HSCG80-15-Q-P00430.pdf

NOTICE FOR FILING AGENCY PROTESTS

It is the policy of the United States Coast Guard (USCG) to issue solicitations and make contract awards in a fair and timely manner. The Ombudsman Program for Agency Protests (OPAP) was established to investigate agency protest issues and resolve them without expensive and time-consuming litigation. OPAP is an independent reviewing authority that is empowered to grant a prevailing protester essentially the same relief as the Government Accountability Office (GAO). Interested parties are encouraged to seek resolution of their concerns within the USCG as an Alternative Dispute Resolution (ADR) forum, rather than filing a protest with the GAO or some external forum. Interested parties may seek resolution of their concerns informally or opt to file a formal agency protest with the contracting officer or Ombudsman.

Informal forum with the Ombudsman. Interested parties who believe a specific USCG procurement is unfair or otherwise defective should first direct their concerns to the cognizant contracting officer. If the contracting officer is unable to satisfy the concerns, the interested party is encouraged to contact the USCG Ombudsman for Agency Protests. Under this informal process, the agency is not required to suspend contract award performance. Use of an informal forum does not suspend any time requirement for filing a protest with the agency or other forum. In order to ensure a timely response, interested parties should provide the following information to the Ombudsman: solicitation/contract number, contracting office, contracting officer, and solicitation closing date (if applicable).

Formal Agency Protest with the Ombudsman. Prior to submitting a formal agency protest, protesters must first use their best efforts to resolve their concerns with the contracting officer through open and frank discussions. If the protester's concerns are unresolved, an independent review is available by the Ombudsman. The protester may file a formal agency protest to either the contracting officer or as an alternative to that, the Ombudsman under the OPAP program. Contract award or performance will be suspended during the protest period unless contract award or performance is justified, in writing, for urgent and compelling reasons or is determined in writing to be in the best interest of the Government. The agency's goal is to resolve protests in less than 35 calendar days from the date of filing. Protests shall include the information set forth in FAR 33.103. If the protester fails to submit the required information, resolution of the protest may be delayed or the protest may be dismissed. This will not preclude re-filing of the protest to meet the requirement. To be timely, protests must be filed within the period specified in FAR 33.103(e). Formal protests filed under the OPAP program should be submitted to:

Department of Homeland Security United States Coast Guard (CG-91) Ombudsman Program for Agency Protests Email: OPAP@uscg.mil Fax: 202-372-8447 Phone: 202-475-5786

More information about the Ombudsman Program for Agency Protests (OPAP) can be found at http://www.uscg.mil/acquisition/business/ombudsman.asp

HSCG80-15-Q-P00430 PAGE 2 OF 39

USCGC CROCODILE (WPB-87369)

W5 / DOCK SIDE REPAIRS

COMBINED SYNOPSIS/ SOLICITATION FOR

DOCK SIDE REPAIRS (W5 TOP END OVERHAUL) FOR USCGC CROCODILE (WPB-87369)

This is a combined synopsis/solicitation for commercial services prepared in accordance with the format in FAR Subpart 12.6, supplemented with additional information included in this notice. This announcement constitutes the only solicitation;

quotations are being requested and a separate written solicitation will not be issued.

The solicitation is issued as a Request for Quotation (RFQ). This solicitation document and incorporated provisions and clauses are those in effect through Federal Acquisition Circular FAC 2005-77. This requirement is being solicited as a Total Small Business Set-aside using Simplified Acquisition Procedures per FAR Subpart 13. The NAICS Code is 336611, Ship Building and Repairing with a small business size standard of 1,000 employees. The solicitation number is HSCG80-15-Q- P00430.

CONTRACT ADMINISTRATION:

The U.S. Department of Homeland Security, U.S. Coast Guard, Surface Forces Logistic Command, CPD, 300 East Main Street, Suite 600, Norfolk, VA 23510-9112 will perform all contract administration. Communications pertaining to contractual administrative matters shall be addressed to one of the Contracting Officers (KO) listed below. Changes in, or deviations from, the specification or terms and conditions of the contract shall not be effected without written modification to the contract as executed by a USCG SFLC CPD Contracting Officer.

The Contracting Officer for this requirement is Andrew Northcutt. He may be reached at 757-441-7032 or Andrew.j.northcutt@uscg.mil.

The Contract Specialist for this requirement is Bernie Caguiat. He may be reached at 510-637-5887 or Bernie.c.caguiat@uscg.mil

The Contracting Officers Representative (COR) is LT Andrew Armstrong. The COR may be reached at 305-926-9333 or Andrew.p.armstrong1@uscg.mil. The COR is the government personnel designated in writing by the Contracting Officer to act as a technical advisor for the Contracting Officer for terms within the scope of the contract. A designation letter will set forth the authorities and limitation of the COR under this contract.

REQUIRED DOCUMENT

Each quoter shall furnish the information required by the solicitation, which includes:

1. Completed USCGC CROCODILE of supplies and services on Page 4

2. Past Performance Documentation page 25

3. Small Business Self Certification annotating Small Business Status under NAICS Code 336611

4. Statement of Insurance Coverage from current Insurance carrier on pages 14 & 15

5. Proof of MTU Certified Technical Representative as outlined on page 25

PLACE OF PERFORMANCE

The place of performance will be at USCGC CROCODILE (WPB-87369); mooring located at 600 8th Ave SE, St. Petersburg, FL 33701.

ANTICIPATED AWARD DATE

The anticipated award date is on or about 23 December 2014, however it is subject to change. The government intends to award a fixed priced contract resulting from this solicitation to the responsible vendor whose complete quote, conforming to the solicitation, provides the best and final offer.

Work covered by this solicitation shall be completed within thirty-four (34) calendar days from the date the vessel becomes available to the Contractor. The availability is scheduled to start on or about 07 January 2015 and end on or about 08 February 2015. An arrival conference normally will be held within 48 hours of the scheduled start date.

HSCG80-15-Q-P00430 PAGE 3 OF 39

QUESTIONS AND REQUEST FOR DRAWINGS: The last day to request drawings or ask questions regarding this solicitation is 03 December 2014 at 10:00AM Pacific Time. After this date further requests may not be accepted due to time constraints. For questions regarding this solicitation, contact Bernie Caguiat, Contract Specialist at 510-637-5887 or Bernie.c.caguiat@uscg.mil.

QUOTATION DUE DATE

Quotations must arrive no later than 10:00 a.m. Pacific Time, 17 December 2014. Quotations may be sent via electronic mail (e-mail) to Bernie.c.caguiat@uscg.mil.

PLEASE NOTE: QUOTATIONS THAT DO NOT INCLUDE ALL REQUIRED DOCUMENTS MAY BE CONSIDERED

INCOMPLETE AND MAY NOT BE CONSIDERED.

DESCRIPTION OF WORK

(a) The Contractor shall furnish all necessary labor, material, services, equipment, supplies, accessories, consumables, and such other things as are necessary, except as otherwise specified, to perform dock side repairs and alterations to the vessel, in accordance with this solicitation and attached USCGC CROCODILE (WPB-87369) specification for dock side repairs FY2015, Rev-0, 06 October 2014.

(b) Failure to read the specifications in their entirety will not relieve the offeror from the responsibility for properly estimating the difficulty or price of successfully performing the work. Failure to do so will be at the offeror’s risk. All Quotations submitted in response to this solicitation shall stand firm for 60 calendar days from the response date of this solicitation.

Each quoter shall furnish the information required by the solicitation, which includes:

1. Schedule of Supplies and Services filled out with a cost associated with each CLIN and cost and breakdown as outlined on page 4

2. Past Performance Documentation as outlined on page 25

3. Small Business Self Certification

4. Proof of Insurance (Statement of Coverage from current Insurance carrier) as outlined on page 14

5. Proof of MTU Certified Technical Representative as outlined on page 25

ALL CONTRACTORS ARE RESPONSIBLE FOR VERIFYING THE RECEIPT OF THEIR QUOTES.

PRICING DATA

Base Contract Line Item Numbers (CLINs) are marked as “D” for Definitive. Optional CLINs are marked “O” for Optional.

Insert unit prices in all CLINs listed in the Schedule unless “NSP” is printed in the Unit Price column for any CLIN. “NSP” in the section means “Not Separately Priced.”

CLIN D-C, “Travel and Per Diem”, is applicable only to Contractors not within the local commuting area (50 miles) of the vessel’s location. It is anticipated that any Contractors within the 50 mile commuting area will enter “zero” (0) or “N/A” for the unit and extended price for this CLIN, on the Schedule of Supplies or Services. The place of performance will be at the vessel’s moorings located at 600 8th Ave, St. Petersburg, FL 33701.

ITEM DESCRIPTION UNIT

PRICE

UNIT QTY EXTENDED

PRICE

D-001 Main Diesel Engine Assemblies, Perform W5 Maintenance (Port Side)

JOB 1

HSCG80-15-Q-P00430 PAGE 4 OF 39

O-00A Composite Labor Rate Hour 180

D-00B GFP Report NSP EA NSP

D-00C Travel and Per Diem JOB 1

Total Price of Definite Items

Total Price of Optional Items

Total Price of Definite and Optional Items

Inspection and Acceptance is at destination

CONTRACT CLAUSES

(1) FAR CLAUSE 52.212-4 CONTRACT TERMS AND CONDITIONS ---COMMERCIAL ITEMS (MAY 2014)

(a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance.

The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights --

(1) Within a reasonable time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C.3727). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract.

(c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties.

(d) Disputes. This contract is subject to the Contract Disputes Act of 1978, as amended (41 U.S.C. 601-613). Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at FAR 52.233-1, Disputes, which is incorporated herein by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract.

(e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference.

(f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

HSCG80-15-Q-P00430 PAGE 5 OF 39

(g) Invoice.

(1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include --

(i) Name and address of the Contractor;

(ii) Invoice date and number;

(iii) Contract number, contract line item number and, if applicable, the order number;

(iv) Description, quantity, unit of measure, unit price and extended price of the items delivered;

(v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading;

(vi) Terms of any discount for prompt payment offered;

(vii) Name and address of official to whom payment is to be sent;

(viii) Name, title, and phone number of person to notify in event of defective invoice; and

(ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract.

(x) Electronic funds transfer (EFT) banking information.

(A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract.

(B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer— System for Award Management, or 52.232-34, Payment by Electronic Funds Transfer—Other Than System for Award Management), or applicable agency procedures.

(C) EFT banking information is not required if the Government waived the requirement to pay by

EFT.

(2) Invoices will be handled in accordance with the Prompt Payment Act (31 U.S.C. 3903) and Office of Management and Budget (OMB) prompt payment regulations at 5 CFR part 1315.

(h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings.

(i) Payment.

(1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract.

HSCG80-15-Q-P00430 PAGE 6 OF 39

(2) Prompt Payment. The Government will make payment in accordance with the Prompt Payment Act (31 U.S.C.

3903) and prompt payment regulations at 5 CFR Part 1315.

(3) Electronic Funds Transfer (EFT). If the Government makes payment by EFT, see 52.212-5(b) for the appropriate EFT clause.

(4) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the specified payment date if an electronic funds transfer payment is made.

(5) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall—

(i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the—

(A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment);

(B) Affected contract number and delivery order number, if applicable;

(C) Affected contract line item or subline item, if applicable; and

(D) Contractor point of contact.

(ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer.

(6) Interest.

(i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in Section 611 of the Contract Disputes Act of 1978 (Public Law 95-563), which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period at fixed by the Secretary until the amount is paid.

(ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract.

(iii) Final decisions. The Contracting Officer will issue a final decision as required by 33.211 if—

(A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days;

(B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or

(C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see 32.607-2).

HSCG80-15-Q-P00430 PAGE 7 OF 39

(iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment.

(v) Amounts shall be due at the earliest of the following dates:

(A) The date fixed under this contract.

(B) The date of the first written demand for payment, including any demand for payment resulting from a default termination.

(vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on—

(A) The date on which the designated office receives payment from the Contractor;

(B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or

(C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor.

(vii) The interest charge made under this clause may be reduced under the procedures prescribed in 32.608-2 of the Federal Acquisition Regulation in effect on the date of this contract.

(j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon:

(1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or

(2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b.

destination.

(k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties.

(l) Termination for the Government’s convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor’s records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided.

(m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

HSCG80-15-Q-P00430 PAGE 8 OF 39

(n) Title. Unless specified elsewhere in this contract, title to items furnished under this contract shall pass to the Government upon acceptance, regardless of when or where the Government takes physical possession.

(o) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

(p) Limitation of liability. Except as otherwise provided by an express warranty, the Contractor will not be liable to the Government for consequential damages resulting from any defect or deficiencies in accepted items.

(q) Other compliances. The Contractor shall comply with all applicable Federal, State and local laws, executive orders, rules and regulations applicable to its performance under this contract.

(r) Compliance with laws unique to Government contracts. The Contractor agrees to comply with 31 U.S.C. 1352 relating to limitations on the use of appropriated funds to influence certain Federal contracts; 18 U.S.C. 431 relating to officials not to benefit; 40 U.S.C. 3701, et seq., Contract Work Hours and Safety Standards Act; 41 U.S.C. 51-58, Anti-Kickback Act of 1986;

41 U.S.C. 4712 and 10 U.S.C. 2409 relating to whistleblower protections; 49 U.S.C. 40118, Fly American; and 41 U.S.C. 423 relating to procurement integrity.

(s) Order of precedence. Any inconsistencies in this solicitation or contract shall be resolved by giving precedence in the following order:

(1) The schedule of supplies/services.

(2) The Assignments, Disputes, Payments, Invoice, Other Compliances, Compliance with Laws Unique to Government Contracts, and Unauthorized Obligations paragraphs of this clause.

(3) The clause at 52.212-5.

(4) Addenda to this solicitation or contract, including any license agreements for computer software.

(5) Solicitation provisions if this is a solicitation.

(6) Other paragraphs of this clause.

(7) The Standard Form 1449.

(8) Other documents, exhibits, and attachments.

(9) The specification.

(t) System for Award Management (SAM).

(1) Unless exempted by an addendum to this contract, the Contractor is responsible during performance and through final payment of any contract for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government’s reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in the SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document.

(2)

HSCG80-15-Q-P00430 PAGE 9 OF 39

(i) If a Contractor has legally changed its business name, “doing business as” name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in Subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day’s written notification of its intention to:

(A) Change the name in the SAM database;

(B) Comply with the requirements of Subpart 42.12 of the FAR;

(C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer.

The Contractor must provide with the notification sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (t)(2)(i) of this clause, or fails to perform the agreement at paragraph (t)(2)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the “Suspension of Payment” paragraph of the electronic funds transfer (EFT) clause of this contract.

(3) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims (see FAR Subpart 32.8, Assignment of Claims). Assignees shall be separately registered in the SAM database. Information provided to the Contractor’s SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the “Suspension of payment” paragraph of the EFT clause of this contract.

(4) Offerors and Contractors may obtain information on registration and annual confirmation requirements via SAM accessed through https://www.acquisition.gov.

(u) Unauthorized Obligations.

(1) Except as stated in paragraph (u)(2) of this clause, when any supply or service acquired under this contract is subject to any End Use License Agreement (EULA), Terms of Service (TOS), or similar legal instrument or agreement, that includes any clause requiring the Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C. 1341), the following shall govern:

(i) Any such clause is unenforceable against the Government.

(ii) Neither the Government nor any Government authorized end user shall be deemed to have agreed to such clause by virtue of it appearing in the EULA, TOS, or similar legal instrument or agreement. If the EULA, TOS, or similar legal instrument or agreement is invoked through an “I agree” click box or other comparable mechanism (e.g., “click-wrap” or “browse-wrap” agreements), execution does not bind the Government or any Government authorized end user to such clause.

(iii) Any such clause is deemed to be stricken from the EULA, TOS, or similar legal instrument or agreement.

(2) Paragraph (u)(1) of this clause does not apply to indemnification by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulations and procedures.

(End of Clause)

HSCG80-15-Q-P00430 PAGE 10 OF 39

ADDENDUM to FAR CLAUSE 52.212-4: the following paragraphs are added to the clause:

(2) FAR 52.217-7 OPTION FOR INCREASED QUANTITY – SEPARATELY PRICED LINE ITEM (MAR 1989) -

VARIATION

The Government may require the performance of the numbered line items, identified in the Schedule as option items, at the unit prices stated in the Schedule. The option quantities shown in the Schedule are estimates only. The Government has the right to require performance of these items at the quantities deemed necessary. Therefore, the Government may exercise an option item on more than one occasion during the contract performance period. The Contracting Officer will provide initial notification of the exercise of an option either verbally, by facsimile, or both. When time is of essence, initial notification will be provided verbally followed within 24 hours by a facsimile of confirmation. A contract modification will be executed shortly thereafter to include those options wherein exercise notification was provided. Such options may be exercised at any phase during the contract performance period as stated herein, or any extension of the performance period. To maintain the contract performance period the Contractor shall commence performance of an option item immediately upon receiving initial notification; but, not later than 24 hours thereafter, unless proper sequencing of the work requires a delay in beginning performance of the option. In that case, the option item shall be commenced as soon as proper sequencing permits. The exercise of any option item listed in the Schedule will not normally extend the contract performance period. However, the Contracting Officer may consider a request by the Contractor for contract extension if an option is exercised after 50% of the contract performance period has expired.

(3) 52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS SUBCONTRACTORS

As prescribed in 32.009-2, insert the following clause:

Providing Accelerated Payments to Small Business Subcontractors (Dec 2013)

(a) Upon receipt of accelerated payments from the Government, the Contractor shall make accelerated payments to its small business subcontractors under this contract, to the maximum extent practicable and prior to when such payment is otherwise required under the applicable contract or subcontract, after receipt of a proper invoice and all other required documentation from the small business subcontractor.

(b) The acceleration of payments under this clause does not provide any new rights under the Prompt Payment Act.

(c) Include the substance of this clause, including this paragraph (c), in all subcontracts with small business concerns, including subcontracts with small business concerns for the acquisition of commercial items.

(End of clause)

(4) FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text.

Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: http://www.arnet.gov/far/index.html

FAR 52.211-15 Defense Priority and Allocation Requirements (APR 2008) DO-N5 Rating

FAR 52.223-3 Hazardous Material Identification and Material Safety Data (JAN 1997) Alternate I (JUL 1995)

FAR 52.228-5 Insurance – Work on a Government Installation (JAN 1997)

FAR 52.232-18 Availability of Funds (APR 1984) FAR 52.242-2 Production Progress Reports (APR 1991) FAR 52.245-1 Government Property (APR 2012) FAR 52.245-9 Use and Charges (APR 2012) HSAR 3052.205-70 Advertisements, Publizing Awards, and Releases (SEP 2012) HSAR 3052.211-70 Index for Specifications (DEC 2003) HSAR 3052.217-90 Delivery and Shifting of Vessel (DEC 2003) HSAR 3052.217-91 Performance (DEC 2003)

HSCG80-15-Q-P00430 PAGE 11 OF 39

HSAR 3052.217-92 Inspection and Manner of Doing Work (DEC 2003) HSAR 3052.217-93 Subcontracts (DEC 2003) HSAR 3052.217-94 Lay Days (DEC 2003) HSAR 3052.217-95 Liability and Insurance (DEC 2003) HSAR 3052.217-96 Title (DEC 2003) HSAR 3052.217-97 Discharge of liens (DEC 2003) HSAR 3052.217-98 Delays (DEC 2003) HSAR 3052.217-99 Department of Labor Safety and Health Regulations for Ship Repair (DEC 2003) HSAR 3052.217-100 Guarantee (JUN 2006) HSAR 3052.222-70 Strikes or Picketing Affecting Timely Completion of the Contract Work (DEC 2003) HSAR 3052.222-71 Strikes or Picketing Affecting Access to a DHS Facility (DEC 2003) HSAR 3052.223-90 Accident and Fire Reporting (DEC 2003) HSAR 3052.228-70 Insurance (Dec 2003) HSAR 3052.242-72 Contracting Officer’s Technical Representative (DEC 2003) is the COR

(5) HSAR 3052.209-70 PROHIBITION ON CONTRACTS WITH CORPORATE EXPATRIATES (JUNE 2006)

(a) Prohibitions.

Section 835 of the Homeland Security Act, 6 U.S.C. 395, prohibits the Department of Homeland Security from entering into any contract with a foreign incorporated entity which is treated as an inverted domestic corporation as defined in this clause, or with any subsidiary of such an entity. The Secretary shall waive the prohibition with respect to any specific contract if the Secretary determines that the waiver is required in the interest of national security.

(b) Definitions. As used in this clause:

Expanded Affiliated Group means an affiliated group as defined in section 1504(a) of the Internal Revenue Code of 1986 (without regard to section 1504(b) of such Code), except that section 1504 of such Code shall be applied by substituting `more than 50 percent' for `at least 80 percent' each place it appears.

Foreign Incorporated Entity means any entity which is, or but for subsection (b) of section 835 of the Homeland Security Act, 6 U.S.C. 395, would be, treated as a foreign corporation for purposes of the Internal Revenue Code of 1986.

Inverted Domestic Corporation. A foreign incorporated entity shall be treated as an inverted domestic corporation if, pursuant to a plan (or a series of related transactions)—

(1) The entity completes the direct or indirect acquisition of substantially all of the properties held directly or indirectly by a domestic corporation or substantially all of the properties constituting a trade or business of a domestic partnership;

(2) After the acquisition at least 80 percent of the stock (by vote or value) of the entity is held—

(i) In the case of an acquisition with respect to a domestic corporation, by former shareholders of the domestic corporation by reason of holding stock in the domestic corporation; or

(ii) In the case of an acquisition with respect to a domestic partnership, by former partners of the domestic partnership by reason of holding a capital or profits interest in the domestic partnership; and

HSCG80-15-Q-P00430 PAGE 12 OF 39

(3) The expanded affiliated group which after the acquisition includes the entity does not have substantial business activities in the foreign country in which or under the law of which the entity is created or organized when compared to the total business activities of such expanded affiliated group.

Person, domestic, and foreign have the meanings given such terms by paragraphs (1), (4), and (5) of section 7701(a) of the Internal Revenue Code of 1986, respectively.

(c) Special rules. The following definitions and special rules shall apply when determining whether a foreign incorporated entity should be treated as an inverted domestic corporation.

(1) Certain stock disregarded. For the purpose of treating a foreign incorporated entity as an inverted domestic corporation these shall not be taken into account in determining ownership:

(i) Stock held by members of the expanded affiliated group which includes the foreign incorporated entity; or

(ii) Stock of such entity which is sold in a public offering related to an acquisition described in section 835(b)(1) of the Homeland Security Act, 6 U.S.C. 395(b)(1).

(2) Plan deemed in certain cases. If a foreign incorporated entity acquires directly or indirectly substantially all of the properties of a domestic corporation or partnership during the 4-year period beginning on the date which is 2 years before the ownership requirements of subsection (b)(2) are met, such actions shall be treated as pursuant to a plan.

(3) Certain transfers disregarded. The transfer of properties or liabilities (including by contribution or distribution) shall be disregarded if such transfers are part of a plan a principal purpose of which is to avoid the purposes of this section.

(d) Special rule for related partnerships. For purposes of applying section 835(b) of the Homeland Security Act, 6 U.S.C.

395(b) to the acquisition of a domestic partnership, except as provided in regulations, all domestic partnerships which are under common control (within the meaning of section 482 of the Internal Revenue Code of 1986) shall be treated as a partnership.

(e) Treatment of Certain Rights.

(1) Certain rights shall be treated as stocks to the extent necessary to reflect the present value of all equitable interests incident to the transaction, as follows:

(i) warrants;

(ii) options;

(iii) contracts to acquire stock;

(iv) convertible debt instruments; and

(v) others similar interests.

(2) Rights labeled as stocks shall not be treated as stocks whenever it is deemed appropriate to do so to reflect the present value of the transaction or to disregard transactions whose recognition would defeat the purpose of Section 835.

(f) Disclosure. The offeror under this solicitation represents that [Check one]:

HSCG80-15-Q-P00430 PAGE 13 OF 39

__ it is not a foreign incorporated entity that should be treated as an inverted domestic corporation pursuant to the criteria of (HSAR) 48 CFR 3009.108-7001 through 3009.108-7003;

__ it is a foreign incorporated entity that should be treated as an inverted domestic corporation pursuant to the criteria of (HSAR) 48 CFR 3009.108-7001 through 3009.108-7003, but it has submitted a request for waiver pursuant to 3009.108-7004, which has not been denied; or

__ it is a foreign incorporated entity that should be treated as an inverted domestic corporation pursuant to the criteria of (HSAR) 48 CFR 3009.108-7001 through 3009.108-7003, but it plans to submit a request for waiver pursuant to 3009.108-7004.

(g) A copy of the approved waiver, if a waiver has already been granted, or the waiver request, if a waiver has been applied for, shall be attached to the bid or proposal.

(6) HSAR 3052.223-70 REMOVAL OR DISPOSAL OF HAZARDOUS SUBSTANCES – APPLICABLE LICENSES

AND PERMITS (JUN 2006)

The Contractor shall have all licenses and permits required by Federal, state, and local laws to perform hazardous substance(s) removal or disposal services. If the Contractor does not currently possess these documents, it shall obtain all requisite licenses and permits within ten (10) days after date of award. The Contractor shall provide evidence of said documents to the Contracting Officer or designated Government representative prior to commencement of work under the contract.

(End of clause)

(7) HAZARDOUS WASTE

Contractors performing dockside ship repair work at Government facilities are required to comply with FAR 52.223-3, Hazardous Material Identification and Material Safety Data (JAN 1997) Alt I, the U.S. Coast Guard shipboard hazardous waste policy, as prescribed in COMDINST M16478.1B, and MLCA standard specifications. Disposal of all hazardous wastes shall be performed by the Contractor and the Contractor shall meet all federal and state requirements. The Contractor is also required to submit an acceptable hazardous waste management plan to the Port Engineer at the Arrival Conference. The plan will be reviewed by the facility hazardous waste manager. An acceptable plan must address, at a minimum, the following requirements:

(a) EPA and local authority hazardous waste generator ID numbers or registration of the Contractors, his transporters, and disposal facilities (TSDFs);

(b) An inventory of all hazardous chemicals, compounds and other agents brought aboard the facility accompanied by their respective Material Safety Data Sheets;

(c) A list of all anticipated hazardous wastes to be generated and a federal/state/local regulation cross reference list for those wastes;

(d) Waste collection and containment procedures;

(e) A hazardous material spill and cleanup plan including tools and materials that will be on hand and readily available to facility containment and cleanup;

(f) Training certification for the Contractor's hazardous waste manager.

(8) VOLATILE ORGANIC COMPOUNDS (VOC) REGULATIONS

(a) Contractors are required to comply with federal, state and local VOC compliance laws and regulations. Among other requirements, certain Contractors may also be required to operate pursuant to a Title V permit. The need for such a permit will depend on the provisions of the applicable state’s “State Implementation Plan” (SIP) and the type/quantity of the Contractor’s regulated emissions, including VOCs. Certain SIPs may also mandate certain Contractors to operate under the terms of a compliance plan intended to reduce VOC emissions.

(b) Contractors, therefore, must submit the following to the designated Port Engineer not later than two weeks after contract award:

HSCG80-15-Q-P00430 PAGE 14 OF 39

1) Copies of any federal, state or local permits required and applicable to the use or application of VOCs at Contractor’s facility or offsite work places;

2) Copies of any compliance plans required and applicable to the use or application of VOCs at Contractor’s facility or offsite work places.

(c) If no federal, state or local permits or compliance plans are required and applicable to the use or application of VOCs at Contractor’s facility or offsite workplaces, then Contractor shall submit to the designated Port Engineer a letter, notarized under oath, that such documents are not required.

(d) Contractors will submit the following to the designated Port Engineer not later than two weeks after contract award: Data Sheets (MSDS) documents, certificates, specifications or any other manufacturing data verifying the VOC ratings of paints to be applied to the Cutter in accordance with MLCA Standard Spec 63000N, Section 5.3.1.

(9) REQUIRED INSURANCE

The Contractor shall, at its own expense, procure and maintain the following kinds of insurance with respect to performance under the contract. In accordance with HSAR 3052.228-70, Insurance (DEC 2003), the Contractor shall furnish the Contracting Officer with proof of insurance for the duration of the contract, including:

1. Ship Repairer's Liability - $500,000 per occurrence.

2. Comprehensive General Liability - $500,000 per occurrence.

3. Full insurance coverage in accordance with the United States’ Longshoremen's and Harbor Worker's Act.

4. Full insurance coverage in accordance with the State's Workmen's Compensation Law (or its equivalent) for all places of performance under this contract.

The insurance certificate must provide the name of the US Coast Guard vessel and the contract and/or solicitation number as specifically insured.

(10) INSPECTIONS

Except as specified elsewhere, the U.S. Coast Guard shall rely on the Contractor to accomplish all inspection and testing needed to ensure that the work conforms to contract quality requirements.

Records of all inspection work by the Contractor shall be kept complete and available to the Government during the term of this contract and for such longer period as may be specified elsewhere in this contract.

The name and telephone number of the U.S. Coast Guard Inspector will be provided after the award of a contract resulting from this solicitation.

(11) GROWTH WORK

(a) The Contractor shall not perform growth work without the Contracting Officer's authorization. Growth work is work within the scope of the contract, which has not been previously priced as a pre-priced CLIN. The Contracting Officer reserves the right to contract for growth work on the basis of a negotiated, firm, fixed price, when it is in the best interest of the Government. If a firm-fixed price contract is awarded, and during the performance period a repair within scope is identified but the Contracting Officer and Contractor are unable to agree on the cost of the work, a bilateral modification may be incorporated into the contract using a Time and Materials modification for this specific repair. In this situation, FAR 52.212-4, Alternate I, will be incorporated.

(b) The Contractor shall furnish a price breakdown directly to the Contracting Officer, itemized as required by the Contracting Officer, of any Quotation submitted for a contract modification. Unless otherwise directed, the breakdown shall be submitted on an SFLC 002 proposal form provided at the arrival conference permitting an analysis of all materials, labor, equipment, subcontract, overhead costs, and profit covering all work involved in the change/modification whether such work was deleted, added or changed. Any amount claimed for subcontracts shall be supported by a separate, similar price breakdown. If the Quotation includes a request for a time extension, justification shall be furnished with the Quotation.

HSCG80-15-Q-P00430 PAGE 15 OF 39

(c) This clause is to be used in conjunction with the clause COMPOSITE LABOR RATE incorporated into this solicitation.

The Contractor is required to have and/or furnish all tools and equipment incidental to each bench trade. Supplies such as wiping rags, hacksaw blades, sandpaper, welding wire, helium, etc., are also to be furnished by the Contractor and shall be included in the Composite Labor Rate. Other materials are to be charged at regular rates and prices currently in effect and as agreed to by the Contracting Officer. Material shall be best commercial quality available except where a precise specification is indicated in which case the specification shall apply, e.g., MILSPEC, FEDERAL SPEC.

(12) DISCOVERIES AND CHANGES TO CONTRACT

Work requests can be transmitted electronically by using email. The bullets below display the process of how work requests are to be followed during an availability:

Work Request Process will occur in the following order:

1. Condition Found Report-Generated by the contractor and provided to COR

2. Condition Report Reply-Generated by the COR and provided to Contractor

3. Work Request- WR and IGE are generated by the COR and forwarded to KO

4. COR provides copy of Work Request to the Contractor

5. Contractor’s Quotation- Provided to the KO for the identified tasking on WR

6. Negotiations- If needed, take place to establish pricing

7. Approved Work Request- Forwarded to Contractor and COR by the KO

8. Modification to Contract- The KS/KO will issue a modification covering all WR’s

(13) COMPOSITE LABOR RATE

The composite labor rate offered shall be the sole labor hour rate used to price the Prime Contractor's direct labor hours for contract changes, i.e. growth work. The Contractor shall not receive any compensation in addition to this rate for the Prime Contractor's direct labor associated with such changes under this contract.

(a) The composite labor hour rate shall represent total compensation for the following:

(1) direct labor wages and salaries;

(2) all employee benefits including, but not limited to, paid leave, supplemental pay, insurance, retirement, savings, and legally required benefits;

(3) other direct costs associated with transit time, delay, disruption, consumables, expendable supplies, and equipment;

(4) all indirect costs such as overhead and general and administrative expense;

(5) any port or association fees, rents, or other levies;

(6) profit (fee);

(7) all direct and indirect costs and profit associated with the following support functions:

Supervision and Management Planning and Estimating Material Handling Housekeeping Engineering Transportation/Drivers Quality Assurance Contract Administration Security Test

(8) all consumables;

(b) The composite labor hour rate will be applied to production labor hours only. Production labor hours include only those hours necessary and reasonable to perform direct production functions and do not include the hours expended on the support functions listed above. This exclusion of support function hours applies whether such support functions are normally charged directly or indirectly by the Contractor's accounting system. These support functions are to be priced into the composite labor rate quoted and shall not be separately compensated.

(c) The Quantity of Composite Labor hours indicated in the Schedule of Supplies/Services, is only an estimate and is an Optional Item pursuant to this solicitation. The Estimated Quantity represents the Government’s best estimate of the total number of additional hours that may be required throughout the contract. The Government may elect to exceed this value at the prices stated in the schedule and its discretion during performance of the contract. The

HSCG80-15-Q-P00430 PAGE 16 OF 39

inclusion of this item does not obligate the Government to exercise the item nor entitle the Contractor to compensation if not exercised.

(14) MAINTAINING, REPORTING, AND DISPOSING OF GOVERNMENT PROPERTY IN THE PERFORMANCE

OF A SHIP REPAIR CONTRACT

1. The Government Property Clause incorporated by reference delineates the Contractor's overall responsibility when taking possession of government property in performance of a contract. In performance of this contract the Contractor will be required to properly identify, track and control property within its possession. This includes, a) property furnished by the government (GFP) to the Contractor in conjunction with specific CLIN Items. These items and their values are listed in the specification, b) property that is pre-existing in a location that during the course of performance will be replaced or renewed.

2. The items listed in the specification, as government furnished property will be provided in the quantities designated.

Government furnished property may be provided in person by an official Coast Guard employee, shipment via commercial carrier, etc.