EXHIBIT B - 2025 LABOR RATES _ CLASS 0808.xlsx

XLSX spreadsheet 132 KB Posted Sep 17, 2025

Attached to: On-Call Architectural and Engineering Services SBE State and local contract opportunity
Solicitation number: 202577962
Issued by: Denver County, Denver City, Colorado

About this file

Written by GovTribe AI · Sep 17, 2025

This is an Exhibit B document for labor rates related to Denver International Airport's (DEN) Design, Engineering, & Construction (DEC) Professional Services Agreements. The document outlines core staff rates for professional services across multiple job categories and experience levels, ranging from entry-level to managerial positions. The contract appears to be for on-call architectural and engineering services, with a focus on Small Business Enterprise (SBE) participation, covering project types including facility modifications, new facility design, building evaluations, reports, studies, architectural programming, planning, permitting, estimating, scheduling, constructability reviews, and construction administration.

The labor rate exhibit provides a comprehensive breakdown of positions with detailed descriptions, including administrative, architectural, construction, engineering, surveying, and specialist roles. Each position is categorized into five experience levels (Entry, Developmental, Full Experience, Supervisory, and Managerial), with corresponding salary ranges and multipliers. The document includes provisions for tracking prime and sub-contractors, with space for multiple companies and a data validation section. The rates appear to be structured for a multi-year contract, with provisions for rate adjustments across six calendar years, suggesting a long-term professional services arrangement with flexible staffing and pricing mechanisms.

View the file

Other files for this state and local contract opportunity

Other files attached to On-Call Architectural and Engineering Services SBE, newest first.
File	Type	Posted
RFP - On-Call AE Svcs SBE 202577962..pdf	PDF	Sep 17, 2025

On GovTribe

Work with this file on GovTribe

Download the original file
Contacts named in this file
Similar government files
Ask GovTribe AI about this file

Try for free Login

Text version

The file's text, extracted by GovTribe without its formatting.

Cover

EXHIBIT B COVER

Denver International Airport

Design, Engineering, & Construction (DEC)

Professional Services Agreements

Core Staff Rates

DEN Contract Name:

DEN Contract Number:

Prime Consultant:

Project Name:

Project Number:

MWBE/SBE/DBE Contractual Goal:

Consultant Main Point of Contact (POC):

Consultant Main POC Email Address:

Consultant Main POC Phone Number:

Contract Point of Contact Signature Contract Point of Contact Name

Date:

City and County of Denver

Company Proprietary Information

Release to others outside of Denver International Airport Design, Engineering, & Construction (DEC) Department is prohibited without expressed written permission from the company named above.

Revision July 2025

Company Information

COMPANY INFO

Prime Consultant and Sub-Consultants Listings

	Company Name	Prime / Sub-Contractor	Multiplier	MWBE / SBE Goal %
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
27
28
29
30
31
32
33
34
35
36
37
38
39
40

Staff Rates

STAFF RATES

Core Staff Rates

** The “Base Rate” for any employee of the Prime or Sub Consultant is the average annual salary for the Position listed, divided by 2,080.

			Company Name	Prime or
Sub-Contractor	Position	Experience Level	Base Rate**	Multiplier	Calendar Year 1	Calendar Year 2	Calendar Year 3	Calendar Year 4	Calendar Year 5	Calendar Year 6
		1
		2
		3
		4
		5
		6
		7
		8
		9
		10
		11
		12
		13
		14
		15
		16
		17
		18
		19
		20
		21
		22
		23
		24
		25
		26
		27
		28
		29
		30
		31
		32
		33
		34
		35
		36
		37
		38
		39
		40
		41
		42
		43
		44
		45
		46
		47
		48
		49
		50
		51
		52
		53
		54
		55
		56
		57
		58
		59
		60
		61
		62
		63
		64
		65
		66
		67
		68
		69
		70
		71
		72
		73
		74
		75
		76
		77
		78
		79
		80
		81
		82
		83
		84
		85
		86
		87
		88
		89
		90
		91
		92
		93
		94
		95
		96
		97
		98
		99
		100
		101
		102
		103
		104
		105
		106
		107
		108
		109
		110
		111
		112
		113
		114
		115
		116
		117
		118
		119
		120
		121
		122
		123
		124
		125
		126
		127
		128
		129
		130
		131
		132
		133
		134
		135
		136
		137
		138
		139
		140
		141
		142
		143
		144
		145
		146
		147
		148
		149
		150

Positions List

POSITION LIST

Level of Experience	Description
Level 1, Entry	Assignments are concentrated in one functional area within individual's discipline or field. Works with close direction as to approach and desires end results. Becomes familiar with techniques, approaches, and

procedures and the nature of engineering systems, equipment, etc., applicable to assignments. Requires engineering degree and 0 to 1 year's experience or the equivalent experience.

Level 2, Developmetal Individual is capable of independently performing most conventional technical functions within discipline. Work is reviewed for application of sound professional judgment. May provide technical direction to a few support personnel. Requires engineering degree plus 2 to 3 years' engineering or equivalent experience.

Level 3, Full Experience Fully experienced and competent individual capable of performing all functions within a discipline and capable of solving difficult problems requiring substantial evaluation, analysis, and modification or adoption of standard techniques or methods. May provide technical direction to a small group of professionals and/or support personnel. Requires engineering degree plus 4 to 6 years' engineering experience or the equivalent.

Level 4, Supervisory Supervisory level responsible for the technical activities related to numerous projects. Staffs, establishes objectives, and reviews performance of activities on projects directed. Requires engineering degree plus 7 to 9 years' experience or the equivalent.

Level 5, Managerial Individual has full managerial responsibility for a given scope of work and the direction, control, and utilization of a staff of professionals and support personnel (at least ten or more in number). Is responsible for the scheduling, budgeting, and quality of projects within assigned discipline and scope of work. Requires engineering degree plus 10 or more years' related experience or the equivalent

Area of Expertise	Job Title	Description
Administrative	Administrative Support	This position is designed to provide essential administrative support, helping to streamline processes and enhance productivity. By managing various tasks, the Project Administrative Assistant contributes to the achievement of business goals and the overall efficiency of daily operations. Performs specialized and/or technical office support work that requires detailed knowledge of the specialized/technical area.
Architectural Design	Architect	Makes authoritative decisions and recommendations of significant impact on firm's primary architectural activities. Negotiates critical and controversial issues with top-level architects, engineers, and officers of other organizations and firms. Individual demonstrates high degree of creativity, foresight, and judgment in planning, organizing, and guiding extensive and/or unique architectural programs and activities.
Surveying	Chain/Rod Technicial	Stakes out and elevates survey points. Performers maintenance of certain equipment and maintains supplies for survey crew.
Construction	Chief Construction Representative	Plans and coordinates all field-inspection activities and reviews the work of Inspectors to ensure compliance with job specifications. Will prepare summary reports, respond to various problems of Inspectors, authorize expenses and overtime, and assist Resident Engineers in completion of construction work in accordance with design. Requires 10 or more years of experience with some technical training or the equivalent.
Commissioning	Commissioning Agent	Independently performs non-routine and complex commissioning work with responsibility for planning and execution. Executes and delegates objectives

from supervisor. Develops and maintains commissioning documentation such as commissioning plans, test plans, test results, observations, issues reporting, recommendations, etc. to verify the project meets the owner's requirements. Sufficiently competent in one or more construction disciplines.

Construction	Construction Coordinator	Position supervises the installation of (discipline) equipment, systems, and components, using the technical knowledge and experience to aid installing contractors. Assures that equipment, systems, and components can be constructed without unnecessary delay. Coordinates scheduling of construction and provides communication with project management regarding progress and conflicts. Provides interpretation of specifications and contracts and monitors the construction process, verifying that work completed is in accordance with contract documents.
Construction	Construction Manager	Responsible, through subordinate Resident Construction Managers, for overall management direction of several construction projects. Accountability includes timely and satisfactory completion of construction projects, assuring satisfactory client service, participating in business- development activities, key field-position staffing, project plans, objectives setting/performance evaluation, and related management activities.
Construction	Construction Manager/Engineer	Responsible for all field-construction activities on a large-scale project. May have own project work force, and will act as prime client contact on construction

matters including participation in negotiations and securing client approvals.

		Construction	Construction Representative	Ensures, through testing and observation, that the project construction complies with plans and specifications and that contractor follows the contract documents. Is experienced in a given discipline of inspection work and/or has the capability to monitor several types of work activity. Requires 2 to 5 years of inspection experience.
		Contract Management	Contract Administrator/Manager	Consistent with management's goals, policies, and procedures; will expedite the preparation, review, and execution of contracts for the procurement of goods, materials, or services as related to the construction function. Involves the proper preparation of Preliminary Agreements and Contracts and the obtaining of all required approvals. Will assure that all clarifications and amendments of negotiations are incorporated into the final construction contract. Generates, maintains, and audits a central contract resource file. Assures that necessary procedural controls exist
		Project Support	Cost/Estimating Engineer	Position involves the preparation of quantity takeoffs (computerized or manual) from which cost database, prices of materials, and labor values can be determined and applied. Requires knowledge of technical methods, procedures, and the types of construction work involved. Requires the capability of applying sound cost-estimating and cost-control methods that are pertinent to the project and the evaluation, analysis, modification, or adoption of standard techniques. The degree of complexity of assignments will be dependent upon experience and technical know-how.
		Analytics Development	Data Analyst/Architect	Data model, data mapping, dashboard development, system integration. Performs analytical assessments and evaluations by fulfilling data requests, providing analytical and methodological support, and data modeling.
		Project Management	Design/Construction
Project Manager	Responsible, through subordinate Design/Construction Project Managers, Project Support staff, Inspectors, and others for overall management direction of several construction projects. Accountability includes timely and satisfactory completion of design/construction projects, assuring satisfactory stakeholder and sponsor service. Responsible for supervising, directing, and coordinating design/construction management of commercial, industrial, and/or municipal projects including direct liaison with stakeholders, designers, and contractors regarding project feasibility, cost, staffing, completion, and maintenance. Will negotiate pricing/fees; formulate and implement budget and work plan; prepare project-status reports; and oversee the review of plans and drawings in accordance with contract documents.
		Document Management	Document Controller/Manager	Develop new document control procedures / adjust existing procedures, expertise in record management, manage document repository systems.
		Engineering	Engineer	Position is responsible for multiple construction projects or a single project of a large scale requiring multiple disciplines. This includes reviewing design and bidding documents; soliciting, receiving, and evaluating contractor bids; supervising construction progress and scheduling; starting up process systems/equipment or facilities for turning over to the owner's personnel. Supervises field staff and contractors on the site with responsibility for quality construction in accordance with plans and specifications. Is responsible for approval of change orders, invoices, and payment applications that may include final payment.
		Engineering	Engineer Technician	Performs non-routine and complex assignments with responsibility for planning and conducting a complete project of relatively limited scope or a portion of a larger and more-diverse project. Engineer outlines objectives, requirements, and design approaches. Maybe assisted by lower-level Technicians. Reviews and analyzes a variety of engineering data to determine requirements to meet engineering objectives; may calculate design data; prepares layouts, detailed specifications, parts lists, estimates, procedures, etc.	$109,171 - $127,337
		Engineering	Engineering/ Architect Specialist	Position is responsible for multiple construction projects or a single project of a large scale requiring multiple disciplines. This includes reviewing design and bidding documents; soliciting, receiving, and evaluating contractor bids; supervising construction progress and scheduling; starting up process systems/equipment or facilities for turning over to the owner's personnel. Supervises field staff and contractors on the site with responsibility for quality construction in accordance with plans and specifications. Is responsible for approval of change orders, invoices, and payment applications that may include final payment.	$77,174 - $109,171
		Construction	Field Engineer	Position monitors the activities of contractors on the construction site within a discipline or multiple disciplines based on experience. Initiates action as required to keep construction progress in line with overall project schedule and in conformance with the contract documents. Assists Resident Engineer or Construction Manager in the coordination of activities. Provides daily inspection of construction activities. Reviews contractors' payment applications, change orders, and equipment-vendor-payment requests, making recommendations to their supervisor. Schedules equipment and/or material delivery with contractor schedules to meet project schedule.	$148,526 - $160,408
		Construction	Field Superintendent	Responsible for the day-to-day construction activities of contractors on-site with regard to scheduling manpower and expediting receipt of equipment and materials for utilization at various phases of work. Will review shop drawings, negotiate change orders, resolve contractor conflicts, and provide site coordination on items pertinent to meeting specific cost and time requirements with the contract documents. Requires significant field-construction exposure that may be gained through practical construction experience and/or a degree in engineering with good field/design experience	$71,457 - $117,905
		Quality Assurance	Inspector	Ensures, through testing and observation, that the project construction complies with plans and specifications and that contractor follows the contract documents.Is experienced in various disciplines of inspection work and/or has the capability to monitor several types of work activity. Plans and coordinates all field-inspection activities and may review the work of Inspectors to ensure compliance with job specifications. Will prepare summary reports, respond to various problems of Inspectors, and assist Project Management staff in completion of construction work in accordance with design.
		Engineering	Instrument Technician	Maintains and operates all instruments and measuring devices needed to complete different types of surveying assignments. Has ability to operate the following equipment: transit, level, the odolites, hp distance meter, ranger, chain, electrotope, and tellurometer.
		Interior Design	Interior Designer	Serves as primary contact with clients, consultants, and public agencies on all assigned projects. Determines standards for project development. Requires substantial knowledge of architectural contract preparation and use. Organizes and leads contract negotiations while providing leadership to project teams. Responsible for developing schedules, manpower allocations, and budgets on all assigned projects
		Auditor	Internal Auditor	Is responsible for auditing accounting, financial, and statistical reports and data within the company to ensure the accuracy of information and compliance

with established accounting principles and company policies. Is able to conduct audits of a moderately complex nature and provide evaluation of findings. Normally has a Bachelor's Degree and 3 to 4 years' experience.

Laboratory Laboratory Technician Performs non-routine and complex scientific laboratory assignments with responsibility for planning and conducting complete projects of limited scope or portions of larger and more diverse projects. Can direct and coordinate efforts of other laboratory technicians when required. Fully competent and proficient in operating sophisticated scientific equipment, having ability to independently perform complex procedures and techniques with accuracy.

		Surveying	Land Surveyor	Responsible for initiating and completing both the preliminary and final land surveys and ensuring that accuracy of surveys reflects the integrity of design and meets all requirements. Is required to be a Registered Land Surveyor with a minimum of 5 years of broad survey experience and some technical-school training. May supervise the activities of survey crews and provide training to staff.
		Landscaping	Landscape Architect	Responsible for complex and/or diverse project assignment design and development, and may supervise lesser-experienced staff toward assigned project task completion.
		Construction	Materials Manager	Monitors, reviews, and coordinates all materials movement and storage. May be required to negotiate materials' shipping and arrival times with carriers and schedule intra-facility materials movement. Oversees warehousing of raw materials and finished goods. Reviews accuracy of freight bills and rates for inbound and outbound shipments. May revise shipping routes for cost-effectiveness, when possible.
		Surveying	Party Chief	Organizes and maintains efficiency of field survey crew in completing specific jobs. Accurately calculates and records field data that are clear and understandable. Reviews job specifications and determines the best course for completing the fieldwork in an efficient and safe manner. (Is non-registered)
		Project Support	Planner/Scheduler	Position is responsible for the assembling and analyzing of project information and preparing understandable documents that serve as a tool to eliminate design discrepancies and problems, while improving the efficient planning and scheduling of projects. Will monitor projects in accordance to set schedules through use of analytical reports. Work requires the application of standard planning / scheduling techniques and methods based on level of experience and may involve substantial evaluation, analysis, and modification of such standards in problem-solving efforts.
		Project Controls/
Reporting	Project Controls Engineer/Manager	Applies diversified knowledge of scientific principles and practices to broad variety of assignments and related fields. Requires use of advanced techniques and modification and extension of theories, precepts, and practices in individual’s field. Participates in planning and executing project programs using specialized knowledge of complexities, methods and probable value of results. May serve as expert in narrow specialty (e.g. Ornithology, Ichthyoplankton, Radiology, etc.) making recommendations and conclusions, which serve as basis for undertaking or rejecting specific project tasks
		Project Support	Project Coordinator	Position supervises the installation of equipment, systems, and components, using the technical knowledge and experience to aid installing contractors. Assures that equipment, systems, and components can be constructed without unnecessary delay. Coordinates scheduling of construction and provides communication with project management regarding progress and conflicts. Provides interpretation of specifications and contracts and monitors the construction process, verifying that work completed is in accordance with contract documents.
		Project Support	Project Engineer	Prepares requests for proposals and reviews technical specifications for accuracy. Will develop bid documents, bid evaluations, and award recommendations for issuance of contracts. Based on experience, the scope of projects evaluated will vary as well as the degree of supervision required of other technical staff. Will resolve contract-engineering problems that may involve evaluation, analysis, and modification or adoption of standard procedures.
		Quality Control	Quality Control Engineer	Position involves the performance of conventional quality-control functions within a discipline to ensure accuracy and completeness of design as they relate

to materials, equipment, systems, and methods required in construction. Ensures that proper testing and analysis are undertaken and completed in the evaluation of these materials, equipment, and systems.

		Risk Management	Risk Manager	Run project specific risk workshops to develop risk registers, contingency and float requirements, provide analysis on risk profile for portfolio.
		Scheduling	Scheduler	Set up baseline schedules, progress updates against baseline, develop schedule reports, contractor schedule reviews, time impacts assessments for change orders, P6 / EPPM Set up, database administration
		Specialist Services	Scientist	Applies diversified knowledge of scientific principles and practices to broad variety of assignments and related fields. Requires use of advanced techniques and modification and extension of theories, precepts, and practices in individual’s field. Participates in planning and executing project programs using specialized knowledge of complexities, methods and probable value of results. May serve as expert in narrow specialty (e.g. Ornithology, Ichthyoplankton, Radiology, etc.) making recommendations and conclusions, which serve as basis for undertaking or rejecting specific project tasks
		Unifier Support/ Primevera
P6 Support	Technical Support	Unifier Certification Required. Primavera P6 Certification Required.
		Unifier Development	Unifier Systems Developer	Unifier Certification Required, Business Process Design, Implementation, Testing

Experience

EXHIBIT B

Level Name	Level Description
Level 1, Entry	Assignments are concentrated in one functional area within individual's discipline or field. Works with close direction as to approach and desires end results. Becomes familiar with techniques, approaches, and procedures and the nature of engineering systems, equipment, etc., applicable to assignments. Requires engineering degree and 0 to 1 year's experience or the equivalent experience.

Level 2, Developmental Individual is capable of independently performing most conventional technical functions within discipline. Work is reviewed for application of sound professional judgment. May provide technical direction to a few support personnel. Requires engineering degree plus 2 to 3 years' engineering or equivalent experience.

Data Validation

Prime / Sub-Contractor	Companies	Positions
Prime	ERROR:#VALUE!	Administrative Support
Sub		Architect
		Chain/Rod Technicial
		Chief Construction Representative
		Commissioning Agent
		Construction Coordinator
		Construction Manager
		Construction Manager/Engineer
		Construction Representative
		Contract Administrator/Manager
		Cost/Estimating Engineer
		Data Analyst/Architect
		Design/Construction

Project Manager

Document Controller/Manager

Engineer

Engineer Technician

Engineering/ Architect Specialist

Field Engineer

Field Superintendent

Inspector

Instrument Technician

Interior Designer

Internal Auditor

Laboratory Technician

Land Surveyor

Landscape Architect

Materials Manager

Party Chief

Planner/Scheduler

Project Controls Engineer/Manager

Project Coordinator

Project Engineer

Quality Control Engineer

Risk Manager

Scheduler

Scientist

Technical Support

Unifier Systems Developer

image1.png image2.png

File details come from the government source that posted it. Updated Sep 17, 2025.