M67400-17-T-0024.pdf

SEE ADDENDUM

(No Collect Calls)

M6740017T0024 28-Feb-2017

b. TELEPHONE NUMBER

011-81-98-970-8145

8. OFFER DUE DATE/LOCAL TIME

09:00 AM 27 Mar 2017

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

M674009. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

MINAKO YARA

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED ORX

SMALL BUSINESS

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

MARINE CORPS REGIONAL CONTRACTING OFFICE

MARINE CORPS BASE

CAMP S.D. BUTLER

PSC 557 BOX 2000

FPO AP CA 96379-2000

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE M02209 16. ADMINISTERED BY

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

M02209

DPRI OFFICIAL

DPRI OFFICE

MCAS IWAKUNI

SEE SCHEDULE

MCAS IWAKUNI AP

TEL: FAX:

FAX:

TEL: 011816117458531

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

NAICS:

334515

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF59

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

M6740017T0024

Section SF 1449 - CONTINUATION SHEET

CLAUSES INCORPORATED BY FULL TEXT

Addendum to FAR 52.212-1 – INSTRUCTIONS TO OFFERORS

SUBMISSION OF QUOTE

1. Requirements of the quote:

PLEASE NOTE FAILURE TO SUBMIT ANY OF THE INFORMATION REQUIRED BY THIS SECTION

MAY RESULT IN A NON-RESPONSIVE DETERMINATION:

(X) SF1449 (Solicitation M67400-17-T-0024) completed (including all unit and extended price quotes).

(X) SF30 Amendment (s) (if applicable) signed.

(X) Offeror shall submit:

Technical Information: Offerors shall submit one original copy and one redacted version. The redacted version is used during the technical evaluation and therefore; it should be without company logo, identifying marks and names must be redacted. Failure to provide a redacted copy may result in a non-responsive determination. Be advsied that all quotes shall be submitted in English. The Government will validate Offerors’ redacted company information but will not make changes to Offerors’ provided redacted offer either to add or delete redacted text/graphics/etc.

(1) Required Items List & Descriptions: Offerors shall provide the specifications of the offering items in the Line Item Specifications, and submit it as a part of their offer.

(2) Descriptive Literature for the offered items: Offerors shall submit “Descriptive Literature” such as catalog(s) and/or brochure(s) as a part of their offer which is required to establish, for the purpose of evaluation and award, details of the product offered that are specified elsewhere in the solicitation and pertain to significant elements such as Size, Design, Materials, Components and Performance characteristics.

(3) Estimated Delivery Date: Offerors shall provide an estimated delivery date (Required “Door to Door

Delivery Date”: 15 days after the contract award)

(4) Warranty Terms and Conditions: Offerors shall provide a statement/document indicating the terms and conditions of the warranty. Warranty shall be provided at least minimum stated for each separate item.

The warranty period shall start from the date of the Government’s acceptance.

To ensure technical acceptability:

EVERY SPECIFICATION, FOR EACH ITEM, SHALL BE ADDRESSED FOR COMPLIANCE WITH THE

REQUIREMENTS. FAILURE TO ADDRESS THE SPECIFICATIONS REQUESTED SHALL RESULT IN AN

UNACCEPTABLE RATING.

Warranty terms shall be provided for all quoted items.

Price Quote

1. Pricing: All quotes submitted shall be the Contractor’s Best Pricing.

2. All shipping and freight charges shall be included in the price of the item. Failure to include the shipping charge in the price of the item may result in a Non-Responsive determination.

Offerors are advised to provide a quote for both delivery locations listed below:

TO:

MCAS Iwakuni Japan

DMO Shipping and Receiving

Bldg No. 1710

Misumi-machi, Iwakuni, Yamaguchi-ken, 740-0025, Japan

3. Pricing terms and conditions: Offerors shall submit their best pricing terms and conditions in accordance with the Government desired pricing terms and conditions

Offeror’s expenses incurred as a result of proposal preparation shall not be reimbursed by the U.S. Government.

Quoter’s Representations and Certifications o Quote shall contain a validation that System for Award Management (SAM) registration Online

Representations and Certifications Application (ORCA) information is up to date and includes all the necessary representations and certifications.

o System for Award Management (SAM) validation

Effective 01 March 1999 all payments made by the government will be made by Electronic Fund Transfer

(EFT). All DoD Contractors are now required to be registered within the SAM database prior to award, during performance and throughout final payment of any contract resulting from this request for quotation.

Quoters may obtain information on registration and annual confirmation requirements by calling 1-312-

463-3376 or via the Internet at: https://www.sam.gov. Registration on line will normally take 5 business days vice the standard 30 days processing time required through other methods.

The following information MUST be provided with this quotation:

Commercial And Government Entity Code (CAGE). ____________________ (U.S. Vendor Only)

NATO Commercial And Government Entity Code (NCAGE). ____________________ (Foreign Vendor Only)

Taxpayer Identification Number (TIN). _____________________________

Data Universal Numbering System (DUNS). __________________________

By submitting the above information, quoters are affirming that they are registered and current in the SAM database.

2. Correspondence

Any and all communications/questions pertaining to this solicitation (with the exception of the quote itself) must be submitted in writing to the responsible Contracting Specialist, Minako Yara, no later than 10 Mar

2017 @9:00AM (Japanese Standard Time) / 09 Mar 2017 @07:00PM (U.S. Eastern Time) . If a quoter believes that the requirements in these instructions contain an error, omission, or are otherwise unsound, the quoter shall immediately notify the Contract Specialist in writing with supporting rationale. The quoter is reminded that the

Government reserves the right to award this effort based on the initial quote, as received, without discussions.

Point of Contact:

Regional Contracting Office

Marine Corps Installations Pacific https://www.sam.gov/

Attn: Minako Yara

PSC 557 Box 2000

FPO AP 96379-2000

Phone: 011-81-98-970-3128 (Ext. 645-3128) (from U.S.) / 098-970-3128 (Ext. 645-3128) (Local)

Fax: 011-81-98-970-0969 (from U.S) / 098-970-0969 (Local)

E-mail: minako.yara.ja@usmc.mil

3. Submission method and considerations.

The solicitation must be returned to the address listed above at the date and time specified in SF1449 block #8, page

#1. Quotes may be submitted by courier, or facsimile. The Government reserves the right to make award solely on the quotes received, or enter into “discussions.” Quoters bear the burden of ensuring that quotes (and any authorized modifications) reach the designated office on time and should allow a reasonable time for facsimile transmissions to be completed.

Quotes may be submitted electronically (emailed); however, due to Government computer firewall security, any e-mail(s) with "zip" files will be automatically rejected. Any e-mails with large volume of attachments might be rejected. Quoters may submit their quotes via several e-mails. In that case, quoters shall specify the number of e-mails and attachments.

It is the quoter’s responsibility to ensure that the Contracting Office receives all required documents. After submitting quote(s), it is the quoter’s responsibility to receive acknowledgment from the Government.

All pages of the submission must reach the Contracting Office before the deadline specified on the solicitation.

Pages of e-mail transmission that arrive in the office after the specified deadline will be marked as late. Quoters shall bear the risk of non-receipt of e-mail transmissions and should confirm by telephone or e-mail that the quote was received. Any e-mail transmission shall clearly state the solicitation number and the name of the Contract

Specialist on the first page, to ensure proper receipt and preparation.

Pages of a facsimile transmission that arrive in the office after the specified deadline will be marked as late. The quoter bears the risk of non-receipt of facsimile transmissions and should confirm by telephone that any facsimile was received. Any facsimile transmission must clearly state the solicitation number and the name of the Contract

Specialist on the first page, to ensure proper receipt.

Other electronic methods of submission (such as web, grid, and cloud distributed system) will not be accepted unless approved by the Government 24 hours prior to the due date of the solicitation.

System for Award Management (SAM) Additional Information. All DoD Contractors are required to be registered within the SAM database prior to award, during performance and throughout final payment of any contract resulting from this request for quotation. Quoters may obtain information on registration and annual confirmation requirements by calling 1-312-463-3376 or via the Internet at: https://www.sam.gov. Registration on line will normally take 5 business days vice the standard 30 days processing time required through other methods.

Quoters shall ensure that all correspondence that is addressed to the United States Government is submitted in

English or with an English translation.

Quoter’s expenses incurred as a result of quote preparation shall not be reimbursed by the U.S. Government.

4. Period of pricing availability.

The quoter agrees to hold the prices in its quote firm for 90 calendar days from the date specified for receipt of quotes, unless another time period is specified in an addendum to the solicitation.

mailto:minako.yara.ja@usmc.mil

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 475 Each Power Meter w/Remote Display

FFP

-Square D/Schneider Electric PM8244

-Commercial Ref No. METSEPM8244

-PM8000 power meter DIN rail mount meter with remote display

-Intermediate metering with class 0.2S accuracy + 3 digital status/counter inputs +

1 KY (form A) energy pulse output and dual port ethernet + serial communications

Price shall include all cost associated with shipping items to MCAS Iwakuni, Japan. (Door to Door)

DMO Shipping and Receiving

Bldg No. 1710

FOB: Destination

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0002 475 Each 14-Pole Electric Switch

FFP

- Square D/Schneider Electric Model CSTM460157

- FMS14-14Z

- 4CT 3 Phase - 4 Wire Utility Grade Test Switch with Clear Cover

Price shall include all cost associated with shipping items to MCAS Iwakuni, Japan. (Door to Door)

DMO Shipping and Receiving

Bldg No. 1710

NET AMT

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

0002 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 15 dys. ADC 475 M02209

DPRI OFFICIAL

DPRI OFFICE

MCAS IWAKUNI

SEE SCHEDULE

MCAS IWAKUNI AP

M02209

0002 15 dys. ADC 475 (SAME AS PREVIOUS LOCATION)

M02209

CLASSIFICATION

Addendum to FAR 52.212-2 EVALUATION

(a) This is a commercial item requirement using Simplified Acquisition Procedures under FAR part 12 and 13, respectively. Evaluation will be conducted using simplified procedures in accordance with FAR 13.106.

(b) The Government will award to the responsible offeror whose quote, conforming to the solicitation and instructions to offerors, will be most advantageous to the Government. A best value determination will be made by the contracting officer using the following factors to evaluate quotes:

1) Quality/technical merit

2) Price

3) Past Performance

c) FAR 9.103 requires contracting officers to make a determination of responsibility prior to awarding a contract to a prospective contractor. FAR 9.104 identifies standards for a responsibility determination, which includes determination of satisfactory past performance. This assessment will primarily be reviewed and assessed through

Federal Awardee Performance and Integrity Information System (FAPIIS), but may include other authorized methods described elsewhere in the FAR. Past performance, for purposes of evaluation, will be assessed as

‘satisfactory’ or ‘unsatisfactory’ at the discretion of the contracting officer based on the totality of information available. A past performance determination of ‘unsatisfactory’ will exclude the offer from consideration for award.

d) Solicitations for supplies valued less than $1 million will use the past performance evaluation procedures outlined in DFARS 213.106-2 and described in clause 252.213-7000, incorporated herein.

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013

52.203-3 Gratuities APR 1984

52.203-11 Certification And Disclosure Regarding Payments To

Influence Certain Federal Transactions

SEP 2007

52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.204-2 Security Requirements AUG 1996

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-7 System for Award Management OCT 2016

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011

52.204-16 Commercial and Government Entity Code Reporting JUL 2016

52.204-17 Ownership or Control of Offeror JUL 2016

52.204-18 Commercial and Government Entity Code Maintenance JUL 2016

52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-2 Prohibition on Contracting with Inverted Domestic

Corporations--Representation

NOV 2015

52.209-5 Certification Regarding Responsibility Matters OCT 2015

52.212-4 Contract Terms and Conditions--Commercial Items MAY 2015

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008

52.225-25 Prohibition on Contracting with Entities Engaging in Certain

Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

52.228-3 Worker's Compensation Insurance (Defense Base Act) JUL 2014

52.228-4 Workers' Compensation and War-Hazard Insurance Overseas APR 1984

52.232-1 Payments APR 1984

52.232-8 Discounts For Prompt Payment FEB 2002

52.232-11 Extras APR 1984

52.232-17 Interest MAY 2014

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013

52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014

52.242-13 Bankruptcy JUL 1995

52.243-1 Changes--Fixed Price AUG 1987

52.246-2 Inspection Of Supplies--Fixed Price AUG 1996

52.246-16 Responsibility For Supplies APR 1984

52.247-34 F.O.B. Destination NOV 1991

52.249-1 Termination For Convenience Of The Government (Fixed

Price) (Short Form)

APR 1984

52.249-8 Default (Fixed-Price Supply & Service) APR 1984

252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.204-7004 Alt A System for Award Management Alternate A FEB 2014

252.204-7005 Oral Attestation of Security Responsibilities NOV 2001

252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

OCT 2016

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of

Terrorism

OCT 2015

252.222-7002 Compliance With Local Labor Laws (Overseas) JUN 1997

252.222-7007 Representation Regarding Combating Trafficking in Persons JAN 2015

252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013

252.225-7001 Buy American And Balance Of Payments Program-- Basic

(Dec 2016)

DEC 2016

252.225-7002 Qualifying Country Sources As Subcontractors DEC 2016

252.225-7012 Preference For Certain Domestic Commodities DEC 2016

252.225-7021 Trade Agreements--Basic DEC 2016

252.225-7031 Secondary Arab Boycott Of Israel JUN 2005

252.227-7015 Technical Data--Commercial Items FEB 2014

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7008 Assignment of Claims (Overseas) JUN 1997

252.232-7010 Levies on Contract Payments DEC 2006

252.233-7001 Choice of Law (Overseas) JUN 1997

252.237-7010 Prohibition on Interrogation of Detainees by Contractor

Personnel

JUN 2013

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.243-7002 Requests for Equitable Adjustment DEC 2012

252.244-7000 Subcontracts for Commercial Items JUN 2013

252.246-7007 Contractor Counterfeit Electronic Part Detection and

Avoidance System

AUG 2016

252.247-7007 Liability and Insurance DEC 1991

CLAUSES INCORPORATED BY FULL TEXT

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian

Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a

Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than

$10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the

Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

(End of provision)

52.209-11 REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A

FELONY CONVICTION UNDER ANY FEDERAL LAW (FEB 2016)

(a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations

Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that--

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that--

(1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

https://www.acquisition.gov/

52.212-1 INSTRUCTIONS TO OFFERORS--COMMERCIAL ITEMS (OCT 2016)

(a) North American Industry Classification System (NAICS) code and small business size standard. The NAICS code and small business size standard for this acquisition appear in Block 10 of the solicitation cover sheet (SF

1449). However, the small business size standard for a concern which submits an offer in its own name, but which proposes to furnish an item which it did not itself manufacture, is 500 employees.

(b) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. Offers may be submitted on the SF 1449, letterhead stationery, or as otherwise specified in the solicitation. As a minimum, offers must show--

(1) The solicitation number;

(2) The time specified in the solicitation for receipt of offers;

(3) The name, address, and telephone number of the offeror;

(4) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary;

(5) Terms of any express warranty;

(6) Price and any discount terms;

(7) "Remit to" address, if different than mailing address;

(8) A completed copy of the representations and certifications at FAR 52.212-3 (see FAR 52.212-3(b) for those representations and certifications that the offeror shall complete electronically);

(9) Acknowledgment of Solicitation Amendments;

(10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the same or similar items and other references (including contract numbers, points of contact with telephone numbers and other relevant information); and

(11) If the offer is not submitted on the SF 1449, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. Offers that fail to furnish required representations or information, or reject the terms and conditions of the solicitation may be excluded from consideration.

(c) Period for acceptance of offers. The offeror agrees to hold the prices in its offer firm for 30 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation.

(d) Product samples. When required by the solicitation, product samples shall be submitted at or prior to the time specified for receipt of offers. Unless otherwise specified in this solicitation, these samples shall be submitted at no expense to the Government, and returned at the sender's request and expense, unless they are destroyed during preaward testing.

(e) Multiple offers. Offerors are encouraged to submit multiple offers presenting alternative terms and conditions or commercial items for satisfying the requirements of this solicitation. Each offer submitted will be evaluated separately.

(f) Late submissions, modifications, revisions, and withdrawals of offers:

(1) Offerors are responsible for submitting offers, and any modifications, revisions, or withdrawals, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that offers or revisions are due.

(2)(i) Any offer, modification, revision, or withdrawal of an offer received at the Government office designated in the solicitation after the exact time specified for receipt of offers is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and--

(A) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of offers; or

(B) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or

(C) If this solicitation is a request for proposals, it was the only proposal received.

(ii) However, a late modification of an otherwise successful offer, that makes its terms more favorable to the

Government, will be considered at any time it is received and may be accepted.

(3) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the offer wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(4) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent

Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(5) Offers may be withdrawn by written notice received at any time before the exact time set for receipt of offers.

Oral offers in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile offers, offers may be withdrawn via facsimile received at any time before the exact time set for receipt of offers, subject to the conditions specified in the solicitation concerning facsimile offers. An offer may be withdrawn in person by an offeror or its authorized representative if, before the exact time set for receipt of offers, the identity of the person requesting withdrawal is established and the person signs a receipt for the offer.

(g) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with offerors. Therefore, the offeror's initial offer should contain the offeror's best terms from a price and technical standpoint. However, the Government reserves the right to conduct discussions if later determined by the Contracting Officer to be necessary. The Government may reject any or all offers if such action is in the public interest; accept other than the lowest offer; and waive informalities and minor irregularities in offers received.

(h) Multiple awards. The Government may accept any item or group of items of an offer, unless the offeror qualifies the offer by specific limitations. Unless otherwise provided in the Schedule, offers may not be submitted for quantities less than those specified. The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit prices offered, unless the offeror specifies otherwise in the offer.

(i) Availability of requirements documents cited in the solicitation. (1)(i) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to--GSA

Federal Supply Service Specifications Section, Suite 8100, 470 East L'Enfant Plaza, SW, Washington, DC

20407, Telephone (202) 619-8925, Facsimile (202) 619-8978.

(ii) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (i)(1)(i) of this provision.

Additional copies will be issued for a fee.

(2) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites:

(i) ASSIST (https://assist.dla.mil/online/start/).

(ii) Quick Search (http://quicksearch.dla.mil/).

(iii) ASSISTdocs.com (http://assistdocs.com).

(3) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point

(DoDSSP) by--

(i) Using the ASSIST Shopping Wizard (https://assist.dla.mil/wizard/index.cfm);

(ii) Phoning the DoDSSP Customer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST; or

(iii) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone

(215) 697-2667/2179, Facsimile (215) 697-1462.

(4) Nongovernment (voluntary) standards must be obtained from the organization responsible for their preparation, publication, or maintenance.

(j) Unique entity identifier. (Applies to all offers exceeding $3,500, and offers of $3,500 or less if the solicitation requires the Contractor to be registered in the System for Award Management (SAM) database.) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation ``Unique Entity Identifier'' followed by the unique entity identifier that identifies the Offeror's name and address. The Offeror also shall enter its Electronic Funds Transfer (EFT) indicator, if applicable. The EFT indicator is a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the Offeror to establish additional SAM records for identifying alternative EFT accounts (see subpart 32.11) for the same entity. If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for unique entity identifier establishment directly to obtain one. The Offeror should indicate that it is an offeror for a Government contract when contacting the entity designated at www.sam.gov for establishing the unique entity identifier.

(k) System for Award Management. Unless exempted by an addendum to this solicitation, by submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance and through final payment of any contract resulting from this solicitation. If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting

Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror. Offerors may obtain information on registration and annual confirmation requirements via the SAM database accessed through https://www.acquisition.gov.

(l) Debriefing. If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable:

(1) The agency's evaluation of the significant weak or deficient factors in the debriefed offeror's offer.

(2) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.

https://assist.dla.mil/online/start/ http://quicksearch.dla.mil/ http://assistdocs.com/ https://assist.dla.mil/wizard/index.cfm http://www.sam.gov/ http://www.sam.gov/

(3) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.

(4) A summary of the rationale for award;

(5) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror.

(6) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL ITEMS (DEC 2016)

ALTERNATE I (OCT 2014)

The offeror shall complete only paragraphs (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal . If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (t) of this provision.

(a) Definitions. As used in this provision--

“Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means--

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: ``Guidance for Executive Order 13673, `Fair Pay and Safe Workplaces' ''. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

https://www.sam.gov/portal http://www.dol.gov/fairpayandsafeworkplaces

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and

Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the occupational

Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are--

(1) Department of Labor Wage and Hour Division (WHD) for--

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(v) The Family and Medical Leave Act; and

(vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for--

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for--

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment

Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for--

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

“Forced or indentured child labor” means all work or service—

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation,” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment

Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the

FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

http://www.osha.gov/dcsp/osp/approved_state_plans.html

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of ``labor laws''.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except—

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate—

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology—

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically—

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act

(50 U.S.C. 1702(b)(3)).

“Service-disabled veteran-owned small business concern”—

(1) Means a small business concern—

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern, consistent with 13 CFR 124.1002,” means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Veteran-owned small business concern” means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans(as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Women-owned business concern” means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

“Women-owned small business concern” means a small business concern --

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least

51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127),” means a small business concern that is at least 51 percent directly and…