IFB_Construction.docx

SCHEDULE OF MATERIAL SUBMITTALS

PROJECT TITLE

PROJECT NUMBER

CONTRACT NUMBER

HSCG82-08-

SPECIFICATION AND

PARAGRAPH NUMBER

NUMBER

MANAGER

DATE CONTRACTOR

NOTIFIED

REMARKS

APPENDIX C – CHAPTER 3033

NOTICE FOR FILING AGENCY PROTESTS

United States Coast Guard Ombudsman Program

It is the policy of the United States Coast Guard (USCG) to issue solicitations and make contract awards in a fair and timely manner. The Ombudsman Program for Agency Protests (OPAP) was established to investigate agency protest issues and resolve them without expensive and time-consuming litigation. OPAP is an independent reviewing authority that is empowered to grant a prevailing protester essentially the same relief as the Government Accountability Office (GAO).

Interested parties are encouraged to seek resolution of their concerns within the USCG as an Alternative Dispute Resolution (ADR) forum rather than filing a protest with the GAO or some external forum. Interested parties may seek resolution of their concerns informally or opt to file a formal agency protest.

Informal Forum with the Ombudsman. Interested parties who believe a specific USCG procurement is unfair or otherwise defective should first direct their concerns to the applicable Contracting Officer. If the Contracting Officer is unable to satisfy their concerns, interested parties are encouraged to contact the U.S. Coast Guard Ombudsman for Agency Protests. Under this informal process the agency is not required to suspend contract award performance. Use of an informal forum does not suspend any time requirement for filing a protest with the agency or other forum. In order to ensure a timely response, interested parties should provide the following information to the Ombudsman: solicitation/contract number, contracting office, Contracting Officer, and solicitation closing date (if applicable).

Formal Agency Protest with the Ombudsman. Prior to submitting a formal agency protest, protesters must first use their best efforts to resolve their concerns with the Contracting Officer through open and frank discussions. If the protester’s concerns are unresolved, an Independent Review is available by the Ombudsman. The protester may file a formal agency protest to either the Contracting Officer or as an alternative to that, the Ombudsman under the OPAP program. Contract award or performance will be suspended during the protest period unless contract award or performance is justified, in writing, for reasons of unusual and compelling urgency or is determined in writing to be in the best interest of the Government. The agency’s goal is to resolve protests in less than 35 calendar days from the date of filing. Protests shall include the information set forth in FAR 33.103(d) (2). If the protester fails to submit the required information, resolution of the protest may be delayed or the protest may be dismissed. To be timely protests must be filed within the period specified in FAR 33.103(e). Formal protests filed under the OPAP program shall be submitted electronically to OPAP@uscg.mil and the Contracting Officer or by hand delivery to the Contracting Officer.

The Ombudsman Hotline telephone number is 202.372.3695.

PART I – THE SCHEDULE

SECTION A - SOLICITATION/CONTRACT FORM/INDEX

Table of Contents

SOLICITATION OFFER

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

HSCG82-15-B-PMV076

2. tYPE OF SOLICITATION

|X| SEALED BID (IFB)

|_| NEGOTIATED (RFP)

3. DATE ISSUED

05/05/2015

PAGE OF PAGES

IMPORTANT - The "offer" section on page 2 must be fully completed by offeror.

4. contract nO.

5. requisition/purchase request no.

21-15-825PMV076

6. project no.

5897961

7. issued by code

8. address offer to

CONTRACTING OFFICER

USCG CIVIL ENGINEERING UNIT MIAMI

15608 SW 117TH AVENUE

MIAMI, FLORIDA 33177-1630

SAME AS BLOCK 7

9. FOR INFORMATION

CALL

a. name

HALIM TOULAS

b telephone no. (Include area code) (no collect calls)

(305) 278-6720

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date):

THIS IS A HUBZONE SMALL BUSINESS CONCERN SET-ASIDE

SUMMARY OF WORK: CONTRACTOR SHALL PROVIDE ALL LABOR, EQUIPMENT, TOOLS, MATERIALS AND SUPERVISION NECESSARY FOR REPLACEMENT OF FLOATING DOCKS AND TIMBER FILE FENDER SYSTEM AT U.S. COAST GUARD GEORGETOWN, SOUTH CAROLINA IN STRICT ACCORDANCE WITH THE SPECIFICATIONS (PROJECT NO. 5897961), DRAWINGS NUMBER (M2066-D) AND THE CONTRACT.

SITE-VISIT POC: MK1 KEVIN BASHAW @ (843) 546-2742

***Notice that funds are not presently available as required by CGAP 3032.703-91.

Offerors are requested to review this IFB as soon as possible upon receipt. If an offeror has any questions regarding the solicitation which require an answer from the issuing office, these questions shall be submitted, in writing, referencing section and paragraph of solicitation, to the U.S. Coast Guard, Civil Engineering Unit Miami, 15608 SW 117 Avenue, Miami, FL 33177. The deadline for submitting Requests for Information (RFIs) and be guaranteed answers is (15 days before Bid Opening Date at 2:00PM); any RFI's received after this date the Government cannot guarantee an answer. A final amendment with questions and answers will be issued 10 days prior to proposal due date. Email address is: halim.toulas@uscg.mil

11. The contractor shall begin performance within 10 calendar days and complete it within 120 calendar days after receiving |_| award, |X| notice to proceed. This performance period is |X| mandatory |_| negotiable. (See Section F).

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

|X| YES |_| NO

12b. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and 0 copies to perform the work required are due at the place specified in Item 8 by 2:00 PM (hour) local time JUNE 4, 2015 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

b. An offer guarantee |X| is, |_| is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than 60 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

OFFER (Must be fully completed by offeror)

14. name and address of offeror (Include ZIP Code)

15. telephone no. (Include area code)

DUNS: _________________________________________

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation - give number and date of each)

20a. name and title of person authorized to sign offer (Type or print) 20b. signature

20c. offer date

AWARD (To be completed by Government)

21. items accepted:

22. amount

23. accounting and appropriation data

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM

BLOCK 27

25. Other than full and open competition pursuant to |_| 10 USC 2304(c) ( 5 ) |_| 41 USC USC 253(c) ( )

26. administered by code

27. payment will be made by

CONTRACTING OFFICER

USCG CIVIL ENGINEERING UNIT MIAMI

15608 SW 117TH AVENUE

MIAMI, FLORIDA 33177-1630

COMMERCIAL INVOICES

U. S. COAST GUARD FINANCE CENTER

1430A KRISTINA WAY

CHESAPEAKE, VA 23326-0324

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

|_| 28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return _____ copies to issuing office.) Contractor agrees to furnish and deliver all items or perform all work, requisitions identified on this form and any continuation sheets for the consideration slated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications or incorporated by reference in or attached to this contract.

|_| 29. AWARD (Contractor is not required to sign this document) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31a. name of contracting officer (Type or print)

30b. signature

30c. DATE

31b. united states of america by 31c. date

STANDARD FORM 1442 (REV. 4-85) BACK

SECTION B - SUPPLIES OR SERVICES AND PRICES

BASE BID ITEM: CONTRACTOR SHALL PROVIDE ALL LABOR, EQUIPMENT, TOOLS, MATERIALS AND SUPERVISION NECESSARY FOR REPLACEMENT OF FLOATING DOCKS AND TIMBER FILE FENDER SYSTEM AT U.S. COAST GUARD GEORGETOWN, SOUTH CAROLINA IN STRICT ACCORDANCE WITH THE SPECIFICATIONS (PROJECT NO. 5897961), DRAWINGS NUMBER (M2066-D) AND THE CONTRACT.

ONE JOB COMPLETE $

SECTION C - DESCRIPTION/SPECIFICATIONS/WORK STATEMENT

C.1 SPECIFICATIONS AND DRAWINGS:

(a) SEE SECTION J - “LIST OF ATTACHMENTS”

(b) DRAWINGS MEASUREMENTS SHOULD BE FIELD VERIFIED BY THE SUCCESSFUL CONTRACTOR PRIOR TO ORDERING MATERIAL

(c) Failure to read the specifications in their entirety will not relieve the offerors from responsibility for properly estimating the difficulty or cost of successfully performing the work. Failure to do so will be at offeror’s risk.

(d) Each offeror shall furnish the information required by the solicitation. Any offer that does not conform to the requirements of this solicitation in every respect will be rejected as non-responsive. Deviations from, or exceptions to, the specifications or delivery schedule are causes for rejection. Offers for supplies or services other than those specified will not be considered unless authorized by this solicitation.

SECTION D - PACKAGING AND MARKING

THIS SECTION IS NOT APPLICABLE

SECTION E - INSPECTION AND ACCEPTANCE

E.1 52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

(a) Definition. “Work” includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not –

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) below.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer’s written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes re-inspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may (1) by contract or otherwise, replace or correct the work and charge the cost to the Contractor or (2) terminate for default the Contractor’s right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or non conforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.

(End of clause)

E.2 CONTRACTOR INSPECTION SYSTEM

(a) Provide all necessary equipment, instruments, qualified personnel, facilities, and test fluids and gases, and perform all inspections, sampling, testing, and certifications specified in the individual Sections of the Specifications; fill out Daily Construction Report forms as documentation and submit the forms to the Government inspector by 10:00 a.m. on the first working day following the day the work was performed. Sample forms are provided in Section J of this contract. Daily Construction Report forms will be furnished to the Contractor.

SECTION F - DELIVERIES OR PERFORMANCE

F.1 THE FOLLOWING FEDERAL ACQUISITION REGULATION CLAUSES ARE INCORPORATED BY REFERENCE:

52.242-14 SUSPENSION OF WORK (APR 1984)

F.2 IN ADDITION TO THE ABOVE CLAUSES INCORPORATED BY REFERENCE, THE FOLLOWING CLAUSES ARE APPLICABLE TO THE SOLICITATION AND RESULTING CONTRACT:

(End of clause)

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

(a) The Contractor shall, within five days after the work commences on the contract or another period of time determined by the Contracting Officer, prepare and submit to the Contracting Officer for approval three copies of a practicable schedule showing the order in which the Contractor proposes to perform the work, and the dates on which the Contractor contemplates starting and completing the several salient features of the work (including acquiring materials, plant, and equipment). The schedule shall be in the form of a progress chart of suitable scale to indicate appropriately the percentage of work schedules for completion by any given date during the period. If the Contractor fails to submit a schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.

(b) The Contractor shall enter the actual progress on the chart as directed by the Contracting Officer, and upon doing so shall immediately deliver three copies of the annotated schedule to the Contracting Officer. If, in the opinion of the Contracting Officer, the Contractor falls behind the approved schedule, the Contractor shall take steps necessary to improve its progress, including those that may be required by the Contracting Officer, without additional cost to the Government. In this circumstance the Contracting Officer may require the Contractor to increase the number of shifts overtime operations days of work and/or the amount of construction plant and to submit for approval any supplementary schedule or schedules in chart form as the Contracting Officer deems necessary to demonstrate how the approved rate of progress will be regained.

(c) Failure of the Contractor to comply with the requirements of the Contracting Officer under this clause shall be grounds for a determination by the Contracting Officer that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the time specified in the contract. Upon making this determination, the Contracting Officer may terminate the Contractor’s right to proceed with the work, or any separable part of it, in accordance with the default terms of this contract.

(End of clause)

F.3 CONTRACTOR’S SCHEDULE

A preliminary copy of the Contractor’s proposed schedule shall be prepared and submitted to the Contracting Officer prior to the preconstruction conference. Any questions or problems that might cause a delay in approval of the schedule can be addressed during this conference.

SECTION G - CONTRACT ADMINISTRATION DATA

G.1 SUBMITTALS/SHOP DRAWINGS:

Contractor shall provide a schedule of required submittals indicating the order in which the Contractor proposes to provide the required submittals and the dates on which the Contractor plans to provide said submittals. This schedule shall be provided prior to the preconstruction conference for review and discussion during the conference. The Contractor is to forward five (5) copies of applicable submittals to the Contracting Officer. The Contracting Officer will indicate his/her approval or disapproval of the submittals/shop drawings and if not approved as submitted shall indicate reasons thereof. Any work done prior to such approval shall be at the Contractor’s risk. Approval by the Contracting Officer shall not relieve the Contractor from responsibility for any errors or omissions in such drawings, nor from the responsibility for complying with the requirements of this contract.

G.2 PRECONSTRUCTION CONFERENCE:

As soon as practicable after the award of contract, a mutually agreeable time and date for a preconstruction conference between the representatives of the Government and the Contractor will be established. This conference will be held either by telephone or, if convenient, at the site or this office to discuss the terms and conditions of the contract. Below are some of the items to be discussed:

(a) Detailed procedures for the administration of the project,

(b) Identify the authorized representatives of the Government and the Contractor’s Superintendent(s),

(c) Contractor’s field office address and telephone number,

(d) Contractor’s draft Construction Progress Schedule (Section F (F.4)) The Notice to Proceed date will be established during this meeting.

(e) Procedures for processing periodic pay estimates (Section G (G.3-6))

(f) Review of Submittal Schedule giving proposed dates Contractor will submit all required contract submittals (Section G (G.1))

(g) Requirements and procedures for preparing work schedules and reporting programs,(Section E (E.2))

(h) Procedures for equal opportunity compliance,

(i) Information on delivery of Government-furnished property (If Applicable).

G.3 DESIGNATED BILLING OFFICE

(a) Submit original invoice to the following designated billing office via one of the following modes, listed in descending order of preference:

(1) FINCEN Website invoice receipt form:

http://www.fincen.uscg.mil/centralinv/central_inv_contr.cfm

(2) Fax: 757-523-6900

(b) Submit a copy of the invoice with any required supporting documentation to the Contracting Office:

CONTRACTING OFFICER

U. S. COAST GUARD

MIAMI, FLORIDA 33177-1630

(c) To facilitate processing, all proper invoices and any supporting information submitted electronically using the FINCEN web based invoice submission capability must be submitted as a single Adobe (.pdf) formatted file, or as otherwise specified in the contract.

(d) Web based submission by the contractor and receipt confirmation does not reflect Government review or acceptance of the invoice.

(e) Payment inquiries and status may be obtained - at the following website: -.

G.4 INVOICE

(a) To be accomplished on the form provided by the Coast Guard. See Section J for copy of said form.

(b) In addition to the items required for a proper invoice under FAR 52.232-5 and 52.232-27, the invoice must also include the following information:

1. Invoice Routing Code: CEU-MIAMI

2. Name of the Contract Specialist

3. Indication that the contractor represents a small business for accelerated payment purposes.

(c) To facilitate the approval and processing of an invoice, contractor shall furnish an advance copy of the invoice to the Contracting Officer’s Technical Representative for review of the invoice amount and estimates of work accomplished prior to submission to the billing office.

G.5 GOVERNMENT REPRESENTATIVES

The Government may, upon contract award or thereafter, name representatives with titles such as Project Engineer, Contracting Officer’s Technical Representative(s), Inspector(s), and so on. Such individuals will be named in writing by the Contracting Officer, with individual responsibilities set forth at that time.

In any event, no such named individual has the authority to issue any direction under this contract either technical or otherwise, which constitutes a change to the terms, conditions, and price or delivery schedule of the contract. Only the Contracting Officer is authorized to alter the contract in any manner.

SECTION H - SPECIAL CONTRACT REQUIREMENTS

H.1. JOB SUPERINTENDENT

Special attention is called to the requirement for superintendence by the Contractor, FAR Clause 52.236-6. The contractor shall provide a job superintendent on the site at all times during contract performance that is able to read, write, understand, and speak English.

H.2 MODIFICATION PROPOSALS - PRICE BREAKDOWN

The contractor, in connection with any proposal made for a contract modification, shall furnish a price breakdown, itemized as required by the Contracting Officer. Unless otherwise directed, the breakdown shall be in sufficient detail to permit an analysis of all material, labor, equipment, subcontract, and overhead costs, as well as profit, and shall cover all work changed. Any amount claimed for subcontracts shall be supported by a similar price breakdown. In addition, if the proposal includes a time extension, a justification therefore shall also be furnished. The proposal, together with the price breakdown and time extension justification, shall be furnished by the date specified by the Contracting Officer. Once a contract modification has been authorized, the contractor shall submit an updated progress schedule that includes all changes implemented by the modification.

H.3 SANITATION

Adequate sanitary conveniences of an approved type for the use of persons employed on the work, and properly secluded from public observation, shall be constructed and maintained by the Contractor in such a manner and at such points as shall be required or approved by the Contracting Officer. These conveniences shall be maintained at all times without nuisance and their use shall be strictly enforced. Upon completion of the work they shall be removed from the premises, leaving the premises clean and free from nuisance.

H.4 WORK OUTSIDE REGULAR WORK HOURS

If the contractor desires to perform work under this contract outside regular work hours or on Saturdays, Sundays or holidays, a written request shall be made, to the Contracting Officer no less than 10 calendar days prior to the planned start of such work. Regular work hours are, for the purpose of this clause, those hours the activity or Command, where the work is to be performed, normally works on a day-by-day basis. Application by the Contractor does not imply consent by the Government. Each application will be considered, and a decision made, on the potential benefit of permitting such work. Approval of a Contractor’s application under this clause will be, unless otherwise agreed in writing, at no additional cost to the Government.

H.5 STATEMENT AND ACKNOWLEDGMENT FORM (SF 1413)

Special attention is called to the requirement for insertion of and compliance with various labor clauses called out in FAR Clause 52.222-11 in any subcontracts regardless of tier. Within 14 days after contract award of the prime contract, an executed SF-1413 is required for each subcontract. This also applies to any subsequently awarded subcontract.

H.6 REQUIRED BONDING –

PERFORMANCE BOND (Standard Form 25) will be required as follows: 100% of total amount of contract;

PAYMENT BOND (Standard Form 25a) will be required as follows: 100% of total amount of contract;

Performance and payment bonds placed with a surety or sureties acceptable to the Government and in the amounts indicated shall be submitted within ten (10) calendar days after receipt of award and shall be maintained for the entire contract.

H.7 REQUIRED INSURANCE

(a) The contractor shall procure and maintain insurance during the entire period of performance under this contract, in accordance with Federal Acquisition Regulation Clause 52.228-5, INSURANCE - WORK ON A GOVERNMENT INSTALLATION (JAN 1997) (See Section I). FAR 28.307-2 states the following minimum amounts of liability:

MINIMUM COVERAGE REQUIRED

(1) Workers’ Compensation and Employer’s Liability - at least $100,000 shall be required, except in States with exclusive or monopolistic funds that do not permit workers’ compensation to be written by private carriers.

(2) General Liability. - bodily injury liability insurance coverage written on the comprehensive form of policy of at least $500,000. per occurrence.

(3) Automobile Liability. - automobile liability insurance written on the comprehensive form of policy of at least $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage.

(b) As evidence that the specified insurance has been obtained, the contractor shall furnish the contracting officer with a certificate of insurance. Such certificate shall be furnished prior to commencement of work and shall provide for thirty (30) calendar days written notice to the Contracting Officer.

PART II – CONTRACT CLAUSES

SECTION I - CONTRACT CLAUSES

I.1 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if it was given in full text. Upon request, the Contracting Officer will make full text available. Also, the full text of a clause may be assessed electronically at this/these address(es): http://www.arnet.gov/far/

I.2 FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES

(d) The environmental point of contact for this contract is: Halim Toulas

I.3 DEPARTMENT OF HOMELAND SECURITY REGULATION (HSAR) (48 CFR CHAPTER 30) CLAUSES

I.4 IN ADDITION TO THE ABOVE CLAUSES INCORPORATED BY REFERENCE, THE FOLLOWING CLAUSES ARE APPLICABLE TO THE SOLICITATION AND RESULTING CONTRACT:

52.204-1 APPROVAL OF CONTRACT (DEC 1989)

This contract is subject to the written approval of Senior Field Contracting Officer, Civil Engineering Unit Miami and shall not be binding until so approved.

(End of Clause)

52.225-9 BUY AMERICAN ACT—CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. As used in this clause-- “Commercially available off-the-shelf (COTS) item”—

(1) Means any item of supply (including construction material) that is—

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

“Component” means an article, material, or supply incorporated directly into a construction material.

“Construction material” means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

“Cost of components” means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

“Domestic construction material” means—

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if—

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which non-availability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

“Foreign construction material” means a construction material other than a domestic construction material.

“United States” means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements the 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows: ______ [Contracting Officer to list applicable excepted materials or indicate “none”]

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute.

(1)

(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison

Item 1

Foreign construction material

Domestic construction material

Item 2

Foreign construction material

Domestic construction material

[List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.] [Include other applicable supporting information.] [*Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).] (End of Clause)

3052.204-71 CONTRACTOR EMPLOYEE ACCESS (SEP 2012)

(a) Sensitive Information, as used in this clause, means any information, which if lost, misused, disclosed, or, without authorization is accessed, or modified, could adversely affect the national or homeland security interest, the conduct of Federal programs, or the privacy to which individuals are entitled under section 552a of title 5, United States Code (the Privacy Act), but which has not been specifically authorized under criteria established by an Executive Order or an Act of Congress to be kept secret in the interest of national defense, homeland security or foreign policy. This definition includes the following categories of information:

(1) Protected Critical Infrastructure Information (PCII) as set out in the Critical Infrastructure Information Act of 2002 (Title II, Subtitle B, of the Homeland Security Act, Public Law 107-296, 196 Stat. 2135), as amended, the implementing regulations thereto (Title 6, Code of Federal Regulations, Part 29) as amended, the applicable PCII Procedures Manual, as amended, and any supplementary guidance officially communicated by an authorized official of the Department of Homeland Security (including the PCII Program Manager or his/her designee);

(2) Sensitive Security Information (SSI), as defined in Title 49, Code of Federal Regulations, Part 1520, as amended, “Policies and Procedures of Safeguarding and Control of SSI,” as amended, and any supplementary guidance officially communicated by an authorized official of the Department of Homeland Security (including the Assistant Secretary for the Transportation Security Administration or his/her designee);

(3) Information designated as “For Official Use Only,” which is unclassified information of a sensitive nature and the unauthorized disclosure of which could adversely impact a person’s privacy or welfare, the conduct of Federal programs, or other programs or operations essential to the national or homeland security interest; and

(4) Any information that is designated “sensitive” or subject to other controls, safeguards or protections in accordance with subsequently adopted homeland security information handling procedures.

(b) “Information Technology Resources” include, but are not limited to, computer equipment, networking equipment, telecommunications equipment, cabling, network drives, computer drives, network software, computer software, software programs, intranet sites, and internet sites.

(c) Contractor employees working on this contract must complete such forms as may be necessary for security or other reasons, including the conduct of background investigations to determine suitability. Completed forms shall be submitted as directed by the Contracting Officer. Upon the Contracting Officer's request, the Contractor's employees shall be fingerprinted, or subject to other investigations as required. All Contractor employees requiring recurring access to Government facilities or access to sensitive information or IT resources are required to have a favorably adjudicated background investigation prior to commencing work on this contract unless this requirement is waived under Departmental procedures.

(d) The Contracting Officer may require the Contractor to prohibit individuals from working on the contract if the Government deems their initial or continued employment contrary to the public interest for any reason, including, but not limited to, carelessness, insubordination, incompetence, or security concerns.

(e) Work under this contract may involve access to sensitive information. Therefore, the Contractor shall not disclose, orally or in writing, any sensitive information to any person unless authorized in writing by the Contracting Officer. For those Contractor employees authorized access to sensitive information, the Contractor shall ensure that these persons receive training concerning the protection and disclosure of sensitive information both during and after contract performance.

(f) The Contractor shall include the substance of this clause in all subcontracts at any tier where the subcontractor may have access to Government facilities, sensitive information, or resources.

(End of clause)

3052.209-70 PROHIBITION ON CONTRACTS WITH CORPORATE EXPATRIATE (DEVIATION) (JUN 2006)

(a) Prohibitions. Section 835 of the Homeland Security Act, 6 U.S.C. 395, prohibits the Department of Homeland Security from entering into any contract with a foreign incorporated entity which is treated as an inverted domestic corporation as defined in this clause, or with any subsidiary of such an entity. The Secretary shall waive the prohibition with respect to any specific contract if the Secretary determines that the waiver is required in the interest of national security.

(b) Definitions. As used in this clause:

Expanded Affiliated Group means an affiliated group as defined in section 1504(a) of the Internal Revenue Code of 1986 (without regard to section 1504(b) of such Code), except that section 1504 of such Code shall be applied by substituting `more than 50 percent' for `at least 80 percent' each place it appears.

Foreign Incorporated Entity means any entity which is, or but for subsection (b) of section 835 of the Homeland Security Act, 6 U.S.C. 395, would be, treated as a foreign corporation for purposes of the Internal Revenue Code of 1986.

Inverted Domestic Corporation. A foreign incorporated entity shall be treated as an inverted domestic corporation if, pursuant to a plan (or a series of related transactions)—

(1) The entity completes the direct or indirect acquisition of substantially all of the properties held directly or indirectly by a domestic corporation or substantially all of the properties constituting a trade or business of a domestic partnership;

(2) After the acquisition at least 80 percent of the stock (by vote or value) of the entity is held—

(i) In the case of an acquisition with respect to a domestic corporation, by former shareholders of the domestic corporation by reason of holding stock in the domestic corporation; or

(ii) In the case of an acquisition with respect to a domestic partnership, by…