Solicitation_1449_revised.docx

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

DATE

AG-9JGP-S-16-0058

DATE

March 3, 2016

Danee Post, Technical Matthew Gagnon, Contracting

b. TELEPHONE NUMBER(No collect calls) 530-919-9496 530-478-6826

8. OFFER DUE DATE/ LOCAL TIME

March 17th, 2016 at 2:00PM Local

9. ISSUED BY CODE

10. THIS ACQUISITION IS |_| UNRESTRICTED OR |X| SET ASIDE: 100 % FOR

|_| SMALL BUSINESS |_| WOMEN-OWNED SMALL BUSINESS

|X| HUBZONE SMALL (WOSB) ELIGIBLE UNDER THE WOMEN-OWNED

BUSINESS SMALL BUSINESS PROGRAM NAICS:

|_| SERVICE DISABLED |_| EDWOSB 115310

VETERAN- OWNED SIZE STANDARD:

SMALL BUSINESS |_| 8(A) $19 million

USDA Forest Service Central California Acquisitions 631 Coyote Street Nevada City, CA 95959

11. DELIVERY FOR FOB DESTINATION UNLESS BLOCK IS MARKED

|_| SEE SCHEDULE

14. METHOD OF SOLICITATION

|X| RFQ |_| IFB |_| RFP

15. DELIVER TO CODE

See specifications.

16. ADMINISTERED BY CODE

See block 9.

17a. CONTRACTOR/ CODE FACILITY

OFFEROR CODE

18a. PAYMENT WILL BE MADE BY CODE

Invoice Processing Platform (www.ipp.gov)

TELEPHONE N0.

|X| SEE ADDENDUM

See separate schedule sheet.

FRED’S FUELS REDUCTION

ELDORADO NATIONAL FOREST

Offers will be accepted hardcopy or via facsimile (fax 530-478-6126).

To verify receipt of an offer, you may call Tracina Schrader at 530-478-6125.

Contractor MUST be registered in the System for Award Management (SAM) in order to qualify for award.

(Use Reverse and/or Attach Additional Sheets as Necessary)

Please allow 21 days before inquiring about award status.

Please monitor the Federal Business Opportunities website (www.fbo.gov) for award information.

E-MAIL

OFFERS

ARE

NOT

AUTHORIZED.

Offers must be fully received by the due date and time. Please plan accordingly.

25. ACCOUNTING AND APPROPRIATION DATA

See IAS requisition.

26. TOTAL AWARD AMOUNT (For Govt. Use Only)

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS: ____________________

MATTHEW GAGNON

31c. DATE SIGNED

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

See schedule on next page.

32a. QUANTITY IN COLUMN 21 HAS BEEN

|_| RECEIVED |_| INSPECTED |_| ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ________________________________________

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE

32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE

32f. TELPHONE NUMBER OF AUTHORZED GOVERNMENT REPRESENTATIVE

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

CORRECT FOR

|PARTIAL | |FINAL

|_| COMPLETE |_| PARTIAL |_| FINAL

42b. RECEIVED AT (Location)

STANDARD FORM 1449 (REV.2/2012) BACK

(Continuation of SF1449: Block 27): The full text of any/all of the included clauses or provisions may be accessed electronically at: www.acquistion.gov/far/ .

PART 1: SCHEDULE OF ITEMS

SUPPLIES/SERVICES & PRICES/COSTS

NOTES:

1. EMAIL QUOTES WILL NOT BE ACCEPTED

2. Responses for quantities less than those listed above may be rejected.

3. Responses without prices for each item and subitem may be rejected.

4. Offers for services/items alternative to those described in the solicitation will be rejected.

Price Submitted By

Signature:

Phone:

Vendor Name:

Fax:

Address:

Email:

DUNS Number:

Contact:

CONTRACT CLAUSES

BLOCK 27: THE FULL TEXT OF A CLAUSE OR PROVISION MAY BE ACCESSED ELECTRONICALLY AT WWW.ACQUISITION.GOV/FAR/

FAR 52.212-4 Contract Terms and Conditions--Commercial Items (MAY 2015) is incorporated by reference.

Addendum to FAR 52.212-4 Contract Terms and Conditions--Commercial Items

FAR 52.211-18 Variation in Estimated Quantity (Apr 1984) If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.

52.242-14 Suspension of Work (Apr 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

AGAR 452.209 – 71 ASSURANCE REGARDING FELONY CONVICTION OR TAX DELINQUENT STATUS FOR CORPORATE APPLICANTS, ALTERNATE 1 (FEB 2012)

(a) This award is subject to the provisions contained in the Consolidated Appropriations Act, 2012 (P.L. No. 112-74), Division E, Sections 433 and 434 regarding corporate felony convictions and corporate federal tax delinquencies. Accordingly, by accepting this award the contractor acknowledges that it –

(1) does not have a tax delinquency, meaning that it is not subject to any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, and

(2) has not been convicted (or had an officer or agent acting on its behalf convicted) of a felony criminal violation under any Federal law within 24 months preceding the award, unless a suspending and debarring official of the United States Department of Agriculture has considered suspension or debarment of the awardee, or such officer or agent, based on these convictions and/or tax delinquencies and determined that suspension or debarment is not necessary to protect the interests of the Government.

(b) If the awardee fails to comply with these provisions, the Forest Service may terminate this contract for default and may recover any funds the awardee has received in violation of sections 433 or 434.

WORK TIMING

The Contractor shall begin work within 3 calendar days after the effective date of the Notice to Proceed and shall prosecute the work at a rate that will result in completion of all work within the following time frame(s):

Failure to begin work on schedule will make the contract subject to immediate termination for cause.

Delays due to normal adverse weather, weekends, and holidays have been included in the calculation of contract time. The Government reserves the right to set the priority of items or subitems. Contractor shall complete all work on one subitem before proceeding to another.

If this solicitation has more than one numbered item, award of more than one item to one contractor will not change the start work dates or the amount of contract time; times will run concurrently.

Notice to Proceed No work may begin on this contract until the Contracting Officer has issued a Notice to Proceed.

Suspension During a period of suspension, the calendar days elapsed will not be charged against the contract time for the applicable units. The Contracting Officer or his/her designated representative may authorize a total or partial suspension until such time as work can proceed, such as when inclement weather sets in and the continuation of work is impractical or during Limited Operating Period’s.

Emergencies See Fire Plan

Area of Responsibility for Fire. Unless otherwise noted elsewhere in the contract, the following define the limits of a contractor's area of responsibility for fire under the terms of the Fire Plan:

Silviculture Projects - 70 meters around the perimeter of the unit being worked in

Superintendence by Contractor The name and the specific authorities of the foreman or superintendent must be designated in writing to the Contracting Officer. The Contractor may use his/her own prepared letterhead stationery or a "Designation of Contractor's Representative" form available from the Contracting Officer. If the Contractor or the designee is not present when work is being performed on the contract, a Suspend Work Order may be issued with contract time continuing to run. The Contractor shall have a person on-site that is fully conversant in the English language.

Camping Permit Compliance Camping will not be permitted at campgrounds or elsewhere on Forest Service land.

Forest Maps Forest maps may be purchased by mailing a check to the office(s) indicated below. Contact the following office for map availability and cost:

USDA Forest Service Eldorado National Forest, 100 Forni Road, Placerville, CA 95667 Ph. 530-622-5061

Archaeological and Historic Sites Location of known archaeological, historic, or pre-historic materials--such as Amerind artifacts and/or historic mining, logging, or fur trapping remains protected by the American Antiquities Act (l6 USC 433)--will be identified for the contractor before work commences.

Spill Plan If the total oil or oil products storage exceeds 1,320 gallons or if any single container exceeds a capacity of 660 gallons, the Contractor shall prepare and implement a Spill Prevention and Countermeasures (SPCC) Plan. Such plan shall meet applicable EPA requirements (40 CFR 112), including certification by a registered professional engineer. The Contractor under the direction of the Contracting Officer, or in the absence of said officer, acting independently, shall immediately take action to contain and clean up, without expense to the Government, all petroleum products spills on or in the vicinity of the project which are caused by the Contractor's employees directly or indirectly as a result of contract operations. The Contractor may be held liable for all damages and costs of additional labor, subsistence, equipment, supplies, and transportation deemed necessary by the Government for the containment and clean-up of petroleum products spills caused by Contractor's employees or resulting from contract operations. The Contractor shall immediately report all petroleum products spills to the Contracting Officer.

Equipment Cleaning All off-road equipment used on this project shall be washed before moving into the project area so that the equipment is free of soil, seeds, vegetative material, or other debris that could contain or hold seeds of noxious weeds. “Off-road equipment” includes all logging and construction equipment and such brushing equipment as brush hogs, masticators, and chippers; it does not include log trucks, chip vans, service vehicles, water trucks, pickup trucks, and similar vehicles not intended for off-road use.

Equipment will be considered clean when visual inspection does not reveal soil, seeds, plant material, or other such debris. Disassembly of equipment components or specialized inspection equipment is not required. Contractor shall notify the COR at least five days in advance of moving equipment in so that arrangements can be made for inspection.

If the project area is known to contain noxious weeds, the equipment shall be cleaned before moving to other Forest Service system lands which do not contain noxious weeds.

Pre-work Pre-work conference. Before work begins on service contracts, a pre-work conference is normally held to discuss the contract--especially the specifications, labor provisions, plan of work, and selected standard clauses. The pre-work meeting should be attended by an officer of the firm or someone designated in writing to act on behalf of the firm. The pre-work meeting may be waived at the discretion of the Contracting Officer.

INSPECTIONS

Sampling Plots. At least one percent of each treatment area will be sampled by a random series of plots distributed over the entire area. Plot size will be 1/50 acre

Specific Inspection Procedures The inspection(s) may not be performed until after the Contracting Officer receives a written request from the Contractor. An inspection may not be made until work (including slash treatment) has been completed on 25% of the contract or at the end of a 30-day period. Work determined not to be in compliance with the Technical Specifications shall be re-done by the Contractor at no additional cost to the Government.

A) Method of Survey - Inspection will be performed in a random manner using 1/50th acre plots (circular plots with a radius of 16.6 feet). Each plot will be on a pass/fail basis and all plots will be averaged for each unit to determine percent quality of the unit. Each unit will be inspected separately and results from one unit will not be averaged with results from other units. NOTE: Units that are (5) acres or less in size WILL have inspection results combined with the closest unit of 5 acres greater and these units will be evaluated as one unit.

B) Determination of Percent Quality - Percent quality will be determined by the Contracting Officer's Representative based on C.8, technical Requirements, including the following:

Item 1A & 1B

a. Spacing, stocking and leave tree selection.

b. Slash treatment and stump height.

c. Barking or minor crop damage is within acceptable limits.

d. Brush treatment.

C) Intensity of Survey - Minimum of one percent of the total area will be inspected in 1/50th acre plots. A complete survey of the area for which payment is requested will be made on the first inspection. On subsequent inspections, the survey may be discontinued in any unit in which data show that Specifications will not be met.

D) Maximum Number of Inspections - Failure of any area to comply with Specifications after two inspections may be considered cause for termination the Contractor's right to proceed with the work.

Acceptance

Work on this contract will be deemed acceptable when a formal inspection employing a systematic survey to determine the percent quality has been completed.

The Contracting Officer’s Representative will determine if Technical Requirements, C.8, have been met. Work determined to be unsatisfactory (less than 80% quality) shall be re-done by the Contractor at no additional cost to the Government. Units determined to be acceptable (80% quality greater) shall be paid for at a rate based on the percent quality.

Government Inspections Government inspections are for the purpose of satisfying the Government that the services are acceptable and do not relieve the Contractor of the responsibility for maintaining quality control.

The Contracting Officer's Representative or designated inspector will conduct all inspections. The Contractor (or designated representative) is encouraged to be present to observe inspections. Summary results will be made available on request.

Compliance Inspections. Visual compliance inspections will be made on a periodic basis. Such inspections are not final and do not constitute acceptance by the Government.

Final Inspections. Final (formal) inspections for payment will be made on completed sub-items only. Contractor shall request final inspections in writing and give the Forest Service at least two working days advanced notice. Inspections will be completed within four working days after the notice is received If the work is not ready for inspection at the time specified by the Contractor, the cost associated with the inspection attempt may be charged to the Contractor.

Disputed Inspection.

The Contractor may request reinspection without rework if the results are unacceptable. Reinspection must be requested in writing within 48 hours after receiving written notice of the inspection results. Reinspection will be accomplished within five working days after receipt of the contractor's written request.

The same sampling and inspection procedures will be used, but new samples will be taken. The inspection pattern will be shifted so that new samples will not overlap previously inspected samples. Results will be rounded to the nearest whole percent.

If reinspection results are within five percentage points of the first inspection, the original inspection result will be used in determining acceptability and payment. If reinspection results are greater than five percentage points above or below the first inspection, the reinspection results will be used.

If the reinspection results are within five percentage points of the first inspection, the Contractor shall pay the actual costs of the reinspection.

Reinspection after Rework. Where rework after a failed inspection may improve the inspection results, the Contractor may rework the area and request (in writing) a second inspection. The Government will charge to the Contractor the cost of this additional inspection. Reinspection will be accomplished within five working days after the notice is received. The results of the second inspection will be final, and no further rework will be permitted. Areas not ready for reinspection at the time specified by the Contractor will not be reinspected, and the results of the first inspection will be final.

Payment Payments may only be requested for fully completed units. Payment will be made in full if inspection results are 90 percent or higher. If inspection results are below 90 percent, a deduction will be made equal to 2 percent for every 1 percent below 90. For example, if inspection results are 87 percent, the bid price would be reduced by 6 percent. No payment will be made if results are less than 80 percent.

Contract Release.

Before final payment will be made the Contractor shall sign a release of all claims against the Government arising by virtue of this contract, other than claims, in stated amounts, that the Contractor has specifically excepted from the operation of the release. A release may also be required of the assignee if the Contractor's claim to amounts payable under this contract has been assigned under the Assignment of Claims Act of 1940 (31 U.S.C. 3727 and 41 U.S.C. 15).

Invoices

All invoices are to be submitted via the electronic Invoice Processing Platform (IPP). This is a mandatory requirement initiated by the U.S. Department of Treasury and you can find more information at this website https://www.ipp.gov/index.htm. There is no pre-award registration.

After award of a contract, please make sure that your company registers promptly at https://www.ipp.gov/vendors/enrollment-vendors.htm to establish your account. The one-time enrollment in IPP means a series of emails will be sent to the point of contact (POC) established in your System for Award Management (SAM) account at www.sam.gov. So, please verify that the POC’s email address is up to date in your company’s SAM account prior to starting the IPP enrollment process. If you have questions on the IPP enrollment process, the help desk phone number is 1-866-973-3131.

Invoices shall be accompanied by the signed contractor certification, using the exact wording in the clauses, FAR 52.232-5, and be up-to-date on certified payrolls for the invoiced timeframe, FAR 52.222-8. (See next page for invoice certification language.) Invoices that do not meet these requirements will be rejected.

The Contractor shall submit payrolls weekly for each week in which any contract work is performed. The copies shall be sent to the COR. Payrolls submitted shall set out accurately and completely all of the information listed on the form WH-347 (available for download at www.dol.gov), including the certification verbatim from the WH-347. Forms from other State or County govIernments are not compliant.

GOVERNMENT-FURNISHED PROPERTY

The Government will provide the following item(s) of Government property to the Contractor for use in the performance of this contract. This property shall be used and maintained by the Contractor in accordance with the provisions of the "Government Property" FAR clause contained elsewhere in the contract.

NONE

FSAR 4G52.222-701 Employment of Eligible Workers (DEC 1999) Section 274A of the Immigration and Nationality Act (8 USC 1324a) makes it unlawful for an employer to hire unauthorized aliens. The Immigration and Naturalization Service (INS) has established the Form I-9, Employment Eligibility Verification Form, as the document to be used for employment eligibility verification (see 8 CFR 274a).

The contractor is required to (1) have all employees complete and sign the I-9 Form to certify that they are eligible for employment; (2) examine documents presented by the employee and ensure the documents appear to be genuine and related to the individual; (3) record information about the documents on the form, and complete the certification portion of the form; (4) retain the form for three years, or one year past the end of employment of the individual, whichever is longer.

It is illegal to discriminate against any individual (other than a citizen of another country who is not authorized to work in the United States) in hiring, discharging, or recruiting because of that individual's national origin or citizenship status.

Compliance with Section 274A of the Immigration and Nationality Act (8 U.S.C. 1324a) is a material condition of the contract. If the contractor employs unauthorized workers during contract performance in violation of section 274A, the Government may terminate the contract, in addition to other remedies or penalties prescribed by law.

For further information on the requirements of the Act, contractors should contact the Employer and Labor Relations Officer of their local INS office.

FSAR 4G52.222-702 Labor Standards for Contracts Involving Migrant and Seasonal Agricultural Workers (DEC 1999)

(a) General. This contract is subject to the Migrant and Seasonal Agricultural Workers Protection Act (MSPA) (29 U.S.C 1801-1872) and to Department of Labor regulations implementing MSPA (see 29 CFR 500). The purpose of MSPA is to eliminate activities that are detrimental to migrant and seasonal agricultural workers, to require registration of farm labor contractors, and to assure necessary protections for the workers. In addition to traditional farm labor activities, the Act applies to predominately manual forestry work including, but not limited to, tree planting, release, pre-commercial thinning, and site preparation and wildland fire fighting.

(b) Definitions.

"Migrant Agricultural Worker" and "Seasonal Agricultural Worker", as used in this clause, mean individuals employed in agricultural (including forestry) work on a seasonal or temporary basis. A worker who moves from one seasonal activity to another is employed on a seasonal basis even though the worker may continue to be employed during a major portion of the year. Migrant workers are required to be absent overnight from their permanent place of residence. Seasonal workers are not required to be absent overnight from their permanent place of residence. Members of the contractor's immediate family are not considered to be either migrant or seasonal workers. "Immediate family" includes only (1) spouse; (2) children, stepchildren, or foster children; (3) parents, stepparents, or foster parents; and (4) brothers and sisters.

"Farm Labor Contractor", as used in this clause, means an individual who, for any money or other valuable consideration, paid or promised to be paid, performs any recruiting, soliciting, hiring, employing, furnishing, or transporting of any migrant or seasonal agricultural worker.

(c) Registration Requirement. Any contractor who provides or hires migrant or seasonal workers to perform agricultural or manual forestry work shall first obtain a Certificate of Registration from the Department of Labor or an authorized State agency. The contractor shall carry the Certificate at all times while engaged in contract performance, and shall display it upon request. Any of the contractor's employees who also perform any one or more of the activities defined for a "Farm Labor Contractor" in paragraph (b) must have their own Farm Labor Contractor Employee Certificate.

(d) Worker Protections. The contractor shall comply with the following protections and standards related to wage disclosure, recordkeeping, vehicle safety, and housing:

(1) The contractor shall display and maintain at the place of employment the MSPA poster provided by the Department of Labor.

(2) Wage and Payroll Standards

(i) The contractor shall disclose in writing to each worker in a language common to the worker the full terms of their employment, including workers compensation information, at the time they are recruited or hired. The Department of Labor provides an optional form WH-516 for contractor's use in disclosure.

(ii) The contractor must keep the following payroll records for each employee: name, address, social security number, basis for wages (i.e. per hour, per tree, per acre), number of units earned if paid on a per unit basis, hours worked, total pay, withholdings and purpose for each, and net pay. Payroll records shall be retained for three years.

(iii) Payments must be made no less frequently than every two weeks or semi-monthly. At the time of each payment, the contractor shall provide to the employee a written itemization of the information listed above and which shall include the employer's tax identification number.

(iv) If paid on a piece rate basis, the employee's wage must be at least equivalent to the required hourly wage for the hours worked, including overtime differential for time in excess of 40 hours per week.

(3) Motor Vehicle Safety

(i) The contractor must be registered to transport employees, unless employees provide their own transportation or carpool by their own arrangement in one of their own vehicles. The authorization to transport employees must appear on the contractor's certificate. If the contractor directs or requests employees to carpool, the registration requirement is still applicable. Any driver who transports workers for a fee or at the direction of the contractor must be registered as a farm labor contractor or a farm labor contractor employee.

(ii) Any vehicle under the ownership or control of the contractor shall comply with safety standards applicable to that vehicle. Generally passenger vehicles or station wagons must comply with Department of Labor regulations at 29 CFR 500.104. Vehicles other than passenger vehicles or station wagons which are driven more than 75 miles must comply with Department of Transportation Regulations at 29 CFR 500.105. All drivers must have a current, valid State driver’s license.

(iii) Each vehicle under the ownership or control of the contractor which is used to transport any migrant or seasonal agricultural worker shall be covered by vehicle insurance of $100,000 per seat (maximum $5,000,000). A workers compensation policy which covers the workers while being transported plus an additional property damage policy for $50,000 for loss or damage in any one accident to the property of others may be substituted for the vehicle insurance requirement.

(4) Housing

(i) The contractor shall house workers only in a commercial establishment or a facility that has been certified by a health authority or other appropriate agency. The contractor must post the certificate of occupancy at the housing site.

(ii) The authorization to furnish housing, other than commercial lodging, must appear on the contractor's certificate.

(e) For further information on the requirements of the Act, contractors should contact their local Wage and Hour Division of the Department of Labor.

FSAR 4G52.222-703 Migrant and Seasonal Agricultural Worker Protection Act Registration (DEC 1999) The Migrant and Seasonal Agricultural Worker Protection Act (MSPA) (29 U.S.C. 1801-1872) and implementing regulations issued by the Department of Labor (29 CFR 500), require any employer who hires or anticipates hiring employees subject to MSPA to obtain an MSPA registration number.

If the contractor employs or anticipates hiring employees subject to MSPA, the contractor shall provide a valid U.S. Department of Labor MSPA Registration Number to the Contracting Officer within 10 days after notification of award of the contract.

The Government may demand that the contractor display MSPA registration at any time during contract performance if it appears that the contractor is employing workers subject to MSPA. On demand, the contractor shall display its MSPA registration or state why it is exempt from MSPA.

Compliance with MSPA is a material condition of the contract. If the contractor fails to provide a valid MSPA number in accordance with this clause, or falsely states that it is exempt from the MSPA, the Government may terminate the contract, in addition to other remedies or penalties prescribed by law.

4G52.222-704 PERSONAL PROTECTIVE EQUIPMENT (FEBRUARY 2007)

The contractor shall train workers in the safe operation and use of equipment that the worker may use before the worker begins using such equipment.

Personal protective equipment, including personal protective equipment for eyes, face, head, and extremities shall be provided, used, and maintained in a sanitary and reliable condition wherever it is necessary by reason of hazards or processes encountered which may cause injury or impairment in the function of any part of the body. Defective or damaged personal protective equipment shall not be used.

The contractor shall provide chain saw chaps to each employee who operates a chain saw, at no cost to the employee. These chaps must be approved by an Underwriters Laboratory or meet Forest Service specification 6170-47. The chaps shall cover the full length of the thigh and shall extend to the top of the boot on each leg.

The contractor shall assure that each employee wears foot protection that provides adequate traction and ankle support. Employees operating chain saws shall wear foot protection that is constructed with cut-resistant material which will protect the employee against contact with a running chain saw.

In any area where the worker is exposed to the potential for flying or falling objects, the contractor shall provide a hard hat, at no cost to the employee, and the contractor shall assure that the employee wears the hard hat. The hard hat must meet the minimum requirements of American National Standards Institute (ANSI) standard Z89.1-1997.

The contractor shall provide, at no cost to the employee, eye protection where there is potential for eye injury due to flying objects. This eye protection must meet the minimum requirements of ANSI standard Z87.1-2003.

The contractor shall provide, at no cost to the employee, hearing protection where there is a potential for hearing loss due to high intensity noise for example, and chainsaw operation.

Worker Housing R5—Supplement to 4G52.222-702 (d) (4) Add the following to the clause at H.8.2, subparagraph (4) Housing:

(iii) If the contractors is not furnishing worker housing;

Workers on this contract may be housed only in a residential accommodation, including a commercial establishment such as a hotel or motel, which meets all applicable state and federal standards for employee housing.

Within 10 days after award, and prior to the issuance of Notice to Proceed, the contractor must notify the Contracting Officer of the planned worker housing site, and must submit for approval a copy of a housing Permit for the site or a statement as to why the site is exempt, as follows:

If the housing site is located on a National Forest, the Contractor must obtain a Permit from the District Ranger for the District on which the housing site is located and the facilities established for the workers must meet the applicable U.S. Department of Labor (USDOL) standards for such sites.

If the housing site is not located on a National Forest, the site must meet the applicable housing standards in MSPA, and in the California Employee Housing Act. Unless the site has an “innkeeper exemption” or other exemption, an employee housing permit is required. Permits for sites housing five or more workers are issued by the California Department of Housing and Community Development (CDHCD). For information regarding the State’s requirements and Permits, for Northern California, call (916) 225-2501 and in Southern California, call (909) 782-4420. If fewer than five workers will be housed at a site, the permit must be issued by the Wage and Hour Division, USDOL.

If an exemption from the permit requirement is claimed, the contractor must provide a written statement identifying the law authorizing the exemption, stating the facts constituting an exemption under that law, and identifying a USDOL and CDHCD employee or official who stated or concurred that the accommodations were exempt, citing name, date, and means of communication.

If the housing site is changed after approval by the Contracting Officer, the contractor must provide a new Permit or exemption statement. The above requirements are material conditions of this contract. If the contractor fails to comply, the Government may terminate the contract. In addition, other remedies or penalties prescribed by law may apply

Field Sanitation

In accordance with US Department of Labor Fact Sheet No. ESA 97-28 “Field Sanitation Standards” (Ref. 29CFR 1928.110), employers must provide:

· Potable drinking water, suitably cool and in sufficient amounts, dispensed in single-use cups or by fountains, located so as to be readily accessible to employees.

· Facilities maintained in accordance with public health sanitation practices include upkeep of water quality through daily change or more often if necessary.

· Notification to each employee of the location of the water and allowance of reasonable opportunities during the workday to use them. The employer also must inform the employee of the relevant health hazards in the field and the practices necessary to minimize them.

Employees cannot be made to bear the costs incurred by the employer for providing required facilities.

FSAR 4G52.222-703 Migrant and Seasonal Agricultural Worker Protection Act Registration (DEC 1999) The Migrant and Seasonal Agricultural Worker Protection Act (MSPA) (29 U.S.C. 1801-1872) and implementing regulations issued by the Department of Labor (29 CFR 500), require any employer who hires or anticipates hiring employees subject to MSPA to obtain an MSPA registration number.

If the contractor employs or anticipates hiring employees subject to MSPA, the contractor shall provide a valid U.S. Department of Labor MSPA Registration Number to the Contracting Officer within 10 days after notification of award of the contract.

The Government may demand that the contractor display MSPA registration at any time during contract performance if it appears that the contractor is employing workers subject to MSPA. On demand, the contractor shall display its MSPA registration or state why it is exempt from MSPA.

Compliance with MSPA is a material condition of the contract. If the contractor fails to provide a valid MSPA number in accordance with this clause, or falsely states that it is exempt from the MSPA, the Government may terminate the contract, in addition to other remedies or penalties prescribed by law.

Solicitation No: AG-9JGP-S-16-0058 2016 Fred’s Fuels Reduction Eldorado National Forest

CONTRACT CLAUSES (CONTINUED)

FAR 52.212-5 Contract Terms and Conditions Required to Implement Statutes or Executive Orders—Commercial Items (FEB 2016)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (NOV 2015)

(2) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).

(3) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.] _X_ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

__ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (OCT 2015) (Pub. L. 110-252, Title VI, Chapter 1 (41 U.S.C. 3509)).

__ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (June 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

_X_ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (OCT 2015) (Pub. L. 109-282) (31 U.S.C. 6101 note).

__ (5) [Reserved].

__ (6) 52.204-14, Service Contract Reporting Requirements (Jan 2014) (Pub. L. 111-117, section 743 of Div. C).

__ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Jan 2014) (Pub. L. 111-117, section 743 of Div. C).

_X_ (8) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (AUG 2015) (31 U.S.C. 6101 note).

__ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (JUL 2013) (41 U.S.C. 2313).

__ (10) [Reserved].

_X_ (11)(i) 52.219-3, Notice of Total HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a).

__ (ii) Alternate I (Nov 2011) of 52.219-3 __ (12)(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

__ (ii) Alternate I (Jan 2011) of 52.219-4 __ (13) [Reserved] __ (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (NOV 2011) (15 U.S.C. 644).

__ (ii) Alternate I (Nov 2011) of 52.219-6.

__ (iii) Alternate II (Nov 2011) of 52.219-6.

__ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644).

__ (ii) Alternate I (Oct 1995) of 52.219-7.

__ (iii) Alternate II (Mar 2004) of 52.219-7.

_X_ (16) 52.219-8, Utilization of Small Business Concerns (Oct 2014) (15 U.S.C. 637(d)(2) and (3)).

__ (17)(i) 52.219-9, Small Business Subcontracting Plan (Oct 2015) (15 U.S.C. 637(d)(4)).

__ (ii) Alternate I (Oct 2001) of 52.219-9.

__ (iii) Alternate II (Oct 2001) of 52.219-9.

__ (iv) Alternate III (Oct 2015) of 52.219-9.

__ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011)(15 U.S.C. 644(r)).

__ (19) 52.219-14, Limitations on Subcontracting (Nov 2011) (15 U.S.C. 637(a)(14)).

__ (20) 52.219-16, Liquidated Damages—Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)).

__ (21) 52.219-27, Notice of Total Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657 f).

_X_ (22) 52.219-28, Post Award Small Business Program Representation (Jul 2013) (15 U.S.C. 632(a)(2)).

__ (23) 52.219-29 Notice of Set-Aside for Economically Disadvantaged Women-Owned Small Business (EDWOSB) Concerns (DEC 2015) (15 U.S.C. 637(m)).

__ (24) 52.219-30 Notice of Set-Aside for Women-Owned Small Business (WOSB) Concerns Eligible under the WOSB Program (DEC 2013) (15 U.S.C. 637(m)).

_X_ (25) 52.222-3, Convict Labor (Jun 2003) (E.O. 11755).

_X_ (26) 52.222-19, Child Labor—Cooperation with Authorities and Remedies (FEB 2016) (E.O. 13126).

_X_ (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

_X_ (28) 52.222-26, Equal Opportunity (Apr 2015) (E.O. 11246).

_X_ (29) 52.222-35, Equal Opportunity for Veterans (APR 2015)(38 U.S.C. 4212).

_X_ (30) 52.222-36, Affirmative Action for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

_X_ (31) 52.222-37, Employment Reports on Veterans (OCT 2015) (38 U.S.C. 4212).

_X_ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

_X_ (33) 52.222-50, Combating Trafficking in Persons (OCT 2015) (22 U.S.C. 7104(g)).

___Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. 7104(g)).

__ (34) 52.222-54, Employment Eligibility Verification (Aug 2013). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

__ (35) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (36) (i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514).

__ (ii) Alternate I (OCT 2015) of 52.223-13.

__ (37) (i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (E.O. 13423 and 13514).

__ (ii) Alternate I (Jun 2014) of 52.223-14.

__ (38) 52.223-15, Energy Efficiency in Energy-Consuming Products (OCT 2015) (42 U.S.C. 8259b).

__ (39) (i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (Jun 2014) (E.O. 13423 and 13514).

__ (ii) Alternate I (Jun 2014) of 52.223-16.

_X_ (40) 52.223-18, Encouraging Contractor Policy to Ban Text Messaging While Driving (Aug 2011) (E.O. 13513).

__ (41) 52.225-1, Buy American Act—Supplies (May 2014) (41 U.S.C. chapter 83).

__ (42) (i) 52.225-3, Buy American Act—Free Trade Agreements—Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43).

__ (ii) Alternate I (May 2014) of 52.225-3.

__ (iii) Alternate II (May 2014) of 52.225-3.

__ (iv) Alternate III (May 2014) of 52.225-3.

__ (43) 52.225-5, Trade Agreements (FEB 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

_X_ (44) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

__ (45) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

__ (46) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).

__ (47) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150).

__ (48) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

__ (49) 52.232-30, Installment Payments for Commercial Items (Oct 1995) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

_X_ (50) 52.232-33, Payment by Electronic Funds Transfer—System for Award Management (Jul 2013) (31 U.S.C. 3332).

__ (51) 52.232-34, Payment by Electronic Funds Transfer—Other than System for Award Management (Jul 2013) (31 U.S.C. 3332).

__ (52) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).

__ (53) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

__ (54) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631).

__ (ii) Alternate I (Apr 2003) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.] __ (1) 52.222-17, Non-displacement of Qualified Workers (May 2014) (E.O.13495).

_X_ (2) 52.222-41, Service Contract Act of 1965 (May 2014) (41 U.S.C. chapter 67).

_X_ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

_X_ (4) 52.222-43, Fair Labor Standards Act and Service Contract Act—Price Adjustment (Multiple Year and Option Contracts) (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

_X_ (5) 52.222-44, Fair Labor Standards Act and Service Contract Act—Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (6) 52.222-51, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment—Requirements (May 2014) (41 U.S.C. chapter 67).

__ (7) 52.222-53, Exemption from Application of the Service Contract Act to Contracts for Certain Services—Requirements (May 2014) (41 U.S.C. chapter 67).

_X_ (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2014)(E.O. 13658).

__ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792).

__ (10) 52.237-11, Accepting and Dispensing of $1 Coin (Sept 2008) (31 U.S.C. 5112(p)(1)).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records—Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this…