L15PS00561_-_Clauses_ _Provisions_Final.docx

Solicitation

Section B - Schedule of Items

SCHEDULE A

Total

Section C - Description/Specifications

See attached specification and plans for details (see section J). A brief summary is below:

Scope of Contract

Furnishing all labor, equipment, supplies, and materials, to reshape existing site road, masonry sign base, small bridge structure, culverts, concrete sidewalks, & concrete parking areas, rock barricades, rock drains, sumps, and slope stabilization, and other miscellaneous improvements. Furnishing all labor, equipment, supplies and materials to install Government furnished road base on all site roads & parking areas, concrete benches, concrete picnic tables, kiosk, fee tubes, registry, grills, & fire rings. The project will also consist of demolition of existing campsite amenities, site signage, culverts, kiosk, parking barriers, gravel pave, toilet building including associated vaults, & other miscellaneous items.

Project Location

Work under this Contract is located in Garfield County, Utah. The work site is at the Starr Springs Campground, off of SR-276, approximately 10 miles North of Ticaboo, Utah.

Performance Time

90 Days from issuance of Notice to Proceed; Work will not begin earlier than September 20, 2015

Disclosure of the Magnitude of Construction Project

Between $100,000 and $250,000

Section D - Packaging and Marking This Section is not used.

Section E - Inspection and Acceptance

52.252-2 Clauses Incorporated by Reference. (FEB 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: https://www.acquisition.gov/?q=browsefar

52.246-12 Inspection of Construction (Aug. 1996) 52.246-13 Inspection-Dismantling, Demolition, or Removal of Improvements (Aug 1996) 52.246-21 Warranty of Construction (March 1994)

1510.301 Inspection (August 1999)

(a) Work will be subject to periodic inspections by the Government to assure satisfactory progress, to determine quantities or work performed for progress payment purposes, to be certain that work is being performed in accordance with contract specifications, and to determine if work corrections are necessary.

(b) Inspection in the form of a review of all required reports will be performed by the Contracting Officer's Representative (COR). Accordingly, all reports, data, and documentation required by the contract will be submitted to the COR who will recommend approval/disapproval for acceptance purposes to the Contracting Officer.

(c) The Contractor shall notify the COR or the Project Inspector (PI) at least 3 days before the scheduled completion date, so the Government can schedule final inspection. The Contractor will not be granted a time extension to perform a work correction required as a result of a periodic or final inspection if such correction is necessary because of improper work by the Contractor. The Contractor or his authorized representative must be at the worksite at time of final inspection.

1510.302 Acceptance (August 1999)

Final inspection and acceptance of all items/services to be delivered under this contract shall be the responsibility of the Contracting Officer. Quality of work is subject to verification by the COR, with final payment to be withheld pending completion of any necessary rework by the Contractor.

Section F - Deliveries or Performance

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: http://www.acquisition.gov

52.242-14 Suspension of Work (April 1984)

52.211-10 Commencement, Prosecution, and Completion of Work (April 1984) The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work within 90 days of the issuance of the Notice to Proceed. The time stated for completion shall include final cleanup of the premises.

52.211-13 Time Extensions. (SEP 2000) Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

52.211-18 Variation in Estimated Quantity (Apr 1984) If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.

Section G - Contract Administration Data

Government Furnished Property (February 2011) The Government will provide the following item(s) of Government property to the Contractor for use in the performance of this contract. This property shall be used and maintained by the Contractor in accordance with the provisions of the "Government Property" FAR clause contained elsewhere in the contract.

See section 01019 of the specifications described in Section J of this document for description of Government Furnished Property.

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

Electronic Invoicing and Payment Requirements - Invoice Processing Platform (IPP) (April 2013) Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov. Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

A copy of the vendor’s commercial invoice The Contractor must use the IPP website to register, access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

1510.322 Procurement Office Representative (August 1999)

The Procurement Office Representative for this requirement is:

Section H - Special Contract Requirements

1510.015 Work Hours (April 1998)

No work will be done on Saturday, Sunday, or legal National Holidays or Federal Holidays unless authorized by the COR. Contract work will commence prior to or immediately after these dates so construction does not interfere with these event dates. Contractor shall schedule and sequence operations necessary to complete the required work in such a manner as to avoid delays in construction.

National and Federal Holidays to be observed are:

October 12, 2015 – Columbus Day November 11, 2015 – Veterans Day November 26, 2015 – Thanksgiving Day December 25, 2015 – Christmas Day

The Contractor shall observe any other day designated by Federal statute, Executive Order or the Presidential proclamation.

When any such day falls on a Saturday, the preceding Friday is observed; when any such day falls on a Sunday, the following Monday is observed. All personnel assigned to perform under this contract shall limit their observation of holidays to those set forth above.

1510.016 Fire Danger Season (April 1998)

If the COR allows the Contractor to continue work during periods of declared fire danger or season, the Contractor shall comply with all applicable state laws relating to fire prevention and with all special conditions of work as directed by the COR.

FIRE DANGER SEASON – LOCAL CLAUSE

If the COR allows the Contractor to continue work during periods of declared fire danger or season, the Contractor shall comply with all applicable state laws relating to fire prevention and with all special conditions of work as directed by the COR.

Fire Prevention Provision Smoking: Will be prohibited in the project area during the fire season, May 10 through October 20, except in areas agreed upon by the Contractor and/or Contracting Officer's Representative (COR).

Refueling Chainsaw/Soil Auger: Refueling will be confined to a six-foot diameter cleared to mineral earth. Chainsaws/soil auger sparks arrester shall be BLM approved, and will be cleaned daily. A size "0" or larger round-pointed shovel with a minimum of a 38-1/2" handle and a fire extinguisher shall be within 10 feet of actual point of chainsaw/soil auger operation.

Burning, Blasting, or Welding: Written Permission from the COR will be required and will contain special stipulations pertinent to the particular job.

Spark Arresters: All internal combustion power equipment used by the Contractor on the project shall be equipped with an approved spark arrester as set forth in 36 CFR 261.52 which requires all such engines to be equipped with a qualified spark arrester that is maintained and has not been modified. They shall be cleaned regularly and maintained in satisfactory working condition. The following are exempt from the requirements of the rule:

(a) Turbo-charged internal combustion engines in which 100 percent of the exhaust gasses pass through a turbo-charger;

(b) Engines of passenger carrying vehicles and light trucks equipped with a muffler with baffles that are kept in good repair (glass packs are not an approved muffler for wildland work);

(c) Water pumping equipment used in firefighting.

Spark arresters must comply with all State and Federal fire requirements.

Lunch and Warming Fires: Cooking and warming fires will not normally be permitted and then only by written authorization of the COR which will contain stipulations regulating use of such fires.

Hand Tools: The Contractor shall furnish one size "0" shovel (38-1/2" handle minimum) or larger, one axe, or pulaski with 26" handle or larger, and one 5 BC or larger rated pressurized fire extinguisher for each truck, each personal vehicle, each tractor, and each grader. For each welder the contractor shall furnish one size "0" shovel and one backpump pump. For each gasoline powered tools (power saw, soil auger, etc.), one shovel (38-1/2" handle minimum) and one 8-ounce or larger BC rated chemical-pressurized fire extinguisher.

Contractor shall also furnish any other equipment called for elsewhere in the contract. The shovel and fire extinguisher will be located within 10 feet of the operating chainsaw/power auger.

Storage and Parking Areas: Equipment service area, parking area, and gas and oil drum storage areas will be cleared of all flammable material for a radius of at least 50 feet. These areas must be approved in writing by the COR in advance of use. Small stationary engine sites shall be cleared of flammable material for a radius of at least 15 feet from such engine.

Notification: Contractor should immediately notify the nearest Dispatch Center (911) of any fires including location and actions taken. Notify the COR of any fires or other hazards as soon as it is possible.

1510.017 Drawings (April 1998)

(a) Typical Drawings. Any drawings titled typical are general only and dimensions of each structure will be fixed by the Contracting Officer to adapt the design to existing conditions at the structure location.

(b) Reduced Size Drawings. Any drawings identified as "REDUCED SIZE DRAWINGS" appearing in the solicitation are photographically reduced in size. Accordingly, measurements and dimensions should not be taken or be based on any numerical scales shown. Prospective bidders desiring to review a copy of the full size drawings may contact the Contracting Officer identified in the solicitation.

1510.018 Preservation of Historical and Archeological Data (April 1998)

(a) Public Law 93-291, May 24, 1974, provides for the preservation of scientific, prehistorical, and archeological data (including relics and specimens) which might otherwise be lost due to alteration of the terrain as a result of any Federal construction project.

(b) The Contractor agrees that should he or any of his employees in the performance of this contract discover evidence of possible scientific, prehistorical, historical, or archeological data he will notify the Contracting Officer immediately in writing giving the location and nature of the findings.

(c) Where appropriate by reason of discovery, the Contracting Officer may order delays in the time of performance and/or changes in the work. If such delays and/or changes are ordered, the time of performance and contract price shall be adjusted in accordance with the applicable clauses in the Contract Clauses Section of this contract.

(d) The Contractor agrees to insert this paragraph in all subcontracts which involve the performance of work on the terrain of the site.

1510.304 Pre-Work Conference (August 1999)

After award a pre-work conference shall be held between the Contractor and the COR. The date and time of the meeting shall be determined by the COR and the Contractor in consultation. Discussions relative to contract requirements and the specific responsibilities of each party will be conducted at this time.

1510.305 Notice to Proceed (August 1999)

After award of contract, the COR will issue a written notice to proceed to the Contractor. Issuance of such notice may be delayed for a reasonable time if adverse soil, vegetative, or climatological conditions exist. The Contractor shall commence work within 10 days of written notice to proceed.

Section I - Contract Clauses

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: http://www.acquisition.gov

52.204-13 System for Award Management Maintenance (Jul 2013) 52.209-6 Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Aug 2013) 52.209-10 Prohibition on Contracting With Inverted Domestic Corporations (Dec 2014) 52.219-3 – Notice of HUBZone Set-Aside or Sole Source Award (Nov 2011) 52.219-28 Post-Award Small Business Program Representation (Jul 2013) 52.222-6 Construction Wage Rate Requirements (May 2014) 52.222-7 Withholding of Funds (May 2014) 52.222-8 Payrolls and Basic Records (May 2014) 52.222-9 Apprentices and Trainees (July 2005) 52.222-10 Compliance with Copeland Act Requirements (February 1988) 52.222-11 Subcontracts (Labor Standards) (May 2014) 52.222-12 Contract Termination-Debarment (May 2014) 52.222-13 Compliance with Davis-Bacon and Related Act Regulations (May 2014) 52.222-14 Disputes Concerning Labor Standards (February 1988) 52.222-15 Certification of Eligibility (May 2014) 52.222-27 Affirmative Action Compliance Requirements for Construction (Apr 2015) 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts (Sep 2013) 52.223-3 Hazardous Material Identification and Material Safety Data (Jan 1997) 52.223-3 Hazardous Material Identification and Material Safety Data – Alternate I (Jan 1997) 52.223-6 Drug Free Workplace (May 2001) 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts (May 2008) 52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving (Aug 2011) 52.227-4 Patent Indemnity – Construction Contracts (December 2007) 52.228-2 Additional Bond Security (October 1997) 52.228-11 Pledges of Assets (Jan 2012) 52.228-12 Prospective Subcontractor Requests for Bonds (May 2014) 52.228-14 Irrevocable Letter of Credit (Nov 2014) 52.232-5 Payments under Fixed-Price Construction Contracts (May 2014) 52.232-23 Assignment of Claims (May 2014) 52.232-27 Prompt Payment for Construction Contracts (May 2014) 52.236-2 Differing Site Conditions (April 1984) 52.236-3 Site Investigation and Conditions Affecting the Work (April 1984) 52.236-5 Material and Workmanship (April 1984) 52.236-6 Superintendence by the Contractor (April 1984) 52.236-7 Permits and Responsibilities (November 1991) 52.236-8 Other Contracts (April 1984) 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements (April 1984) 52.236-10 Operations and Storage Areas (April 1984) 52.236-11 Use and Possession Prior to Completion (April 1984) 52.236-12 Cleaning Up (April 1984) 52.236-13 Accident Prevention (November 1991) 52.236-14 Availability and Use of Utility Services (April 1984) 52.236-21 Specifications and Drawings for Construction (February 1997) 52.236-26 Preconstruction Conference (February 1995) 52.243-5 Changes and Changed Conditions (April 1984) 52.245-1 Government Property (Apr 2012) 52.249-1 Termination for Convenience of the Government (Fixed-Price) (Short Form) (April 1984) 52.249-10 Default (Fixed-Price Construction) (April 1984)

52.213-4 Terms and Conditions -- Simplified Acquisitions (Other Than Commercial Items) (May 2015)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

(ii) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(iii) 52.222-26, Equal Opportunity (Apr 2015) (E.O. 11246).

(iv) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(v) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).

(vi) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Pub. L. 108-77, 108-78 (19 U.S.C. 3805 note)).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (Apr 1984).

(ii) 52.232-8, Discounts for Prompt Payment (Feb 2002).

(iii) 52.232-11, Extras (Apr 1984).

(iv) 52.232-25, Prompt Payment (Jul 2013).

(v) 52.232-39, Unenforceability of Unauthorized Obligations (Jun 2013).

(vi) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Dec 2013)

(vii) 52.233-1, Disputes (May 2014).

(viii) 52.244-6, Subcontracts for Commercial Items (Apr 2015).

(ix) 52.253-1, Computer Generated Forms (Jan 1991).

(b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Jul 2013) (Pub. L. 109-282) (31 U.S.C. 6101 note) (Applies to contracts valued at $25,000 or more).

(ii) 52.222-19, Child Labor—Cooperation with Authorities and Remedies (Jan 2014) (E.O. 13126). (Applies to contracts for supplies exceeding the micro-purchase threshold).

(iii) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment Exceeding $15,000 (May 2014) (41 U.S.C. chapter 65) (Applies to supply contracts over $15,000 in the United States, Puerto Rico, or the U.S. Virgin Islands).

(iv) 52.222-35, Equal Opportunity for Veterans (Jul 2014) (38 U.S.C. 4212) (Applies to contracts of $100,000 or more).

(v) 52.222-36, Equal Employment for Workers with Disabilities (Jul 2014) (29 U.S.C. 793) (Applies to contracts over $15,000, unless the work is to be performed outside the United States by employees recruited outside the United States.) (For purposes of this clause, “United States” includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.)

(vi) 52.222-37, Employment Reports on Veterans (Jul 2014) (38 U.S.C. 4212) (Applies to contracts of $100,000 or more).

(vii) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67) (Applies to service contracts over $2,500 that are subject to the Service Contract Labor Standards statute and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf.)

(viii)(A) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627) (Applies to all solicitations and contracts).

(B) Alternate I (Mar 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2014) (Executive Order 13658) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States the 50 States and the District of Columbia).

(x) 52.223-5, Pollution Prevention and Right-to-Know Information (May 2011) (E.O. 13423) (Applies to services performed on Federal facilities).

(xi) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b) (Unless exempt pursuant to 23.204, applies to contracts when energy-consuming products listed in the ENERGY STAR® Program or Federal Energy Management Program (FEMP) will be—

(A) Delivered;

(B) Acquired by the Contractor for use in performing services at a Federally-controlled facility;

(C) Furnished by the Contractor for use by the Government; or

(D) Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance).

(xii) 52.225-1, Buy American —Supplies (May 2014) (41 U.S.C. chapter 83) (Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold and the acquisition--

(A) Is set aside for small business concerns; or

(B) Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $25,000).

(xiii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792) (Applies to contracts greater than $25,000 that provide for the provision, the service, or the sale of food in the United States).

(xiv) 52.232-33, Payment by Electronic Funds Transfer— System for Award Management (Jul 2013) (Applies when the payment will be made by electronic funds transfer (EFT) and the payment office uses the System for Award Management (SAM) database as its source of EFT information.)

(xv) 52.232-34, Payment by Electronic Funds Transfer—Other than System for Award Management (Jul 2013) (Applies when the payment will be made by EFT and the payment office does not use the SAM database as its source of EFT information.)

(xvi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. App.1241) (Applies to supplies transported by ocean vessels (except for the types of subcontracts listed at 47.504(d).)

(2) Listed below are additional clauses that may apply:

(i) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Aug 2013) (Applies to contracts over $30,000).

(ii) 52.211-17, Delivery of Excess Quantities (Sep 1989) (Applies to fixed-price supplies).

(iii) 52.247-29, F.o.b. Origin (Feb 2006) (Applies to supplies if delivery is f.o.b. origin).

(iv) 52.247-34, F.o.b. Destination (Nov 1991) (Applies to supplies if delivery is f.o.b. destination).

(c) FAR 52.252-2, Clauses Incorporated by Reference (Feb 1998). This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

www.acquisition.gov/far

(d) Inspection/Acceptance. The Contractor shall tender for acceptance only those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. The Government must exercise its postacceptance rights --

(1) Within a reasonable period of time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(e) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(f) Termination for the Government’s convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges that the Contractor can demonstrate to the satisfaction of the Government, using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor’s records. The Contractor shall not be paid for any work performed or costs incurred that reasonably could have been avoided.

(g) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(h) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

52.225-9 Buy American–Construction Materials (May 2014)

(a) Definitions. As used in this clause-- “Commercially available off-the-shelf (COTS) item”—

(1) Means any item of supply (including construction material) that is—

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

“Component” means an article, material, or supply incorporated directly into a construction material.

“Construction material” means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

“Cost of components” means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

“Domestic construction material” means—

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if—

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

“Foreign construction material” means a construction material other than a domestic construction material.

“United States” means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements the 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows: None

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute.

(1)

(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison

Item 1

Foreign construction material

Domestic construction material

Item 2

Foreign construction material

Domestic construction material

[List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.] [Include other applicable supporting information.] [*Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).]

52.225-10 Notice of Buy American Requirement--Construction Materials (May 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American--Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers.

(1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested—

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.228-13 ALTERNATIVE PAYMENT PROTECTIONS (JULY 2000)

(a) The Contractor shall submit one of the following payment protections Payment Bond Irrevocable Letter of Credit Cashier’s Check Tripartite Escrow Agreement

(b) The amount of the payment protection shall be 100 percent of the contract price.

(c) The submission of the payment protection is required within 10 days of after contract award but before commencement of work.

(d) The payment protection shall provide protection for the full contract performance period plus a one-year period.

(e) Except for escrow agreements and payment bonds, which provide their own protection procedures, the Contracting Officer is authorized to access funds under the payment protection when it has been alleged in writing by a supplier of labor or material that a nonpayment has occurred, and to withhold such funds pending resolution by administrative or judicial proceedings or mutual agreement of the parties.

(f) When a tripartite escrow agreement is used, the Contractor shall utilize only suppliers of labor and material that signed the escrow agreement.

52.252-4 Alterations in Contract (Apr 1984)

Portions of this contract are altered as follows:

52.252-6 Authorized Deviations in Clauses (Apr 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the date of the clause.

(b) The use in this solicitation or contract of any _____. [insert regulation name] (48 CFR _____) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the name of the regulation.

Section J - List of Documents, Exhibits and Other Attachments

K - Representations, Certifications, and Other Statements of Bidders

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: http://www.acquisition.gov

52.204-19 Incorporation by Reference of Representations and Certifications (Dec 2014) 52.209-2 Prohibition on Contracting With Inverted Domestic Corporations--Representation (Dec 2014) 52.223-1 Biobased Product Certification (May 2012) 52.223-4 Recovered Material Certification (May 2008) 52.236-28 Preparation of Proposals -- Construction (Oct 1997)

52.204-8 Annual Representations and Certifications (Dec 2014) (a)

(1) The North American Industry classification System (NAICS) code for this acquisition is 236210.

(2) The small business size standard is $36.5 Million.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)

(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in the System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certification in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

[_] (i) Paragraph (d) applies.

[_] (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)

(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(iv) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(v) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations—Representation.

(vi) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(vii) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(viii) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(ix) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(x) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xi) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xii) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xiii) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xiv) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xv)…