HSCG40-15-R-60302.doc

PAGE

Commander

U.S. Coast Guard

Surface Forces Logistics Center

CPD-C&P3-SSD

2401 Hawkins Point Road M/S 25 Baltimore, MD 21226

REQUEST FOR PROPOSAL

HSCG40-15-R-60302

DYNAMOMETER DESIGN AND INSTALLATION

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, & 30

1. REQUISITION NUMBER

2115405Y6125540001

2. CONTRACT NO.

3. AWARD/EFFECTIVE

DATE

4. ORDER NUMBER

5. SOLICITATION NUMBER

HSCG40-15-R-60302

6. SOLICITATION

ISSUE DATE

7/23/2015

b. TELEPHONE NUMBER (no collect calls) 410-762-6978

8. OFFER DUE DATE/ LOCAL TIME: 8/25/15

12:00 pm EST

9. ISSUED BY CODE:

USCG Surface Forces Logistics Center Contracting & Procurement Div. (C&P3-SSD)

2401 Hawkins Point Road, M/S 25

Baltimore, MD 21226

10. THIS ACQUISITION IS

FORMCHECKBOX

UNRESTRICTED OR

FORMCHECKBOX

SET ASIDE 100% FOR:

FORMCHECKBOX

SMALL BUSINESS EMERGING SMALL

HUBZONE SMALL BUSINESS

BUSINESS

8(A)

SERVICE DISABLED VETERAN-

OWNED SMALL BUSINESS

NAICS: 334519 SIZE STANDARD: 500

11. DELIVERY FOR FOB DESTINATION UNLESS BLOCK IS MARKED

FORMCHECKBOX

SEE SCHEDULE

12. DISCOUNT

TERMS

FORMCHECKBOX

13a. THIS CONTRACT IS A RATED ORDER UNDER DPAS (15 CFR 700) 13b. RATING DO-N5

14. METHOD OF SOLICITATION

RFP IFB RFQ

15. DELIVER TO CODE

SEE SCHEDULE

16. ADMINISTERED BY CODE

WALTER A. MACK JR.

CONTRACT SPECIALIST

410-762-6978

17a. CONTRACTOR/ CAGE CODE FACILITY

OFFEROR CODE

18a. PAYMENT WILL BE MADE BY CODE U.S. Coast Guard Yard

P.O. Box 4122

Chesapeake, VA 23327-4122

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

25. ACCOUNTING AND APPROPRIATION DATA

26. TOTAL AWARD AMOUNT (FOR GOVT USE ONLY)

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1, 52.212-4. FAR 52.212-3 & 52.212-5 ARE ATTACHED. ADDENDA ARE ARE NOT ATTACHED.

ARE NOT ATTACHED. ARE 27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4, FAR 52.212-5 IS ATTACHED. ADDENDA

OFFER DATED . YOUR OFFER ON SOLICITATION (BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR

31a. UNITED STATES OF AMERICA (SINGATURE OF CONTRACTING OFFICER)

30b. NAME AND TITLE OF SIGNER

30c. DATE SIGNED

31b. NAME OF CONTRACTING OFFICER

31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

STANDARD FORM 1449 (Rev. 3/2005) PREVIOUS EDITION IS NOT USABLE Prescribed by GSA – FAR (48 CFR) 53.21

NOTICE FOR FILING AGENCY PROTESTS

United States Coast Guard Ombudsman Program

It is the policy of the United States Coast Guard (USCG) to issue solicitations and make contract awards in a fair and timely manner. The Ombudsman Program for Agency Protests (OPAP) was established to investigate agency protest issues and resolve them without expensive and time consuming litigation. OPAP is an independent reviewing authority that is empowered to grant a prevailing protester essentially the same relief as the Government Accountability Office (GAO).

Interested parties are encouraged to seek resolution of their concerns within the USCG as an Alternative Dispute Resolution (ADR) forum rather than filing a protest with the GAO or some external forum. Interested parties may seek resolution of their concerns informally or opt to file a formal agency protest with the Contracting Officer or Ombudsman.

Informal Forum with the Ombudsman. Interested parties who believe a specific USCG procurement is unfair or otherwise defective should first direct their concerns to the applicable Contracting Officer. If the Contracting Officer is unable to satisfy their concerns, interested parties are encouraged to contact the U.S. Coast Guard Ombudsman for Agency Protests. Under this informal process the agency is not required to suspend contract award performance. Use of an informal forum does not suspend any time requirement for filing a protest with the agency or other forum. In order to ensure a timely response, interested parties should provide the following information to the Ombudsman: solicitation/contract number, contracting office, Contracting Officer, and solicitation closing date (if applicable).

Formal Agency Protest with the Ombudsman. Prior to submitting a formal agency protest, protesters must first use their best efforts to resolve their concerns with the Contracting Officer through open and frank discussions. If the protester’s concerns are unresolved, an Independent Review is available by the Ombudsman. The protester may file a formal agency protest to either the Contracting Officer or as an alternative to that, the Ombudsman under the OPAP program. Contract award or performance will be suspended during the protest period unless contract award or performance is justified, in writing, for urgent and compelling reasons or is determined in writing to be in the best interest of the Government. The agency’s goal is to resolve protests in less than 35 calendar days from the date of filing. Protests shall include the information set forth in FAR 33.103(d) (2). If the protester fails to submit the required information, resolution of the protest may be delayed or the protest may be dismissed. This will not preclude re-filing of the protest to meet the requirement. To be timely protests must be filed within the period specified in FAR 33.103(e). Formal protests filed under the OPAP program should be submitted to:

Department of Homeland Security

United States Coast Guard (CG-91)

Ombudsman Program for Agency Protests

Email: OPAP@uscg.mil Fax: 202-372-8447

Phone: 202-475-5786

More information about the Ombudsman Program for Agency Protests (OPAP) can be found at http://www.uscg.mil/acquisition/business/ombudsman.asp

Alternative Point of Contact:

Walter A. Mack Jr. Contracting Officer

U.S. Coast Guard

Surface Forces Logistics Center

2401 Hawkins Point Road

Baltimore, MD 21226

410-762-6162

Walter.a.mackjr@uscg.mil

CONTINUATION OF STANDARD FORM (SF) 1449 – BLOCKS 17a - 25

(1) Block 17a: Contractor shall include DUNS number.

(2) Block 17b: REMITTANCE ADDRESS: Payment will be made to the Financial Institution listed in the System for Award Management (SAM). To receive award Contractor must be registered in SAM, http://sam.gov.

(3) Block 19 through 24: SEE SCHEDULE OF SUPPLIES/SERVICES BELOW.

(4) Block 25: ACCOUNTING AND APPROPRIATION DATA: To be included on contract award document.

DESCRIPTION OF WORK:

(a) The Contractor shall furnish all necessary labor, material, services, equipment, supplies, power, accessories, facilities and such other things as are necessary, except as otherwise specified, to provide an initial design/layout of the existing facilities for installation of a dynamometer capable of testing an MTU 20V4000M93L and Paxman RP200M main diesel engines found on board 110’ CG vessels.

(b) Failure to read the specifications in their entirety will not relieve the offeror from the responsibility for properly estimating the difficulty or price of successfully performing the work. Failure to do so will be at the offeror 's risk. All proposals submitted in response to this solicitation shall stand firm for 60 calendar days from the response date of this solicitation.

ALL CONTRACTORS ARE RESPONSIBLE FOR VERIFYING THE RECEIPT OF THEIR PROPOSALS.

Mailed or hand delivered proposals will be accepted. Faxed and e-mail proposals are not preferred.

PLEASE NOTE: PROPOSALS THAT DO NOT INCLUDE ALL REQUIRED DOCUMENTS MAY BE CONSIDERED INCOMPLETE AND MAY NOT BE CONSIDERED

Contract Type: This solicitation will result in the award of one (1) firm fixed-price contract with a definite CLIN for design services and, upon approval of the design, optional CLINs for the manufacture and installation of the dynamometer and related systems.

Performance Period: The performance period for this requirement includes submission of design/layout within 60 days after contract award. Upon approval of the design, manufacture and installation is to be completed one (1) year after optional CLINs have been exercised.

PRE-PROPOSAL CONFERENCE/SITE VISIT

In an effort to promote clear communication of government requirements for this acquisition, a pre-proposal conference is scheduled for August 7, 2015 @ 9:00 am EST at the following location:

USCG Yard

2401 Hawkins Point Road

Berry Hall Large Room

Baltimore, MD 21226-5000

POC: Eric Linton

Companies interested in attending this meeting will need to contact the POC via email eric.m.linton@uscg.mil with individual’s names for Yard access. Please note that the date and location may be subject to change due to unforeseen delays, and the Government cannot be held liable for any costs incurred by you or your company should there be any unforeseen changes to the event. Attendance at the pre-proposal conference, while encouraged, is completely voluntary. Any known changes to the scheduled date will be communicated in writing via solicitation amendment.

FAR 52.237-1 SITE VISIT (APR 1984)

Offerors are urged and expected to inspect the site where services are to be performed and to satisfy themselves regarding all general and local conditions that may affect the cost of contract performance, to the extent that the information is reasonable obtainable. In no event shall failure to inspect the site constitute grounds for a claim after contract award.

(End of Provision)

SUPPLIES OR SERVICES AND PRICE/COSTS

Total Amount

*(O) denotes Optional CLINS

DESCRIPTION/SPECIFICATIONS/STATEMENT OF WORK

All work to be completed under this requirement shall be in accordance with CG Yard Dynamometer Specification (Attachment 1).

PACKAGING AND MARKING

Standard Commercial Warranty

If the item(s) required in the contract resulting from this solicitation are customarily warranted in the trade by a standard commercial warranty, such warranty shall be incorporated into this contract and thereby provided to the Government at no additional cost. Any standard commercial warranty provided shall be identical to the standard commercial warranty normally offered by the Contractor to the Contractor's most favored customer.

Offerors are requested to state the terms and conditions of their standard commercial warranty in the space provided below and attach a copy of the warranty terms with their offer. ________________________________________________________________________

(End of provision)

INSPECTION AND ACCEPTANCE

GOVERNMENT ACCEPTANCE (DESTINATION)

Final acceptance shall be made by a Government representative at destination. Acceptance shall be contingent upon verification of no damage in transit, correctness and completeness of the order, and conformance to all the requirements spelled out in the specification. (Attachment 1)

FAR 52.211-8 TIME OF DELIVERY(JUN 1997)

a) The Government requires delivery to be made according to the following schedule:

0002g(O)

0002h(O)

0002i(O)

0003(O)

The Government will evaluate, as regards to time of delivery, offers that propose delivery of each quantity within the applicable delivery period specified above, may be considered unacceptable and may be rejected. The Government reserves the right to award under either the required delivery schedule or the proposed delivery schedule, when an Offeror offers an earlier delivery schedule than required above. If the Offeror proposes no other delivery schedule, the required delivery schedule above will apply.

OFFEROR’S PROPOSED DELIVERY SCHEDULE

0002g(O)

0002h(O)

0002i(O)

0003(O)

(b) Attention is directed to the Contract Award provision of the solicitation that provides that a written award or acceptance of offer mailed or otherwise furnished to the successful Offeror results in a binding contract. The Government will mail or otherwise furnish to the Offeror an award or notice of award not later than the day the award is dated. Therefore, the Offeror shall compute the time available for performance beginning with the actual date of award, rather than the date the written notice of award is received from the Contracting Officer through the ordinary mails. However, the Government will evaluate an offer that proposes delivery based on the Contractor’s date of receipt of the contract or notice of award by adding (1) five calendar days for delivery of the award through the ordinary mails, or (2) one working day if the solicitation states that the contract or notice of award will be transmitted electronically. (The term “working day” excludes weekends and U.S. Federal holidays.) If, as so computed, the offered delivery date is later than the required delivery date; the offer will be considered nonresponsive and rejected.

(End of Clause)

PLACE OF DELIVERY – DESTINATION

(a) Destination delivery address:

U.S. Coast Guard Yard

2401 Hawkins Point Rd

Baltimore MD, 21226-5000

(b) Any written reports shall be delivered to the Contract Administrator, at the following address:

Surface Forces Logistics Center

Attn: Walter A. Mack Jr., Contracting Officer

Mail Stop #25, Bldg. 707

M/F: Contract Number: {To be furnished at the time of award}

And copies to the Contracting Offer’s Representative (COR), at the following address:

U.S. Coast Guard Yard Industrial Bldg. 58 2401 Hawkins Point Road

Baltimore, MD 21226-5000 M/F: Contract Number: {To be furnished at the time of award} Or submitted electronically to: walter.a.mackjr@uscg.mil or eric.m.linton@uscg.mil

CONTRACT ADMINISTRATION

ADDRESS OF CORRESPONDENCE

All correspondence, except as otherwise specified, shall be delivered to the following address:

Attn: Walter A. Mack Jr., Contract Specialist

Mail Stop #26, Bldg. 707

CONTRACT ADMINISTRATION

The Contracting Officer or authorized representative, located at the U.S. Coast Guard Surface Forces Logistics Center, 2401 Hawkins Point Road, Baltimore, MD 21226-5000, shall be contract administrator for this contract – Walter A. Mack Jr. (410)762-6978

INVOICING REQUIREMENTS – FIRM-FIXED PRICE CONTRACTS

All items ordered under this contract shall be billed once the work is completed and accepted by the Surface Forces Logistics Center. An original invoice shall be submitted to the following designated payment office:

U.S. Coast Guard Yard

P.O. Box 4122

Chesapeake, VA 23327-4122

Invoices may also be submitted electronically by accessing and completing the invoice form found at FIN-SMB-YardTeam@uscg.mil.

All invoices must contain the following information to constitute a proper invoice:

(1) Name and address of Contractor

(2) Invoice date

(3) Contract Number

(4) Description, quantity, unit of measure, unit price and extended price

(5) Terms of any prompt payment discounts offered

(6) Dun & Bradstreet (DUNS) Number

(7) Federal Tax Identification Number

(8) Name, title, and telephone number of individual to be notified upon receipt of improper invoice(s)

Invoices shall be processed in accordance with the Prompt Payment Act (31 U.S.C. 3903) and Office of Management and Budget (OMB) Circular A-125, Prompt Payment. The Contractor is encouraged to assign an identification number to each invoice.

Upon receipt of partial shipment, partial payment may be made.

Failure to submit invoices directly to this office will delay prompt payment of your invoice. A copy of any invoice submitted for payment must also be forwarded to the Contracting Officer.

ELECTRONIC FUNDS TRANSFER

Any payment that we make to you will be made by electronic funds transfer unless you certify in writing that you do not have an account with a financial institution or an authorized payment agent.

INVOICE AND PAYMENT INFORMATION FOR CONTRACTORS

The Data Universal Numbering Systems (DUNS) number is the primary identifier in the System for Awards Management (SAM). Contracts are located and identified in SAM by their DUNS number. Therefore, to facilitate payment, it is in the contractor’s best interest to ensure that the DUNS number is recorded on every invoice submitted to the U.S. Coast Guard.

Effective 01 January 2002, all Coast Guard vendors must be registered in the System for Awards Management (SAM) in order to be awarded a contract. For more information on SAM and to register online, simply visit the SAM web site: http://www.sam.gov or call the Coast Guard Finance Center Customer Service line at (757) 523-6940.

UNAUTHORIZED INSTRUCTIONS FROM GOVERNMENT PERSONNEL

(a) The Contractor shall not accept any instructions issued by any person employed by the U.S. Government or otherwise other than the Contracting Officer or the Contracting Officer’s Representative acting within the limits of their authority. A Contracting Officer’s Representative shall be designated in writing to the Contractor and shall set forth the scope of their authority.

(b) No information, other than that which may be contained in an authorized amendment to this purchase instrument duly issued by the Contracting Officer, which may be received from any person employed by the Government or otherwise will be considered as grounds for deviation from any stipulations of the purchase instruments.

GOVERNMENT REPRESENTATIVES

(a) The Government may, upon contract award or thereafter, name representatives with titles such as Project Officer, Contracting Officer's Representative(s), and so on. Such individuals, IF APPOINTED, will be named in writing by the Contracting Officer. The letter of appointment will indicate the individuals, titles, and stipulate the rights, responsibilities, and limitations of their appointment.

(b) In any event, no such named individual has the authority to issue any direction under this contract, either technical or otherwise, which constitutes a change to the terms, conditions, and price or delivery schedule of the contract. ONLY the Contracting Officer is authorized to alter the contract in any manner.

RESPONSIBLE OFFICIAL(S) WHO CAN RECEIVE NOTIFICATION OF AN IMPROPER INVOICE AND ANSWER QUESTIONS REGARDING THE INVOICE

For use in the event your firm receives a contract as a result of this solicitation, designate below the responsible official(s) who can receive notification of an improper invoice and answer questions regarding the invoice.

NAME:

TITLE:

ADDRESS:

PHONE NUMBER:

WITHHOLDING PAYMENT FOR NONDELIVERY OF DATA

(a) If technical data such as plans, drawings, reports, spare parts lists, repair parts lists, or the like, or instruction books (including manuscripts or printer’s copy) or any part thereof, are not delivered within the time specified by this contract are deficient upon delivery, the Contracting Officer shall, at his/her discretion, withhold from each invoice a percentage of the contract price in accordance with the following table:

When Contract Total Price is

Percentage to be withheld is

Less than $250,000

10%

$250,000 to $1,000,000

5%

Over $1,000,000

2%

(b) The withholding of any sums pursuant to this clause shall not be construed as, or constitute in any manner, a waiver by the Government of the Contractor’s obligation to furnish the data required under this contract. In the event the Contractor fails to furnish these items, the Government shall have those rights and remedies provided by law and pursuant to this contract in addition to, and not in lieu of, the sum withheld in accordance with this clause.

CONTRACTOR PERFORMANCE ASSESSMENT REPORT (CPAR)

(a) GENERAL: The U.S. Coast Guard Surface Forces Logistic Center (SFLC) will monitor and evaluate the successful offeror’s past performance of this contract and prepare a Contractor Performance Assessment Report (CPAR) in accordance with FAR Part 42.15. All information contained in this assessment may be used, within the limitations of FAR 42.15, by the government for future source selections and in accordance with FAR 15.304, when past performance is an evaluation factor for award.

(b) NOTIFICATION: Upon completion of the contract, the contractor will be notified of the assessment. The contractor will be allowed 30 days to respond to the SLFC’s assessment of its performance entered into CPARS. The contractor’s response, if any, will be made part of the CPAR system.

(c) INFORMATION: Information included in the CPAR may include, but is not limited to, the contractor’s record of conforming to contract requirements and to standards of good workmanship; the contractor’s record of forecasting and controlling costs; the contractor’s adherence to contract schedules, including the administrative aspects of performance; the contractor’s history of reasonable and cooperative behavior and commitment to customer satisfaction; the contractor’s record of integrity and business ethics, and generally, the contractor’s business-like concern for the interest of the customer.

(d) RELEASE OF DATA: CPARS information is considered business sensitive and will not be released except: (1) to other Federal procurement activities which request it; (2) when SFLC must release pursuant to a Freedom of Information Act (FOIA) request; or (3) when prior written consent is requested and obtained from the contractor.

SPECIAL CONTRACT REQUIREMENTS

REQUIRED STANDARD OF WORKMANSHIP

Unless otherwise specifically provided in this contract, the quality of all manufactured parts rendered hereunder shall conform to the highest standards in the relevant profession, trade, or field of endeavor. All manufactured parts shall be rendered or supervised directly by individuals fully qualified in the relevant profession, trade, or field, and holding any licenses required by law.

CONTRACT CLAUSES

FAR 52.212-4 CONTRACT TERMS AND CONDITIONS – COMMERCIAL ITEMS (MAY 2015) – ADDENDUM

ADDITIONAL TERMS AND CONDITIONS

Additional terms and conditions applicable to this contract are as follows.

The following Federal Acquisition Regulation (FAR) Clauses are hereby incorporated into this Agreement by reference with the same force and effect as if incorporated in full text. Also, the full text of a clause may be accessed electronically at www.arnet.gov.

FAR 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JUL 2013)

(a) Definitions. As used in this provision—

“Administrative proceeding” means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceeding at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

“Federal contracts and grants with total value greater than $10,000,000” means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

“Principal” means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror [_] has [_] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in—

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the Central Contractor Registration database at http://www.ccr.gov (see 52.204-7).

(End of provision)

FAR 52.246-2 INSPECTION OF SUPPLIES – FIXED-PRICE (AUG 1996)

(a) Definition. “Supplies,” as used in this clause, includes but is not limited to raw materials, components, intermediate assemblies, end products, and lots of supplies.

(b) The Contractor shall provide and maintain an inspection system acceptable to the Government covering supplies under this contract and shall tender to the Government for acceptance only supplies that have been inspected in accordance with the inspection system and have been found by the Contractor to be in conformity with contract requirements. As part of the system, the Contractor shall prepare records evidencing all inspections made under the system and the outcome. These records shall be kept complete and made available to the Government during contract performance and for as long afterwards as the contract requires. The Government may perform reviews and evaluations as reasonably necessary to ascertain compliance with this paragraph. These reviews and evaluations shall be conducted in a manner that will not unduly delay the contract work. The right of review, whether exercised or not, does not relieve the Contractor of the obligations under the contract.

(c) The Government has the right to inspect and test all supplies called for by the contract, to the extent practicable, at all places and times, including the period of manufacture, and in any event before acceptance. The Government shall perform inspections and tests in a manner that will not unduly delay the work. The Government assumes no contractual obligation to perform any inspection and test for the benefit of the Contractor unless specifically set forth elsewhere in this contract.

(d) If the Government performs inspection or test on the premises of the Contractor or a subcontractor, the Contractor shall furnish, and shall require subcontractors to furnish, at no increase in contract price, all reasonable facilities and assistance for the safe and convenient performance of these duties. Except as otherwise provided in the contract, the Government shall bear the expense of Government inspections or tests made at other than the Contractor’s or subcontractor’s premises; provided, that in case of rejection, the Government shall not be liable for any reduction in the value of inspection or test samples.

(e)(1) When supplies are not ready at the time specified by the Contractor for inspection or test, the Contracting Officer may charge to the Contractor the additional cost of inspection or test.

(2) The Contracting Officer may also charge the Contractor for any additional cost of inspection or test when prior rejection makes re-inspection or retest necessary.

(f) The Government has the right either to reject or to require correction of nonconforming supplies. Supplies are nonconforming when they are defective in material or workmanship or are otherwise not in conformity with contract requirements. The Government may reject nonconforming supplies with or without disposition instructions.

(g) The Contractor shall remove supplies rejected or required to be corrected. However, the Contracting Officer may require or permit correction in place, promptly after notice, by and at the expense of the Contractor. The Contractor shall not tender for acceptance corrected or rejected supplies without disclosing the former rejection or requirement for correction, and, when required, shall disclose the corrective action taken.

(h) If the Contractor fails to promptly remove, replace, or correct rejected supplies that are required to be removed or to be replaced or corrected, the Government may either (1) by contract or otherwise, remove, replace, or correct the supplies and charge the cost to the Contractor or (2) terminate the contract for default. Unless the Contractor corrects or replaces the supplies within the delivery schedule, the Contracting Officer may require their delivery and make an equitable price reduction. Failure to agree to a price reduction shall be a dispute.

(i)(1) If this contract provides for the performance of Government quality assurance at source, and if requested by the Government, the Contractor shall furnish advance notification of the time—

(i) When Contractor inspection or tests will be performed in accordance with the terms and conditions of the contract; and

(ii) When the supplies will be ready for Government inspection.

(2) The Government’s request shall specify the period and method of the advance notification and the Government representative to whom it shall be furnished. Requests shall not require more than 2 workdays of advance notification if the Government representative is in residence in the Contractor’s plant, nor more than 7 workdays in other instances.

(j) The Government shall accept or reject supplies as promptly as practicable after delivery, unless otherwise provided in the contract. Government failure to inspect and accept or reject the supplies shall not relieve the Contractor from responsibility, nor impose liability on the Government, for nonconforming supplies.

(k) Inspections and tests by the Government do not relieve the Contractor of responsibility for defects or other failures to meet contract requirements discovered before acceptance. Acceptance shall be conclusive, except for latent defects, fraud, gross mistakes amounting to fraud, or as otherwise provided in the contract.

(l) If acceptance is not conclusive for any of the reasons in paragraph (k) hereof, the Government, in addition to any other rights and remedies provided by law, or under other provisions of this contract, shall have the right to require the Contractor (1) at no increase in contract price, to correct or replace the defective or nonconforming supplies at the original point of delivery or at the Contractor’s plant at the Contracting Officer’s election, and in accordance with a reasonable delivery schedule as may be agreed upon between the Contractor and the Contracting Officer; provided, that the Contracting Officer may require a reduction in contract price if the Contractor fails to meet such delivery schedule, or (2) within a reasonable time after receipt by the Contractor of notice of defects or nonconformance, to repay such portion of the contract as is equitable under the circumstances if the Contracting Officer elects not to require correction or replacement. When supplies are returned to the Contractor, the Contractor shall bear the transportation cost from the original point of delivery to the Contractor’s plant and return to the original point when that point is not the Contractor’s plant. If the Contractor fails to perform or act as required in paragraph (l) (1) or (l) (2) of this clause and does not cure such failure within a period of 10 days (or such longer period as the Contracting Officer may authorize in writing) after receipt of notice from the Contracting Officer specifying such failure, the Government shall have the right by contract or otherwise to replace or correct such supplies and charge to the Contractor the cost occasioned the Government thereby.

(End of clause)

HSAR 3052.209-70 PROHIBITION ON CONTRACTS WITH CORPORATE EXPATRIATES (JUN 2006)

(a) Prohibitions.

Section 835 of the Homeland Security Act, 6 U.S.C. 395, prohibits the Department of Homeland Security from entering into any contract with a foreign incorporated entity which is treated as an inverted domestic corporation as defined in this clause, or with any subsidiary of such an entity. The Secretary shall waive the prohibition with respect to any specific contract if the Secretary determines that the waiver is required in the interest of national security.

(b) Definitions. As used in this clause:

Expanded Affiliated Group means an affiliated group as defined in section 1504(a) of the Internal Revenue Code of 1986 (without regard to section 1504(b) of such Code), except that section 1504 of such Code shall be applied by substituting `more than 50 percent' for `at least 80 percent' each place it appears.

Foreign Incorporated Entity means any entity which is, or but for subsection (b) of section 835 of the Homeland Security Act, 6 U.S.C. 395, would be, treated as a foreign corporation for purposes of the Internal Revenue Code of 1986.

Inverted Domestic Corporation. A foreign incorporated entity shall be treated as an inverted domestic corporation if, pursuant to a plan (or a series of related transactions)—

(1) The entity completes the direct or indirect acquisition of substantially all of the properties held directly or indirectly by a domestic corporation or substantially all of the properties constituting a trade or business of a domestic partnership;

(2) After the acquisition at least 80 percent of the stock (by vote or value) of the entity is held—

(i) In the case of an acquisition with respect to a domestic corporation, by former shareholders of the domestic corporation by reason of holding stock in the domestic corporation; or

(ii) In the case of an acquisition with respect to a domestic partnership, by former partners of the domestic partnership by reason of holding a capital or profits interest in the domestic partnership; and

(3) The expanded affiliated group which after the acquisition includes the entity does not have substantial business activities in the foreign country in which or under the law of which the entity is created or organized when compared to the total business activities of such expanded affiliated group.

Person, domestic, and foreign have the meanings given such terms by paragraphs (1), (4), and (5) of section 7701(a) of the Internal Revenue Code of 1986, respectively.

(c) Special rules. The following definitions and special rules shall apply when determining whether a foreign incorporated entity should be treated as an inverted domestic corporation.

(1) Certain stock disregarded. For the purpose of treating a foreign incorporated entity as an inverted domestic corporation these shall not be taken into account in determining ownership:

(i) Stock held by members of the expanded affiliated group which includes the foreign incorporated entity; or

(ii) Stock of such entity which is sold in a public offering related to an acquisition described in section 835(b)(1) of the Homeland Security Act, 6 U.S.C. 395(b)(1).

(2) Plan deemed in certain cases. If a foreign incorporated entity acquires directly or indirectly substantially all of the properties of a domestic corporation or partnership during the 4-year period beginning on the date which is 2 years before the ownership requirements of subsection (b)(2) are met, such actions shall be treated as pursuant to a plan.

(3) Certain transfers disregarded. The transfer of properties or liabilities (including by contribution or distribution) shall be disregarded if such transfers are part of a plan a principal purpose of which is to avoid the purposes of this section.

(d) Special rule for related partnerships. For purposes of applying section 835(b) of the Homeland Security Act, 6 U.S.C. 395(b) to the acquisition of a domestic partnership, except as provided in regulations, all domestic partnerships which are under common control (within the meaning of section 482 of the Internal Revenue Code of 1986) shall be treated as a partnership.

(e) Treatment of Certain Rights.

(1) Certain rights shall be treated as stocks to the extent necessary to reflect the present value of all equitable interests incident to the transaction, as follows:

(i) warrants;

(ii) options;

(iii) contracts to acquire stock;

(iv) convertible debt instruments; and

(v) others similar interests.

(2) Rights labeled as stocks shall not be treated as stocks whenever it is deemed appropriate to do so to reflect the present value of the transaction or to disregard transactions whose recognition would defeat the purpose of Section 835.

(f) Disclosure. The offeror under this solicitation represents that [Check one]:

__ it is not a foreign incorporated entity that should be treated as an inverted domestic corporation pursuant to the criteria of (HSAR) 48 CFR 3009.108-7001 through 3009.108-7003;

__ it is a foreign incorporated entity that should be treated as an inverted domestic corporation pursuant to the criteria of (HSAR) 48 CFR 3009.108-7001 through 3009.108-7003, but it has submitted a request for waiver pursuant to 3009.108-7004, which has not been denied; or

__ it is a foreign incorporated entity that should be treated as an inverted domestic corporation pursuant to the criteria of (HSAR) 48 CFR 3009.108-7001 through 3009.108-7003, but it plans to submit a request for waiver pursuant to 3009.108-7004.

(g) A copy of the approved waiver, if a waiver has already been granted, or the waiver request, if a waiver has been applied for, shall be attached to the bid or proposal.

(End of provision)

FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: http://www.arnet.gov/far/index.html

FAR 52.203-17

Contractor Employee Whistleblower Rights and Requirement to Inform Employees of Whistleblower Rights (Apr 2014)

FAR 52.232-40

Providing Accelerated Payment to Small Business Subcontractors (Dec 2013)

FAR 52.212-5 – CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUS OR EXECUTIVE ORDERS – COMMERCIAL ITEMS (MAY 2015)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Dec 2014)

(2) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(3) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. Laws 108-77, 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.] _X_ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 253g and 10 U.S.C. 2402).

___ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (41 U.S.C. 3509).

___ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub L. 111-5) (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009).

_X_ (4) 52.204-10, Reporting Executive compensation and First-Tier Subcontract Awards (Jul 2013) (Pub. L. 109-282) (31 U.S.C. 6101 note).

___ (5) [Reserved]

___ (6) 52.204-14, Service Contract Reporting Requirements (Jan 2014) (Pub. L. 11-117, section 743 of Div. C).

___ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Jan 2014)(Pub. L. 111-117, section 743 of Div. C).

_X_ (8) 52.209-6, Protecting the Government’ Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Aug 2013) (31 U.S.C. 6101 note).

_X_ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41 U.S.C. 2313).

___ (10) [Reserved] ___ (11) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a).

___ (ii) Alternate I (Nov 2011) of 52.219-3.

___ (12) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2011) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C. 657a).

___ (ii) Alternate I (Jan 2011) of 52.219-4.

___ (13) [Reserved]

_X_ (14) (i) 52.219-6, Notice of Total Small Business Aside (Nov 2011) (15 U.S.C. 644).

___ (ii) Alternate I (Nov 2011).

___ (iii) Alternate II (Nov 2011).

___ (15) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644).

___ (ii) Alternate I (Oct 1995) of 52.219-7.

___ (iii) Alternate II (Mar 2004) of 52.219-7.

_X_ (16) 52.219-8, Utilization of Small Business Concerns (Oct 2014) (15 U.S.C. 637(d)(2) and (3)).

___ (17) (i) 52.219-9, Small Business Subcontracting Plan (Oct 2014) (15 U.S.C. 637 (d)(4).)

___ (ii) Alternate I (Oct 2001) of 52.219-9.

___ (iii) Alternate II (Oct 2001) of 52.219-9.

___ (iv) Alternate III (July 2010) of 52.219-9.

___ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)).

_X_ (19) 52.219-14, Limitations on Subcontracting (Nov 2011) (15 U.S.C. 637(a)(14)).

___ (20) 52.219-16, Liquidated Damages—Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)).

___ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011)(15 U.S.C. 657f).

_X_ (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)).

___ (23) 52.219-29, Notice of Set-Aside for Economically Disadvantaged Women-Owned Small Business (EDWOSB) Concerns (Jul 2013) (15 U.S.C. 637(m)).

___ (24) 52.219-30, Notice of Set-Aside for Women-Owned Small Business (WOSB) Concerns Eligible Under the WOSB Program (Jul 2013) (15 U.S.C. 637(m)).

_X_ (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

_X_ (26) 52.222-19, Child Labor—Cooperation with Authorities and Remedies (Jan 2014) (E.O. 13126).

_X_ (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

_X_ (28) 52.222-26, Equal Opportunity (Apr 2015) (E.O. 11246).

_X_ (29) 52.222-35, Equal Opportunity for Veterans (Jul 2014) (38 U.S.C. 4212).

_X_ (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

_X_ (31) 52.222-37, Employment Reports on Veterans (Jul 2014) (38 U.S.C. 4212).

_X_ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

_X_ (33) (i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627).

___ (II) Alternate (Mar 2015) of 52.222-50, (22 U.S.C. chapter 78 and E.O. 13627).

___ (34) 52.222-54, Employment Eligibility Verification (Aug 2013). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

___ (35) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

___ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

___ (36) (i) 52.223-13, Acquisition of EPEAT® – Registered Imaging Equipment (Jun 2014)(E.O.s 13423 and 13514)

___ (ii) Alternate I (Jun 2014) of 52.223-13.

___ (37) (i) 52.223-14, Acquisition of EPEAT® - Registered Television (Jun 2014)(E.O.s 13423 and 13514).

___ (ii) Alternate I (Jun 2014) of 52.223-14.

___ (38) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b).

___ (39) (i) 52.223-16, Acquisition of EPEAT® - Registered Personal Computer Products (Jun 2014)(E.O.s 13423 and 13514) ___ (ii) Alternate I (Jun 2014) of 52.223-16.

_X_ (40) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging while Driving (Aug 2011).

_X_ (41) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83).

___ (42) (i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42 and 112-43).

___ (ii) Alternate I (May 2014) of 52.225-3.

___ (iii) Alternate II (May 2014) of 52.225-3.

___ (iv) Alternate III (May 2014) of 52.225-3.

___ (43) 52.225-5, Trade Agreements (Nov 2013) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

_X_ (44) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets…