ATTACHMENT E NOTIFICATION OF COMPLIANCE WITH INSURANCE REQUIREMENTS.docx

ATTACHMENT E – NOTIFICATION OF COMPLIANCE WITH INSURANCE REQUIREMENTS

36C25622Q1421

NOTIFICATION OF COMPLIANCE WITH INSURANCE REQUIREMENTS

The undersigned Contractor hereby acknowledges that he or she has read and understands the insurance requirements specified in this contract and hereby agrees (1) that such insurance will be maintained in at least the amounts and types specified in this contract and during any modifications and or time extensions granted thereto; (2) that the policies evidencing required insurance shall contain an endorsement to the effect that any cancellation or any material change adversely affecting the Government's interest shall not be effective for such period as the laws of the State in which this contract is to be performed prescribe, or until 30 days after the insurer or contractor gives written notice to the Contracting Officer, whichever period is longer; (3) that ________________ (State) Workmen's Compensation Insurance, or letter of reciprocal agreement with another state, shall be maintained on this contract for and during the entire performance period and for any modifications and time extensions granted thereto; and (4) that a copy of all subcontractors’ proof of insurance shall be maintained and shall be made available to the Contracting Officer upon request. This agreement shall become a part of the above referenced contract file.

INSURANCE COMPANY(S): ____________________________________

(NAME[S]) (TELEPHONE NUMBER[S]): ______________________________________________

CONTRACTOR: ____________________________________________

(NAME): __________________________________________________

(ADDRESS): _______________________________________________

(AUTHORIZED SIGNATURE) (DATE): _______________________________________________

(TYPED NAME AND TITLE):________________________________________________________