclear Propulsion (NAVSEA 08).

(c) In all cases where mercury or a mercury compound has contacted hardware surfaces required to be mercury-free the Contractor shall immediately provide a report to the NAVSEA Dry Environmental Systems and Hazardous Materials (NAVSEA 05P5) via the cognizant contract administration safety office. Reports concerning systems covered by NAVSEA Manual 0989-064-3000 must include NAVSEA Nuclear Propulsion Directorate (SEA 08) in the distribution. Reports must be in letter form and include the date and details of the contact, the surfaces contacted, the recovery actions taken, and the status of the affected surfaces.

(End of Text)

C-223-N002 RESTRICTIONS ON USE OF YELLOW MATERIAL (NAVSEA) (OCT 2018)

Yellow colored items are of special significance within the Shipyard and are subject to strict controls. Accordingly, contractors shall not use yellow or orange-yellow colored materials for the following purposes: protective clothing, hoods, sheeting, tarpaulins, polyethylene bottles or other containers, tapes, bags, banding, identification marks on tools, boundary markers, ribbons, vent ducts, etc. Contractor generated yellow colored waste shall be disposed of by the Contractor off-yard. Shipyard refuse containers shall not be used for disposal of yellow colored waste materials. Yellow colored contract generated debris shall be bagged in non-translucent containers, and promptly removed from the Shipyard.

C-223-W002 ON-SITE SAFETY REQUIREMENTS (NAVSEA) (OCT 2018)

(a) The contractor shall ensure that each contractor employee reads any necessary safety documents within 30 days of commencing performance at any Government facility. Required safety documents can be obtained from the respective safety office. Contractors shall notify the Safety office points of contact below to report completion of the required training via email. The email shall include the contractor employee’s name, work site, and contract number.

(b) It is expected that contractor employees will have received training from their employer on hazards associated with the areas in which they will be working and know what to do in order to protect themselves. Contractors are required to adhere to the requirements of 29 CFR 1910, 29 CFR 1926 and applicable state and local requirements while in Government spaces. The contractor shall ensure that all on-site contractor work at the Government facility is in accordance with any local safety instructions as provided via the COR. The contractor shall report all work-related injuries/illnesses that occurred while working at the Government site to the COR.

(c) Contractors whose employees perform work within Government spaces in excess of 1000 hours per calendar quarter during a calendar year shall submit the data elements on OSHA Form 300A, Summary of Work Related Injuries and Illnesses, for those employees to the safety office, via the COR by 15 January for the previous calendar year, even if no work related injuries or illnesses occurred. If a contractor’s injury/illness rates are above the Bureau of Labor Statistics industry standards, a safety assessment may be performed by the Safety Office to determine if any administrative or engineering controls can be utilized to prevent further injuries/illnesses, or if any additional Personal Protective Equipment or training will be required.

(d) Any contractor employee exhibiting unsafe behavior may be removed from the Government site. Such removal shall not relieve the contractor from meeting its contractual obligations and shall not be considered an excusable delay as defined in FAR 52.249-14.

(e) The Safety Office points of contacts are as follows:

Michael Fyrer, Code 106

C-228-H001 INDEMNIFICATION FOR ACCESS TO VESSEL (NAVSEA) (DEC 2018)

Notwithstanding any provision in the "Access to Vessel" clause (DFARS 252.217- 7011), or any other clause of the contract, the Contractor agrees to allow officers, employees, and associates of the Government, or other prime contractors with the Government and their subcontractors, and officers, employees, and associates of offerors on other contemplated work, admission to the Contractor's facilities and access to the vessel without any further request for indemnification from any party, which has not been previously included in the contract price.

C-228-H002 MINIMUM INSURANCE REQUIREMENTS (NAVSEA) (JAN 2019)

(a) In accordance with the clause(s) of this contract entitled "Insurance--Work On a Government Installation" (FAR 52.228-5) and “Liability and Insurance” (DFARS 252.217-7012), as applicable, the Contractor shall procure and maintain insurance, of at least the kinds and minimum amounts set forth below:

(i) Workers' compensation and employer’s liability coverage shall be at least $100,000, except as provided in FAR 28.307-2(a), if applicable

(ii) Bodily injury liability insurance coverage shall be written on the comprehensive form of policy of at least $500,000 per occurrence.

(iii) Automobile liability policies covering automobiles operated in the United States shall provide coverage of at least $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage. The amount of liability coverage on other policies shall be commensurate with any legal requirements of the locality and sufficient to meet normal and customary claims.

(b) To be approved by the Contracting Officer, insurance certificates must include the following cancellation policy statement: Prior to cancellation or material change in coverage, the contractor shall give 30 days written notice to the Contracting Officer.

(c) Physical work cannot begin until the insurance certificate has been approved by the Contracting Officer. Failure to provide an acceptable insurance certificate will not remove the contractor’s responsibility to meet the delivery requirements outlined in Section F and FAR 52.211-11, Liquidated Damages – Supplies, Services, or Research and Development, if applicable.

C-233-H001 DOCUMENTATION OF REQUESTS FOR EQUITABLE ADJUSTMENT--BASIC (NAVSEA) (OCT 2018)

(a) For the purposes of this special contract requirement, the term "change" includes not only a change that is made pursuant to a written order designated as a "change order" but also (1) an engineering change proposed by the Government or by the Contractor and (2) any act or omission to act on the part of the Government in respect of which a request is made for equitable adjustment.

(b) Whenever the Contractor requests or proposes an equitable adjustment of $100,000 or more per vessel in respect to a change made pursuant to a written order designated as a "change order" or in respect to a proposed engineering change and whenever the Contractor requests an equitable adjustment in any amount in respect to any other act or omission to act on the part of the Government, the proposal supporting such request shall contain the following information for each individual item or element of the request:

(1) A description (i) of the work required by the contract before the change, which has been deleted by the change, and (ii) of the work deleted by the change which already has been completed. The description is to include a list of components, equipment, and other identifiable property involved. Also, the status of manufacture, procurement, or installation of such property is to be indicated. Separate description is to be furnished for design and production work.

Items of raw material, purchased parts, components and other identifiable hardware, which are made excess by the change and which are not to be retained by the Contractor, are to be listed for later disposition;

(2) Description of work necessary to undo work already completed which has been deleted by the change;

(3) Description of work not required by the terms hereof before the change, which is substituted or added by the change. A list of components and equipment (not bulk materials or items) involved should be included. Separate descriptions are to be furnished for design work and production work;

(4) Description of interference and inefficiencies in performing the change;

(5) Description of each element of disruption and exactly how work has been, or will be disrupted:

(i) The calendar period of time during which disruption occurred, or will occur;

(ii) Area(s) aboard the vessel where disruption occurred, or will occur;

(iii) Trade(s) disrupted, with a breakdown of manhours for each trade;

(iv) Scheduling of trades before, during, and after period of disruption;

(v) Description of measures taken to lessen the disruptive effect of the change;

(6) Delay in delivery attributable solely to the change;

(7) Other work attributable to the change;

(8) Supplementing the foregoing, a narrative statement of the direct "causal" relationship between any alleged Government act or omission and the claimed consequences therefor, cross-referenced to the detailed information provided as required above; and

(9) A statement setting forth a comparative enumeration of the amounts "budgeted" for the cost elements, including the material costs, labor hours and pertinent indirect costs, estimated by the Contractor in preparing its initial and ultimate proposal(s) for this contract, and the amounts claimed to have been incurred and/or projected to be incurred corresponding to each such "budgeted cost" elements.

(c) Each proposal in excess of $100,000 submitted in support of a claim for equitable adjustment under any requirement of this contract shall, in addition to the information required by paragraph (b) hereof, contain such information as the Contracting Officer may require with respect to each individual claim item.

(d) It is recognized that individual claims for equitable adjustment may not include all of the factors listed in paragraph

(b) above. Accordingly, the Contractor is required to set forth in its proposal information only with respect to those factors which are comprehended in the individual claim for equitable adjustment. In any event, the information furnished hereunder shall be in sufficient detail to permit the Contracting Officer to cross-reference the claimed increased costs, or delay in delivery, or both, as appropriate, submitted pursuant to paragraph (c) of this requirement, with the information submitted pursuant to paragraph (b) hereof.

C-245-H007 REMOVAL AND SHIP OUT OF GOVERNMENT PROPERTY (NAVSEA) (OCT 2018)

The Contractor shall remove from the vessel and suitably pack for shipment those items of equipment specifically listed in the Inactivation Work Package, directly or by reference, for ship out to designated Government agencies.

The Government will ship such items of equipment on Government Bills of Lading (GBL). Scrap generated by other inactivation work shall remain Government property and, as such shall be shipped to Portsmouth Naval Shipyard as directed by the Government. Those items of equipment for which specific ship out directions are not provided shall be left installed on the vessel. Equipment removed to allow access for authorized removals shall be shipped to Portsmouth Naval Shipyard as directed by the Government.

C-247-H001 PERMITS AND RESPONSIBILITIES (NAVSEA) (DEC 2018)

The Contractor shall, without additional expense to the Government, be responsible for obtaining any necessary licenses and permits for complying with any applicable Federal, State, and Municipal laws, codes, and regulations for shipping and transportation including, but not limited to, any movement over public highways of overweight/over dimensional materials.

C-251-H001 ACCESS TO THE NAVY SUPPLY SYSTEM (NAVSEA) (OCT 2018)

(a) In compliance with the comparability requirement of 10 U.S.C. 7314, Public and Private Shipyards will be provided equal access to the Naval Supply System. Use by private yards is permissive, not mandatory.

(b) Pursuant to the clause of this contract entitled "Government Supply Sources" (FAR 52.251-1) the Contracting Officer hereby authorizes the Contractor to place orders with the Navy Supply System for materials and equipment or other supplies necessary to perform the required work. The Naval Supply System shall process such orders in the same manner as it would for any other Navy supply user, and the Contractor shall make payment on account of materials and equipment and other supplies ordered or received in accordance with the normal requirements of the Naval Supply Systems Command, but in no event shall payment in full be any later than 30 days after receipt by the Contractor of each order. The Contractor shall pay the Naval Supply System any costs for materials, equipment, or other supplies obtained including any surcharges normally charged to any other Naval Supply System user.

(c) This contract has been priced on the basis that, except as specifically provided elsewhere in this contract with regards to Government furnished property, the Contractor shall provide all necessary materials, equipment and supplies for performance of this contract. If the Contractor uses the Naval Supply System, it has elected to use the system for its own convenience to meet its contractual obligations to perform the work under this contract. The Naval Supply System is considered to be an alternate source or vendor of contractor furnished material; therefore, materials, equipment, or other supplies ordered or obtained from the Naval Supply System are specifically not considered to be Government furnished material, but are considered to be contractor furnished material. The Government makes no representation as to the availability of materials, equipment, or other supplies for the performance of the work required under this contract, nor shall unavailability, late delivery, delivery of non-conforming supplies, higher costs of the Naval Supply System (if any), or any failure of the Naval Supply System to meet the expectations or requirements of the Contractor constitute excusable delay or grounds for equitable or any other adjustment to the contract or relief from the requirement to perform in accordance with the terms of the contract.

Section D - Packaging and Marking

D-211-H004 IDENTIFICATION MARKING OF PARTS--BASIC (NAVSEA) (OCT 2018)

For all parts not subject to the marking requirements in DFARS 252.211-7003 – Item Unique Identification and Valuation, marking shall be accomplished in accordance with the following:

(1) Parts shall be marked in accordance with generally accepted commercial practice.

(2) In cases where parts are so small as not to permit identification marking as provided above, such parts shall be appropriately coded so as to permit ready identification.

D-247-H004 MARKING AND PACKING LIST(S) – BASIC (NAVSEA) (OCT 2018)

(a) Marking. Shipments, shipping containers and palletized unit loads shall be marked in accordance with ASTM- D-3951-15 approved 1 December 2015, Standard Practice for Commercial Packing.

(b) Packing List(s). A packing list (DD Form 250 Material Inspection and Receiving Report may be used) identifying the contents of each shipment, shipping container or palletized unit load shall be provided by the Contractor with each shipment. When a contract line item identified under a single stock number includes an assortment of related items such as kit or set components, detached parts or accessories, installation hardware or material, the packing list(s) shall identify the assorted items. Where assortment of related items is included in the shipping container, a packing list identifying the contents shall be furnished.

(c) Master Packing List. In addition to the requirements in paragraph (b) above, a master packing list shall be prepared where more than one shipment, shipping container or palletized unit load comprise the contract line item being shipped. The master packing list shall be attached to the number one container and so identified.

(d) Part Identification. All items within the kit, set, installation hardware or material shall be suitably segregated and identified within the unit pack(s) or shipping container by part number and/or national stock number.

D-247-W001 PROHIBITED PACKING MATERIALS (NAVSEA) (OCT 2018)

The use of asbestos, excelsior, newspaper or shredded paper (all types including waxed paper, computer paper and similar hygroscopic or non-neutral material) is prohibited. In addition, the use of yellow wrapping or packaging material is prohibited except where used for the containment of radioactive material. Loose fill polystyrene is prohibited for shipboard use.

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government 0003 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.246-2 Inspection Of Supplies--Fixed Price AUG 1996 52.246-15 Certificate of Conformance APR 1984 52.246-16 Responsibility For Supplies APR 1984

E-246-H016 INSPECTION AND ACCEPTANCE OF F.O.B. DESTINATION DELIVERIES (NAVSEA) (OCT 2018)

Item(s) 0001 - 0003 - Inspection and acceptance shall be made at destination by a representative of the Government.

E-246-H022 INSPECTION AND TEST RECORDS (NAVSEA) (JAN 2019)

Inspection and test records shall, as a minimum, indicate the nature of the observations, number of observations made, and the number and type of deficiencies found. Data included in inspection and test records shall be complete and accurate, and shall be used for trend analysis and to assess corrective action and effectiveness. The data shall, on request, be identified and made available for on-site review by the Contracting Officer or designated Government representative.

E-246-W002 CERTIFICATE OF COMPLIANCE (NAVSEA) (OCT 2018)

(a) A certification of material shall be provided by the Contractor, one (1) copy to accompany the shipment (in the packing list envelope) and (l) copy mailed to arrive at time of receipt of the shipment. Mark all certificates to the attention of Code 00Q.

(b) The certificate shall state compliance of material with drawing specification and contract/order requirements. The certificate shall as a minimum state the company name, contract/order number, drawing or specification number, and date. The certificate shall state, above the signature of a legally authorized representative of the company, the following:

This certification concerns a matter within the jurisdiction of an agency of the United States and the making of a false, fictitious, or fraudulent certification may render the maker subject to prosecution under Title 18, United States Code, Section 1001.

(c) Failure to provide certification at the time of shipment may result in material being rejected and returned at the contractor's expense.

(d) The certificate shall read as…