Attach 1 Specifications.pdf

MINUTE MAN MISSILE

NATIONAL HISTORIC SITE

South Dakota

RENOVATE ELEVATOR ELECTRICAL CONTROL PANEL

AT DELTA 01 LCF

MIMI

PMIS NO. 257286

PROJECT SPECIFICATIONS

(FINAL Construction Documents)

NATIONAL PARK SERVICE

MIDWEST REGION

January 2021

THIS PAGE INTENTIONALLY LEFT BLANK

MIMI - 257286 00 01 10 - 1

Table of Contents

TABLE OF CONTENTS

DIVISION 01 — GENERAL REQUIREMENTS

01 11 00 - SUMMARY OF WORK

01 11 00A - MIMI DELTA 01 LCF SITE AND FIRST FLOOR PLAN

01 26 01 - CONTRACT MODIFICATION PROCEDURES

01 27 00 - DEFINITION OF CONTRACT LINE ITEMS

01 31 00 - PROJECT MANAGEMENT AND COORDINATION

01 32 16 - CONSTRUCTION SCHEDULE

01 32 33 - PHOTO DOCUMENTATION FOR HISTORIC PRESERVATION PROJECTS

01 33 23 - SUBMITTAL PROCEDURES

01 33 23A - SUBMITTAL LIST

01 35 23 - SAFETY REQUIREMENTS

01 35 91 - HISTORIC PRESERVATION TREATMENT PROCEDURES

01 40 00 - QUALITY REQUIREMENTS

01 42 00 - REFERENCE STANDARDS

01 50 00 - TEMPORARY FACILITIES AND CONTROLS

01 67 00 - PRODUCT REQUIREMENTS

01 73 40 - EXECUTION

01 74 19 - CONSTRUCTION WASTE MANAGEMENT AND DISPOSAL

01 77 00 - CLOSEOUT PROCEDURES

01 77 00A - CLOSEOUT AND OPERATION & MAINTENANCE REQUIREMENTS

01 78 23 - OPERATION AND MAINTENANCE DATA

01 79 00 - DEMONSTRATION AND TRAINING

DIVISION 14 — CONVEYING EQUIPMENT

14 20 10 - ELECTRIC ELEVATOR UPGRADES

14 20 10A - ELEVATOR PHOTOS

D I V I S I O N 0 1

GENERAL REQUIREMENTS

MIMI - 257286 01 11 00 - 1

SUMMARY OF WORK

2020/11/19

SECTION 01 11 00 - SUMMARY OF WORK

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes the following:

1. Work covered by the Contract Documents.

2. Contractor use of premises.

3. Public use of site.

4. Occupancy requirements for buildings.

5. Work Restrictions.

6. Special Construction Requirements.

1.2 WORK COVERED BY CONTRACT DOCUMENTS

A. Project Location: Delta 01 Launch Control Facility, Minuteman Missile National Historic Site, South Dakota. Project site information is located at:

https://www.nps.gov/mimi/planyourvisit/visiting_delta-01lcf.htm

B. The Work consists of the following:

1. The Work includes the renovation of the Elevator Electrical Control Panel at Delta 01 Launch Control Facility. Work includes utilizing and retaining some of the existing equipment;

while upgrading components and equipment to upgrade the existing elevator operation.

All existing cabinets must be reused to maintain the legacy nature of the equipment. All new work must be out of sight, not visible, or contained within the existing cabinets to remain.

See attachment 01 11 00A for Site Plan and Launch Control Facility footprint for orientation and information

C. Project will be constructed under a single prime contract. Period of Performance is 50 Calendar Days.

1.3 CONTRACTOR USE OF SITE

A. General: Contractor shall have limited use of the site for construction operations. Limit use of premises to parking areas adjacent to the Delta 01 facility and coordinated with on-site NPS staff. Location of and access to the elevator room shall be coordinated with the Contracting

Officer or on-site NPS staff. See attachment 01 11 00A.

1. Limits: Confine constructions operations to the elevator room, cab, and shaft as required.

B. Storage of Materials: Confine storage of materials to the elevator room or other location coordinated with the Contracting Officer or on-site NPS staff that does not affect current operations or tours.

https://www.nps.gov/mimi/planyourvisit/visiting_delta-01lcf.htm

MIMI - 257286 01 11 00 - 2

C. Preservation of Natural Features:

1. Prevent damage to natural surroundings. Restore damaged areas, repairing or replacing damaged trees and plants, at no additional expense to the Government.

2. Provide temporary barriers to protect existing trees and plants and root zones.

3. Do not remove, injure, or destroy trees or other plants without prior approval. Consult with Contracting Officer and remove agreed-on roots and branches that interfere with construction.

4. Do not fasten ropes, cables, or guys to existing trees.

5. Carefully supervise excavating, grading, filling, and other construction operations near trees to prevent damage.

D. Driveways and Entrances: Keep driveways, sidewalks, list other areas if applicable and entrances serving premises clear and available to Government, Government's employees, and emergency vehicles at all times. Do not use these areas for parking or storage of materials unless requested in advanced and approved by the Contracting Officer.

1. Schedule deliveries to minimize use of driveways and entrances.

2. Schedule deliveries to minimize space and time requirements for storage of materials and equipment on-site.

E. Construction Camp: Establishment of a camp within the park will not be permitted.

F. Hauling Restrictions: Comply with all legal load restrictions in the hauling of materials. Load restrictions on park roads are identical to the state load restrictions with such additional regulations as may be imposed by the Park Superintendent. Information regarding rules and regulations for vehicular traffic on park roads may be obtained from the Office of the Park

Superintendent. A special permit will not relieve Contractor of liability for damage which may result from moving of equipment.

1.4 PUBLIC USE OF SITE

A. Contractor shall at all times conduct his operations to ensure the least inconvenience to the public. Building and Road closures will not be permitted..

1.5 OCCUPANCY REQUIREMENTS FOR BUILDINGS

A. Existing Buildings:

1. Partial Government Occupancy: Government will occupy the premises during entire construction period, with the exception of areas under construction. Cooperate with

Government during construction operations to minimize conflicts and facilitate

Government usage. Perform the Work so as not to interfere with Government’s operations. Maintain existing exits, unless otherwise indicated.

a. Maintain access to existing walkways, corridors, and other adjacent occupied or used facilities. Do not close or obstruct walkways, corridors, or other occupied or used facilities without written permission from the Contracting Officer (CO).

MIMI - 257286 01 11 00 - 3

1.6 CONDUCT OF OPERATIONS

A. At all times the contractor shall conduct his operations in conformance with the rules and regulations promulgated by the Secretary of the Interior for the National Park Service, and applicable park rules and regulations prescribed by the Park Superintendent.

B. Work on Saturdays, Sundays, Federal holidays or at night may not be performed without prior consent from the Contracting Officer. Submit requests 48 hours in advance of the work to the

Contracting Officer for approval.

C. No signs or advertisements (except those specified herein) shall be displayed on the construction site or within the park unless approved by the Contracting Officer.

1.7 WORK RESTRICTIONS

A. On-Site Work Hours: Work shall be generally performed during normal business working hours of 8:00 a.m. to 4:00 p.m., Monday through Friday, except when otherwise indicated.

1. Weekend Hours: None.

2. Early Morning Hours: None.

3. Hours for Core Drilling: 8:00 a.m to 9:00 a.m.

B. Existing Utilities:

1. Existing Utilities: Notify Contracting Officer and utility companies of proposed locations and times for excavation.

2. Contractor shall be responsible for locating and preventing damage to known utilities. If damage occurs, repair utility at no additional expense to the Government.

3. If damage occurs to an unknown utility, repair utility. An equitable adjustment will be made in accordance with the Changes clause of the contract.

C. Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by

Government or others unless permitted under the following conditions and then only after arranging to provide temporary utility services according to requirements indicated:

1. Notify Contracting Officer not less than two days in advance of proposed utility interruptions.

2. Do not proceed with utility interruptions without Contracting Officer’s written permission.

3. Hours for Utility Shutdowns: No more than 2 hours in length and must be coordinated with Contracting Officer.

1.8 SPECIAL CONSTRUCTION REQUIREMENTS

A. No special requirements anticipated during contract that would limit access due to seasonal shutdown, park activities, or other government requirements.

MIMI - 257286 01 11 00 - 4

PART 2 - PRODUCTS (NOT USED)

PART 3 - EXECUTION (NOT USED)

END OF SECTION 01 11 00

RMATYA

Image

RMATYA

Image

RMATYA

Callout

DELTA 01 LAUNCH CONTROL FACILITY

RMATYA

Text Box

DELTA 01 LAUNCH CONTROL FACILITY - SITE ORIENTATION AERIAL MAPS

Rectangle

RMATYA

Callout

ELEVATOR CONTROL PANEL ROOM LOCATION

RMATYA

Text Box

DELTA 01 LAUNCH CONTROL FACILITY

RMATYA

Text Box

FIRST FLOOR PLAN

Line

MIMI - 257286 01 26 01 - 1

CONTRACT MODIFICATION PROCEDURES

2020/10/16

SECTION 01 26 01 - CONTRACT MODIFICATION PROCEDURES

PART 1 - GENERAL

1.1 SUMMARY

A. The work of this section consists of administrative and procedural requirements for contract modifications.

1.2 DEFINITIONS AND ALLOWANCES

A. Home Office Overhead: Those costs incurred in support of all of a contractor’s projects and not attributable to a specific job. The cost for home office overhead is only allowed as a percentage of all direct work excluding profit. The following items represent allowable home office overhead costs identified in Part 31 of the Federal Acquisition Regulation (FAR):

1. Rent

2. Utilities

3. Furnishings

4. Office equipment

5. Executive and management staff not exclusively assigned to the project

6. Support, accounting, and administrative staff

7. Preparation of cost proposals, estimating, and schedule analyses connected with

Modifications

8. Estimating and preconstruction services

9. Mortgage costs

10. Real estate and corporate taxes

11. Automobile maintenance and travel costs for home office personnel

12. Home office insurances i.e. structure, automotive, umbrella, flood, etc.

13. Depreciation of equipment and other assets

14. Home office supplies (paper, staples, etc.)

15. Legal services

16. Accounting and data processing

17. Professional fees/registration

B. General Conditions (Field Office Overhead): Management and administrative costs incurred on site for the designated project. Costs associated with the preparation of modifications will not be allowed. The costs for these items are to be included only in the general conditions of the modification estimate. Only in the case of a contract time extension are additional general conditions included in modifications. The following items, if applicable, are considered allowable costs for calculating General Conditions:

1. Project Manager, Assistant Project Manager

2. Superintendent, Assistant Superintendent

3. Quality Control, Safety Officer, Environmental Manager, etc.

4. Engineers

MIMI - 257286 01 26 01 - 2

5. Travel, lodging, and per diem (as established by Federal Travel Regulations)

6. Scheduling

7. Field Office Trailers and associated temporary utilities

8. Field office supplies

a. Mailing and couriers

b. Reproduction costs

c. Storage

d. Phones

e. Computers

f. Copiers

9. Personal vehicles i.e. Superintendent Pickup trucks

C. General Requirements: These are costs directly associated with the project and are necessary to perform the actual work of the modification. These costs shall be shown as direct costs in the estimate. The following items, if applicable, are considered allowable costs for calculating

General Requirements:

1. Hoisting

2. Material handling

3. Temporary fencing

4. Port-a-lets

5. Trash removal, dumpsters

6. Barricades

7. Small tools

8. Safety supplies

9. Scaffolding

10. Daily cleaning

11. Traffic control

12. Temporary signage

13. Temporary heating and power

D. Personnel Costs: Costs included in the modification must only be for General Conditions staff and workers actually present and working on the project site. Modification costs for salaried workers are only allowed within the structure of a 40 hour week and no overtime or holiday pay will be allowed.

1. Worker Hourly Rates are costs directly associated with the individual worker and consist of the following:

a. Base Rate: This is the hourly rate paid directly to the worker

b. Labor Burden: Employer payments of all applicable burdens, this includes insurance and taxes that the business must pay on behalf of the worker to government entities and educational forums , such as:

1) Social Security

2) Medicare

3) Workers Compensation– Policy and company calculation to be made available.

MIMI - 257286 01 26 01 - 3

4) FUTA– Cap Rate and percentage to be proportionally allocated over one year.

5) SUTA– Cap Rate and percentage to be proportionally allocated over one year.

6) Union agreement costs – Other costs required under an enforceable collective bargaining agreement.

c. Fringe Benefits: Various non-wage compensations provided to employees such as:

1) Health Care Insurance Premiums

2) Cell Phone

3) Clothing

4) 401K and Pensions

5) Vehicle allowances

6) Gas allowance

7) Life insurance premiums

8) Disability insurance

9) Other Fringe Benefits required under an enforceable collective bargaining agreement

E. Bonuses or Deferred Compensation: No Bonus or Deferred Compensation will be allowed within any components of pricing including Home Office Overhead, General Conditions, General Requirements, Hourly Worker Rates, or the direct costs of work.

F. General Liability Insurance: An insurance policy that protects the contractor from claims resulting from bodily injury or property damage to a third party. Include this as a separate line item within all modification proposals and provide a current insurance quote upon request.

G. Performance and Payment Bonds: A performance bond is a surety bond issued by an insurance company or bank to guarantee satisfactory completion of a project. The Payment Bond guarantees that the contractor will pay the labor and material costs they have incurred. Banks and Insurance companies charge a premium for each individual project based on a sliding scale which relates to the size of the project. Include this as a separate line item in modification proposals and provide current company bonding rates upon request.

H. Builder’s Risk Insurance: This covers the contractor’s loss due to fire, high winds, or other natural forces. This is not reimbursed by the National Park Service (NPS) and shall not be included in modification proposals.

1.3 MODIFICATION PROPOSAL PRICING REQUIREMENTS

A. General:

1. Your proposal must be received in the format and within the time frame specified in the

Request for Proposal letter. Costs or delays resulting from failure of contractor to submit within the time frame specified will not be compensable.

http://en.wikipedia.org/wiki/Employee http://en.wikipedia.org/wiki/Surety_bond http://en.wikipedia.org/wiki/Insurance http://en.wikipedia.org/wiki/Bank

MIMI - 257286 01 26 01 - 4

2. The proposal must be detailed with itemized lists of equipment, materials, labor, production rates, overhead, profit, and bond markup for each item. Labor costs must be itemized by craft and hourly rate, including Fringe Benefits and Labor Burden. If the costs of Fringe Benefits and Labor Burden are not itemized, it is assumed that that they are included in the hourly rate shown, or contractor is not requesting reimbursement.

Contractor may utilize the government provided Contractor Estimate Form, or their own form, provided that it contains the same information and level of detail as the Gov’t provided form.

3. Requests for extensions of contract time as a result of this change must be justified with a

Time Impact Analysis (TIA). Refer to Division 01 Specification, “Construction

Schedule”, for time impact analysis requirements. TIA and associated costs must be received with the proposal by the date shown within the Request for Proposal letter.

Contractor’s failure to submit within the specified time frame will be construed as the

Contractor waiving the right for additional time and no time extension will be allowed.

4. All supporting documentation used to justify the proposed modification will be made available to the Contracting Officer upon request.

5. Contractor must review and approve all subcontractor/supplier pricing in detail for proper format, scope, production rates, and pricing prior to submission to the NPS. All delay costs associated with not reviewing and approving subcontractor/supplier pricing will be borne by the Contractor.

6. All pricing and production rates within the estimate must be based on fair and reasonable pricing and cannot include built-in contingency.

B. Labor:

1. Contractor shall estimate the cost of labor by itemizing each craft involved, indicating worker hourly rate (base rate + labor burden + fringe benefits) for each and itemizing the hours required for each craft that will be directly engaged in modification work. Any work proposed that will require overtime work or premium pay shall be itemized separately. All rates shall be in accordance with the Davis-Bacon Act as incorporated herein. Labor Burden may include payroll taxes, Social Security, unemployment insurances, workers compensation insurance, FICA, FUTA, and other direct costs resulting from Federal, State or local laws.

2. Itemize labor costs for equipment operators separate from equipment costs.

3. The labor cost for foremen shall only be costs for related work required for the modification.

C. Materials:

1. The estimated cost for materials shall include quotes from multiple sources. Material prices must include all applicable fees and credits, including but not limited to, sales tax, freight and delivery charges, and tax rebates.

2. No markup shall be applied to any material provided by the NPS.

D. Equipment:

1. Equipment used for the project must be appropriately sized for the work being performed.

2. Do not include costs for “miscellaneous tools and equipment”, in your proposal for a replacement value of $500 or less. Costs shown in excess of $500 must be broken out separately.

http://www.nps.gov/dscw/publicforms.htm#ct

MIMI - 257286 01 26 01 - 5

3. Regardless of ownership, the rates to be used in determining equipment rental costs shall be the lowest cost from one of the following sources:

a. U.S. Army Corps of Engineers , Ownership and Operating Expense Schedule (use latest edition and applicable region)

b. Construction Blue Book

c. Local equipment rental rates, documented by actual invoice charges, or itemized vendor quotes.

4. The estimated equipment rates shall include the operating costs of all fuel, oil, lubrication, supplies, small tools, necessary attachments, ground engaging components, tires & tracks, routine repairs and maintenance (cost of major repair and overhaul is not allowed per FAR 31.105(d)(2)), depreciation, storage, insurance, and all incidentals.

Mobilization, if applicable, may be included for equipment solely used on the modification work but must be listed separately.

5. Estimate the full rate for equipment only for the duration that the equipment will be utilized to accomplish the work of the modification.

6. Standby unit rates used are to be in accordance with paragraph 1.3, D, 2, above. If the US

Army Corp of Engineers is utilized then their standby rates prevail. If Bluebook or local equipment pricing is accepted, then ½ of the equipment costs minus any operating costs, major repair and overhaul will be accepted.

7. If equipment is in standby mode due solely to a documented NPS delay, the established standby rate shall apply from the first day of the delay.

8. Equipment that is not used and on the jobsite for up to five consecutive days may be classified at standby rates, provided that the equipment is or has been used solely to perform work on the modification and will be necessary to complete additional modification work. Equipment that is still on the jobsite but not in use after five consecutive days will not be considered in the modification pricing.

9. Requests for compensation for equipment stand by time must be justified, documented and itemized separately.

10. The estimated timeframe (daily, weekly, monthly) for use of the equipment must reflect the lowest cost to the Government.

E. Establishment and Application of Overhead and Profit Percentages:

1. Home Office Overhead and Profit (OH&P) shall be applied to direct costs only. Profit shall not be applied to overhead amounts; and overhead shall not be applied to profit.

Home office overhead shall contain only allowable, allocable, and reasonable costs per the contract documents and FAR Part 31. Profit percentages are based on risk factors found in FAR Part 31which have been applied to the specific type of work included in this project. Negotiated rates shall not exceed the following percentages for OH&P for contractor self-performed work:

Overhead………………10%

Profit……………… 5%

2. Total aggregate limit of markup (OH&P) for contractor and subcontractors on modification work shall not exceed 25%. The NPS will not be responsible for allocation of percentages between contractor and subcontractors at any tier.

MIMI - 257286 01 26 01 - 6

3. If contractors form a partnership, than the partnership may only receive home office overhead and profit in the same amount as an individual contractor (refer to par 1.3,E,1 above). It is the responsibility of the partners to decide on the division of revenue.

4. Combined Increases and Decreases: On proposals involving both increases and decreases in the Contract Price, the overhead and profit mark-ups are required on the net increases and deducted on net decreases.

5. At no time can profit be calculated on Overhead or itself, it must be calculated on direct costs of work only.

PART 2 - PRODUCTS (NOT USED)

END OF SECTION 01 26 01

MIMI - 257286 01 27 00 - 1

DEFINITION OF CONTRACT LINE ITEMS

2020/10/16

SECTION 01 27 00 - DEFINITION OF CONTRACT LINE ITEMS

PART 1 - GENERAL

1.1 SUMMARY

A. The intent of this section is to explain, in general, what is and what is not included in a contract line item, and the limits or cut-off points where one item ends and another begins.

B. If no contract line item exists for a portion of the work, include the costs in a related item.

PART 2 - PRODUCTS (NOT USED)

PART 3 - EXECUTION

3.1 LIST OF CONTRACT LINE ITEMS

A. Contract Line Item No.0001 All work complete for Renovate Elevator Electrical Control Panel at Delta 01 Launch Control Facility (LCF) .

1. This item consists of all costs associated with all work required to furnish labor, materials, and equipment for the entire project.

2. No separate measurement for payment will be made.

3. Payment will be made at the contract lump sum price.

END OF SECTION 01 27 00

MIMI - 257286 01 31 00 - 1

PROJECT MANAGEMENT AND COORDINATION

2020/10/16

SECTION 01 31 00 - PROJECT MANAGEMENT AND COORDINATION

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes administrative provisions for coordinating construction operations on

Project including, but not limited to, the following:

1. Definitions

2. Construction Coordination.

3. Submittals

4. Coordination Drawings.

5. Requests for Information (RFIs).

6. Project meetings.

B. Related Requirements:

1. Section 01 32 16 “Construction Schedule” for preparing and submitting Contractor’s construction schedule.

2. Section 01 73 40 “Execution” for procedures for coordinating general installation and field-engineering services, including establishment of benchmarks and control points.

3. Section 01 77 00 “Closeout Procedures” for coordinating closeout of the Contract.

1.2 DEFINITIONS

A. Agency with Jurisdiction: An Agency that has been granted legal authority over a location, action, or resource. This authority includes the ability to issue a permit or other legal permission document.

1.3 CONSTRUCTION COORDINATION

A. Coordination: Coordinate construction operations included in different Sections of the

Specifications to ensure efficient and orderly installation of each part of the Work. Coordinate construction operations, included in different Sections, which depend on each other for proper installation, connection, and operation.

1. Schedule construction operations in sequence required to obtain the best results where installation of one part of the Work depends on installation of other components, before or after its own installation.

2. Where availability of space is limited, coordinate installation of different components to ensure maximum performance and accessibility for required maintenance, service, and repair of all components, including mechanical and electrical.

http://www.nps.gov/dscw/definitionsdc_a.htm#awj

MIMI - 257286 01 31 00 - 2

B. Prepare memoranda for distribution to each party involved, outlining special procedures required for coordination. Include such items as required notices, reports, and list of attendees at meetings.

C. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction activities and activities of other contractors to avoid conflicts and to ensure orderly progress of the Work. Such administrative activities include, but are not limited to, the following:

1. Preparation of Contractor's Construction Schedule.

2. Preparation of the Schedule of Values.

3. Delivery and processing of submittals.

4. Progress meetings.

5. Pre-installation conferences.

6. Project closeout activities.

1.4 SUBMITTALS

A. Division 01 documents: The following items shall be submitted a minimum of one week prior to the Preconstruction Conference. Contracting Officer will notify Contractor of tentative date for the Pre-Construction Conference.

1. Letter designating Project Superintendent.

2. Construction Schedule.

3. A comprehensive breakdown of the Schedule of Values.

4. Accident Prevention Plan.

5. A list of Subcontractors for this project.

6. Written statements from subcontractors certifying compliance with applicable labor standard clauses.

7. Satisfactory evidence of liability insurance coverage and workman’s compensation for the Contactor and all subcontractors.

8. Quality Control Plan.

9. Historic Preservation Treatment Plan.

10. List of Required Construction Permits. None anticipated.

B. All items listed must be provided to the Contracting Officer before the Pre-Construction

Conference is held. If all of these documents have not been received one week prior to the scheduled Pre-Construction Conference date, the conference will be cancelled, Notice to

Proceed will not be issued, and the Contracting Officer will consider other contractual remedies.

Work shall not commence until written Notice to Proceed has been issued.

1.5 REQUESTS FOR INFORMATION (RFIS)

A. General: Immediately on discovery of the need for additional information or interpretation of the Contract Documents, Contractor shall prepare and submit an RFI.

1. CO will not respond to RFIs submitted by other entities controlled by Contractor.

2. Coordinate and submit RFIs in a prompt manner to avoid delays in the work.

MIMI - 257286 01 31 00 - 3

B. Content of the RFI: Include a detailed, legible description of item needing information or interpretation and the following:

1. RFI number, numbered sequentially.

2. Date.

3. RFI subject.

4. Specification Section number and title and related paragraphs, as appropriate.

5. Drawing number and detail references, as appropriate.

6. Field dimensions and conditions, as appropriate.

7. Contractor's suggested resolution. If Contractor's suggested resolution impacts the

Contract Time or the Contract Sum, Contractor shall state impact in the RFI.

8. Contractor's signature.

9. Requested date for response.

10. Attachments: Include sketches, descriptions, measurements, photos, Product Data, Shop

Drawings, coordination drawings, and other information necessary to fully describe items needing interpretation.

a. Include dimensions, thicknesses, structural grid references, and details of affected materials, assemblies, and attachments on attached sketches.

C. Contracting Officer’s Action: CO will review each RFI, determine action required, and respond. CO will determine the critical nature of each RFI and issue a response accordingly.

1. The following are not considered to be RFIs and will receive no action:

a. Requests for approval of submittals.

b. Requests for approval of substitutions.

c. Requests for approval of Contractor's means and methods.

d. Requests for coordination information already indicated in the Contract

Documents.

e. Requests for adjustments in the Contract Time or the Contract Sum.

f. Requests for interpretation of Architect's actions on submittals.

g. Incomplete RFIs or inaccurately prepared RFIs.

2. CO's action may include a request for additional information, in which case time for response will date from time of receipt of additional information.

3. CO's action on RFIs may result in the need for a change to the Contract Time or the

Contract Sum. All contract changes will be processed following the terms and conditions of the contract.

1.6 PROJECT MEETINGS

A. Preconstruction Conference: Before start of construction, Contracting Officer will arrange an on-site meeting with Contractor. The meeting agenda will include the following as a minimum:

1. Roles & Responsibilities/ Lines of Authority.

2. Park rules and regulations.

3. Jobsite Safety.

4. Resolution of comments on required Division 01 documents.

5. Coordination of Subcontractors.

MIMI - 257286 01 31 00 - 4

6. Labor law application.

7. Modifications.

8. Payments to Contractor.

9. Payroll reports.

10. Contract time.

11. Liquidated damages.

12. Contractor Performance Evaluation.

13. Display of Hotline posters.

14. Notice to proceed.

15. Correspondence procedures.

16. Acceptance/rejection of work.

17. Progress meetings.

18. Submittal procedures.

19. NPS Final Accessibility Inspection.

20. As-constructed drawings/operation and maintenance (O&M) manuals.

21. Saturday, Sunday, holiday and night work.

22. Reference materials.

23. Value engineering.

B. Progress Meetings: The Contracting Officer will schedule weekly meetings with the

Contractor.

1. Attendees: In addition to Government Representatives, each Contractor, Subcontractor, supplier, and other entity concerned with current progress or involved in planning, coordination, or performance of future activities shall be represented at these meetings.

All participants at the meeting shall be familiar with the Project and authorized to conclude matters relating to the Work.

2. Agenda: Review and correct or approve minutes of previous progress meeting. Review other items of significance that could affect progress. The meeting agenda will include the following:

a. Approval of minutes of previous meetings.

b. Submittal status.

c. Review of off-site fabrication and delivery schedules.

d. Requests for information (RFI) and other issues.

e. Modifications.

f. Work in progress and projected.

1) Status of required inspections (Special Inspections, Accessibility, etc.)

g. Inspections of work in progress and projected (Special inspections,

h. Construction Schedule update (provide updated CPM).

i. Status of Project Record Drawings and O&M manuals.

j. Other business relating to work.

k. Permit requirements.

MIMI - 257286 01 31 00 - 5

C. Preinstallation Conferences: Conduct a preinstallation conference at Project site before each construction activity that requires coordination with other construction.

1. Attendees: Installer and representatives of manufacturers and fabricators involved in or affected by the installation and its coordination or integration with other materials and installations that have preceded or will follow, shall attend the meeting. Advise CO of scheduled meeting dates.

2. Agenda: Review progress of other construction activities and preparations for the particular activity under consideration, including requirements for the following:

a. Contract Documents.

b. Options.

c. Related RFIs.

d. Related Change Orders.

e. Purchases.

f. Deliveries.

g. Submittals.

h. Possible conflicts.

i. Compatibility requirements.

j. Time schedules.

k. Weather limitations.

l. Manufacturer's written instructions.

m. Warranty requirements.

n. Compatibility of materials.

o. Acceptability of substrates.

p. Space and access limitations.

q. Regulations of agency(ies) with jurisdiction.

r. Testing and inspecting requirements.

s. Installation procedures.

t. Coordination with other work.

u. Required performance results.

v. Protection of adjacent work.

w. Protection of construction and personnel.

3. Record significant conference discussions, agreements, and disagreements, including required corrective measures and actions.

4. Reporting: Distribute minutes of the meeting to each party present and to other parties requiring information.

5. Do not proceed with installation if the conference cannot be successfully concluded.

Initiate whatever actions are necessary to resolve impediments to performance of the

Work and reconvene the conference at earliest feasible date.

PART 2 - PRODUCTS (NOT USED)

END OF SECTION 01 31 00

MIMI - 257286 01 32 16 - 1

CONSTRUCTION SCHEDULE

2020/10/16

SECTION 01 32 16 - CONSTRUCTION SCHEDULE

PART 1 - GENERAL

1.1 SUMMARY

A. This Section consists of Construction Schedule requirements including but not limited to the following:

1. Schedule of Values

2. Construction Schedule Requirements.

3. Construction Schedule Updates.

4. Time Impact Analysis.

B. Purpose: The purpose of the Construction Schedule is to ensure adequate planning, coordination, scheduling, and reporting during execution of the work by the Contractor. The

Construction Schedule will assist the Contractor and Contracting Officer in monitoring the progress of the work, evaluating proposed changes, and processing the Contractor's monthly progress payment.

1.2 DEFINITIONS

A. Activity: A discrete part of a project that can be identified for planning, scheduling, monitoring, and controlling the construction project. Activities included in a construction schedule consume time and resources.

1. Critical activities are activities on the critical path. They must start and finish on the planned early start and finish times.

2. Predecessor Activity: An activity that precedes another activity in the network.

3. Successor Activity: An activity that follows another activity in the network.

B. Cost Loading: The allocation of the Schedule of Values for the completion of an activity as scheduled. The sum of costs for all activities must equal the total Contract Sum, unless otherwise approved by the Contracting Officer.

C. CPM: Critical path method, which is a method of planning and scheduling a construction project where activities are arranged based on activity relationships. Network calculations determine when activities can be performed and the critical path of Project.

D. Critical Path: The longest connected chain of interdependent activities through the network schedule that establishes the minimum overall Project duration and contains no float.

E. Float: The measure of leeway in starting and completing an activity.

1. Float: Float is not for the exclusive use or benefit of either the Government or the

Contractor but is jointly owned.

MIMI - 257286 01 32 16 - 2

2. Free float is the amount of time an activity can be delayed without adversely affecting the early start of the successor activity.

3. Total float is the measure of leeway in starting or completing an activity without adversely affecting the planned Project completion date.

F. Resource Loading: The allocation of manpower and equipment necessary for the completion of an activity as scheduled.

G. Fragnet: A partial or fragmentary network that breaks down activities into smaller activities for greater detail.

1.3 SUBMITTALS

A. Electronic Copies: All schedules and reports submitted shall be posted on the NPS DSC

SharePoint project website, provided in the native electronic file format. It is the intent of the

Government to limit the number of printed reports to only those reports determined by the project team to be essential.

B. Schedule of Values: After contract award and before the Pre-Construction conference submit a schedule of dollar values based on the Contract Price Schedule.

C. Construction Baseline Schedule: After contract award and before the Pre-Construction conference, submit two paper copies of baseline schedule, large enough to show entire schedule for entire construction period.

D. CPM Reports: Concurrent with CPM schedule, submit two paper copies of each of the following computer-generated reports. Format for each activity in reports shall contain activity number, activity description, resource loading, original duration, remaining duration, early start date, early finish date, late start date, late finish date, and total float in calendar days.

1. Activity Report: List of all activities sorted by activity number and then early start date, or actual start date if known.

2. Logic Report: List of predecessor and successor tasks for all activities, sorted in ascending order by activity number and then early start date, or actual start date if known.

3. Total Float Report: List of all activities sorted in ascending order of total float.

E. Construction Schedule Updates: On or before the 7th day preceding the progress payment request date, submit estimates of the percent completion of each schedule activity and necessary supporting data. Provide two paper copies.

F. Construction Schedule Revisions and Time Impact Analysis: For each Construction Schedule revision submit two paper copies of a Time Impact Analysis. Each Time Impact Analysis shall include a Fragmentary Network (Fragnet), incorporated into the currently accepted Construction

Schedule, demonstrating how the Contractor proposes to incorporate a modification, change, delay, or Contractor request.

MIMI - 257286 01 32 16 - 3

1.4 QUALITY ASSURANCE

A. The Contractor shall meet with the Contracting Officer on the day of the preconstruction conference to go over the following:

1. Review software limitations, content and format for reports.

2. Verify availability of qualified personnel needed to develop and update schedule.

3. Discuss constraints, including work stages and area separations.

4. Review time required for review of submittals and re-submittals.

5. Review requirements for tests and inspections by independent testing and inspecting agencies.

6. Review time required for completion and startup procedures.

7. Review and finalize list of construction activities to be included in schedule.

8. Review baseline schedule comments, resolve issues and progress on incorporating them

9. Review procedures for updating schedule.

10. Discuss reporting requirements and establish a protocol for naming and transmitting electronic schedules.

B. Contractor's Schedule Representative: Before or at the preconstruction conference, designate an authorized representative to be responsible for the preparation and maintenance of the

Construction Schedule. A resume outlining the qualifications of the Scheduler shall be submitted to the Contracting Officer for acceptance. The Scheduler shall have prepared and maintained at least 5 previous schedules of similar size and complexity similar to this Contract, demonstrating proficiency in the use of scheduling software. The authorized representative will be responsible for preparing the Baseline Schedule, all required updates, revisions, Time Impact

Analyses, and preparation of reports.

1.5 COORDINATION

A. Coordinate preparation and processing of schedules and reports with performance of construction activities and with scheduling and reporting of separate Contractors.

B. Coordinate Construction Baseline Schedule with the Schedule of Values, list of subcontracts, Submittals Schedule, progress reports, payment requests, and other required schedules and reports.

1. In developing the Construction Baseline Schedule, ensure that the Subcontractor’s work at all tiers, as well as the prime Contractor’s work, is included and coordinated.

2. Secure time commitments for performing critical elements of the Work from parties involved.

3. Coordinate each construction activity in the network with other activities and schedule them in proper sequence.

MIMI - 257286 01 32 16 - 4

PART 2 - PRODUCTS

2.1 SCHEDULE OF VALUES

A. Breakdown each lump-sum item into component work activities used in the schedule, for which progress payments may be requested. The work activities broken out within the schedule of values shall be integrated into and made a logical part of the construction baseline schedule submitted under this specification. The total costs for the component work activities shall equal the contract price for that lump-sum item. The Contracting Officer may request data to verify accuracy of dollar values. Include mobilization, general condition costs, overhead and profit in the total dollar value of unit price items and in the component work activities for each lump-sum item. Do not include mobilization, general condition costs, overhead or profit as a separate item.

B. Do not break down unit price items. Use only the contract price for unit price items.

C. The total cost of all items shall equal the contract price. The Schedule of Values will form the basis for progress payments.

D. An acceptable Schedule of Values shall be agreed upon by the Contractor and Contracting

Officer before the first progress payment is processed.

2.2 CONSTRUCTION SCHEDULE REQUIREMENTS

A. Construction Baseline Schedule: Prepare Construction Baseline Schedule using a computerized, resource-loaded, time-scaled CPM network analysis diagram for the Work.

1. Develop and finalize Construction Baseline Schedule so it can be accepted for use no later than 21 days after date established for the Notice of Award.

a. Failure to include any work item required for performance of this Contract shall not excuse Contractor from completing all work within applicable completion dates, regardless of Governments acceptance of the schedule.

2. Establish procedures for monitoring and updating Construction Baseline Schedule and for reporting progress. Coordinate procedures with progress meeting and payment request dates.

B. Construction Baseline Schedule Preparation: Prepare a list of all activities required to complete the Work. Using the preliminary CPM network diagram, prepare a skeleton network to identify probable critical paths.

1. Activities: Indicate the estimated duration, sequence requirements, and relationship of each activity in relation to other activities.

2. Critical Path Activities: Identify critical path activities, including those for interim completion dates. Scheduled start and completion dates shall be consistent with Contract milestone dates.

MIMI - 257286 01 32 16 - 5

3. Processing: Process data to produce output data on a computer-drawn, time-scaled network. Revise data, reorganize activity sequences, and reproduce as often as necessary to produce the CPM schedule within the limitations of the Contract Time.

4. The Construction Baseline Schedule as developed shall show the sequence and interdependence of activities required for complete performance of the work. Ensure all work sequences are logical and the Construction Baseline Schedule shows a coordinated plan of the work.

5. Resource loading of each activity shall include all personnel by labor category and equipment type and capacity proposed to complete the activity in the duration shown.

6. Consider seasonal weather conditions in planning and scheduling all work influenced by high and low ambient temperatures, wind, or precipitation to ensure completion of all work within the contract time.

7. Time Frame: Proposed duration assigned to each activity shall be the Contractor's best estimate of time required to complete the activity considering the scope and resources planned for the activity.

a. An early finish date may be shown but the late finish date must be the same date as the last day of the contract period. An early completion schedule must contain the following:

1) Insert an activity titled “Project Float” as a successor to the last activity in the early project completion schedule network.

2) Add a milestone titled “Contract End Date” as a successor to the activity

“Project Float”.

3) Add duration to the activity “Project Float” as required so the milestone

“Contract End Date” equals the last day of the Contract Period.

b. Contract completion date shall not be changed by submission of a schedule that shows an early completion date.

c. The Contractor shall limit use of lead or lag duration’s between schedule activities.

d. Project Calendars: Develop and incorporate the following calendars:

1) Administrative Calendar: Include a calendar that is based on a 7 day week to be used on any activities that are based on calendar days. Apply this calendar to administrative tasks or any other tasks that are not affected by non-working days (Federal Holidays, weather, etc.).

2) Project Calendar: Include a calendar that is based on the planned work week for the project. Include Federal Holidays, weekends, and any other non-work days indicated in the contract documents. Apply this calendar to activities which are not anticipated to be affected by weather.

3) Weather Calendar: Utilize the Project Calendar and show anticipated normal downtime related to weather as non-working time. Weather days shall be based on data for the local area from a reliable source like the National

Oceanic and Atmospheric Administration (NOAA), National Park Service records, or source acceptable to the Contracting Officer. Apply this calendar to activities that are anticipated to be affected by weather.

e. Activity Duration: Define activities so no activity is longer than 15 days, except for non-construction activities including mobilization, shop drawings and submittals, fabrication and delivery of materials and equipment.

MIMI - 257286 01 32 16 - 6

f. Procurement Activities: Include procurement process activities for the following long lead items and major items, requiring a cycle of more than 60 calendar days, as separate activities in the schedule. Procurement cycle activities include, but are not limited to, submittals, approvals, purchasing, fabrication, and delivery.

g. Submittal Review Time: Include review and re-submittal times indicated.

Coordinate submittal review times in Construction Baseline Schedule.

h. Startup and Testing Time: Include not less than 7 days for startup testing.

i. Substantial Completion: Allow time for Government administrative procedures necessary for certification of Substantial Completion. (For more information, refer to Division 01 Specification 01 77 00 Closeout Procedures.)

8. Constraints: Include constraints and work restrictions indicated in the Contract

Documents and as follows in schedule, and show how the sequence of the Work is affected.

a. Work Stages: Indicate important stages of construction for each major portion of the Work.

1) Subcontract awards.

2) Submittals.

3) Purchases.

4) Deliveries.

5) Installation.

6) Tests and inspections.

7) Adjusting.

9. Milestones: Include milestones indicated in the Contract Documents in schedule, including, but not limited to, the Notice to Proceed and Substantial Completion.

C. Joint Review, Revision, and Acceptance:

1. Within seven calendar days of receipt of the Contractor's proposed Construction Baseline

Schedule, the Contracting Officer and Contractor shall meet for joint review, correction, or adjustment of the initial Construction Baseline Schedule. Any areas which, in the opinion of the Contracting Officer, conflict with timely completion of the project shall be subject to revision by the Contractor.

2. Within seven calendar days after the joint review between the Contractor and Contracting

Officer, the Contractor shall revise and resubmit the Construction Baseline Schedule in accordance with agreements reached during the joint review.

3. In the event the Contractor fails to define any element of work, activity, or logic, and the

Contracting Officer review does not detect this omission or error, such omission or error, when discovered by the Contractor or Contracting Officer, shall be corrected by the

Contractor within seven calendar days and shall not affect the contract period.

4. Upon acceptance of the Construction Baseline Schedule by the Contracting Officer, save the schedule as a baseline and update on a monthly basis. The construction schedule update will be used to evaluate the Contractor's monthly applications for payment based upon information developed at the monthly Construction Schedule update meeting.

MIMI - 257286 01 32 16 - 7

D. Recovery Schedule: When periodic schedule update indicates the Work is 14 or more calendar days behind the current accepted schedule, a separate recovery schedule indicating means by which Contractor intends to regain compliance with the schedule must also be submitted.

Indicate changes to working hours, working days, crew sizes, and equipment required to achieve compliance, and date by which recovery will be accomplished.

E. Computer Software: Prepare schedules using a program that has been developed specifically to manage construction schedules.

PART 3 - EXECUTION

3.1 CONSTRUCTION SCHEDULE UPDATES

A. Progress Meeting Updates: Provide a 2 week look-ahead schedule, derived from the currently accepted schedule, before each weekly progress meeting. Utilize the look-ahead schedule to facilitate and take notes on discussions held during the progress meeting.

B. Monthly Schedule Updates:

1. General: Update the Construction Schedule on a monthly basis to reflect actual construction progress and activities throughout the entire contract period and until project substantial completion. The status date of each schedule update shall be the 7th day preceding the progress payment request date.

2. Procedure: The Contractor shall meet with the Contracting Officer each month at a

Construction Schedule update meeting to review actual progress made through the status date of the Construction Schedule update, including dates activities were started and/or completed and the percentage of work completed on each activity started and/or completed.

3. Reports: Concurrent with making revisions to schedule, prepare tabulated reports showing the following:

a. Identification of activities that have changed.

b. Changes in early and late start dates.

c. Changes in early and late finish dates.

d. Changes in activity durations in workdays.

e. Changes in the critical path.

f. Changes in total float or slack time.

g. Changes in the Contract Time.

4. Narrative: The report shall…