Placerville_SECTION_F__Water_Line_Installation_and_Fire_Hydrant_Replacement.docx

SECTION F – DELIVERIES OR PERFORMANCE

CLAUSES INCORPORATED BY REFERENCE ((FAR 52.252-2)(FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

www.acquisition.gov/far/

FEDERAL ACQUISITION REGULATION 948 CFR CHAPTER 1) CLAUSES

FAR 52.242-14 Suspension of Work (APR 1984) FAR 52.242-15 Stop Work Order (AUG 1989)

Commencement, Prosecution, and Completion of Work (FAR 52.211-10)(APR 1984) The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 76 calendar days. The time stated for completion shall include final cleanup of the premises.

Work is estimated to begin August 1, 2014.

SUPERINTENDENCE BY THE CONTRACTOR (FAR 52.236-6)(APR 1984)

At all times during performance of this contract and until the work is completed and accepted, the Contractor shall directly superintend the work or assign and have on the worksite a competent superintendent who is satisfactory to the Contracting Officer and has authority to act for the Contractor.

PERIOD OF PERFORMANCE (AGAR 452.211-74)(FEB 1988)

The period of performance of this contract is from award date through October 31, 2014.

Work Timing Delays due to normal adverse weather, weekends, and holidays have been included in the calculation of contract time.

BIO PREFERRED PRODUCT PERFORMANCE REQUIREMENTS SUMMARY

Required Service – Ensure the mandatory purchasing & use of bio-based products Performance Indicator – Quantitative Factor Performance Standard – Contractor compliance with FSIRA, EO 13423 and FAR Surveillance Methodology – 100% Inspection

AQL – 100%

Deduction – COR state dollar amount or percentage of deduction for non-compliance