Amend 2-AG9702-S-10-0095.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE PAGE OF PAGES

1 2

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)

6/18/2010

6. ISSUED BY CODE 9702 7. ADMINISTERED BY (If other than Item 6) CODE

USDA Forest Service

EROC-SW

1323 Club Drive Vallejo, CA 94592

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State, and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NO.

AG-9702-S-10-0095

9B. DATED (SEE ITEM 11)

05/21/2010

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

(X) A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN

THE CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return 1 copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.

See SUMMARY OF CHANGES, page 2 of 2.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

George Morrissey, Contracting Officer

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

/s/ 6/17/2010

(Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070

Previous edition unusable

30-105 STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

AMENDMENT OF

SOLICITATION/MODIFICAT

ION OF CONTRACT -

Attachment to SF 30

Page 2of 2 Pages

ISSUANCE DATE: 06/17/2010 PROJECT NAME: West Side Bridge Painting

AMENDMENT NUMBER: 0002

List below (or on attached sheet, if necessary) each proposed modification identified by Item Number, location of station, etc., giving the reasons for the modifications.

SUMMARY OF CHANGES:

A. Questions and Answers Below Clarify the information in the Solicitation

1) How many day do we have to complete the project the specs state to be complete by Aug 2011 ANSWER: Contract calls for completion by August 15, 2011 based on a notice to proceed on June 14, 2010. As the NTP date is delayed, the completion date will move back also.

I should be noted that our goal is to have all work completed no later than September 2 2011.

2) Are we required to remove the paint on top of the steel beams where the pt decking is attached.

ANSWER: Steel structure surfaces exposed during repair work (deck replacement) are to be painted.

We will not remove deck just to paint the beam flange

3) The little north fork bridge specs state that 90% of the paint and red primer will be removed . is this also true for pevine creek and french creek. will sspc method 6 be enough to remove 90%. the commercial blast will this be water or abrasives ANSWER: That requirement will be removed. See Drawing Sheet 3R (Solicitation Amendment 01- Posted 06/16/2010 on FBO.)

4) When the wood is being replace on french creek bridge will we be able to close it to traffic ANSWER: As noted in Section G, the contract will allow for a three day closure on the French Creek Bridge for deck replacement

5) Is full time fire watch required. no hot saw will be needed on this project.

ANSWER: For the various work activities being engaged in, only those requirements of the effective Project Activity Level must be complied with. We may be able to obtain a variance for some activities not involving power saws and tracked equipment however, that is not assured.

B. All other terms and conditions remain unchanged.

(End of Amendment)