FA860121R0053 Synopsitation Document.pdf

FA860121R0053

Supplies or Services and Prices/Cost

Additional Information/Notes

Item

Supplies/Service

Quantity

Unit

Unit Price

Amount

SPRING START UP OF AFTC PROVIDE

ALL MANAGEMENT, LABOR, TOOLS,

EQUIPMENT, TRANSPORTATION,

MATERIALS, AND PARTS

NECESSARY TO PERFORM SPRING

STARTUP OF FIRE TRAINING

FACILITY IN MARCH-APRIL. THE

CONTRACTOR WILL RECEIVE

NOTICE FROM 88 CES/CEOES FOR

THE EXACT DATE. THE

CONTRACTOR WILL PERFORM A

SEMI-ANNUAL INSPECTION DURING

SPRING START UP.

Product Service Code: J042 Firm Fixed Price

Each

WINTERIZATION OF AFTC PROVIDE

ALL MANGEMENT, LABOR, TOOLS,

EQUIPMENT, TRANSPORTATION,

MATERIALS AND PARTS

NECESSARY TO PERFORM

WINTERIZATION OF FIRE TRAINING

FACILITY IN NOV. - DEC. THE

CONTRACTOR WILL RECEIVE

NOTICE FROM 88 CES/CEOES FOR

THE EXACT DATE. THE

CONTRACTOR WILL PERFORM A

SEMI-ANNUAL INSPECTION DURING

WINTERIZATION.

EMERGENCY REPAIRS OF AFTC T&M

- THE CONTRACTOR SHALL

PERFORM EMERGENCY REPAIRS

WITHIN 72 HOURS OF NOTIFICATION

FROM 88 CES/CEOES IN

ACCORDANCE WITH THE PWS

PARAGRAPH 1.2.5. CONTRACTOR -

PLEASE REFER TO ATTACHMENT 5

AND FILL IN YELLOW HIGHLIGHTED

AREAS ONLY. THIS WILL POPULATE

PRICING FOR THE BASE AND

OPTION YEARS FOR THIS CLIN.

Labor Hours

EMERGENCY REPAIRS OF AFTC T&M

- THE CONTRACTOR SHALL

PERFORM EMERGENCY REPAIRS

WITHIN 72 HOURS OF NOTIFICATION

FROM 88 CES/CEOES IN

ACCORDANCE WITH THE PWS

PARAGRAPH 1.2.5. CONTRACTOR -

PLEASE REFER TO ATTACHMENT 5

AND FILL IN YELLOW HIGHLIGHTED

AREAS ONLY. THIS WILL POPULATE

PRICING FOR THE BASE AND

OPTION YEARS FOR THIS CLIN.

10,000

Option Line Item

SPRING START UP OF AFTC FFP -

PROVIDE ALL MANAGEMENT,

LABOR, TOOLS, EQUIPMENT,

TRANSPORTATION, MATERIALS,

AND PARTS NECESSARY TO

PERFORM SPRING STARTUP OF FIRE

TRAINING FACILITY IN MARCH-

APRIL. THE CONTRACTOR WILL

RECEIVE NOTICE FROM 88 CES

/CEOES FOR THE EXACT DATE. THE

CONTRACTOR WILL PERFORM A

SEMI-ANNUAL INSPECTION DURING

SPRING START UP.

Item

WINTERIZATION OF AFTC FFP -

PROVIDE ALL MANGEMENT, LABOR,

TOOLS, EQUIPMENT,

TRANSPORTATION, MATERIALS

AND PARTS NECESSARY TO

PERFORM WINTERIZATION OF FIRE

TRAINING FACILITY IN NOV. - DEC.

THE CONTRACTOR WILL RECEIVE

NOTICE FROM 88 CES/CEOES FOR

THE EXACT DATE. THE

CONTRACTOR WILL PERFORM A

SEMI-ANNUAL INSPECTION DURING

WINTERIZATION.

Item

EMERGENCY REPAIRS OF AFTC T&M

- THE CONTRACTOR SHALL

PERFORM EMERGENCY REPAIRS

WITHIN 72 HOURS OF NOTIFICATION

FROM 88 CES/CEOES IN

ACCORDANCE WITH THE PWS

PARAGRAPH 1.2.5. CONTRACTOR -

PLEASE REFER TO ATTACHMENT 5

AND FILL IN YELLOW HIGHLIGHTED

AREAS ONLY. THIS WILL POPULATE

PRICING FOR THE BASE AND

OPTION YEARS FOR THIS CLIN.

Item

PARTS FOR EMERGENCY REPAIRS

TO AFTC T&M - CONTRACTOR

SHALL PROVIDE ALL PARTS AND

MATERIALS TO SUPPORT REPAIRS

UNDER LINE ITEM 1004.

Item

SPRING START UP OF AFTC FFP -

PROVIDE ALL MANAGEMENT,

LABOR, TOOLS, EQUIPMENT,

TRANSPORTATION, MATERIALS,

AND PARTS NECESSARY TO

PERFORM SPRING STARTUP OF FIRE

TRAINING FACILITY IN MARCH-

APRIL. THE CONTRACTOR WILL

RECEIVE NOTICE FROM 88 CES

2001 /CEOES FOR THE EXACT DATE. THE

CONTRACTOR WILL PERFORM A

SEMI-ANNUAL INSPECTION DURING

SPRING START UP.

Item

WINTERIZATION OF AFTC FFP -

PROVIDE ALL MANGEMENT, LABOR,

TOOLS, EQUIPMENT,

TRANSPORTATION, MATERIALS

AND PARTS NECESSARY TO

PERFORM WINTERIZATION OF FIRE

TRAINING FACILITY IN NOV. - DEC.

THE CONTRACTOR WILL RECEIVE

NOTICE FROM 88 CES/CEOES FOR

THE EXACT DATE. THE

CONTRACTOR WILL PERFORM A

SEMI-ANNUAL INSPECTION DURING

WINTERIZATION.

Item

EMERGENCY REPAIRS OF AFTC T&M

- THE CONTRACTOR SHALL

PERFORM EMERGENCY REPAIRS

WITHIN 72 HOURS OF NOTIFICATION

FROM 88 CES/CEOES IN

ACCORDANCE WITH THE PWS

PARAGRAPH 1.2.5. CONTRACTOR -

PLEASE REFER TO ATTACHMENT 5

AND FILL IN YELLOW HIGHLIGHTED

AREAS ONLY. THIS WILL POPULATE

PRICING FOR THE BASE AND

OPTION YEARS FOR THIS CLIN.

Item

PARTS FOR EMERGENCY REPAIRS

T&M - CONTRACTOR SHALL

PROVIDE ALL PARTS AND

MATERIALS TO SUPPORT REPAIRS

UNDER LINE ITEM 2004.

Description/Specifications/Statement of Work

Requirements

Crash Fire Facility Maintenance

Packaging and Marking

Inspection and Acceptance

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.246-6 Inspection-Time-and-Material and Labor-Hour. 2001-05 52.246-16 Responsibility for Supplies. 1984-04

DFARS Clauses Incorporated by Reference

252.245-7001 Tagging, Labeling, and Marking of Government-Furnished Property. 2012-04

0001 Inspection and Acceptance Location Both Other Instructions: N/A

DoDAAC: F4F2AA Cage:

DunsNumber:

Duns4Number:

CountryCode: USA

F4F2AA 88 CEG

AF NO MILSBILLS PROC CP 9372573781

1450 LITTRELL RD

WRIGHT PATTERSON

AFB, OH 45433 5261

UNITED STATES

OfficeCode:

Sean Thomson Telephone: Sean Thomson

0002 Inspection and Acceptance Location

DunsNumber:

1450 LITTRELL RD

WRIGHT PATTERSON

Telephone: 937-904-2216

0003 Inspection and Acceptance Location

DunsNumber:

1450 LITTRELL RD

WRIGHT PATTERSON

0004 Inspection and Acceptance Location

DunsNumber:

1450 LITTRELL RD

WRIGHT PATTERSON

Option Line Item 1001 Inspection and Acceptance Location

DunsNumber:

1450 LITTRELL RD

WRIGHT PATTERSON

Option Line Item 1002 Inspection and Acceptance Location

DunsNumber:

1450 LITTRELL RD

WRIGHT PATTERSON

Option Line Item 1003 Inspection and Acceptance Location

DunsNumber:

1450 LITTRELL RD

WRIGHT PATTERSON

Option Line Item 1004

Inspection and Acceptance Location

DunsNumber:

1450 LITTRELL RD

WRIGHT PATTERSON

Option Line Item 2001 Inspection and Acceptance Location

DunsNumber:

1450 LITTRELL RD

WRIGHT PATTERSON

Option Line Item 2002 Inspection and Acceptance Location

DunsNumber:

1450 LITTRELL RD

WRIGHT PATTERSON

Option Line Item 2003 Inspection and Acceptance Location

Instructions: N'A

DunsNumber:

1450 LITTRELL RD

WRIGHT PATTERSON

Option Line Item 2004 Inspection and Acceptance Location

DunsNumber:

1450 LITTRELL RD

WRIGHT PATTERSON

Deliveries or Performance

Delivery Procedures Commercial Vehicles All vehicles larger than a large pick-up truck are required to be inspected by the WrightPatterson Air Force Base Commercial Vehicle Delivery Gate (CVDG) prior to entering the installation. Vehicles to be inspected include, but are not limited to, the following:

1. Step van/panel truck

2. Tractor/trailer, box and flatbed containing cargo

3. Tanker trucks

4. Box trucks

5. Tour buses

6. Garbage/recycled waste trucks

7. Concrete trucks/mixers, dump trucks

8. Cranes, recreational vehicles, petroleum tanker This inspection will be conducted at Gate 26A located off State Highway 235.

The following are exemptions to vehicles utilizing the CVDG:

1. If the vehicle has the product inside (concrete and asphalt trucks) and timely delivery is necessary due to product deterioration it does not need to enter the CVDG. To bypass the CVDG, the contractor shall submit a list containing drivers' names, social security numbers and the state in which the driver's license is held for those drivers who will be entering the base. This shall be accomplished 24 hours prior to requested entry time. If entry is requested on Monday, this list must be submitted by Friday at 1630 hours. All lists shall be submitted to the 88th ABW/CE Directorate contract inspector. The only gates that may be used under this exemption shall be 15A, 38A, and gate 1B. If the driver's name is not on the list, he/she will not be allowed access to the installation through these gates and the base will not assume liability for denied access.

2. If a delivery vehicle must exit, and then re-enter the base to complete its route, the vehicle shall be resealed upon exiting the base. After initially passing through the commercial vehicle delivery gate, trucks shall be resealed at Gates 15A, 38A and 22B. The resealing of the trucks will allow them to continue to any other area of the installation (Areas A and B) without reprocessing through the CVDG. To receive resealing assistance, the drivers shall physically stop at one of the three authorized gates and request the installation entry controller to reseal their truck and provide the next location of their delivery. The controller will reseal the truck and give the delivery driver a pre-clearance form. The driver shall present the pre-clearance form to the entry controller at the next point of installation entry. This reentry can be through any base gate.

Vehicles may be subject to an inspection at any of installation entry control points during a directed random antiterrorism measure (RAM.) Any commercial vehicle, regardless of size, can be directed to the VDG at the discretion of the installation entry controller.

(End of Statement)

Delivery Schedule

Period of Performance

From

01 MAR 2022

To

28 FEB 2023

01 MAR 2022

01 MAR 2022

01 MAR 2022

Option Line

Item 1001 Delivery Schedule

01 MAR 2023

28 FEB 2024

Item 1002 Delivery Schedule

01 MAR 2023

Item 1003 Delivery Schedule

01 MAR 2023

Item 1004 Delivery Schedule

01 MAR 2023

Item 2001 Delivery Schedule

01 MAR 2024

28 FEB 2025

Item 2002 Delivery Schedule

01 MAR 2024

Item 2003 Delivery Schedule

01 MAR 2024

Item 2004 Delivery Schedule

01 MAR 2024

52.247-34 F.o.b. Destination. 1991-11

Contract Administration Data

252.201-7000 Contracting Officer's Representative. 1991-12 252.204-7006 Billing Instructions. 2005-10 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. 2018-12

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. 2018-12

As prescribed in 232.7004(b), use the following clause:

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) Definitions. As used in this clause-

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall-

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items-

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

N/A

(Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

COMBO

(Contracting Officer: Insert either "Invoice 2in1" or the applicable invoice and receiving report document type(s) for fixed price line items for services.)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

(f) [Note: The Contractor may use a WAWF "combo" document type to create some combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF

Data to be entered in WAWF

Pay Official DoDAAC

F87700

Issue By DoDAAC

FA8601

Admin DoDAAC

FA8601

Inspect By DoDAAC

F4F2AA

Ship To Code

Ship From Code

Mark For Code

Service Approver (DoDAAC)

Service Acceptor (DoDAAC)

Accept at Other DoDAAC

LPO DoDAAC

DCAA Auditor DoDAAC

Other DoDAAC(s)

(*Contracting Officer: Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert "See Schedule" or "Not applicable.")

(**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).)

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

Help Desk

(Contracting Officer: Insert applicable information or "Not applicable.")

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

252.232-7007 Limitation of Government's Obligation. 2014-04

As prescribed in 232.705-70, use the following clause:

LIMITATION OF GOVERNMENT'S OBLIGATION (APR 2014)

(a) Contract line item(s) [Contracting Officer insert after negotiations] is/are incrementally funded. For this/these item(s), the sum of $ [Contracting Officer insert after negotiations] of the total price is presently available for payment and allotted to this contract. An allotment schedule is set forth in paragraph (j) of this clause.

(b) For item(s) identified in paragraph (a) of this clause, the Contractor agrees to perform up to the point at which the total amount payable by the Government, including reimbursement in the event of termination of those item(s) for the Government's convenience, approximates the total amount currently allotted to the contract. The Contractor is not authorized to continue work on those item(s) beyond that point. The Government will not be obligated in any event to reimburse the Contractor in excess of the amount allotted to the contract for those item(s) regardless of anything to the contrary in the clause entitled "Termination for Convenience of the Government." As used in this clause, the total amount payable by the Government in the event of termination of applicable contract line item(s) for convenience includes costs, profit, and estimated termination settlement costs for those item(s).

(c) Notwithstanding the dates specified in the allotment schedule in paragraph (j) of this clause, the Contractor will notify the Contracting Officer in writing at least ninety days prior to the date when, in the Contractor's best judgment, the work will reach the point at which the total amount payable by the Government, including any cost for termination for convenience, will approximate 85 percent of the total amount then allotted to the contract for performance of the applicable item(s). The notification will state (1) the estimated date when that point will be reached and (2) an estimate of additional funding, if any, needed to continue performance of applicable line items up to the next scheduled date for allotment of funds identified in paragraph (j) of this clause, or to a mutually agreed upon substitute date. The notification will also advise the Contracting Officer of the estimated amount of additional funds that will be required for the timely performance of the item(s) funded pursuant to this clause, for a subsequent period as may be specified in the allotment schedule in paragraph (j) of this clause or otherwise agreed to by the parties. If after such notification additional funds are not allotted by the date identified in the Contractor's notification, or by an agreed substitute date, the Contracting Officer will terminate any item(s) for which additional funds have not been allotted, pursuant to the clause of this contract entitled "Termination for Convenience of the Government."

(d) When additional funds are allotted for continued performance of the contract line item(s) identified in paragraph (a) of this clause, the parties will agree as to the period of contract performance which will be covered by the funds. The provisions of paragraphs (b) through (d) of this clause will apply in like manner to the additional allotted funds and agreed substitute date, and the contract will be modified accordingly.

(e) If, solely by reason of failure of the Government to allot additional funds, by the dates indicated below, in amounts sufficient for timely performance of the contract line item(s) identified in paragraph (a) of this clause, the Contractor incurs additional costs or is delayed in the performance of the work under this contract and if additional funds are allotted, an equitable adjustment will be made in the price or prices (including appropriate target, billing, and ceiling prices where applicable) of the item(s), or in the time of delivery, or both. Failure to agree to any such equitable adjustment hereunder will be a dispute concerning a question of fact within the meaning of the clause entitled "Disputes."

(f) The Government may at any time prior to termination allot additional funds for the performance of the contract line item(s) identified in paragraph (a) of this clause.

(g) The termination provisions of this clause do not limit the rights of the Government under the clause entitled "Default." The provisions of this clause are limited to the work and allotment of funds for the contract line item(s) set forth in paragraph (a) of this clause. This clause no longer applies once the contract is fully funded except with regard to the rights or obligations of the parties concerning equitable adjustments negotiated under paragraphs (d) and (e) of this clause.

(h) Nothing in this clause affects the right of the Government to terminate this contract pursuant to the clause of this contract entitled "Termination for Convenience of the Government."

(i) Nothing in this clause shall be construed as authorization of voluntary services whose acceptance is otherwise prohibited under 31 U.S.C.

1342.

(j) The parties contemplate that the Government will allot funds to this contract in accordance with the following schedule:

On execution of contract $

(month) (day), (year) $

Special Contract Requirements

DFARS Clauses Incorporated by Full Text

252.211-7003 Item Unique Identification and Valuation. 2016-03

As prescribed in 211.274-6(a)(1), use the following clause:

ITEM UNIQUE IDENTIFICATION AND VALUATION (MAR 2016)

(a) Definitions. As used in this clause-

"Automatic identification device" means a device, such as a reader or interrogator, used to retrieve data encoded on machine-readable media.

"Concatenated unique item identifier" means-

(1) For items that are serialized within the enterprise identifier, the linking together of the unique identifier data elements in order of the issuing agency code, enterprise identifier, and unique serial number within the enterprise identifier; or

(2) For items that are serialized within the original part, lot, or batch number, the linking together of the unique identifier data elements in order of the issuing agency code; enterprise identifier; original part, lot, or batch number; and serial number within the original part, lot, or batch number.

"Data matrix" means a two-dimensional matrix symbology, which is made up of square or, in some cases, round modules arranged within a perimeter finder pattern and uses the Error Checking and Correction 200 (ECC200) specification found within International Standards Organization (ISO)/International Electrotechnical Commission (IEC) 16022.

"Data qualifier" means a specified character (or string of characters) that immediately precedes a data field that defines the general category or intended use of the data that follows.

"DoD recognized unique identification equivalent" means a unique identification method that is in commercial use and has been recognized by DoD. All DoD recognized unique identification equivalents are listed at http://www.acq.osd.mil/dpap/pdi/uid/iuid_equivalents.html.

"DoD item unique identification" means a system of marking items delivered to DoD with unique item identifiers that have machine-readable data elements to distinguish an item from all other like and unlike items. For items that are serialized within the enterprise identifier, the unique item identifier shall include the data elements of the enterprise identifier and a unique serial number. For items that are serialized within the part, lot, or batch number within the enterprise identifier, the unique item identifier shall include the data elements of the enterprise identifier; the original part, lot, or batch number; and the serial number.

" Enterprise " means the entity (e.g., a manufacturer or vendor) responsible for assigning unique item identifiers to items.

" Enterprise identifier" means a code that is uniquely assigned to an enterprise by an issuing agency.

"Government's unit acquisition cost" means-

(1) For fixed-price type line, subline, or exhibit line items, the unit price identified in the contract at the time of delivery;

(2) For cost-type or undefinitized line, subline, or exhibit line items, the Contractor's estimated fully burdened unit cost to the Government at the time of delivery; and

(3) For items produced under a time-and-materials contract, the Contractor's estimated fully burdened unit cost to the Government at the time of delivery.

"Issuing agency" means an organization responsible for assigning a globally unique identifier to an enterprise, as indicated in the Register of Issuing Agency Codes for ISO/IEC 15459, located at http://www.aimglobal.org/?Reg_Authority15459.

"Issuing agency code" means a code that designates the registration (or controlling) authority for the enterprise identifier.

"Item" means a single hardware article or a single unit formed by a grouping of subassemblies, components, or constituent parts.

" Lot or batch number" means an identifying number assigned by the enterprise to a designated group of items, usually referred to as either a lot or a batch, all of which were manufactured under identical conditions.

"Machine-readable" means an automatic identification technology media, such as bar codes, contact memory buttons, radio frequency identification, or optical memory cards.

"Original part number" means a combination of numbers or letters assigned by the enterprise at item creation to a class of items with the same form, fit, function, and interface.

http://www.acq.osd.mil/dpap/pdi/uid/iuid_equivalents.html http://www.aimglobal.org/?Reg_Authority15459

"Parent item" means the item assembly, intermediate component, or subassembly that has an embedded item with a unique item identifier or DoD recognized unique identification equivalent.

"Serial number within the enterprise identifier" means a combination of numbers, letters, or symbols assigned by the enterprise to an item that provides for the differentiation of that item from any other like and unlike item and is never used again within the enterprise.

"Serial number within the part, lot, or batch number" means a combination of numbers or letters assigned by the enterprise to an item that provides for the differentiation of that item from any other like item within a part, lot, or batch number assignment.

"Serialization within the enterprise identifier" means each item produced is assigned a serial number that is unique among all the tangible items produced by the enterprise and is never used again. The enterprise is responsible for ensuring unique serialization within the enterprise identifier.

"Serialization within the part, lot, or batch number" means each item of a particular part, lot, or batch number is assigned a unique serial number within that part, lot, or batch number assignment. The enterprise is responsible for ensuring unique serialization within the part, lot, or batch number within the enterprise identifier.

"Type designation" means a combination of letters and numerals assigned by the Government to a major end item, assembly or subassembly, as appropriate, to provide a convenient means of differentiating between items having the same basic name and to indicate modifications and changes thereto.

"Unique item identifier" means a set of data elements marked on items that is globally unique and unambiguous. The term includes a concatenated unique item identifier or a DoD recognized unique identification equivalent.

"Unique item identifier type" means a designator to indicate which method of uniquely identifying a part has been used. The current list of accepted unique item identifier types is maintained at http://www.acq.osd.mil/dpap/pdi/uid/uii_types.html.

(b) The Contractor shall deliver all items under a contract line, subline, or exhibit line item.

(c) Unique item identifier.

(1) The Contractor shall provide a unique item identifier for the following:

(i) Delivered items for which the Government's unit acquisition cost is $5,000 or more, except for the following line items:

Contract Line, Subline, or

Exhibit Line Item Number Item Description

(ii) Items for which the Government's unit acquisition cost is less than $5,000 that are identified in the Schedule or the following table:

Contract Line, Subline, or

Exhibit Line Item Number Item Description

(If items are identified in the Schedule, insert "See Schedule in this table.)

(iii) Subassemblies, components, and parts embedded within delivered items, items with warranty requirements, DoD serially managed reparables and DoD serially managed nonreparables as specified in Attachment Number .

(iv) Any item of special tooling or special test equipment as defined in FAR 2.101 that have been designated for preservation and storage for a Major Defense Acquisition Program as specified in Attachment Number .

(v) Any item not included in (i), (ii), (iii), or (iv) for which the contractor creates and marks a unique item identifier for traceability.

(2) The unique item identifier assignment and its component data element combination shall not be duplicated on any other item marked or registered in the DoD Item Unique Identification Registry by the contractor.

http://www.acq.osd.mil/dpap/pdi/uid/uii_types.html

(3) The unique item identifier component data elements shall be marked on an item using two dimensional data matrix symbology that complies with ISO/IEC International Standard 16022, Information technology – International symbology specification – Data matrix; ECC200 data matrix specification.

(4) Data syntax and semantics of unique item identifiers. The Contractor shall ensure that-

(i) The data elements (except issuing agency code) of the unique item identifier are encoded within the data matrix symbol that is marked on the item using one of the following three types of data qualifiers, as determined by the Contractor:

(A) Application Identifiers (AIs) (Format Indicator 05 of ISO/IEC International Standard 15434), in accordance with ISO/IEC International Standard 15418, Information Technology – EAN/UCC Application Identifiers and Fact Data Identifiers and Maintenance and ANSI MH

10.8.2 Data Identifier and Application Identifier Standard.

(B) Data Identifiers (DIs) (Format Indicator 06 of ISO/IEC International Standard 15434), in accordance with ISO/IEC International Standard 15418, Information Technology – EAN/UCC Application Identifiers and Fact Data Identifiers and Maintenance and ANSI MH

10.8.2 Data Identifier and Application Identifier Standard.

(C) Text Element Identifiers (TEIs) (Format Indicator 12 of ISO/IEC International Standard 15434), in accordance with the Air Transport Association Common Support Data Dictionary; and

(ii) The encoded data elements of the unique item identifier conform to the transfer structure, syntax, and coding of messages and data formats specified for Format Indicators 05, 06, and 12 in ISO/IEC International Standard 15434, Information Technology – Transfer Syntax for High Capacity Automatic Data Capture Media.

(5) Unique item identifier.

(i) The Contractor shall-

(A) Determine whether to-

(1) Serialize within the enterprise identifier;

(2) Serialize within the part, lot, or batch number; or

(3) Use a DoD recognized unique identification equivalent (e.g. Vehicle Identification Number); and

(B) Place the data elements of the unique item identifier (enterprise identifier; serial number; DoD recognized unique identification equivalent; and for serialization within the part, lot, or batch number only: original part, lot, or batch number) on items requiring marking by paragraph (c)(1) of this clause, based on the criteria provided in MIL-STD-130, Identification Marking of U.S. Military Property, latest version;

(C) Label shipments, storage containers and packages that contain uniquely identified items in accordance with the requirements of MIL-STD-129, Military Marking for Shipment and Storage, latest version; and

(D) Verify that the marks on items and labels on shipments, storage containers, and packages are machine readable and conform to the applicable standards. The contractor shall use an automatic identification technology device for this verification that has been programmed to the requirements of Appendix A, MIL-STD-130, latest version.

(ii) The issuing agency code-

(A) Shall not be placed on the item; and

(B) Shall be derived from the data qualifier for the enterprise identifier.

(d) For each item that requires item unique identification under paragraph (c)(1)(i), (ii), or (iv) of this clause or when item unique identification is provided under paragraph (c)(1)(v), in addition to the information provided as part of the Material Inspection and Receiving Report specified elsewhere in this contract, the Contractor shall report at the time of delivery, as part of the Material Inspection and Receiving Report, the following information:

(1) Unique item identifier.

(2) Unique item identifier type.

(3) Issuing agency code (if concatenated unique item identifier is used).

(4) Enterprise identifier (if concatenated unique item identifier is used).

(5) Original part number (if there is serialization within the original part number).

(6) Lot or batch number (if there is serialization within the lot or batch number).

(7) Current part number (optional and only if not the same as the original part number).

(8) Current part number effective date (optional and only if current part number is used).

(9) Serial number (if concatenated unique item identifier is used).

(10) Government's unit acquisition cost.

(11) Unit of measure.

(12) Type designation of the item as specified in the contract schedule, if any.

(13) Whether the item is an item of Special Tooling or Special Test Equipment.

(14) Whether the item is covered by a warranty.

(e) For embedded subassemblies, components, and parts that require DoD item unique identification under paragraph (c)(1)(iii) of this clause or when item unique identification is provided under paragraph (c)(1)(v), the Contractor shall report as part of the Material Inspection and Receiving Report specified elsewhere in this contract, the following information:

(1) Unique item identifier of the parent item under paragraph (c)(1) of this clause that contains the embedded subassembly, component, or part.

(2) Unique item identifier of the embedded subassembly, component, or part.

(3) Unique item identifier type.**

(4) Issuing agency code (if concatenated unique item identifier is used).**

(5) Enterprise identifier (if concatenated unique item identifier is used).**

(6) Original part number (if there is serialization within the original part number).**

(7) Lot or batch number (if there is serialization within the lot or batch number).**

(8) Current part number (optional and only if not the same as the original part number).**

(9) Current part number effective date (optional and only if current part number is used).**

(10) Serial number (if concatenated unique item identifier is used).**

(11) Description.

** Once per item.

(f) The Contractor shall submit the information required by paragraphs (d) and (e) of this clause as follows:

(1) End items shall be reported using the receiving report capability in Wide Area WorkFlow (WAWF) in accordance with the clause at 252.232-7003. If WAWF is not required by this contract, and the contractor is not using WAWF, follow the procedures at http://dodprocurementtoolbox.com/site/uidregistry/.

(2) Embedded items shall be reported by one of the following methods-

(i) Use of the embedded items capability in WAWF;

(ii) Direct data submission to the IUID Registry following the procedures and formats at http://dodprocurementtoolbox.com/site /uidregistry/; or

(iii) Via WAWF as a deliverable attachment for exhibit line item number (fill in) , Unique Item Identifier Report for Embedded Items, Contract Data Requirements List, DD Form 1423.

(g) Subcontracts. If the Contractor acquires by subcontract, any item(s) for which item unique identification is required in accordance with paragraph (c)(1) of this clause, the Contractor shall include this clause, including this paragraph (g), in the applicable subcontract(s), including subcontracts for commercial items.

http://dodprocurementtoolbox.com/site/uidregistry/ http://dodprocurementtoolbox.com/site

Contract Clauses

52.202-1 Definitions. 2020-06 52.203-3 Gratuities. 1984-04 52.203-5 Covenant Against Contingent Fees. 2014-05 52.203-6 Restrictions on Subcontractor Sales to the Government. 2020-06 52.203-6 Alternate I Restrictions on Subcontractor Sales to the Government. - (Alternate I) 2020-06 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity. 2014-05 52.203-10 Price or Fee Adjustment for Illegal or Improper Activity. 2014-05 52.203-12 Limitation on Payments to Influence Certain Federal Transactions. 2020-06 52.203-13 Contractor Code of Business Ethics and Conduct. 2020-06 52.204-13 System for Award Management Maintenance. 2018-10 52.204-18 Commercial and Government Entity Code Maintenance. 2020-08 52.204-19 Incorporation by Reference of Representations and Certifications. 2014-12 52.223-5 Pollution Prevention and Right-to-Know Information. 2011-05 52.223-19 Compliance with Environmental Management Systems. 2011-05 52.225-26 Contractors Performing Private Security Functions Outside the United States. 2016-10 52.228-5 Insurance-Work on a Government Installation. 1997-01 52.232-18 Availability of Funds. 1984-04 52.232-23 Assignment of Claims. 2014-05 52.232-39 Unenforceability of Unauthorized Obligations. 2013-06 52.232-40 Providing Accelerated Payments to Small Business Subcontractors. 2013-12 52.237-2 Protection of Government Buildings, Equipment, and Vegetation. 1984-04 52.245-1 Government Property. 2017-01 52.245-9 Use and Charges. 2012-04 52.249-1 Termination for Convenience of the Government (Fixed-Price) (Short Form). 1984-04 52.249-6 Alternate IV Termination (Cost-Reimbursement). (Alternate IV) 2004-05 52.249-14 Excusable Delays. 1984-04

252.203-7000 Requirements Relating to Compensation of Former DoD Officials. 2011-09 252.203-7002 Requirement to Inform Employees of Whistleblower Rights. 2013-09 252.204-7003 Control of Government Personnel Work Product. 1992-04 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting. 2019-12 252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support. 2016-05

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services.

252.209-7004 Subcontracting with Firms that are Owned or Controlled by the Government of a

2021-01

2019-05

FAR Clauses Incorporated by Full Text

Country that is a State Sponsor of Terrorism.

252.211-7007 Reporting of Government-Furnished Property. 2012-08 252.223-7006 Prohibition on Storage, Treatment, and Disposal of Toxic or Hazardous Materials. 2014-09 252.223-7008 Prohibition of Hexavalent Chromium. 2013-06 252.225-7001 Buy American and Balance of Payments Program. 2017-12 252.225-7002 Qualifying Country Sources as Subcontractors. 2017-12 252.225-7048 Export-Controlled Items. 2013-06 252.232-7010 Levies on Contract Payments. 2006-12

252.232-7017 Accelerating Payments to Small Business Subcontractors-Prohibition on Fees and Consideration.

2020-04

252.237-7010 Prohibition on Interrogation of Detainees by Contractor Personnel. 2013-06 252.242-7006 Accounting System Administration. 2012-02 252.243-7001 Pricing of Contract Modifications. 1991-12 252.244-7000 Subcontracts for Commercial Items. 2020-10 252.245-7002 Reporting Loss of Government Property 2021-01 252.245-7003 Contractor Property Management System Administration 2012-04

52.204-1 Approval of Contract. 1989-12

As prescribed in 4.103 , insert the following clause:

APPROVAL OF CONTRACT (DEC 1989)

This contract is subject to the written approval of [identify title of designated agency official here] and shall not be binding until so approved.

52.211-11 Liquidated Damages-Supplies, Services, or Research and Development. 2000-09

As prescribed in 11.503(a), insert the following clause in solicitations and contracts:

LIQUIDATED DAMAGES-SUPPLIES, SERVICES, OR RESEARCH AND DEVELOPMENT (SEPT 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $ per calendar day of delay [Contracting Officer insert amount].

(b) If the Government terminates this contract in whole or in part under the Default-Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default-Fixed-Price Supply and Service clause in this contract.

52.212-4 Alternate I Contract Terms and Conditions-Commercial Items. (Alternate I) 2018-10

As prescribed in 12.301(b)(3), insert the following clause:

CONTRACT TERMS AND CONDITIONS-COMMERCIAL ITEMS (OCT 2018)

(a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights-

(1) Within a reasonable time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.

C. 3727). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract.

(c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties.

(d) Disputes. This contract is subject to 41 U.S.C. chapter 71, Contract Disputes. Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at FAR 52.233-1, Disputes, which is incorporated herein by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract.

(e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference.

(f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(g) Invoice. (1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include-

(i) Name and address of the Contractor;

(ii) Invoice date and number;

(iii) Contract number, line item number and, if applicable, the order number;

(iv) Description, quantity, unit of measure, unit price and extended price of the items delivered;

(v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading;

(vi) Terms of any discount for prompt payment offered;

(vii) Name and address of official to whom payment is to be sent;

(viii) Name, title, and phone number of person to notify in event of defective invoice; and

(ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract.

(x) Electronic funds transfer (EFT) banking information.

(A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract.

(B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer-System for Award Management, or 52.232-34, Payment by Electronic Funds Transfer-Other Than System for Award Management), or applicable agency procedures.

(C) EFT banking information is not required if the Government waived the requirement to pay by EFT.

(2) Invoices will be handled in accordance with the Prompt Payment Act (31 U.S.C.3903) and Office of Management and Budget (OMB) prompt payment regulations at 5 CFR Part 1315.

(h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings.

(i) Payment.- (1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract.

(2) Prompt payment. The Government will make payment in accordance with the Prompt Payment Act (31 U.S.C.3903) and prompt payment regulations at 5 CFR Part 1315.

(3) Electronic Funds Transfer (EFT). If the Government makes payment by EFT, see 52.212-5(b) for the appropriate EFT clause.

(4) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the specified payment date if an electronic funds transfer payment is made.

(5) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall-

(i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the-

(A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment);

(B) Affected contract number and delivery order number, if applicable;

(C) Affected line item or subline item, if applicable; and

(D) Contractor point of contact.

(ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer.

(6) Interest. (i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in 41 U.S.C. 7109, which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period as fixed by the Secretary until the amount is paid.

(ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract.

(iii) Final decisions. The Contracting Officer will issue a final decision as required by 33.211 if-

(A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days;

(B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or

(C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see 32.607-2).

(iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment.

(v) Amounts shall be due at the earliest of the following dates:

(A) The date fixed under this contract.

(B) The date of the first written demand for payment, including any demand for payment resulting from a default termination.

(vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on-

(A) The date on which the designated office receives payment from the Contractor;

(B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or

(C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor.

(vii) The interest charge made under this clause may be reduced under the procedures prescribed in 32.608-2 of the Federal Acquisition Regulation in effect on the date of this contract.

(j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon:

(1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or

(2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b. destination.

(k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties.

(l) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided.

(m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the…