B08_Solicitation-Specifications.pdf

Div. 1 V. 2023-11-11 Page | 1

PERRY’S VICTORY & INTERNATIONAL

PEACE MEMORIAL

PUT-IN BAY, OHIO

Replace Bollard Lights and Concrete Base

PMIS 328911

PROJECT SPECIFICATIONS

NATIONAL PARK SERVICE

4/2/2024

Page | 2

TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

Section 01 10 00 - Division 01 Short Form General Requirements

DIVISION 32 – EXTERIOR IMPROVEMENTS

Section 32 13 13 Concrete Paving

Appendices

Appendix A: Photographs

Appendix B: Controller (Or Equal)

Appendix C: Bollard Lights (Or Equal)

Appendix D: Concrete Joint Sealant (Or Equal)

Page | 3

SECTION 01 10 00

DIVISION 1 SHORT FORM GENERAL REQUIREMENTS

PART 1 – GENERAL

ITEM 1 - DESCRIPTION OF WORK

1.1 Background: The Visitor Center was built in 2001 and opened to the public in 2002. The park opens for visitors May thru October. On average, 95,000 people enter the visitor center in that time frame. The bollard lighting outlines the visitor drop off area in the front of the building. There are also bollard lighting along the sidewalk that is between the parking lot and the visitor center on the south side of the building. Through the years and the abuse from cars and golf carts running over the curbs and striking the bollard lights has caused this requirement.

1.2 Work Covered by the Contract Documents:

A. Project Location: The location of the park is on Put in Bay Island. It is accessible by ferry boat during the warmer months of the year that the water is not frozen. Typically, the ferry boat operates between the months of March into the month of December. The address of the Visitor

Center is 180 Toledo Ave. Put in Bay OH, 43456. This address is the location of the project. See www.millerferry.com for pricing and schedules to accommodate work hours.

B. Work consists of: Removing the existing 15 bollard lights and replace with new Bronze Metallic

Hawthorne Path Lights. (Appendix C - HawthorneType 4, or equal, preferred). If the contractor chooses a different unit, it must meet or exceed the salient characteristics called out in Appendix

Page | 4

C. The existing lights are on a concrete strip that also needs to be fully removed and replaced.

(See Photos in Appendix A) The controller inside the building will also need to be replaced with a

Intermatic electronic timer control or equal called out in appendix B. If the contractor chooses a different unit, it must meet or exceed the salient characteristics called out in appendix B.

The concrete strip is approximately 18 inches wide and 270 foot long. Remove the concrete and base material under the concrete with a new fully excavated 6” base course of ¾ minus aggregate. The existing conduits may be repaired and reused. All conduits will be fully sealed and waterproof. The contractor may reuse the existing wiring in the system but must ensure continuity between all points. The existing controller will be replaced in the same location as the existing inside the Visitor Center. The new concrete will be the same size as the existing concrete. Approximately 18 inches wide and 270 foot in length. Place and compact a layer of ¾ minus aggregate as the base for the new concrete, must be at least 6” thick. Use a half inch expansion joint between existing sidewalk and new concrete. Apply Vulkem 45SSL (Appendix D) to all new joints including over the expansion joint. If the contractor chooses a different sealant, it must meet or exceed the salient characteristics called out in Appendix D. Wire and mount the new bollards using the existing conduits and wiring if the contractor chooses. Tool expansion joints in the same pattern as the existing sidewalk. After the forms are removed, backfill and grade topsoil to the same elevation as the concrete and seed the affected area with NPS provided seed and protect the new seeding with straw.

C. All work will be performed under a single contract.

D. Period of performance: Work shall be completed within 120 calendar days of the start date provided on the Notice to Proceed.

a. Clarification: The Notice to Proceed will be issued with a period of performance that is all inclusive of supply lead times, material deliveries, decommissioning, installation, anticipated average weather days for location, final commissioning, and acceptance of completed work. The contractor will be expected to provide a project schedule with adequate critical path details to ensure all work is completed within the stated calendar days from issuance of the Notice to Proceed. If weather impacts project beyond typical average weather patterns, contractor shall provide documentation in request for additional days.

1.3 Existing Condition Protections:

A. Preservation of Historical and Archeological Fabric:

i. The Historic and Archeological Data Preservation Act of 1974, provides for the preservation of historical and archeological data that might otherwise be lost as the result of alterations to the terrain caused by a federal or federally licensed activity or program.

ii. IF, in connection with operations under this contract, the Contractor, subcontractors, or employees of any of them, discovers, encounters or becomes aware of any possible historical or archeological data, objects or sites of cultural value on the project area, such as historical ruins, graves or grave markers, fossils, or artifacts, the Contractor shall immediately suspend all operations in the vicinity of the discovery and notify the

Contracting Officer immediately, when safe to do so, and follow up in writing within 2

Page | 5 days, giving the location and nature of the findings. No objects of cultural resource value may be removed. Contracting Officer will contact other entities as required.

iii. Where appropriate by reason of discovery, the Contracting Officer may order delays in the time of performance and/or changes in the work. If such delays and/or changes are ordered, the time of performance and contract price shall be adjusted in accordance with Changes clause.

iv. The Contractor will be responsible for protecting the cultural resources within and adjacent to the project area from damage. In addition, the Contractor will be liable for all damage to the cultural resources caused by their actions or the actions of their agents or representatives. The Contractor shall immediately notify the Contracting

Officer or their representative if any damage occurs to any cultural resource and immediately suspend work in the area in which damage has occurred until authorized to proceed.

v. The Contractor agrees to include this language within all subcontracts.

ITEM 2 – PROTECTING EXISTING UTILITIES

2.1 Protecting Existing Utilities: Notify Contracting Officer (CO), Contracting Officer’s Representative

(COR) and utility companies as required to request location services prior to and to coordinate any excavation/digging operations, and/or for demolition if within Scope of Work.

2.2 Contractor shall be responsible for locating and preventing damage to known utilities on site or indoors. If contractor damage occurs, alert CO and COR as soon as safely possible, and repair utility at no additional expense to the Government. If damage occurs to an unknown utility, contact CO and COR as soon as safely possible.

2.3 Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by Government or others unless permitted under the following conditions and then only after arranging to provide temporary utility services according to requirements indicated below:

A. Notify CO and COR not less than two business days in advance of proposed utility interruptions.

B. Hours for Utility Shutdowns: Shutdowns shall not exceed 2 to 3 hours. Temporary provisions will be needed by the Contractor for periods longer than stated allowance or if required for critical systems as determined by COR.

ITEM 3 - CONTRACTOR’S USE OF PREMISES

3.1 Conduct of Operations: At all times the contractor shall conduct his operations in conformance with the rules and regulations promulgated by the Secretary of the Interior for the National Park

Service, and applicable park rules and regulations prescribed by the Park Superintendent.

Superintendent's Compendium - Perry's Victory & International Peace Memorial (U.S.

National Park Service) (nps.gov)

A. Communications: Contractor shall provide the Contracting Officer and COR with methods of communications including land and/or cell phone numbers (note some areas of work have https://www.nps.gov/pevi/learn/management/superintendents-compendium.htm https://www.nps.gov/pevi/learn/management/superintendents-compendium.htm

Page | 6 limited service coverage), email and in case of emergency 24-hour contact options for duration of time operations.

B. No signs or advertisements (except those specified herein and as required for safety) shall be displayed on the construction site or within the park unless approved by the Contracting

Officer.

C. Smoking is not permitted within any Federal building or within 25 feet of entrances, operable windows, or outdoor air intakes.

D. Public Use of Site: Contractor shall at all times conduct operations to ensure the least inconvenience to the public. This project will interfere with the sidewalks that lead to the park visitor center. The contractor will install temporary fencing around all disturbed or exposed areas to prevent public access until the new work is complete. The contractor may close the drop off lane for concrete deliveries, but this area must be kept open as much as possible for visitor access to the VC. Contractor will always provide an open path to the entrance of the visitor center and mark a safe path to the entrance for the public to use.

3.2 On-site work hours: Work shall be generally performed during normal business working hours of

7 a.m. to 4 p.m., Monday through Friday, except when otherwise indicated.

A. Work on Saturdays, Sundays, Federal holidays, early morning, or at night may not be performed without prior consent from the CO and COR. Submit requests for work outside of the stated normal business hours to the CO and COR for approval at least 48 hours in advance of the work.

The following Federal holidays are observed by the National Park Service:

New Year Day

Martin Luther King, Jr’s Birthday

Washington’s Birthday

Memorial Day

Juneteenth National Independence Day

Independence Day

Labor Day

Columbus Day

Veterans Day

Thanksgiving Day

Christmas Day

B. Note: Any of the above holidays falling on a Saturday will be observed on the preceding

Friday; holidays falling on Sunday will be observed on the following Monday. The specific day that each holiday is recognized for each year can be found at the following site: Federal

Holidays (opm.gov).

3.3 Contractor Use of Site:

https://www.opm.gov/policy-data-oversight/pay-leave/federal-holidays/#url=2022 https://www.opm.gov/policy-data-oversight/pay-leave/federal-holidays/#url=2022

Page | 7

A. General: Contractor shall have limited use of the site for construction operations. Limit use of premises to construction area as shown on site plan, below. Do not disturb portions of Project site beyond areas in which the Work is indicated. The dumpster location called out is temporary and must be in place only during demolition.

B. Driveways and Entrances: Keep driveways, access roads, and entrances serving premises clear and available to park visitors, Government, Government's employees, and emergency vehicles at all times. Do not use these areas for parking or storage of materials. Schedule deliveries to minimize use of driveways and entrances.

C. Do Not disturb site outside of noted disturbance area, including earthwork and clearing of vegetation, to:

1. 12 inches beyond edge of existing concrete

Contractor shall provide appropriate matts for equipment on turf areas to reduce soil compaction. Contractor shall remediate soil compaction as directed to do so by the CO/COR.

D. Utilities

1. General: Cost or use charges for temporary facilities shall be included in the Contract Sum as required.

2. Water Service: Water from existing water system is available for use without metering and without payment of use charges. Provide connections and extensions of services as

Page | 8 required for construction operations without any additional permit costs. Use resources wisely and minimize waste of water.

3. Electric Power Service: Electric power from existing system is available for use without metering and without payment of use charges. Provide connections and extensions of services as required for construction operations without any additional permit costs. Power may or may not meet your construction power tool requirements, provide generators if questionable. Use power in a resourceful manner and avoid excess power waste.

4. Waste Operation:

a. Toilets: Contractor shall be able to use the existing restroom facilities at the monument located approximately 400 feet from the job site. The contractor will not use the restrooms in the Visitor Center. The monument restroom facilities shall be kept in immaculate condition. At the discretion of Park personnel and/or COR; contractor may lose the use of the restroom facilities if they are not kept clean and orderly. Restroom use will be a “One strike and you’re out” policy.

1. If restroom privileges are revoked Contractor will be required to provide a toilet for contracting personnel, sufficiently lighted and ventilated toilet facilities in weatherproof, sight proof, handicap accessible (if required), sturdy enclosures with privacy locks. Coordinate with COR for approved location. If the monument restrooms are not sufficient for contractor use, then the contractor may provide their own toilets and they will be placed in the contractor parking area identified on the site plan. Coordinate with COR for approved location if not shown on attached site plan.

b. Waste Removal / Recycling: Contractor is responsible for removing all waste created by the project. Contractor shall recycle to the highest degree possible and empty dumpsters as necessary to avoid debris on site. Locate as shown on site plan or coordinated with COR.

E. Security and Protection facilities:

1. Environmental Protection: Provide protection, operate temporary facilities, and conduct construction in ways and by methods that comply with state and federal environmental regulations and that minimize possible air, waterway, and subsoil contamination or pollution or other undesirable effects.

2. Cleaning of Equipment: The Contractor shall ensure that prior to moving on to the Project Area, all equipment, is free of soil, seeds, vegetative matter, or other debris that could contain or hold seeds. Ensure that all equipment has been pressure washed and is free of exotic species prior to start-up of operations and moving of equipment to Project Area.

Equipment shall be considered free of soil, seeds, and other debris when a visual inspection does not disclose such material. Disassembly of equipment components or specialized inspection tools are not required.

3. Tree and Plant Protection: N/A.

4. Pest Control: Follow best practices to minimize attraction and harboring of rodents, roaches, and other pests and to perform extermination and control procedures at regular intervals so Project will be free of pests and their residues at project completion. Perform control operations lawfully, using environmentally safe materials.

Page | 9

5. Temporary Enclosures: Provide temporary enclosures such as snow fence as required for protection of construction in progress and completed, from access by visitors or staff, other construction operations, and similar activities.

6. Site Enclosure Fence: N/A

7. Hot Work Permit: N/A

3.4 Storage - Staging Areas:

A. Confine Storage of materials and equipment to the project staging area noted on the plans/aerial. Specific storage units shall be provided by the contractor and exact location within staging area may be discussed at the preconstruction briefing. All storage units provided by the contractor shall be in a clean and acceptable condition to the COR. Security of the materials and equipment on site is the Contractor’s responsibility.

3.5 Preservation of Natural Features: N/A

3.6 Hauling Restrictions: Contractor shall verify and be responsible for the path accessing the site and obtaining / maintaining all local, state and federal permits/licenses associated with hauling/road requirements and dumping of materials associated with the project.

3.7 Housekeeping:

A. Keep project neat, orderly, and in a safe condition at all times.

1. Dispose of waste materials and recycling legally outside the park. The contractor shall not use park dumpsters

2. Address Recycling: Government goal is to salvage and recycle as much nonhazardous construction waste as possible. Use sustainable methods to extent possible during this project, recycling material as is probable with local means. Maintain accurate documentary records for submittal of all recycled materials used including fly ash and slag cement.

3.8 Occupancy Requirements for Buildings:

A. Existing Buildings: N/A

B. New /Existing Buildings Unoccupied: N/A

3.9 Photo Documentation:

A. Contractor must provide existing condition, progress, and completion photos. All photos shall be in focus, show maximum range of depth of field general photo and then close up detail photo as needed. Shall be in JPEG digital form and submitted preferably electronically by email or optional via CD-R Archival Gold or DVD-R Archival Gold media with printed labels and 8 mega pixels minimum within 7 days from time of taken or as approved by COR.

Page | 10

B. Existing Condition Images:

1. Before starting construction, take color, dated, digital images of project site and adjacent property/roads/etc. that may be impacted by construction activity/traffic. Include existing items to remain or be salvaged from different vantage points and with context for location identification.

C. Construction Progress Images:

1. Document all sub-surface work/ trenches etc. prior to backfill with photos covering enough overall field view to show location and then zoom in for details. (Locations and dimensions shall also be noted on as built drawing set.)

2. Maintain organized index for photos with date, description, etc.

3. Additional images as needed when questions or emergency situations occur. Submit within 24 hours.

D. Completion Images:

1. Document all completed work within scope of work.

2. Maintain organized index for photos with date, description, etc..

3. Additional images as needed when questions or emergency situations occur. Submit within 24 hours.

3.10 Fire and Life Safety:

B. As a minimum, conduct one weekly 15 minute "toolbox" safety meetings. These meetings shall be conducted by a foreman or supervisor and attended by all construction personnel at the worksite. Topics need to coincide with work scheduled for the following week. Document and submit meeting minutes to the CO and COR within one day after the meeting and document the meetings on the daily reports.

C. Comply with the requirements of NFPA 241 (Standard for Safeguarding Construction, Alteration, and Demolition Operations). Take all necessary precautions to prevent fire during construction. Provide adequate ventilation during use of volatile or noxious substances.

D. Store and handle hazardous materials in accordance with manufacturers and OSHA 29CFR1926 Subpart D requirements 1926 | Occupational Safety and Health Administration (osha.gov). Maintain readily available, on site, MSDS/Safety Data Sheets (SDS) for each chemical.

1. Immediately report all spills of hazardous materials to the CO, COR, and park.

2. Maintain a spill emergency response kit.

3. Train employees how to respond to a spill and use the emergency response kit.

3.11 Noise and Acoustics Management

A. Contractor shall not have personal radios or other media sources and they shall not be broadcast within NPS property.

B. Noise Control: N/A https://www.osha.gov/laws-regs/regulations/standardnumber/1926 https://www.osha.gov/laws-regs/regulations/standardnumber/1926

Page | 11

ITEM 4 - COMMENCEMENT, PROSECUTION, AND COMPLETION

4.1 The Contractor shall commence work in accordance with the terms and conditions of the contract.

Contractor shall coordinate and incorporate long lead and delivery time items within the schedule.

ITEM 5 - EXAMINATION OF THE SITE

5.1 All bidders are urged to visit the job site and examine existing conditions before submitting bids.

Contractors will be accountable for understanding existing conditions. No cost changes for items visible during site visit will be allowed.

ITEM 6 - ABBREVIATIONS

6.1 The list of abbreviations, standards and organizations which may be used in/referred within the

Construction Specifications or Special Provisions, may be found linked from the listed page below. On the home page, follow the link under “Contracting and Procurement” labeled “NPS

Reference Standards.” https://www.nps.gov/orgs/1671/do-business-with-us.htm

ITEM 7 - ACCIDENT PREVENTION

7.1 Description: The work of this section consists of establishing and implementing an effective accident prevention program (APP) and providing a safe environment for all personnel and visitors.

7.2 Submittals:

A. Accident Prevention (Safety) Plan (APP): Submit a site-specific accident prevention (safety) plan. The Plan shall be written to comply with OSHA and project requirements (a generic plan is not acceptable) including but not limited to the following:

1. Name and qualifications of responsible supervisor to carry out the program.

2. First aid and rescue procedures.

3. Training, both initial and continuing.

4. Outline of each phase of the work, the hazards associated with each major phase, and the methods proposed to provide for property protection and safety of the public, National

Park Service personnel, and Contractor's employees. Identify the work included under each phase, with a Job Hazard Analysis (JHA)/Job Safety Analysis (JSA), etc. A sample

JHA template may be provided upon request.

5. Planning for possible emergency situations, such as cave-ins, earthquake, explosions, fires, floods, power outages, slides, and windstorms. Such planning shall take into consideration the nature of construction, site conditions, and degree of exposure of persons and property.

6. Contractor to identify nearest location of medical facility for emergencies

7. Recognition that works will be performed in remote areas with limited communication or cell phone coverage if applicable.

8. Supplemental hazard specific plans may be required IAW 29 CFR 1926 or 1910.

https://www.nps.gov/orgs/1671/do-business-with-us.htm

Page | 12

B. Meeting and Inspection Reports: Safety Meetings: As a minimum, conduct 15 minute

"toolbox" safety meetings. These meetings shall be conducted by a foreman and attended by all construction personnel at the worksite. Submit a report of safety meetings and inspections to CO and COR within one day after the meeting and document the meetings on the daily reports.

7.3 Qualification of Employees:

A. Ensure that employees are physically qualified to perform their assigned duties in a safe manner to include operators of vehicles and equipment. Provide operating instructions for all equipment.

B. Do not allow employees to work whose ability or alertness is impaired because of drugs, fatigue, illness, intoxication, or other conditions that may expose themselves or others to injury.

7.4 Accident Reporting: The Contractor shall report all accidents to the CO and COR as soon as safely possible and assist the CO and COR and other officials as required in the investigation of the accident.

7.5 First Aid Facilities: Provide access to facilities for the number of employees and appropriate to the hazards associated with the types of ongoing construction work at the site.

7.6 Emergency Instructions: Post telephone numbers and reporting instructions for ambulance, physician, hospital, fire department, and police in conspicuous locations at the work site.

7.7 Personal Protective Equipment (PPE): It is the Contractor's responsibility to require all those working on or visiting the site to wear necessary protective equipment at all times.

A. PPE must meet requirements of applicable ANSI standards. Selection shall conform to OSHA

29CFR 1926 Subpart E.

B. A hard hat use area shall be designated by the Contractor. The hard hat area shall be posted by the Contractor in a manner satisfactory to the Contracting Officer.

C. All PPE will be serviceable at all times. At a minimum, maintain two sets of PPE including hard hats and all other Accident Prevention Plan required equipment.

7.8 Hazardous Materials: It shall be the responsibility of all operators and contractors, functioning within the park to properly cleanup, mitigate and remediate if necessary, all unauthorized discharges of hazardous materials or non-hazardous chemical and biological products released from fleet and/or other support vehicles or stationary sources. Response shall be consistent with guidelines established by federal, state, and local regulations, and as outlined within the operator's Safety or Hazardous Materials Business Plan.

A. If a spill, leak, or other release occurs, the operator shall as soon as possible, without impeding cleanup, notify the local 911 Emergency Response, COR and or the National Park

Service Emergency Dispatch.

Page | 13

ITEM 8 - PRECONSTRUCTION CONFERENCE

8.1 If the Contracting Officer decides to conduct a preconstruction conference, the successful offeror will be notified and will be required to attend. The Contracting Officer’s notification will include specific details regarding the date, time, and location of the conference, any need for attendance by subcontractors, and information regarding the items to be discussed. See Item 9.1C below.

ITEM 9 - SUBMITTALS

9.1 General Contracting Submittal Procedures:

A. General: Prepare and submit submittals required by individual Technical Specification

Sections. Types of submittals are indicated in individual specific sections.

1. CM-16 Transmittal Form: All submittals shall be transmitted via electronic email using

National Park Service form CM-16 form. The form will be provided by the Contracting

Officer. No action will be taken on a submittal item unless accompanied by the CM-16 transmittal form. Submit completed CM-16 forms to the CO and the COR

B. Submittal List: administrative required submittals are listed below in 9.1.C and does not include technical section submittal requirements included in each technical section.

C. Preconstruction Conference Submittal: Satisfactory evidence of liability insurance coverage and workman’s compensation, and any applicable bonds, must be submitted within 10 calendar days of Notice of Award. The following items are to be submitted prior to the

Preconstruction Conference or as specified at the CO’s discretion. The timeline for the documents to be submitted will be addressed at the pre-construction conference for those items that were not received and approved prior. Notice to Proceed may not be issued, and the Contracting Officer will consider other contractual remedies if not resolved as directed.

Work shall not commence until written Notice to Proceed has been issued. Contracting

Officer will notify Contractor of tentative date for the Pre-Construction Conference:

1. Letter designating Project Superintendent.

2. Construction Schedule. (Must include shop drawings, procurement time including long lead time items, mobilization, trade work progression and completion at minimum.)

3. A comprehensive breakdown of the Schedule of Values.

4. Accident Prevention (Safety) Plan (see section 7 of this document).

5. A list of Subcontractors for this project.

6. Written statements from subcontractors certifying compliance with applicable labor standard clauses (SF1413).

7. Quality Control Plan.

9.2 Project Submittal Process (Shop Drawings, Product Data, and Samples): Contracting Officer will provide sample cover sheet and a list of required submittals is included in each technical specification or attached at the end of this document.

A. Shop Drawings: Indicate all coordinating materials and work impacting the installation coordination, connection details, anchorage requirements, hardware locations, and installation

Page | 14 details and locations.

1. Submit Shop Drawings according to Part 9.1 of this section to include one digital file (.PDF or .TIF) and two full size hardcopy documents to COR.

B. Product Data: Provide component construction and specification data sheets, anchorage requirements and any other product specific data.

1. Submit Product Data according to Part 9.1 of this section to include one digital file (.PDF or .TIF) to COR.

C. Samples: Submit 2 color samples 4” x 6” minimum in size for all product color selections.

Paint samples shall be actual paint finish drawdown for all project colors.

1. Submit Samples CM-16 Transmittal Form according to Part 9.1 of this section to include one digital file (.PDF or .TIF) and physical samples of actual material to COR.

D. For submittals specified above, forward submittals to Contracting Officer and COR at least 15 days before need for approval (depends on length of project).

E. After approving submittals, Contracting Officer and/or COR will return one copy to the

Contractor. If submittals are not approved, Contracting Officer will return all copies to

Contractor with reasons for rejection. Resubmit, identifying changes. Any work done before approval shall be at Contractor's own risk.

9.3 Approved Equals: All brand names noted are subject to ‘or equal’ products. If an item in this solicitation is identified as “brand name or equal” or lists more than 1 manufacturer, the description of the proposed item must reflect the characteristics and level of quality that will satisfy the Government’s needs as demonstrated by the salient physical, functional, or performance characteristics that “equal” products must meet and/or exceed that as specified in the solicitation or relevant specification. Contractor shall incorporate and be responsible for all collateral costs due to the or equal proposed as required to provide a complete project.

A. For each item proposed as an “approved equal,” submit supporting data, including:

1. Drawings and samples as appropriate.

2. Comparison of the characteristics of the proposed item with that specified and with the salient characteristics provided.

3. Changes required in other elements of the work because of the substitution.

4. Name, address, and telephone number of vendor.

5. Manufacturer’s literature regarding installation, operation, and maintenance, including schematics for electrical and hydraulic systems, lubrication requirements, and parts lists.

Describe availability of maintenance service, and state source of replacement materials.

B. A request for approval constitutes a representation that General Contractor:

1. Has investigated and shall provide documentation in request showing that the proposed item is equal or superior in all respects to the salient characteristics specified.

2. Will meet or exceed warranties for the proposed item specified.

Page | 15

3. Has determined that the proposed item is compatible with interfacing items.

4. Will coordinate the installation of an approved item and make all changes required in other elements of the work because of the substitution.

5. Waives all claims for additional expenses that may be incurred as a result of the substitution.

C. Approved Equals will be evaluated and approved/disapproved during the submittal process.

9.4 Schedule of Values: Submit the Schedule of Values a minimum of one week prior to the

Preconstruction Conference for COR review. Schedule of Values shall include defined work line items with cost break downs including labor, material, and equipment for COR approval.

9.5 Progress Reporting: The initial Construction Schedule and Schedule of Values are required a minimum of one week prior to the Preconstruction Conference. After the Notice to Proceed is issued and after on-site work begins, progress will be documented via daily logs and by providing an updated Construction Schedule and Schedule of Values when requested, but minimally with each pay application. Submit digital copy electronically (PDF preferred) of all required documents.

Construction Schedules are normally in bar chart form and indicate estimated starting and completion dates for each part of the work. For a pay application to be reviewed and processed in a timely manner, the following information must either be submitted prior to or accompany submission of the pay application:

A. Daily/weekly progress reports during construction as part of the administration process.

B. Updated Schedule of Values: Breakdown each lump-sum item into component work activities used in the schedule, for which progress payments may be requested. The Schedule of

Values will form the basis for payment. The work activities broken out within the schedule of values shall be integrated into and made a logical part of the construction baseline schedule submitted under this specification. The total costs for the component work activities shall equal the contract price for that lump-sum item. The Contracting Officer may request data to verify accuracy of dollar values. A sample Schedule of Values format may be provided upon request.

ITEM 10 – TEMPORARY SERVICES

10.1 It is the Contractor’s responsibility to provide temporary services, equipment, tools, and skilled labor as required for the chosen means and methods to perform the work in accomplishing this

Contract.

ITEM 11 - PROJECT CLOSEOUT

11.1 Description: The work of this section consists of final cleanup, closeout submittals, final inspection procedures working toward Final Acceptance.

11.2 Cleaning: Remove all tools, equipment, surplus materials, and rubbish. Move attic stock to location coordinated with COR. At time of final inspection, project shall be thoroughly clean and ready for intended use. Inspector holds the right to reschedule if project is not ready for inspection.

Page | 16

11.3 Completion and Final Inspection: Contractor shall submit written certification of project completion and request a final inspection to the Contracting Officer and COR. The Contracting

Officer or designee will make an inspection within 10 days of receipt of request or at a mutually agreeable time.

A. If the work is determined to be complete following the final inspection with minor comments, the COR will prepare and provide the Contractor a Punch List noting outstanding items to be addressed.

B. If the work is not determined to be complete following the final inspection, the Contracting

Officer will notify Contractor in writing, stating reasons. Contractor, after completing the work according to the Contract Documents, shall resubmit completion and request a new final inspection. Re-inspection costs may be charged against the Contractor in accordance with the Inspection of Construction contract clause.

C. Contractor shall complete the Punch List within 30 calendar days, or a time directed by the

CO.

D. Once Contractor completes all items of work on the Punch List and all contractually required items are accepted, Contracting Officer will issue Letter of Final Acceptance of Work and request the final pay application.

E. If the Contractor fails to complete the work within the time frame, the Contracting Officer may correct the work with an appropriate reduction in contract price or charge for re-inspection costs in accordance with the Inspection of Construction contract clause.

F. Disposition of any permits and warranties required by the specifications in this section.

11.4 Final Acceptance of the Work: After all punch list deficiencies have been corrected, a Letter of

Final Acceptance will be issued. A Release of Claims document must be executed and submitted to the Contracting Officer before final payment can occur.

11.5 Warranties

A. Construction Warranty shall be based on date of final acceptance of the work and remain in effect for one year.

B. Provide all manufacturer warranty information of products installed organized by Division. All contact information, extent of coverage and conditions shall be clearly noted as well as date of overall final acceptance.

C. Information shall include operation and maintenance manuals for each warranted product.

PART 2 – PRODUCTS (NOT USED)

PART 3 – EXCUTION (NOT USED)

END OF SECTION

Page | 17

SECTION 321313

CONCRETE PAVING

PART 2 - GENERAL

2.1 SCOPE OF WORK

Perrys Victory and International Peace Memorial

A. Project Location: 93 Delaware Ave, Put In Bay OH 43456

2.2 SUMMARY

A. Section Includes Concrete Paving, Including the Following:

1. Walks.

2.3 PREINSTALLATION MEETINGS

A. Preinstallation Conference: Conduct conference at Project site.

1. Review methods and procedures related to concrete paving, including but not limited to, the following:

a. Concrete mixture design.

b. Quality control of concrete materials and concrete paving construction practices.

2. Require representatives of each entity directly concerned with concrete paving to attend, including the following:

a. Contractor's superintendent.

b. Concrete paving Subcontractor.

2.4 ACTION SUBMITTALS

A. Product Data: For each of the following:

1. Joint filler

2. Joint sealant

3. Concrete admixtures

4. Concrete curing compounds

Page | 18

B. Samples for Initial Selection: For each type of product, ingredient, or admixture requiring color selection.

C. Samples for Verification: For each type of product or exposed finish, prepared as Samples of size indicated below:

1. Exposed Aggregate: 10-lb Sample of each mix.

D. Design Mixtures: For each concrete paving mixture. Include alternate design mixtures when characteristics of materials, Project conditions, weather, test results, or other circumstances warrant adjustments. Consult and verify alternate design mix with COR.

E. Shop Drawings

F. Grass seed mix (provided by NPS).

2.5 INFORMATIONAL SUBMITTALS

A. Qualification Data: For qualified ready-mix concrete manufacturer.

B. Material Test Reports: For each of the following:

1. Aggregates

2.6 SUBMITTAL COORDINATION

A. Submittal List: A submittal list has been attached to the end of this Specification Section. The intent is to provide an overall summary of the submittal requirements and not a comprehensive list. The requirements of the individual Specification Sections, terms and conditions of the Contract still apply regardless of what is shown on the submittal list.

2.7 QUALITY ASSURANCE

A. Ready-Mix-Concrete Manufacturer Qualifications: A firm experienced in manufacturing ready-mixed concrete products and that complies with ASTM C 94 requirements for production facilities and equipment.

1. Manufacturer certified according to NRMCA's "Certification of Ready Mixed Concrete Production Facilities" (Quality Control Manual - Section 3, "Plant Certification Checklist").

2.8 FIELD CONDITIONS

A. Traffic Control: Maintain access for vehicular and pedestrian traffic as required for other construction activities.

B. Cold-Weather Concrete Placement: Protect concrete work from physical damage or reduced strength that could be caused by frost, freezing, or low temperatures. Comply with ACI 306.1 and the following:

1. When air temperature has fallen to or is expected to fall below 40 deg F, uniformly heat water and aggregates before mixing to obtain a concrete mixture temperature of not less than 50 deg F and not more than 80 deg F at point of placement.

2. Do not use frozen materials or materials containing ice or snow.

3. Do not use calcium chloride, salt, or other materials containing antifreeze agents or chemical accelerators unless otherwise specified and approved in design mixtures.

Page | 19

C. Hot-Weather Concrete Placement: Comply with ACI 301 and as follows when hot-weather conditions exist:

1. Cool ingredients before mixing to maintain concrete temperature below 90 deg F at time of placement. Chilled mixing water or chopped ice may be used to control temperature, provided water equivalent of ice is calculated in total amount of mixing water. Using liquid nitrogen to cool concrete is Contractor's option.

2. Cover steel reinforcement with water-soaked burlap, so steel temperature will not exceed ambient air temperature immediately before embedding in concrete.

3. Fog-spray forms and subgrade just before placing concrete. Keep subgrade moisture uniform without standing water, soft spots, or dry areas.

PART 3 - PRODUCTS

3.1 CONCRETE, GENERAL

A. ACI Publications: Comply with ACI 301 unless otherwise indicated.

3.2 FORMS

A. Form Materials: Plywood, metal, metal-framed plywood, or other approved panel-type materials to provide full-depth, continuous, straight, and smooth exposed surfaces.

1. Use flexible or uniformly curved forms for curves with a radius of 100 feet or less. Do not use notched and bent forms.

B. Form-Release Agent: Commercially formulated form-release agent that will not bond with, stain, or adversely affect concrete surfaces and that will not impair subsequent treatments of concrete surfaces.

3.3 STEEL REINFORCEMENT N/A

3.4 CONCRETE MATERIALS

A. Cementitious Materials: Use the following cementitious materials, of same type, brand, and source throughout Project:

1. Portland Cement: ASTM C 150, gray portland cement Type I/II.

B. Normal-Weight Aggregates: ASTM C 33, uniformly graded. Provide aggregates from a single source with documented service-record data of at least 10 years' satisfactory service in similar paving applications and service conditions using similar aggregates and cementitious materials.

1. Maximum Coarse Aggregate Size: 1 inch nominal.

2. Fine Aggregate: Free of materials with deleterious reactivity to alkali in cement.

C. Air-Entraining Admixture: ASTM C 260.

D. Chemical Admixtures: Admixtures certified by manufacturer to be compatible with other admixtures and to contain not more than 0.1 percent water-soluble chloride ions by mass of cementitious material.

1. Water-Reducing Admixture: ASTM C 494.

2. Retarding Admixture: ASTM C 494.

Page | 20

3.

4. Plasticizing and Retarding Admixture: ASTM C 1017.

E. Water: Potable and complying with ASTM C 94.

3.5 CURING MATERIALS N/A

3.6 JOINT SEALANTS

A. Compatibility: Provide joint sealants, backing materials, and other related materials that are compatible with one another and with joint substrates under conditions of service and application, as demonstrated by joint-sealant manufacturer, based on testing and field experience.

B. Cold-Applied Joint Sealants

1. Single-Component, Nonsag, Silicone Joint Sealant: ASTM D5893

C. Hot-Applied Joint Sealants

1. Hot-Applied, Single-Component Joint sealant: ASTM D6690.

3.7 RELATED MATERIALS

A. Joint Fillers: ASTM D 1751, asphalt-saturated cellulosic fiber in preformed strips.

3.8 CONCRETE MIXTURES

A. Prepare design mixtures, proportioned according to ACI 301, for each type and strength of normal-weight concrete, and as determined by either laboratory trial mixtures or field experience.

1. Use a qualified independent testing agency for preparing and reporting proposed concrete design mixtures for the trial batch method.

2. When automatic machine placement is used, determine design mixtures and obtain laboratory test results that comply with or exceed requirements.

B. Add air-entraining admixture at manufacturer's prescribed rate to result in normal-weight concrete at point of placement having an air content as follows:

1. Air Content: 6 percent plus or minus 1-1/2 percent for 3/4-inch nominal maximum aggregate size.

C. Chemical Admixtures: Use admixtures according to manufacturer's written instructions.

1. Use water-reducing and retarding admixture when required by high temperatures, low humidity, or other adverse placement conditions.

D. Concrete Mixtures: Normal-weight concrete.

1. Compressive Strength (28 Days): 4000 psi for sidewalks, pavement, curbs and gutters.

2. Maximum W/C Ratio at Point of Placement: 0.45.

3. Slump Limit: 3 inches, plus or minus 1 inch.

Page | 21

3.9 CONCRETE MIXING

A. Ready-Mixed Concrete: Measure, batch, and mix concrete materials and concrete according to ASTM C 94. Furnish batch certificates for each batch discharged and used in the Work.

1. When air temperature is between 85 and 90 deg F, reduce mixing and delivery time from 1-1/2 hours to 75 minutes; when air temperature is above 90 deg F, reduce mixing and delivery time to 60 minutes.

B. Project-Site Mixing: Measure, batch, and mix concrete materials and concrete according to ASTM C 94. Mix concrete materials in appropriate drum-type batch machine mixer.

1. For concrete batches of 1 cu. yd. or smaller, continue mixing at least 1-1/2 minutes, but not more than 5 minutes after ingredients are in mixer, before any part of batch is released.

2. For concrete batches larger than 1 cu. yd., increase mixing time by 15 seconds for each additional 1 cu. yd.

3. Provide batch ticket for each batch discharged and used in the Work, indicating Project identification name and number, date, mixture type, mixing time, quantity, and amount of water added.

3.10 SEED

A. Grass Seed: Fresh, clean, dry, new-crop seed complying with AOSA's "Rules for Testing Seeds" for purity and germination tolerances. Provided by NPS.

PART 4 - EXECUTION

4.1 SITE CLEARING

A. Remove slabs, paving, curbs, gutters, and walks as indicated.

1. Unless existing full-depth joints coincide with line of demolition, neatly saw-cut along line of existing pavement to remain before removing adjacent existing pavement. Saw-cut faces vertically.

2. Paint cut ends of any steel reinforcement in concrete to remain with two coats of antirust coating, following coating manufacturer’s written instructions. Keep paint off surfaces that will remain exposed.

4.2 EXAMINATION

A. Examine exposed subgrades and subbase surfaces for compliance with requirements for dimensional, grading, and elevation tolerances.

B. Proceed with installation only after unsatisfactory conditions have been corrected.

4.3 PREPARATION

A. Uniformly moisten or aerate subgrade and each subsequent fill or backfill soil layer before compaction to within 2 percent of optimum moisture content.

1. Do not place backfill or fill soil material on surfaces that are muddy, frozen, or contain frost or ice.

Page | 22

2. Remove and replace, or scarify and air dry, otherwise satisfactory soil material that exceeds optimum moisture content by 2 percent and is too wet to compact to specified dry unit weight.

B. Under pavement and walks, scarify and recompact the top 12 inches of existing subgrade and each layer of backfill or fill soil material to a minimum distance of two feet beyond the edge of paving at 95 percent of maximum dry unit weight according to ASTM D698.

C. Remove loose material from compacted subbase surface immediately before placing concrete.

D. Protect subgrades from freezing temperatures and frost. Remove temporary protection before placing subsequent materials.

E. Repair and reestablish grades where completed or partially completed surfaces become eroded, rutted, settled, or where they lose compaction due to subsequent construction operations or weather conditions.

4.4 EDGE FORMS AND SCREED CONSTRUCTION

A. Set, brace, and secure edge forms, bulkheads, and intermediate screed guides to required lines, grades, and elevations. Install forms to allow continuous progress of work and so forms can remain in place at least 24 hours after concrete placement.

B. Clean forms after each use and coat with form-release agent to ensure separation from concrete without damage.

4.5 JOINTS

A. General: Form construction, isolation, and contraction joints and tool edges true to line, with faces perpendicular to surface plane of concrete. Construct transverse joints at right angles to centerline unless otherwise indicated.

1. When joining existing paving, place transverse joints to align with previously placed joints unless otherwise indicated.

B. Construction Joints: Set construction joints at side and end terminations of paving and at locations where paving operations are stopped for more than one-half hour unless paving terminates at isolation joints.

1. Continue steel reinforcement across construction joints unless otherwise indicated. Do not continue reinforcement through sides of paving strips unless otherwise indicated.

2. Provide tie bars at sides of paving strips where indicated.

3. Keyed Joints: Provide preformed keyway-section forms or bulkhead forms with keys unless otherwise indicated. Embed keys at least 1-1/2 inches into concrete.

4. Doweled Joints: Install dowel bars and support assemblies at joints where indicated.

Lubricate or coat with asphalt one-half of dowel length to prevent concrete bonding to one side of joint.

C. Isolation Joints: Form isolation joints of preformed joint-filler strips abutting concrete curbs, catch basins, manholes, inlets, structures, other fixed objects, and where indicated.

1. Extend joint fillers full width and depth of joint.

2. Terminate joint filler not less than 1/2 inch or more than 1 inch below finished surface if joint sealant is indicated.

3. Place top of joint filler flush with finished concrete surface if joint sealant is not indicated.

Page | 23

4. Furnish joint fillers in one-piece lengths. Where more than one length is required, lace or clip joint-filler sections together.

5. During concrete placement, protect top edge of joint filler with metal, plastic, or other temporary preformed cap. Remove protective cap after concrete has been placed on both sides of joint.

D. Contraction Joints: Form weakened-plane contraction joints, sectioning concrete into areas as indicated. Construct contraction joints for a depth equal to at least one-fourth of the concrete thickness, as follows, to match jointing of existing adjacent concrete paving:

1. Grooved Joints: Form contraction joints after initial floating by grooving and finishing each edge of joint with grooving tool to a 1/4-inch radius. Repeat grooving of contraction joints after applying surface finishes. Eliminate grooving-tool marks on concrete surfaces.

2. Sawed Joints: Form contraction joints with power saws equipped with shatterproof abrasive or diamond-rimmed blades. Cut 1/8-inch- wide joints into concrete when cutting action will not tear, abrade, or otherwise damage surface and before…