AG-7335-S-15-0010.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

732366

USDA-NRCS-OKLAHOMA STATE OFFICE

100 USDA, SUITE 206

STILLWATER OK 74074-2655

NRCS-OK-127335

USDA-NRCS

Attn: Sharla K. Goforth 100 USDA, Suite 206 Stillwater, OK 74074

SHARLA GOFORTH 405-742-1231

104/23/2015

AG-7335-S-15-0010

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

Wetland Reserve Program Restoration Project in McCurtain County, Oklahoma.

Estimated price range - $100,000 - $250,000

A site showing will be held April 29, 2015. Information on location and time of the site showing can be found in Section L.6 of this solicitation.

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

5 96 calendar days and complete it within ________________ ________________ calendar days after receiving

05/26/2015

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

USDA-NRCS-OKLAHOMA STATE OFFICE

100 USDA, SUITE 206

STILLWATER OK 74074-2655

NRCS-OK-127335

SHARLA K. GOFORTH

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 35

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

AG-7335-S-15-0010

FOB: Destination

001 Construction for Restoration - Lowe WRP -

66733511012BK - McCurtain

002 Construction for Restoration - Pietzyk WRP -

6673351000Z8H - McCurtain

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

B.1

ITEM NO. SCHEDULE OF ITEMS SUPPLIES/SERVICES UNIT

1 MOBILIZATION-L 200 1 LS $ XXXXXX $

2 DEEP WATER HABITAT-L 211 7,500 CY $ $

3 SHALLOW WATER HABITAT-L 211 2100 CY $ $

4 SWALE-L 729 4 EA $ $

5 NATIVE GRASS SEEDING-L 275 4 AC $ $

6 TEMPOARY COVER CROP-L 280 4 AC $ $

7 MOBILIZATION-P 200 1 LS $ XXXXXX $

8 DEEP WATER HABITAT-P 211 7,500 CY $ $

9 SWALE-P 729 2 EA $ $

10 UNIT 1 EMBANKMENT-P 723 5,467 CY $ $

11 WATER CONTROL STRUCTURE-P 52 68 LF $ $

12 NATIVE GRASS SEEDING-P 275 4.5 AC $ $

13 TEMPOARY COVER CROP-P 280 4.5 AC $ $

Total $

OFFEROR DATE

TAX ID #

DUNS #

B.2

B.3 52.211-18 VARIATION IN ESTIMATED QUANTITY. (APR 1984)

PIETZYK WRP

SPEC

NO.

LOWE WRP

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://www.acquisition.gov/far/index.html

Section B - Supplies or Services

LOWE & PIETZYK WRP - McCURTAIN COUNTY One award for the aggregate of all items will be made under this solicitation.

AMOUNT

ESTIMATED

QUANTITY

UNIT

COST

AG-7335-S-15-0010 Page 4 of 35

SECTION C - DESCRIPTION/SPECIFICATIONS/WORK STATEMENT

C.1 AGAR 452.211-72 STATEMENT OF WORK/SPECIFICATIONS (FEB 1988)

The Contractor shall furnish the necessary personnel, material, equipment, services and facilities (except as otherwise specified), to perform the Statement of Work/Specifications referenced in Section J.

C.2 AGAR 452.211-73 ATTACHMENTS TO STATEMENT OF WORK/SPECIFICATIONS (FEB

1988)

The attachments to the Statement of Work/Specifications listed in Section J are hereby made part of this solicitation and any resultant contract.

AG-7335-S-15-0010 Page 5 of 35

SECTION D - PACKAGING AND MARKING

THERE ARE NO CLAUSES INCLUDED IN THIS SECTION

AG-7335-S-15-0010 Page 6 of 35

SECTION E - INSPECTION AND ACCEPTANCE

E.1 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://www.acquisition.gov/far/index.html

I. FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES

NUMBER TITLE DATE

52.246-12

INSPECTION OF CONSTRUCTION

AUG 1996

AG-7335-S-15-0010 Page 7 of 35 http://www.arnet.gov/far/

SECTION F - DELIVERIES OR PERFORMANCE

F.1 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available.

Also, the full text of a clause may be accessed electronically at this/these address(es):

I. FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES

52.211-18

VARIATION IN ESTIMATED QUANTITY APR 1984

52.242-14 SUSPENSION OF WORK APR 1984

F.2 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK

(APR 1984)

The Contractor shall be required to (a) commence work under this contract within five (5) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than ninety-six (96) calendar days. The time stated for completion shall include final cleanup of the premises.

F.3 AGAR 452.249-70 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (NOV

2013)

(a) This clause specifies the procedures for determination of time extensions for unusually severe weather in accordance with the FAR Clause 52.249-10 DEFAULT (Fixed Price Construction). In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe; that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

(b) The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the baseline for monthly weather time evaluations. The Contractor's progress schedule must reflect those anticipated adverse weather delays in all weather dependent activities.

AG-7335-S-15-0010 Page 8 of 35

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY WORK DAYS BASED ON A FIVE DAY

WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

9 7 6 4 4 3 2 2 3 3 5 8

(c) Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record the occurrence of adverse weather and resultant impact to normally scheduled work.

Actual adverse weather delay must prevent work on critical activities for fifty (50) percent or more of the contractor's scheduled work day. The number of actual adverse weather days shall include days impacted by actual adverse weather (even if adverse weather occurred in the previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph (b) above, the contractor may submit a written request for a modification for extension of performance time due to unusually severe weather. The Contracting Officer will convert any qualifying delays into calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with FAR clause 52.249-10, Default (Fixed Price Construction).

F.4 ACTUAL DAMAGES—CONSTRUCTION

(a) If the Contractor fails to complete the work within the time specified in the contract, or any extension, the Contractor shall pay to the Government as actual damages, the total expenses for the COR and Inspector. These expenses shall include but is not limited to the salary and travel costs associated with this project.

(b) If the Government terminates the Contractor's right to proceed, the resulting damage will consist of actual damages until such reasonable time as may be required for final completion of the work together with any increased costs occasioned the Government in completing the work.

(c) If the Government does not terminate the Contractor's right to proceed, the resulting damage will consist of actual damages until the work is completed or accepted.

F.5 MAXIMUM WORKWEEK – CONSTRUCTION SCHEDULE

Within 10 calendar days after receipt of a written request from the Contracting Officer, the Contractor must submit the following in writing for approval, the hours (including the daily starting and stopping times) and days of the week the Contractor proposes to carry out the work.

The maximum workweek that will be approved is 8 hours per day, five days per week, Monday through Friday.

F.6 WORK PERFORMANCE ON HOLIDAYS

The Contractor shall not perform work on the following holidays except in the case of emergency as permitted elsewhere in this contract:

Independence Day Labor Day Thanksgiving Day Christmas Day New Year's Day

AG-7335-S-15-0010 Page 9 of 35

The contract performance time has been established to allow for the non-working holidays stated above.

The Contractor may be permitted to work the following remaining designated Federal holidays provided that he/she submits a letter of request to the Contracting Officer at least five (5) days in advance of the holiday.

Columbus Day Veterans Day Washington's Birthday Martin Luther King, Jr.'s Birthday Memorial Day

AG-7335-S-15-0010 Page 10 of 35

SECTION G - CONTRACT ADMINISTRATION DATA

G.1 CONTRACTING OFFICER’S AUTHORITY

The Contracting Officer (CO) is the only person authorized to approve changes in any of the requirements of this contract.

This authority remains solely with the CO. In the event that the Contractor effects any change at the direction of any person other than the CO, the change will be considered to have been made without authority and NO adjustment will be made in the contract price to cover any INCREASE in costs incurred as a result thereof.

G.2 CONTRACTING OFFICER’S REPRESENTATIVE

The Contracting Officer’s Representative (COR) is an individual designated in writing by the Contracting Officer (CO) to act as an authorized representative of the CO to perform specific contract administrative functions within the scope and limitations as defined by the CO. The COR does not have the authority to modify the contract. Any subsequent change to the COR or COR responsibilities will be confirmed, in writing, by the CO. In no instance shall the COR be delegated authority to order any change in the Contractor’s performance which would affect cost.

G.3 DESIGNATED PAYMENT OFFICE CONTACT POINT

The contact point described below coordinates the issuance of payments under this contract. If payment is not received within 5 days after the due date specified in the contract, contact the payment office designated below for information on when payment will be made.

USDA, National Finance Center Administrative Payments Branch (APB) Telephone: (800) 421-0323 or (504) 426-6510

If questions arise on the amount paid, contact the contracting officer at the number or address shown in the contract.

G.4 INVOICE PAYMENT PLATFORM (IPP)

“Electronic Invoicing and Payment Requirements – Invoice Payment Platform (IPP)”

Invoices must be submitted electronically through the U.S. Department of the Treasury’s Invoice Payment Platform System (IPP) or the Contractor must be willing to accept payment by Government purchase card.

The Contractor must use the IPP website (https://www.ipp.gov) to register, access, and use IPP for submitting invoices.

Contractor assistance with enrollment can be obtained by calling (866) 973-3131.

Invoices submitted by means other than IPP will not be accepted unless the Contracting Officer authorizes alternate procedures in writing. The written authorization from the Contracting Officer shall be maintained in the contract file.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

1. Payment Schedule of Values

2. Invoice Certification

AG-7335-S-15-0010 Page 11 of 35 https://www.ipp.gov/

G.5 OTHER INVOICING REQUIREMENTS UNDER PROMPT PAYMENT FOR CONSTRUCTION

CONTRACTS

(1) In addition to the information required in Clause 52.232-27 Prompt Payment for Construction Contracts, and Clause 52.232-5, Payments Under Fixed Price Construction Contracts, the contractor shall provide the following:

(i) The original and one copy of each invoice are to be delivered to the Contracting Officer at the location shown in Block 24 of SF-1442.

(ii) One copy of each invoice is to be submitted simultaneously to the Contracting Officer’s

Representative who will be identified prior to a work start.

(2) The following must be attached to the original invoice submitted to the Contracting Officer and to the copy submitted to the Contracting Officer’s Representative:

(i) A complete remittance address along with vendor identification number on the second line, if electronic funds transfer (EFT) is elected.

(ii) Billing period.

(iii) If requesting payment for materials delivered but not installed, contractor will provide evidence of title to the materials as required by FAR Clause 52.232-5, Payments Under Fixed Price Construction Contracts.

(iv) Itemization of payment requests by contract item number (CIN) as shown in Schedule B of the contract. Invoice will include the quantity performed that is being invoiced, the unit price and the CIN total price, and a sum total of amount of payment requested. Invoice will also include the cumulative quantities and amount by CIN.

(v) A listing of the amount included for work performed by each subcontractor under the contract.

(vi) A listing of the total amount of each subcontract under the contract.

(vii) A listing of the amounts previously paid to each such subcontractor under the contract

(viii) A signed certification as required by FAR Clause 52.232-5, Payments Under Fixed Price

Construction Contracts.

(ix) A copy of the payrolls and statements of compliance not previously submitted to cover the billing period.

(3) The FINAL invoice billing shall also contain the following RELEASE OF CLAIMS statement as required by

FAR 52.232-5, Payments Under Fixed Price Construction Contracts:

I, (Name of Contractor), do hereby release the United States of America from any and all claims and liabilities of any character whatsoever arising under and by virtue of contract number (Identify Contract) dated (Date) as amended, except as stated.

(Date of Release) (Signature of Contractor)

AG-7335-S-15-0010 Page 12 of 35

SECTION H - SPECIAL CONTRACT REQUIREMENTS

H.1 52.236-13 ACCIDENT PREVENTION (NOV 1991)

(a) The Contractor shall provide and maintain work environments and procedures which will --

(1) Safeguard the public and Government personnel, property, materials, supplies, and equipment exposed to Contractor operations and activities;

(2) Avoid interruptions of Government operations and delays in project completion dates; and

(3) Control costs in the performance of this contract.

(b) For these purposes on contracts for construction or dismantling, demolition, or removal of improvements, the Contractor shall --

(1) Provide appropriate safety barricades, signs, and signal lights;

(2) Comply with the standards issued by the Secretary of Labor at 29 CFR Part 1926 and 29 CFR Part 1910; and

(3) Ensure that any additional measures the Contracting Officer determines to be reasonably necessary for the purposes are taken.

(c) If this contract is for construction or dismantling, demolition or removal of improvements with any Department of Defense agency or component, the Contractor shall comply with all pertinent provisions of the latest version of U.S. Army Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1, in effect on the date of the solicitation.

(d) Whenever the Contracting Officer becomes aware of any noncompliance with these requirements or any condition which poses a serious or imminent danger to the health or safety of the public or Government personnel, the Contracting Officer shall notify the Contractor orally, with written confirmation, and request immediate initiation of corrective action. This notice, when delivered to the Contractor or the Contractor’s representative at the work site, shall be deemed sufficient notice of the noncompliance and that corrective action is required. After receiving the notice, the Contractor shall immediately take corrective action. If the Contractor fails or refuses to promptly take corrective action, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. The Contractor shall not be entitled to any equitable adjustment of the contract price or extension of the performance schedule on any stop work order issued under this clause.

(e) The Contractor shall insert this clause, including this paragraph (e), with appropriate changes in the designation of the parties, in subcontracts.

(f) As provided for in (b)(3) above, the contractor shall also comply with the NRCS Supplement to OSHA Parts 1910 and 1926, which is made a part of this contract.

AG-7335-S-15-0010 Page 13 of 35

H.2 NATURAL RESOURCES CONSERVATION SERVICE SUPPLEMENT TO OSHA PARTS

1910 and 1926

CONSTRUCTION INDUSTRY AND INTERPRETATIONS

The contractor shall comply with OSHA (Occupational Safety and Health Administration) Parts 1910 and 1926, Construction Industry Standards and Interpretations, and with this supplement.

Requests for variances or waivers from this supplement are to be made to the contracting officer in writing supported by evidence that every reasonable effort has been made to comply with the contractual requirements. A written request for a waiver or a variance shall include--

(1) Specific reference to the provision or standard in question;

(2) An explanation as to why the waiver is considered justified; and

(3) The contractor's proposed alternative, including technical drawings, materials, or equipment specifications needed to enable the contracting officer to render a decision.

No waiver or variance will be approved if it endangers any person. The contractor shall not proceed under any requested revision of a provision until the contracting officer has given written approval.

The contractor is to hold and save harmless the Natural Resources Conservation Service free from any claims or causes of action whatsoever resulting from the contractor or subcontractors proceeding under a waiver or approved variance. Copies of OSHA Part 1910 and 1926, Construction Industry Standards and Interpretations, may be obtained from:

Superintendent of Documents U. S. Government Printing Office Washington, D.C. 20402

GENERAL CONTRACTOR REQUIREMENTS

1.1 SAFETY PROGRAM. Each contractor is to demonstrate that he or she has the facilities for conducting a safety program commensurate with the work under the contract. The contractor is to submit a written safety program to the contracting officer for approval before the start of construction operations. The program is to specifically state what provisions the contractor proposes to take for the health and safety of all employees.

1.2 PRECONSTRUCTION SAFETY MEETING. Representatives for the contractor are to meet with the contracting officer (CO) or the CO's representative before the start of construction to discuss the safety program and the implementation of all health and safety standards pertinent to the work under this contract.

1.3 JOINT SAFETY POLICY COMMITTEE. The contractor or designated onsite representative is to participate in monthly meetings of a Joint Safety Committee, composed of Natural Resources Conservation Service and contractor supervisory personnel. At these meetings the contractor's project manager and the Contracting Officer will review the effectiveness of the contractor's safety effort, resolve current health and safety problems, and coordinate safety activities for upcoming work.

1.4 SAFETY PERSONNEL. Each contractor is to designate a competent supervisory employee satisfactory to the Contracting officer to administer the safety program.

1.5 SAFETY MEETINGS. A minimum of one "one-the-job" or "toolbox" safety meeting is to be conducted each week by all field supervisors for all construction personnel at the job site. The contractor is to also conduct regularly scheduled supervisory safety meetings at least monthly for all levels of job supervision.

AG-7335-S-15-0010 Page 14 of 35

1.6 SAFETY INSPECTION. The contractor shall perform frequent and regular safety inspections of the jobsite, materials, and equipment, and shall correct deficiencies.

1.7 FIRST AID TRAINING. Every contractor foreman's work crew must include an employee who has a current first aid certificate from the Mine Safety and Health Administration, American Red Cross, or other state-approved organization.

1.8 REPORTS. Each contractor is to maintain an accurate record of all job related deaths, diseases, or disabling injuries. The records shall be maintained in a manner approved by the contracting officer. A copy of all reports is to be provided to the contracting officer. All fatal or serious injuries are to be reported immediately to the contracting officer, and every assistance is to given to the investigation of the incident, including submission of a comprehensive narrative report to the contracting officer. Other occurrences with serious accident potential, such as equipment failures, slides and cave-ins, must also be reported immediately. The contractor is to assist and cooperate fully with the contracting officer in conducting accident investigations. The contracting officer is to be furnished all information and data pertinent to investigation of the accident.

FIRST-AID AND MEDICAL FACILITIES

2.1 FIRST AID KITS. A 16-unit first aid kit approved by the American Red Cross is to be provided at accessible, well identified, locations at the ratio of at least 1 kit for each 25 employees. The first aid kits are to be moisture proof and dust tight, and the contents of the kits are to be replenished as used or as they become ineffective or outdated.

2.2 EMERGENCY FIRST AID. At least one employee certified to administer emergency first aid must be available on each shift and duly designated by the contractor to care for injured employees. The names of the certified employees shall be posted at the job site.

2.3 COMMUNICATION AND TRANSPORTATION. Prior to the start to work, the contractor is to make necessary arrangements for prompt and dependable communications, transportation, and medical care for injured employees. At least one stretcher and two blankets shall be readily available for transporting injured employees.

2.4 FIRST AID AND MEDICAL REPORTS. The contractor is to maintain a record system for first aid and medical treatment on the jobsite. Such records are to be readily available to the contracting officer and are to include:

(a) A daily treatment log listing chronologically all persons treated for occupational injuries and illnesses;

(b) Cumulative record of injury for each individual;

(c) Monthly statistical records of occupational injuries, classified by type and nature of injury; and

(d) Required records for worker's compensation.

2.5 SIGNS AND DIRECTIONAL MARKINGS. Adequate identification and directional markers are to be provided to readily denote the location of all first aid stations.

2.6 EMERGENCY LISTING. A listing of telephone numbers and addresses of doctor, rescue squad, hospital, police, and fire departments is to be provided at all first aid locations.

AG-7335-S-15-0010 Page 15 of 35

PHYSICAL QUALIFICATION OF EMPLOYEES

3.1 GENERAL REQUIREMENTS. Persons employed throughout the contract are to be physically qualified to perform their assigned duties.

Employees must not knowingly be permitted or required to work while their ability or alertness is impaired by fatigue, illness, or other reason that may jeopardize themselves or others.

3.2 HOIST OPERATORS. Operators of cranes, cableways, and other, hoisting equipment shall be examined annually by a physician and provided with a certification stating that they are physically qualified to safely operate hoisting equipment. The contractor is to submit a copy of each certification to the contracting officer.

3.3 MOTOR VEHICLE OPERATORS. Operators of motor vehicles engaged primarily in the transportation of personnel are to be 18 years of age or older and have a valid state operator's permit or license for the equipment being operated. The operators must have passed a physical examination administered by a licensed physician within the part year showing that they are physically qualified to operate vehicles safely.

PERSONAL PROTECTIVE EQUIPMENT

4.1 HARDHAT AREAS. The entire jobsite, with the exception of offices, will be considered a hardhat area.

All persons entering the area are, without exception, required to wear hardhats. The contractor shall provide hardhats to visitors entering hardhat areas.

4.1.1 LABELS. Hardhats shall bear a manufacturer's label indicating design compliance with the appropriate ANSI (American National Standards Institute) standard.

4.2 POSTING. Signs at least 3 by 4 feet worded as follows with red letters (minimum 6 inches high) with white background shall be erected at access points to designated hardhat areas:

CONSTRUCTION AREA -- HARDHATS REQUIRED BEYOND THIS POINT

These signs are to be furnished and installed by the contractor at entries to shops, construction yards, and job access points.

MACHINERY AND MECHANIZED EQUIPMENT

5.1 SAFE CONDITION. Before any machinery or mechanized equipment is initially used on the job, it must be inspected and tested by qualified personnel and determined to be in safe operating condition and appropriate for the intended use. Operators shall inspect their equipment prior to the beginning of each shift.

Any deficiencies or defects shall be corrected prior to using the equipment. Safety equipment, such as seatbelts, installed on machinery is to be used by equipment operators.

5.2 TAGGING AND LOCKING. The controls of power-driven equipment under repair are to be locked.

An effective lockout and tagging procedure is to be established, prescribing specific responsibility and safety procedures to be followed by the persons performing repair work.

5.3 HAUL ROAD FOR EQUIPMENT

5.3.1 ROAD MAINTENANCE. The contractor shall maintain all roadways, including haul roads and access roads, in a safe condition so as to eliminate or control dust and ice hazards. Wherever dust is a hazard adequate dust-laying equipment shall be available at the jobsite and utilized to control dust.

AG-7335-S-15-0010 Page 16 of 35

5.3.2 SINGLE LANE HAUL ROADS. Single-lane haul roads with two-way traffic shall have adequate turnouts. Where turnouts are not practical, a traffic control system shall be provided to prevent accidents.

5.3.3 TWO-WAY HAUL ROADS. On two-way haul roads, arrangements are to be such that vehicles travel on the right side wherever possible. Signs and traffic control devices are to be employed to indicate clearly any variations from a right-hand traffic pattern. The road shall be wide enough to permit safe passage of opposing traffic, considering the type of hauling equipment used.

5.3.4 DESIGN AND CONSTRUCTION OF HAUL ROADS. Haul road design criteria and drawings, if requested by the contracting officer, are to be submitted for approval prior to road construction. Sustained grades shall not exceed 12 percent and all curves shall have open-sight line with as great a radius as practical.

All roads shall be posted with curve signs and maximum speed limits that will permit the equipment to be stopped within one-half the minimum sight distance.

5.3.5 OPERATORS. Machinery and mechanized equipment shall be operated only by authorized qualified persons.

5.3.6 RIDING ON EQUIPMENT. Riding on equipment by unauthorized personnel is prohibited. Seating and safety belts shall be provided for the operator and all passengers.

5.3.7 GETTING ON OR OFF EQUIPMENT. Getting on or off equipment while the equipment is in motion is prohibited.

5.3.8 HOURS OF OPERATION. Except in emergencies, an equipment operator shall not operate any mobile or hoisting equipment for more than 12 hours without an 8-hour rest interval away from the job.

5.4 POWER CRANES AND HOISTS (TRUCK CRANES, CRAWLER CRANES, TOWER CRANES,

GANTRY CRANES, HAMMERHEAD CRANES, DERRICKS, CABLEWAYS, AND HOISTS)

5.4.1 PERFORMANCE TEST. Before initial onsite operation, at 12-month intervals, and after major repairs or modification, power cranes, derricks, cableways, and hoists must satisfactorily complete a performance test to demonstrate the equipment's ability to safety handle and maneuver the rated loads. The tests shall be conducted in the presence of a representative of the contracting officer. Test data shall be recorded and a copy furnished the contracting officer.

5.4.2. PERFORMANCE TEST--POWER CRANES (Crawler mounted, truck mounted, and wheel mounted).

The performance test is to be carried out with outriggers set and with a test load weighing 110 percent of the rated load. In testing cableways the test load is to be traveled to the upstream and downstream limits of travel and thoroughly performance tested in at least three travel positions, including both limits of travel.

5.4.3. PERFORMANCE TEST--DERRICKS, GANTRY CRANES, TOWER CRANES, CABLEWAYS,

AND HOISTS, INCLUDING OVERHEAD CRANES. This equipment is to be performance tested with a test load weighing 110 percent of the rated load. In testing cableways, the test load is to be traveled to the upstream and downstream limits of travel and thoroughly performance tested in at least three travel positions, including both limits of travel.

5.4.4 BOOM ANGLE INDICTOR. Power cranes (includes draglines) with booms capable of moving in the vertical plane shall be provided with a boom angle indicator in good working order.

5.4.5 CRANE TEST CERTIFICATION. The performance test required by 5.4.2 and 5.4.3 is fulfilled if the contractor provides the contracting officer a copy of the certificate of inspection made within the past 12 months by a qualified person or by a government or private agency satisfactory to the contracting officer.

AG-7335-S-15-0010 Page 17 of 35

5.4.6 POSTING FOR HIGH VOLTAGE LINES. A notice of the 10- foot (or greater) clearance required by OSHA 1926.550, Subpart N, shall be posted in the operator's cab of cranes, shovels, boom-type concrete pumps, backhoes and related equipment.

5.4.7 BOOM STOPS. Cranes or derricks with cable-supported booms, except draglines, shall have a device attached between the gantry of the A-frame and the boom chords to limit the elevation of the boom. The device shall control the vertical motions of the boom with increasing resistance from 83 or less, until completely stopping the boom at not over 87 above horizontal.

5.4.8 SAFETY HOOKS. Hooks used in hoisting personnel or hoisting loads over construction personnel or in the immediate vicinity of construction personnel shall be forged steel equipped with safety keepers. When shackles are used under these conditions, they shall be of the locking type or have the pin secured to prohibit turning.

5.5 ROLLOVER PROTECTIVE STRUCTURES (ROPS)

5.5.1 ROLLOVER PROTECTIVE STRUCTURES. OSHA 1926 Subpart W Overhead Protection Sections 1000 and 1002 are applicable regardless of the year in which the equipment was manufactured and regardless of the struck capacity of the equipment.

5.5.2 EQUIPMENT REQUIRING ROPS. The requirement for ROPS meeting 5.5.1 above applies to crawler and rubber-tired tractors such as dozers, push and pull tractors, winch tractors with backhoes, and mowers;

off-highway, self-propelled, pneumatic-tired earthmovers, including cabs). These requirements shall also apply to agricultural and industrial tractors and similar equipment.

5.5.3 EQUIPMENT REQUIRING SEATBELTS. The requirements for seatbelts as specified in OSHA Subpart 0, Motor Vehicles, Mechanized Equipment, and Marine Operations, Section 1926.602 shall also apply to self-propelled compactors and rollers, and rubber-tired skid-steer equipment.

5.6 LADDERS AND SCAFFOLDING.

5.6.1 LADDERS. OSHA 1926, Subpart L - Section 450. Ladders shall be used as work platforms only when use of small hand tools or handling of light material is involved. No work requiring lifting of heavy materials or substantial exertion shall be done from ladders.

5.6.2 SCAFFOLDING. OSHA 1926, Subpart L - Section 451. Scaffolds, platforms or temporary floors shall be provided for all work except that which can be done safely from the ground or similar footing.

5.6.3 SAFETY BELTS, LIFELINE, AND LANDYARDS. OSHA 1926, Subpart E, Section 104. Lifelines, safety belts and lanyards independently attached or attended, shall be used when performing such work as the following when the requirements of 5.6.1 and 5.6.2 above cannot be met.

a. Work on stored material in hoppers, bins, silos, tanks or other confined spaces.

b. Work on hazardous slopes, structural steel, or poles; erection or dismantling of safety nets, typing reinforcing bars; and work from or other unguarded locations at elevations greater than 6 feet.

c. Work on skids and platforms used in shafts by crews when the skip or cage does not block the opening to within 1 foot of the sides of the shaft, unless cages are provided.

AG-7335-S-15-0010 Page 18 of 35

H.3 52.252-4 ALTERATIONS IN CONTRACT (APR 1984)

Portions of this contract are altered as follows: 52.236-13 Accident Prevention is altered to include the NRCS supplement to OSHA Parts 1910 and 1926, Construction Standards and Interpretations.

H.4 AGAR 452.236-73 ARCHAEOLOGICAL OR HISTORIC SITES (FEB 1988)

If a previously unidentified archaeological or historic site(s) is encountered, the Contractor shall discontinue work in the general area of the site(s) and notify the Contracting Officer immediately.

H.5 AGAR 452.236-74 CONTROL OF EROSION, SEDIMENTATION, AND POLLUTION (NOV

1996)

(a) Operations shall be scheduled and conducted to minimize erosion of soils and to prevent silting and muddying of streams, rivers, irrigation systems, and impoundments (lakes, reservoirs, etc.).

(b) Pollutants such as fuels, lubricants, bitumens, raw sewage, and other harmful materials shall not be discharged on the ground; into or nearby rivers, streams, or impoundments; or into natural or man-made channels. Wash water or waste from concrete or aggregate operations shall not be allowed to enter live streams prior to treatment by filtration, settling, or other means sufficient to reduce the sediment content to not more than that of the stream into which it is discharged.

(c) Mechanized equipment shall not be operated in flowing streams without written approval by the Contracting Officer.

H.6 AGAR 452.236-76 SAMPLES AND CERTIFICATES (FEB 1988)

When required by the specifications or the Contracting Officer, samples, certificates, and test data shall be submitted after award of the contract, prepaid, in time for proper action by the Contracting Officer or his/her designated representative. Certificates and test data shall be submitted in triplicate to show compliance of materials and construction specified in the contract performance requirements.

Samples shall be submitted in duplicate by the Contractor, except as otherwise specified, to show compliance with the contract requirements. Materials or equipment for which samples, certifications or test data are required shall not be used in the work until approved in writing by the Contracting Officer.

AG-7335-S-15-0010 Page 19 of 35

PART II - CONTRACT CLAUSES

SECTION I - CONTRACT CLAUSES

I.1 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

I. FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) AND

AGRICULTURAL ACQUISITION REGULATION (48 CFR CHAPTER 4 PARTS 401-453)

CLAUSES

52.204-10

***REPORTING EXECUTIVE COMPENSATION AND

FIRST-TIER SUBCONTRACT AWARDS JUL 2014

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE JUL 2013

52.204-18 COMMERCIAL AND GOVERNMENT ENTTITY CODE

MAINTENANCE NOV 2014

52.209-6 ****PROTECTING THE GOVERNMENT'S INTEREST WHEN

SUBCONTRACTING WITH CONTRACTORS DEBARRED,

SUSPENDED, OR PROPOSED FOR DEBARMENT AUG 2013

52.213-4 TERMS AND CONDITIONS – SIMPLIFIED ACQUISITION

PROCEDURES (OTHER THAN COMMERCIAL) DEC 2014

52.215-8 ORDER OF PRECEDENCE – UNIFORM CONTRACT FORMAT OCT 1997

52.219-6 NOTICE OF TOTAL SMALL BUSINESS SET-ASIDE NOV 2011

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM

REPRESENTATION JUL 2013

52.222-1 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES FEB 1997

52.222-3 CONVICT LABOR JUN 2003

52.222-6 CONSTRUCTION WAGE RATE REQUIREMENTS MAY 2014

52.222-7 WITHHOLDING OF FUNDS MAY 2014

52.222-8 PAYROLLS AND BASIC RECORDS MAY 2014

52.222-9 APPRENTICES AND TRAINEES JUL 2005

52.222-10 COMPLIANCE WITH COPELAND ACT REQUIREMENTS FEB 1988

52.222-11 SUBCONTRACTS (LABOR STANDARDS) MAY 2014

52.222-12 CONTRACT TERMINATION - DEBARMENT MAY 2014

52.222-13 COMPLIANCE WITH CONSTRUCTION WAGE RATE

REQUIREMENTS AND RELATED REGULATIONS MAY 2014

52.222-14 DISPUTES CONCERNING LABOR STANDARDS FEB 1988

52.222-15 CERTIFICATION OF ELIGIBILITY MAY 2014

52.222-21 * PROHIBITION OF SEGREGATED FACILITIES FEB 1999

52.222-26 * EQUAL OPPORTUNITY MAR 2007

AG-7335-S-15-0010 Page 20 of 35

52.222-27 *AFFIRMATIVE ACTION COMPLIANCE

REQUIREMENTS FOR CONSTRUCTION FEB 1999

52.222-35 *****EQUAL OPPORTUNITY FOR VETERANS JUL 2014

52.222-36 **EQUAL OPPORTUNITY FOR WORKERS WITH

DISABILITIES JUL 2014

52.222-37 EMPLOYMENT REPORTS ON VETERANS JUL 2014

52.222-50 COMPATING TRAFFICKING IN PERSONS FEB 2009

52.222-55 MINIMUM WAGES UNDER EXECUTIVE ORDER 13658 DEC 2014

52.223-2 AFFIRMATIVE PROCUREMENT OF BIOBASED PRODUCTS

UNDER SERVICE AND CONSTRUCTION CONTRACTS SEP 2013

52.223-3 HAZARDOUS MATERIAL IDENTIFICATION AND

MATERIAL SAFETY DATA

-ALTERNATE 1

JAN 1997

JUL 1995

52.223-6 DRUG FREE WORKPLACE MAY 2001

52.223-18 ENCOURAGING CONTRACTOR POLICIES TO BAN

TEXT MESSAGING WHILE DRIVING AUG 2011

52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES JUN 2008

52.227-1 AUTHORIZATION AND CONSENT DEC 2007

52.227-2 NOTICE AND ASSISTANCE REGARDING PATENT AND

COPYRIGHT INFRINGEMENT DEC 2007

52.227-4 PATENT INDEMNITY - CONSTRUCTION CONTRACTS DEC 2007

52.228-2 ADDITIONAL BOND SECURITY OCT 1997

52.228-11 PLEDGES OF ASSETS JAN 2012

52.228-12 ****PROSPECTIVE SUBCONTRACTOR REQUESTS FOR

BONDS MAY 2014

52.228-13 **** ALTERNATIVE PAYMENT PROTECTIONS JUL 2000

52.228-14 IRREVOCABLE LETTER OF CREDIT NOV 2014

52.232-5 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION

CONTRACTS MAY 2014

52.232-23 ASSIGNMENT OF CLAIMS MAY 2014

52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS JUL 2013

52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER-

SYSTEM FOR AWARD MANAGEMENT JUL 2013

52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS JUN 2013

52.232-40 PROVIDING ACCURATE PAYMENTS TO SMALL BUSINESS

SUBCONTRACTORS DEC 2013

52.233-1 DISPUTES MAY 2014

52.233-3 PROTEST AFTER AWARD AUG 1996

52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM OCT 2004

52.236-2 DIFFERING SITE CONDITION APR 1984

52.236-3 SITE INVESTIGATIONS AND CONDITIONS AFFECTING THE

WORK APR 1984

52.236-5 MATERIAL AND WORKMANSHIP APR 1984

52.236-7 PERMITS AND RESPONSIBILITIES NOV 1991

52.236-8 OTHER CONTRACTS APR 1984

52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES,

EQUIPMENT, UTILITIES, AND IMPROVEMENTS APR 1984

52.236-10 OPERATIONS AND STORAGE AREAS APR 1984

52.236-11 USE AND POSSESSION PRIOR TO COMPLETION APR 1984

52.236-12 CLEANING UP APR 1984

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS APR 1984

52.236-16 QUANTITY SURVEYS APR 1984

AG-7335-S-15-0010 Page 21 of 35

52.236-17 LAYOUT OF WORK APR 1984

52.236-21 SPECIFICATION AND DRAWINGS FOR CONSTRUCTION FEB 1997

52.243-5 CHANGES AND CHANGED CONDITIONS APR 1984

52.244-6 SUBCONTRACTS FOR COMMERCIAL ITEMS OCT 2014

52.249-1 TERMINATION FOR CONVENIENCE OF THE

GOVERNMENT (FIXED-PRICE) (SHORT FORM) APR 1984

52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) APR 1984

52.253-1 COMPUTER GENERATED FORMS JAN 1991

* Applies over $10,000 ** Applies over $15,000 *** Applies over $25,000 **** Applies over $30,000 ***** Applies over $100,000

I.2 52.222-99 ESTABLISHING A MINIMUM WAGE FOR CONTRACTORS (DEVIATION 2014-001)

(OCT 2014)

This clause implements Executive Order 13658, Establishing a Minimum Wage for Contractors, dated February 12, 2014 and OMB Policy Memorandum M-14-09, Implementation of the President’s Executive Order Establishing a Minimum Wage for Contractors, dated June 12, 2014.

(a) Each service employee, laborer, or mechanic employed in the United States (the 50 states and the District of Columbia) in the performance of this contract by the prime contractor or any subcontractor, regardless of any contractual relationship which may be alleged to exist between the Contractor and service employee, laborer, or mechanic, shall be paid not less than the applicable minimum wage under Executive Order 13658. The minimum wage required to be paid to each service employee, laborer, or mechanic performing work on this contract between January 1, 2015, and December 31, 2015, shall be $10.10 per hour.

(b) The Contractor shall adjust the minimum wage paid under this contract each time the Secretary of Labor’s annual determination of the applicable minimum wage under Section 2(a)(ii) of Executive Order 13658 results in a higher minimum wage. Adjustments to the Executive Order minimum wage under Section 2(a)(ii) of Executive Order 13658 will be effective for all service employees, laborers, or mechanics subject to the Executive Order beginning January 1 of the following year. The Secretary of Labor will publish annual determinations in the Federal Register no later than 90 days before such new wage is to take effect. The Secretary will also publish the minimum wage on www.wdol.gov (or any successor website). The applicable published minimum wage is incorporated by reference in this contract.

(c) The Contracting Officer will adjust the contract price or contract unit price under this clause only for the increase in labor costs resulting from the annual inflation increases in the Executive Order 13658 minimum wage beginning on January 1, 2016. The Contracting Officer shall consider documentation as to the specific costs and workers impacted in determining the amount of the adjustment.

(d) The Contracting Officer will not adjust the contract price under this clause for any costs other than those identified in paragraph (c) of this clause, and will not provide price adjustments under this clause that result in duplicate price adjustments with the respective clause of this contract implementing the Service Contract Labor Standards (formerly known as the Service Contract Act) or the Wage Rate Requirements (Construction) statute (formerly known as the Davis Bacon Act).

(e) The Contractor shall include the substance of this clause, including this paragraph (e) in all subcontracts.

AG-7335-S-15-0010 Page 22 of 35 http://www.wdol.gov/

I.4 52.225-9 BUY AMERICAN ACT--CONSTRUCTION MATERIALS (MAY 2014)

a) Definitions. As used in this clause—

“Commercially available off-the-shelf (COTS) item”—

(1) Means any item of supply (including construction material) that is—

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

“Component” means an article, material, or supply incorporated directly into a construction material.

“Construction material” means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

“Cost of components” means—

(3) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(4) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

“Domestic construction material” means—

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if—

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

“Foreign construction material” means a construction material other than a domestic construction material.

“United States” means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C.