Clauses_HSFE06-16-R-0201.pdf

A - Solicitation/Contract Form Clauses

B - Supplies or Services/Prices Clauses

C - Description/Specifications Clauses

D - Packaging and Marking Clauses

E - Inspection and Acceptance Clauses

F - Deliveries or Performance Clauses

G - Contract Administration Data Clauses

H - Special Contract Requirements Clauses

I - Contract Clauses Clauses

J - List of Documents, Exhibits and Other Attachments List of Documents, Exhibits, and Other Attachments Clauses

K - Representations, Certifications, and Other Statements of Bidders Clauses

A - Solicitation/Contract Form

Clauses

52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984)

The Contractor shall be required to (a) commence work under this contract within [Contracting Officer insert number] calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than [* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date]. The time stated for completion shall include final cleanup of the premises.

(End of clause)

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984) - Alternate I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within [Contracting Officer insert number] calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than [* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.]. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by [Contracting Officer insert date]. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

52.211-12 Liquidated Damages - Construction. (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of [Contracting Officer insert amount] for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.232-5 Payments Under Fixed-Price Construction Contracts. (MAY 2014)

52.236-1 Performance of Work by the Contractor. (APR 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least [insert the appropriate number in words followed by numerals in parentheses] percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

(End of clause)

52.236-2 Differing Site Conditions. (APR 1984)

52.236-3 Site Investigation and Conditions Affecting the Work. (APR 1984)

52.236-5 Material and Workmanship. (APR 1984)

52.236-7 Permits and Responsibilities. (NOV 1991)

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements.

(APR 1984)

52.236-12 Cleaning Up. (APR 1984)

52.236-13 Accident Prevention. (NOV 1991)

52.246-12 Inspection of Construction. (APR 1996)

52.246-21 Warranty of Construction. (MAR 1994)

52.249-10 Default (Fixed-Price Construction). (APR 1984)

B - Supplies or Services/Prices

Clauses

C - Description/Specifications

Clauses

D - Packaging and Marking

Clauses

E - Inspection and Acceptance

Clauses

F - Deliveries or Performance

Clauses

52.247-33 F.o.b. Origin, with Differentials. (FEB 2006)

(a) The term "f.o.b. origin, with differentials," as used in this clause, means-

(1) Free of expense to the Government delivered-

(i) On board the indicated type of conveyance of the carrier (or of the Government, if specified) at a designated point in the city, county, and State from which the shipments will be made and from which line-haul transportation service (as distinguished from switching, local drayage, or other terminal service) will begin;

(ii) To, and placed on, the carrier's wharf (at shipside, within reach of the ship's loading tackle, when the shipping point is within a port area having water transportation service) or the carrier's freight station;

(iii) To a U.S. Postal Service facility; or

(iv) If stated in the solicitation, to any Government-designated point located within the same city or commercial zone as the f.o.b. origin point specified in the contract (the Federal Motor Carrier Safety Administration prescribes commercial zones at Subpart B of 49 CFR part 372); and

(2) Differentials for mode of transportation, type of vehicle, or place of delivery as indicated in Contractor's offer may be added to the contract price.

(b) The Contractor shall-

(1)(i) Pack and mark the shipment to comply with contract specification; or

(ii) In the absence of specifications, prepare the shipment in conformance with carrier requirements to protect the goods and to ensure assessment of the lowest applicable transportation charge;

(2)(i) Order specified carrier equipment when requested by the Government; or

(ii) If not specified, order appropriate carrier equipment not in excess of capacity to accommodate shipment;

(3) Deliver the shipment in good order and condition to the carrier, and load, stow, trim, block, and/or brace carload or truckload shipment (when loaded by the Contractor) on or in the carrier's conveyance as required by carrier rules and regulations;

(4) Be responsible for any loss of and/or damage to the goods-

(i) Occurring before delivery to the carrier;

(ii) Resulting from improper packing and marking; or

(iii) Resulting from improper loading, stowing, trimming, blocking, and/or bracing of the shipment, if loaded by the Contractor on or in the carrier's conveyance;

(5) Complete the Government bill of lading supplied by the ordering agency or, when a Government bill of lading is not supplied, prepare a commercial bill of lading or other transportation receipt. The bill of lading shall show-

(i) A description of the shipment in terms of the governing freight classification or tariff (or Government rate tender) under which lowest freight rates are applicable;

(ii) The seals affixed to the conveyance with their serial numbers or other identification;

(iii) Lengths and capacities of cars or trucks ordered and furnished;

(iv) Other pertinent information required to effect prompt delivery to the consignee, including name, delivery address, postal address and ZIP code of consignee, routing, etc.;

(v) Special instructions or annotations requested by the ordering agency for bills of lading; e.g., "This shipment is the property of, and the freight charges paid to the carrier will be reimbursed by, the Government"; and

(vi) The signature of the carrier's agent and the date the shipment is received by the carrier; and

(6) Distribute the copies of the bill of lading, or other transportation receipts, as directed by the ordering agency.

(c)(1) It may be advantageous to the offeror to submit f.o.b. origin prices that include only the lowest cost to the Contractor for loading of shipment at the Contractor's plant or most favorable shipping point. If, at the time of shipment, the Government specifies a mode of transportation, type of vehicle, or place of delivery for which the offeror has set forth a differential, the Contractor shall include the total of such differential costs (the applicable differential multiplied by the actual weight) as a separate reimbursable item on the Contractor's invoice for the supplies.

Accordingly, the offeror may indicate differentials that may be added to the offered price. These differentials shall be expressed as a rate in cents for each 100 pounds (CWT) of the supplies for one or more of the options under this clause that the Government may specify at the time of shipment.

(2) These differential(s) will be considered in the evaluation of offers to determine the lowest overall cost to the Government. If, at the time of shipment, the Government specifies a mode of transportation, type of vehicle, or place of delivery for which the offeror has set forth a differential, the Contractor shall include the total of such differential costs (the applicable differential multiplied by the actual weight) as a separate reimbursable item on the Contractor's invoice for the supplies.

(3) The Government shall have the option of performing or arranging at its own expense any transportation from Contractor's shipping plant or point to carrier's facility at the time of shipment and, whenever this option is exercised, the Government shall make no reimbursement based on a quoted differential.

(4) Offeror's differentials in cents for each 100 pounds for optional mode of transportation, types of vehicle, transportation within a mode, or place of delivery, specified by the Government at the time of shipment and not included in the f.o.b. origin price indicated in the Schedule by the offeror, are as follows:

[ ] (carload, truckload, less-load, [ ] wharf, flatcar, driveaway, etc.)

(End of clause)

G - Contract Administration Data

Clauses

OPO-G-002 Invoicing Requirements

The Contractor shall invoice following the guidance and instruction provided in FAR clause 52.232-7 incorporated in full text above. The invoice shall be sent via e-mail to the USCIS COTR and the USCIS Contracting Officer. The payment office address is as follows:

Dallas Finance Center

PO Box 561547

Dallas, TX 75356-1547

(End of Language)

H - Special Contract Requirements

OPO-H-001 Advertisements, Publicizing Awards, and News Releases

All press releases or announcements about agency programs, projects, and contract awards need to be cleared by the Program Office and Contracting Officer. Under no circumstances shall the Contractor, or anyone acting on behalf of the Contractor, refer to the supplies, services, or equipment furnished pursuant to the provisions of this contract in any publicity news release or commercial advertising without first obtaining explicit written consent to do so from the Program Office and the Contracting Officer.

The Contractor agrees not to refer to awards in commercial advertising in such a manner as to state or imply that the product or service provided is endorsed or preferred by the Federal Government or is considered to be superior to other products or services.¿

OPO-H-004 Branding

The Contractor shall comply with the requirements of any DHS Branding and Marking policies. As a matter of law, Federal criminal statutes prohibit unauthorized use of the DHS Seal. In addition, DHS policy prohibits granting authorization for certain commercial uses of the Seal. It is permissible to reference DHS in materials if the reference is limited to true, factual statements. The words DHS and/or Homeland Security should appear in the same color, font, and size as the rest of the text in the document. Moreover, such references shall not imply in any way an endorsement of a product, company, or technology.

Requests to use the DHS Seal must be submitted using the DHS Official Seal Usage Approval form. A copy of this form may be requested from the Contracting Officer. The Comments section should be used to describe why use of the seal is being requested, and how it will be used. Completed forms should be sent via e-mail to the Deputy Director of Strategic Communications for Public Affairs, [], and to the Contracting Officer.

I - Contract Clauses

Clauses

52.202-1 Definitions. (NOV 2013)

52.203-5 Covenant Against Contingent Fees. (MAY 2014)

52.203-7 Anti-Kickback Procedures. (MAY 2014)

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights. (APR 2014)

52.204-14 Service Contract Reporting Requirements. (JAN 2014)

52.216-4 Economic Price Adjustment - Labor and Material. (JAN 1997)

52.216-8 Fixed Fee. (JUN 2011)

52.219-3 Notice of HUBZone Set-Aside or Sole Source Award. (NOV 2011)

52.222-6 Construction Wage Rate Requirements. (MAY 2014)

52.222-12 Contract Termination - Debarment. (MAY 2014)

52.222-13 Compliance With Construction Wage Rate Requirements and Related Regulations. (MAY 2014)

52.222-50 Combating Trafficking in Persons. (MAR 2015)

(a) Definitions. As used in this clause-

Agent means any individual, including a director, an officer, an employee, or an independent contractor, authorized to act on behalf of the organization.

Coercion means-

(1) Threats of serious harm to or physical restraint against any person;

(2) Any scheme, plan, or pattern intended to cause a person to believe that failure to perform an act would result in serious harm to or physical restraint against any person; or

(3) The abuse or threatened abuse of the legal process.

Commercial sex act means any sex act on account of which anything of value is given to or received by any person.

Commercially available off-the-shelf (COTS) item means-

(1) Any item of supply (including construction material) that is-

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

Debt bondage means the status or condition of a debtor arising from a pledge by the debtor of his or her personal services or of those of a person under his or her control as a security for debt, if the value of those services as reasonably assessed is not applied toward the liquidation of the debt or the length and nature of those services are not respectively limited and defined.

Employee means an employee of the Contractor directly engaged in the performance of work under the contract who has other than a minimal impact or involvement in contract performance.

Forced Labor means knowingly providing or obtaining the labor or services of a person-

(1) By threats of serious harm to, or physical restraint against, that person or another person;

(2) By means of any scheme, plan, or pattern intended to cause the person to believe that, if the person did not perform such labor or services, that person or another person would suffer serious harm or physical restraint; or

(3) By means of the abuse or threatened abuse of law or the legal process.

Involuntary servitude includes a condition of servitude induced by means of-

(1) Any scheme, plan, or pattern intended to cause a person to believe that, if the person did not enter into or continue in such conditions, that person or another person would suffer serious harm or physical restraint; or

(2) The abuse or threatened abuse of the legal process.

Severe forms of trafficking in persons means-

(1) Sex trafficking in which a commercial sex act is induced by force, fraud, or coercion, or in which the person induced to perform such act has not attained 18 years of age; or

(2) The recruitment, harboring, transportation, provision, or obtaining of a person for labor or services, through the use of force, fraud, or coercion for the purpose of subjection to involuntary servitude, peonage, debt bondage, or slavery.

Sex trafficking means the recruitment, harboring, transportation, provision, or obtaining of a person for the purpose of a commercial sex act.

Subcontract means any contract entered into by a subcontractor to furnish supplies or services for performance of a prime contract or a subcontract.

Subcontractor means any supplier, distributor, vendor, or firm that furnishes supplies or services to or for a prime contractor or another subcontractor.

United States means the 50 States, the District of Columbia, and outlying areas.

(b) Policy. The United States Government has adopted a policy prohibiting trafficking in persons including the trafficking-related activities of this clause. Contractors, contractor employees, and their agents shall not-

(1) Engage in severe forms of trafficking in persons during the period of performance of the contract;

(2) Procure commercial sex acts during the period of performance of the contract;

(3) Use forced labor in the performance of the contract;

(4) Destroy, conceal, confiscate, or otherwise deny access by an employee to the employee's identity or immigration documents, such as passports or drivers' licenses, regardless of issuing authority;

(5)(i) Use misleading or fraudulent practices during the recruitment of employees or offering of employment, such as failing to disclose, in a format and language accessible to the worker, basic information or making material misrepresentations during the recruitment of employees regarding the key terms and conditions of employment, including wages and fringe benefits, the location of work, the living conditions, housing and associated costs (if employer or agent provided or arranged), any significant cost to be charged to the employee, and, if applicable, the hazardous nature of the work;

(ii) Use recruiters that do not comply with local labor laws of the country in which the recruiting takes place;

(6) Charge employees recruitment fees;

(7)(i) Fail to provide return transportation or pay for the cost of return transportation upon the end of employment-

(A) For an employee who is not a national of the country in which the work is taking place and who was brought into that country for the purpose of working on a U.S. Government contract or subcontract (for portions of contracts performed outside the United States); or

(B) For an employee who is not a United States national and who was brought into the United States for the purpose of working on a U.S.

Government contract or subcontract, if the payment of such costs is required under existing temporary worker programs or pursuant to a written agreement with the employee (for portions of contracts performed inside the United States); except that-

(ii) The requirements of paragraphs (b)(7)(i) of this clause shall not apply to an employee who is-

(A) Legally permitted to remain in the country of employment and who chooses to do so; or

(B) Exempted by an authorized official of the contracting agency from the requirement to provide return transportation or pay for the cost of return transportation;

(iii) The requirements of paragraph (b)(7)(i) of this clause are modified for a victim of trafficking in persons who is seeking victim services or legal redress in the country of employment, or for a witness in an enforcement action related to trafficking in persons. The contractor shall provide the return transportation or pay the cost of return transportation in a way that does not obstruct the victim services, legal redress, or witness activity. For example, the contractor shall not only offer return transportation to a witness at a time when the witness is still needed to testify. This paragraph does not apply when the exemptions at paragraph (b)(7)(ii) of this clause apply.

(8) Provide or arrange housing that fails to meet the host country housing and safety standards; or

(9) If required by law or contract, fail to provide an employment contract, recruitment agreement, or other required work document in writing. Such written work document shall be in a language the employee understands. If the employee must relocate to perform the work, the work document shall be provided to the employee at least five days prior to the employee relocating. The employee's work document shall include, but is not limited to, details about work description, wages, prohibition on charging recruitment fees, work location(s), living accommodations and associated costs, time off, roundtrip transportation arrangements, grievance process, and the content of applicable laws and regulations that prohibit trafficking in persons.

(c) Contractor requirements. The Contractor shall-

(1) Notify its employees and agents of-

(i) The United States Government's policy prohibiting trafficking in persons, described in paragraph (b) of this clause; and

(ii) The actions that will be taken against employees or agents for violations of this policy. Such actions for employees may include, but are not limited to, removal from the contract, reduction in benefits, or termination of employment;

and

(2) Take appropriate action, up to and including termination, against employees, agents, or subcontractors that violate the policy in paragraph (b) of this clause.

(d) Notification. (1) The Contractor shall inform the Contracting Officer and the agency Inspector General immediately of-

(i) Any credible information it receives from any source (including host country law enforcement) that alleges a Contractor employee, subcontractor, subcontractor employee, or their agent has engaged in conduct that violates the policy in paragraph (b) of this clause (see also 18 U.S.C. 1351, Fraud in Foreign Labor Contracting, and 52.203-13(b)(3)(i)(A), if that clause is included in the solicitation or contract, which requires disclosure to the agency Office of the Inspector General when the Contractor has credible evidence of fraud); and

(ii) Any actions taken against a Contractor employee, subcontractor, subcontractor employee, or their agent pursuant to this clause.

(2) If the allegation may be associated with more than one contract, the Contractor shall inform the contracting officer for the contract with the highest dollar value.

(e) Remedies. In addition to other remedies available to the Government, the Contractor's failure to comply with the requirements of paragraphs (c), (d), (g), (h), or (i) of this clause may result in-

(1) Requiring the Contractor to remove a Contractor employee or employees from the performance of the contract;

(2) Requiring the Contractor to terminate a subcontract;

(3) Suspension of contract payments until the Contractor has taken appropriate remedial action;

(4) Loss of award fee, consistent with the award fee plan, for the performance period in which the Government determined Contractor non-compliance;

(5) Declining to exercise available options under the contract;

(6) Termination of the contract for default or cause, in accordance with the termination clause of this contract; or

(7) Suspension or debarment.

(f) Mitigating and aggravating factors. When determining remedies, the Contracting Officer may consider the following:

(1) Mitigating factors. The Contractor had a Trafficking in Persons compliance plan or an awareness program at the time of the violation, was in compliance with the plan, and has taken appropriate remedial actions for the violation, that may include reparation to victims for such violations.

(2) Aggravating factors. The Contractor failed to abate an alleged violation or enforce the requirements of a compliance plan, when directed by the Contracting Officer to do so.

(g) Full cooperation. (1) The Contractor shall, at a minimum-

(i) Disclose to the agency Inspector General information sufficient to identify the nature and extent of an offense and the individuals responsible for the conduct;

(ii) Provide timely and complete responses to Government auditors' and investigators' requests for documents;

(iii) Cooperate fully in providing reasonable access to its facilities and staff (both inside and outside the U.S.) to allow contracting agencies and other responsible Federal agencies to conduct audits, investigations, or other actions to ascertain compliance with the Trafficking Victims Protection Act of 2000 (22 U.S.C. chapter 78), E.O. 13627, or any other applicable law or regulation establishing restrictions on trafficking in persons, the procurement of commercial sex acts, or the use of forced labor; and

(iv) Protect all employees suspected of being victims of or witnesses to prohibited activities, prior to returning to the country from which the employee was recruited, and shall not prevent or hinder the ability of these employees from cooperating fully with Government authorities.

(2) The requirement for full cooperation does not foreclose any Contractor rights arising in law, the FAR, or the terms of the contract. It does not-

(i) Require the Contractor to waive its attorney-client privilege or the protections afforded by the attorney work product doctrine;

(ii) Require any officer, director, owner, employee, or agent of the Contractor, including a sole proprietor, to waive his or her attorney client privilege or Fifth Amendment rights; or

(iii) Restrict the Contractor from-

(A) Conducting an internal investigation; or

(B) Defending a proceeding or dispute arising under the contract or related to a potential or disclosed violation.

(h) Compliance plan. (1) This paragraph (h) applies to any portion of the contract that-

(i) Is for supplies, other than commercially available off-the-shelf items, acquired outside the United States, or services to be performed outside the United States; and

(ii) Has an estimated value that exceeds $500,000.

(2) The Contractor shall maintain a compliance plan during the performance of the contract that is appropriate-

(i) To the size and complexity of the contract; and

(ii) To the nature and scope of the activities to be performed for the Government, including the number of non-United States citizens expected to be employed and the risk that the contract or subcontract will involve services or supplies susceptible to trafficking in persons.

(3) Minimum requirements. The compliance plan must include, at a minimum, the following:

(i) An awareness program to inform contractor employees about the Government's policy prohibiting trafficking-related activities described in paragraph (b) of this clause, the activities prohibited, and the actions that will be taken against the employee for violations. Additional information about Trafficking in Persons and examples of awareness programs can be found at the Web site for the Department of State's Office to Monitor and Combat Trafficking in Persons at http://www.state.gov/j/tip/.

(ii) A process for employees to report, without fear of retaliation, activity inconsistent with the policy prohibiting trafficking in persons, including a means to make available to all employees the hotline phone number of the Global Human Trafficking Hotline at 1-844-888-FREE and its email address at help@befree.org.

(iii) A recruitment and wage plan that only permits the use of recruitment companies with trained employees, prohibits charging recruitment fees to the employee, and ensures that wages meet applicable host-country legal requirements or explains any variance.

(iv) A housing plan, if the Contractor or subcontractor intends to provide or arrange housing, that ensures that the housing meets host-country housing and safety standards.

(v) Procedures to prevent agents and subcontractors at any tier and at any dollar value from engaging in trafficking in persons (including activities in paragraph

(b) of this clause) and to monitor, detect, and terminate any agents, subcontracts, or subcontractor employees that have engaged in such activities.

(4) Posting. (i) The Contractor shall post the relevant contents of the compliance plan, no later than the initiation of contract performance, at the workplace (unless the work is to be performed in the field or not in a fixed location) and on the Contractor's Web site (if one is maintained). If posting at the workplace or on the Web site is impracticable, the Contractor shall provide the relevant contents of the compliance plan to each worker in writing.

(ii) The Contractor shall provide the compliance plan to the Contracting Officer upon request.

(5) Certification. Annually after receiving an award, the Contractor shall submit a certification to the Contracting Officer that-

(i) It has implemented a compliance plan to prevent any prohibited activities identified at paragraph (b) of this clause and to monitor, detect, and terminate any agent, subcontract or subcontractor employee engaging in prohibited activities; and

(ii) After having conducted due diligence, either-

(A) To the best of the Contractor's knowledge and belief, neither it nor any of its agents, subcontractors, or their agents is engaged in any such activities; or

(B) If abuses relating to any of the prohibited activities identified in paragraph (b) of this clause have been found, the Contractor or subcontractor has taken the appropriate remedial and referral actions.

(i) Subcontracts. (1) The Contractor shall include the substance of this clause, including this paragraph (i), in all subcontracts and in all contracts with agents. The requirements in paragraph

(h) of this clause apply only to any portion of the subcontract that-

(A) Is for supplies, other than commercially available off-the-shelf items, acquired outside the United States, or services to be performed outside the United States; and

(B) Has an estimated value that exceeds $500,000.

(2) If any subcontractor is required by this clause to submit a certification, the Contractor shall require submission prior to the award of the subcontract and annually thereafter.

The certification shall cover the items in paragraph (h)(5) of this clause.

(End of clause)

52.223-13 Acquisition of EPEAT(R)-Registered Imaging Equipment. (JUN 2014)

(a) Definitions. As used in this clause-

Imaging equipment means the following products:

(1) Copier-A commercially available imaging product with a sole function of the production of hard copy duplicates from graphic hard-copy originals. The unit is capable of being powered from a wall outlet or from a data or network connection. This definition is intended to cover products that are marketed as copiers or upgradeable digital copiers (UDCs).

(2) Digital duplicator-A commercially available imaging product that is sold in the market as a fully automated duplicator system through the method of stencil duplicating with digital reproduction functionality. The unit is capable of being powered from a wall outlet or from a data or network connection. This definition is intended to cover products that are marketed as digital duplicators.

(3) Facsimile machine (fax machine)-A commercially available imaging product whose primary functions are scanning hard-copy originals for electronic transmission to remote units and receiving similar electronic transmissions to produce hard-copy output.

Electronic transmission is primarily over a public telephone system but also may be via computer network or the Internet. The product also may be capable of producing hard copy duplicates. The unit is capable of being powered from a wall outlet or from a data or network connection. This definition is intended to cover products that are marketed as fax machines.

(4) Mailing machine-A commercially available imaging product that serves to print postage onto mail pieces. The unit is capable of being powered from a wall outlet or from a data or network connection. This definition is intended to cover products that are marketed as mailing machines.

(5) Multifunction device (MFD)-A commercially available imaging product, which is a physically integrated device or a combination of functionally integrated components, that performs two or more of the core functions of copying, printing, scanning, or faxing. The copy functionality as addressed in this definition is considered to be distinct from single-sheet convenience copying offered by fax machines. The unit is capable of being powered from a wall outlet or from a data or network connection. This definition is intended to cover products that are marketed as MFDs or multifunction products.

(6) Printer-A commercially available imaging product that serves as a hard-copy output device and is capable of receiving information from single-user or networked computers, or other input devices (e.g., digital cameras). The unit is capable of being powered from a wall outlet or from a data or network connection. This definition is intended to cover products that are marketed as printers, including printers that can be upgraded into MFDs in the field.

(7) Scanner-A commercially available imaging product that functions as an electro-optical device for converting information into electronic images that can be stored, edited, converted, or transmitted, primarily in a personal computing environment. The unit is capable of being powered from a wall outlet or from a data or network connection.

This definition is intended to cover products that are marketed as scanners.

(b) Under this contract, the Contractor shall deliver, furnish for Government use, or furnish for Contractor use at a Federally controlled facility, only imaging equipment that, at the time of submission of proposals and at the time of award, was EPEAT® bronze-registered or higher.

(c) For information about EPEAT®, see www.epa.gov/epeat.

(End of clause)

52.223-14 Acquisition of EPEAT(R)-Registered Televisions. (JUN 2014)

52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. (AUG 2011)

52.225-13 Restrictions on Certain Foreign Purchases. (JUN 2008)

52.228-15 Performance and Payment Bonds - Construction. (OCT 2010)

52.232-27 Prompt payment for construction contracts. (MAY 2014)

52.232-33 Payment by Electronic Funds Transfer - System for Award Management. (JUL 2013)

52.232-39 Unenforceability of Unauthorized Obligations. (JUN 2013)

52.233-3 Protest after Award. (AUG 1996)

52.233-4 Applicable Law for Breach of Contract Claim. (OCT 2004)

52.243-4 Changes. (JUN 2007)

52.249-2 Termination for Convenience of the Government (Fixed-Price). (APR 2012) - Alternate I

(SEP 1996)

3052.215-70 Key personnel or facilities. (DEC 2003)

3052.223-90 Accident and fire reporting. (USCG) (DEC 2003)

3052.225-70 Requirement for Use of Certain Domestic Commodities. (AUG 2009)

(a) Definitions. As used in this clause--

(1) "Commercial," as applied to an item described in subsection (b) of this clause, means an item of supply, whether an end product or component, that meets the definition of "commercial item" set forth in (FAR) 48 CFR 2.101.

(2) "Component" means any item supplied to the Government as part of an end product or of another component.

(3) "End product" means supplies delivered under a line item of this contract.

(4) "Non-commercial," as applied to an item described in subsections (b) or (c) of this clause, means an item of supply, whether an end product or component, that does not meet the definition of "commercial item" set forth in (FAR) 48 CFR 2.101.

(5) "Qualifying country" means a country with a memorandum of understanding or international agreement with the United States under which DHS procurement is covered.

(6) "United States" includes the possessions of the United States.

(b) The Contractor shall deliver under this contract only such of the following commercial or non-commercial items, either as end products or components, that have been grown, reprocessed, reused, or produced in the United States:

(1) Clothing and the materials and components thereof, other than sensors, electronics, or other items added to, and not normally associated with, clothing and the materials and components thereof; or

(2) Tents, tarpaulins, covers, textile belts, bags, protective equipment (such as body armor), sleep systems, load carrying equipment (such as fieldpacks), textile marine equipment, parachutes or bandages.

(c) The Contractor shall deliver under this contract only such of the following non-commercial items, either as end products or components, that have been grown, reprocessed, reused, or produced in the United States:

(1) Cotton and other natural fiber products.

(2) Woven silk or woven silk blends.

(3) Spun silk yarn for cartridge cloth.

(4) Synthetic fabric or coated synthetic fabric (including all textile fibers and yarns that are for use in such fabrics).

(5) Canvas products.

(6) Wool (whether in the form of fiber or yarn or contained in fabrics, materials, or manufactured articles).

(7) Any item of individual equipment manufactured from or containing any of the fibers, yarns, fabrics, or materials listed in this paragraph (c).

(d) This clause does not apply--

(1) To items listed in (FAR) 48 CFR 25.104, or other items for which the Government has determined that a satisfactory quality and sufficient quantity cannot be acquired as and when needed at United States market prices;

(2) To incidental amounts of cotton, other natural fibers, or wool incorporated in an end product, for which the estimated value of the cotton, other natural fibers, or wool is not more than 10 percent of the total price of the end product; or

(3) To items that are eligible products per (FAR) 48 CFR Subpart 25.4.

(End of clause)

52.222-99 Establishing a Minimum Wage for Contractors (DEVIATION)

ESTABLISHING A MINIMUM WAGE FOR CONTRACTORS

(DHS FAR CLASS DEVIATION 14-O3) (JUL 2014)

This clause implements Executive Order 13658, Establishing a Minimum Wage for Contractors, dated February 12, 2014, and OMB Policy Memorandum M-14-09, Implementation of the President’s Executive Order Establishing a Minimum Wage for Contractors, dated June 12, 2014.

(a) Each service employee, laborer, or mechanic employed in the United States (the 50 States and the District of Columbia) in the performance of this contract by the prime Contractor or any subcontractor, regardless of any contractual relationship which may be alleged to exist between the Contractor and service employee, laborer, or mechanic, shall be paid not less than the applicable minimum wage under Executive Order 13658. The minimum wage required to be paid to each service employee, laborer, or mechanic performing work on this contract between January 1, 2015, and December 31, 2015, shall be $10.10 per hour.

(b) The Contractor shall adjust the minimum wage paid under this contract each time the Secretary of Labor’s annual determination of the applicable minimum wage under section 2(a)(ii) of Executive Order 13658 results in a higher minimum wage. Adjustments to the Executive Order minimum wage under section 2(a)(ii) of Executive Order 13658 will be effective for all service employees, laborers, or mechanics subject to the Executive Order beginning January 1 of the following year. The Secretary of Labor will publish annual determinations in the Federal Register no later than 90 days before such new wage is to take effect. The Secretary will also publish the applicable minimum wage on www.wdol.gov (or any successor website). The applicable published minimum wage is incorporated by reference into this contract.

(c) The Contracting Officer will adjust the contract price or contract unit price under this clause only for the increase in labor costs resulting from the annual inflation increases in the Executive Order 13658 minimum wage beginning on January 1, 2016. The Contracting Officer shall consider documentation as to the specific costs and workers impacted in determining the amount of the adjustment.

(d) The Contracting Officer will not adjust the contract price under this clause for any costs other than those identified in paragraph (c) of this clause, and will not provide price adjustments under this clause that result in duplicate price adjustments with the respective clause of this contract implementing the Service Contract Labor Standards statute (formerly known as the Service Contract Act) or the Wage Rate Requirements (Construction) statute (formerly known as the Davis Bacon Act).

(e) The Contractor shall include the substance of this clause, including this paragraph (e) in all subcontracts.

(End of clause)

52.232-99 Providing Accelerated Payment to Small Business Subcontractors (DEVIATION)

The contracting officer shall insert the following clause in all solicitations and resultant contracts.

PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS SUBCONTRACTORS

(DEVIATION) (AUG 2012)

This clause implements the temporary policy provided by OMB Policy Memorandum M-12-16, Providing Prompt Payment to Small Business Subcontractors, dated July 11, 2012.

(a) Upon receipt of accelerated payments from the Government, the contractor is required to make accelerated payments to small business subcontractors to the maximum extent practicable after receipt of a proper invoice and all proper documentation from the small business subcontractor.

(b) Include the substance of this clause, including this paragraph (b), in all subcontracts with small business concerns.

(c) The acceleration of payments under this clause does not provide any new rights under the Prompt Payment Act.

3052.209-70 Prohibition on contracts with corporate expatriates.

RESERVED - See HSAR Class Deviation (Number 09-02), July 2, 2009.

J - List of Documents, Exhibits and Other Attachments

List of Documents, Exhibits, and Other Attachments

Attachment Number Title Date

K - Representations, Certifications, and Other Statements of Bidders

Clauses

52.204-19 Incorporation by Reference of Representations and Certifications. (DEC 2014)

52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-Representation and Certifications. (OCT 2015)

52.227-6 Royalty Information. (APR 1984) - Alternate I (APR 1984)

(a) When the response to this solicitation covers charges for special construction or special assembly that contain costs or charges for royalties totaling more than $250, the following information shall be included in the response relating to each separate item of royalty or license fee:

(1) Name and address of licensor.

(2) Date of license agreement.

(3) Patent numbers, patent application serial numbers, or other basis on which the royalty is payable.

(4) Brief description, including any part or model numbers of each contract item or component on which the royalty is payable.

(5) Percentage or dollar rate of royalty per unit.

(6) Unit price of contract item.

(7) Number of units.

(8) Total dollar amount of royalties.

(b) Copies of current licenses. In addition, if specifically requested by the Contracting Officer before execution of the contract, the offeror shall furnish a copy of the current license agreement and an identification of applicable claims of specific patents.

(End of provision)

52.227-7 Patents - Notice of Government Licensee. (APR 1984)

The Government is obligated to pay a royalty applicable to the proposed acquisition because of a license agreement between the Government and the patent owner. The patent number is [Contracting Officer fill in], and the royalty rate is [Contracting Officer fill in]. If the offeror is the owner of, or a licensee under, the patent, indicate below:

[ ] Owner [ ] Licensee

If an offeror does not indicate that it is the owner or a licensee of the patent, its offer will be evaluated by adding thereto an amount equal to the royalty.

(End of provision)

52.236-28 Preparation of Proposals - Construction. (OCT 1997)

3052.209-79 Representation by Corporations Regarding a Felony Criminal Violation under any Federal or State Law or Unpaid Federal Tax Liability. (FEB 2014) (DHS FAR CLASS DEVIATION 14-02)

(a) In accordance with sections 561 and 562 of Division F, Title V of the Consolidated Appropriations Act, 2014 (Pub. L. 113-76), none of the funds made available by that Act may be used to enter into a contract with any corporation that:

(1) Was convicted (or had an officer or agent of such corporation acting on behalf of the corporation convicted) of a felony criminal violation under any Federal or State law within the preceding 24 months, where the awarding agency is aware of the conviction, unless the agency has considered suspension or debarment of the corporation, or such officer or agency, and made a determination that this further action is not necessary to protect the interests of the Government.

(2) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless the agency has considered suspension or debarment of the corporation and made a determination that this further action is not necessary to protect the interests of the Government.

(b) The Offeror represents that:

(1) It is [ ] is not [ ] a corporation that was convicted (or had an officer or agent of such corporation acting on behalf of the corporation convicted) of a felony criminal violation under any Federal or State law within the preceding 24 months.

(2) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability.

(c) If the offeror represents in (b) above that it is a corporation that was convicted (or had an officer or agent of such corporation acting on behalf of the corporation convicted) of a felony criminal violation under any Federal or State law within the preceding 24 months, or that it is a corporation that has unpaid Federal tax liability that has been assessed, the offeror shall provide all information related to the felony or tax liability within 3 business days of the Government¿s request.

(End of provision)