AG-4670-S-15-0122_Bristol_Trail_(TR-76)_Bridge_Replacement.doc

PAGE

OMB APPROVAL NO. 2700-0042

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

AG-4670-S-15-0122

2. TYPE OF SOLICITATION

FORMCHECKBOX

SEALED BID (IFB)

FORMCHECKBOX

NEGOTIATED (RFP)

3. DATE ISSUED

05 Aug 2015

PAGE OF PAGES

IMPORTANT - The “offer” section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

5. REQUISITION/PURCHASE REQUEST NO.

6. PROJECT NO.

7. ISSUED BY

CODE

USDA FOREST SERVICE-EAZ ACQUISITION MANAGEMENT

4931 Broad River Road

Columbia, SC 29212 Same as Block 7

9. FOR INFORMATION

CALL:

A. NAME

Kelly B Updegraff kbupdegraff@fs.fed.us B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

(803) 561-4093 FAX (803) 561-4010 (NOTE: FAXED bids over $150,000 will NOT be accepted)

SOLICITATION

NOTE: In sealed bid solicitations “offer” and “offeror” mean “bid” and “bidder.”

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date):

This solicitation is a 100% SMALL BUSINESS SET ASIDE.

NAICS Code: 237310 Size Standard: $36.5 Million

BRISTOL TRAIL (TR-76) BRIDGE REPLACEMENT – TUSQUITEE RANGER DISTRICT

Price Range: The Government's estimate is between $25,000 and $100,000.

DUNS # ______________ Tax ID# _____________________

NOTE: Offeror must be ACTIVE in the System for Award Management (www.SAM.gov) at the time of award. Those contractors not active in SAM at the time of award will be rejected and not considered for award.

A PRE-BID SITE VISIT IS SCHEDULED ON 19 AUGUST 2015 AT 1000 AM EST. THE PRE-BID SITE VISIT LOCATION IS THE PROJECT SITE.

11. The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 09 SEPT 2015. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer. See FAR 52.211-10, Alternate 1

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If “YES,” indicate within how many calendar days after award in Item 12B.)

FORMCHECKBOX

YES

FORMCHECKBOX

NO

12B. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A.

Sealed offers in original and 1 copies to perform the work required are due at the place specified in Item 8 by 1200 p.m. EST (hour) local time 09 SEPTEMBER 2015. If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror’s name and address, the solicitation number, and the date and time offers are due.

B.

An offer guarantee

FORMCHECKBOX

is, FORMCHECKBOX is not required.

C.

All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D.

Offers providing less than 120 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

NSN 7540-01-155-3212

1442-101

STANDARD FORM 1442 (REV. 4-85)

Computer Generated

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14)

CODE

FACILITY CODE

17.

The offeror agrees to perform the work at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government within calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

20B. SIGNATURE

20C. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT

23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

FORMCHECKBOX

10 U.S.C. 2304(c)( )

FORMCHECKBOX

41 U.S.C. 253(c)( 5)

26. ADMINISTERED BY

CODE

See Block 7

INVOICE PROCESSING PLATFORM - IPP

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

FORMCHECKBOX

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return __1__ copies to issuing office.) Contractor agrees to furnish and deliver all items or perform all work, requisitions identified on this form and any continuation sheets for the consideration slated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications or incorporated by reference in or attached to this contract.

FORMCHECKBOX

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31A. NAME OF CONTRACTING OFFICER (Type or print)

KELLY B. UPDEGRAFF

30B. SIGNATURE

30C. DATE

31B. UNITED STATES OF AMERICA

BY

31C. AWARD DATE

Computer Generated

STANDARD FORM 1442 BACK (REV. 4-85)

TABLE OF CONTENTS

SECTION B - SUPPLIES OR SERVICES AND PRICES/COSTS

SECTION C - DESCRIPTION/SPECIFICATIONS/STATEMENT OF WORK

SECTION D - PACKAGING AND MARKINGS

SECTION E - INSPECTION AND ACCEPTANCE

SECTION F - DELIVERIES OR PERFORMANCE

SECTION G - CONTRACT ADMINISTRATION DATA

SECTION H - SPECIAL CONTRACT REQUIREMENTS

SECTION I - CONTRACT CLAUSES

SECTION J - LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

SECTION B - SUPPLIES OR SERVICES AND PRICES/COSTS

Contractor shall furnish all labor, equipment, materials, tools, transportation, supplies (including safety), and supervision necessary to complete this construction project in compliance with the terms, specifications, drawings, conditions, and provisions of this solicitation. Any work shown on drawings or in specifications that is not included in scheduled items is incidental to other items.

MAGNITUDE OF THIS PROJECT IS BETWEEN $25,000 and $100,000.

Payment Bond Is Required.

CONTRACTORS MUST SUBMIT THE FOLLOWING DOCUMENTS:

1) SF 1442 – PAGES 1-2

2) CONTRACTOR INFORMATION – PAGE 4

3) SECTION K

a. Contractors NOT currently ACTIVE in www.sam.gov: ALL of Section K (pages 19-27)

b. Contractors currently active in www.sam.gov: AGAR 452.209-70 only (pages 26-27)

4) ATTACHMENT 1: SCHEDULE OF ITEMS

5) ATTACHMENT 5: EXPERIENCE QUESTIONNAIRE

6) AMENDMENTS (AS APPLICABLE)

ALL TECHNICAL QUESTIONS MUST TO BE SUBMITTED IN WRITING TO MR. KELLY UPDEGRAFF VIA FAX (803) 561-4010 OR EMAIL AT KBUPDEGRAFF@FS.FED.US

CONTRACTOR INFORMATION

REGISTERED IN THE SYSTEM FOR AWARD MANAGEMENT (SAM)? (To be awarded this contract, contractor MUST be registered and active in SAM prior to award as prescribed in FAR 52.204-7). _______ YES _______ NO

COMPANY NAME: ________________________________________

TAX ID# _________________________________________________

DUNS# __________________________________________________

POINT OF CONTACT ______________________________________

EMAIL ADDRESS _________________________________________

PHONE # ___ _____________________________________________

FAX # ___ ________________________________________________

SECTION C STATEMENT OF WORK

SCOPE OF CONTRACT – Contractor shall furnish all labor, equipment, materials, tools, transportation, supplies (including safety), and supervision necessary to complete this construction project in accordance with the Specifications and Drawings identified in Section J.

Biobased Products

The Contractor must comply with the Agricultural Act of 2014; the Food, Conservation and Energy Act of 2008 (FCEA), 7 U.S.C. 8102; the Farm Security and Rural Investment Act of 2002 (FSRIA), 7 U.S.C. 8102; the Federal Acquisition Regulation; Executive Order (EO) 13514, “Federal Leadership in Environmental, Energy and Economic Performance,” dated October 5, 2009; EO 13423, “Strengthening Federal Environmental, Energy, and Transportation Management,” dated January 24, 2007; and Presidential Memorandum, “Driving Innovation and Creating Jobs in Rural America through Biobased and Sustainable Product Procurement,” dated February, 2012 to provide biobased products.

All supplies and materials shall be of a type and quantity that conform to applicable Federal specifications and standards, and to the extent feasible and reasonable; include the exclusive use of biobased and recycled products.

The following is a list of categories for biopreferred products that are required for performance of this service contract.

Equipment Lubricants, Hydraulic Fluids, Fuel Additives, Engine Oils, Office Products (Ink, paper, cleaning products) For more information regarding the Department of Agriculture Biobased Program go to: http://www.biopreferred.gov

AGRICULTURE ACQUISITION REGULATIONS (48 CFR CHAPTER 4) CLAUSES

452.211-72 STATEMENT OF WORK/SPECIFICATIONS. (FEB 1988)

452.211-73 ATTACHMENTS TO STATEMENTS OF WORK/SPECIFICATIONS. (FEB 1988)

SECTION D—PACKAGING AND MARKING

{For this Solicitation, there are NO clauses in this Section}

SECTION E—INSPECTION AND ACCEPTANCE

FAR 52.252-2 Clauses Incorporated by Reference (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): https://www.acquisition.gov/far/index.html www.usda.gov/procurement/policy/agar.html

FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES

52.246-12 Inspection of Construction (AUG 1996)

SECTION F—DELIVERIES OR PERFORMANCE

FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES

FAR 52.252-2 Clauses Incorporated by Reference (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): https://www.acquisition.gov/far/index.html

FAR 52.242-14

Suspension of Work (APR 1984)

52.211-10 Commencement, Prosecution, and Completion of Work.

As prescribed in 11.404(b), insert the following clause in solicitations and contracts when a fixed-price construction contract is contemplated. The clause may be changed to accommodate the issuance of orders under indefinite-delivery contracts for construction.

Commencement, Prosecution, and Completion of Work (Apr 1984)

The Contractor shall be required to (a) commence work under this contract within __10____ [Contracting Officer insert number] calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than _120___.* The time stated for completion shall include final cleanup of the premises.

(End of clause)

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

Alternate I (Apr 1984). If the completion date is expressed as a specific calendar date, computed on the basis of the contractor receiving the notice to proceed by a certain day, add the following paragraph to the basic clause:

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by _9 September 2015__ [Contracting Officer insert date]. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

SECTION G—CONTRACT ADMINISTRATION DATA

Contractor is required to submit as an attachment in IPP for their invoice a cost breakdown for the invoice being submitted.

Contract is required to forward Payrolls, via email, to the COR prior to submission of the invoice in IPP.

Contractor is required to forward daily diaries for each day worked on the project to the COR with the payrolls.

INVOICING: All Invoices must be submitted through the Department of Treasury's Invoice Processing Platform (IPP). The contractor must follow the instructions on how to register and submit invoices via IPP as prescribed in the previous communications from USDA and Treasury. All invoices are to be submitted via the electronic Invoice Processing Platform. This is a mandatory requirement initiated by the U.S. Department of Treasury and you can find more information at this website https://www.ipp.gov/index.htm Please make sure that your company has registered at https://www.ipp.gov/vendors/enrollment-vendors.htm to establish your account.

AGAR 452.215-73 Post Award Conference (NOV 1996) A post award conference with the successful offeror is required. It will be scheduled and held within 30 calendar days after the date of contract award. The conference will be held at a location designated by the Contracting Officer.

SECTION H—SPECIAL CONTRACT REQUIREMENTS

AGAR 452.209-71, Alternate 1 Contract Clause (FEB 2012)

ASSURANCE REGARDING FELONY CONVICTION OR TAX DELINQUENT STATUS FOR CORPORATE APPLICANTS

(a) This award is subject to the provisions contained in the Consolidated Appropriations Act, 2012 (P.L. No. 112-74), Division E, Section 433 and 434 regarding corporate felony convictions and corporate federal tax delinquencies. Accordingly, by accepting this award the contractor acknowledges that it –

(1) Does not have a tax delinquency, meaning that it is not subject to any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, and

(2) Has not been convicted (or had an officer or agent acting on its behalf convicted) of a felony criminal violation under any Federal law within 24 months preceding the award, unless a suspending and debarring official of the United States Department of Agriculture has considered suspension or debarment of the awardee, or such officer or agent, based on these convictions and/or tax delinquencies and determined that suspension or debarment is not necessary to protect the interests of the Government.

(b) If the awardee fails to comply with these provisions, the Forest Service may terminate this contract for default and may recover any funds the awardee has received in violation of sections 433 or 434.

SECTION I—CONTRACT CLAUSES

FAR 52.252-2 Clauses Incorporated by Reference (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov/far/index.html www.usda.gov/procurement/policy/agar.html

FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES

52.202-1 Definitions (NOV 2013)

52.203-3 Gratuities (APR 1984)

52.203-5 Covenant Against Contingent Fees (MAY 2014)

52.203-7 Anti-Kickback Procedures (MAY 2014)

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity (MAY 2014)

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity (MAY 2014)

52.203-13 Contractor Code of Business Ethics and Conduct (APR 2010)

52.203-14 Display of Hotline Poster(s) (DEC 2007)

52.203-16 Preventing Personal Conflicts of Interest (DEC 2011)

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights (APR 2014)

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper (MAY 2011)

52.204-9 Personal Identity Verification of Contractor Personnel (JAN 2011)

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards (JUL 2013)

52.204-12 Data Universal Numbering System Number Maintenance (DEC 2012)

52.204-13 System For Award Management Maintenance (JUL 2013) 52.209-6 Protecting The Government's Interest When Subcontracting With Contractors Debarred, Suspended, Or Proposed For Debarment. (AUG 2013)

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters (JUL 2013)

52.211-10 Commencement, Prosecution, and Completion of Work (APR 1984) and Alternative 1 (APR 1984) 52.211-13 Time Extensions (SEP 2000)

52.211-18 Variation in Estimated Quantity (APR 1984) 52.214-18 Preparation of Bids – Construction (APR 1984) 52.215-2 Audit and Records-Negotiation (OCT 2010), Alternate 1 (MAR 2009), and Alternate 3 (JUN 1999)

52.215-8 Order of Precedence-Uniform Contract Format (OCT 1997)

52.215-14 Integrity of Unit Prices (OCT 2010)

52.215-19 Notification of Ownership Changes (OCT 1997)

52.219-6 Notice of Total Small Business Set-Aside (NOV 2011)

52.219-28 Post-Award Small Business Representation (JUL 2013) 52.222-3 Convict Labor (JUN 2003)

52.222-4 Contract Work Hours and Safety Standards Act – Overtime Compensation (MAY 2014)

52.222-6 Construction Wage Rate Requirements (MAY 2014) 52.222-7 Withholding of Funds (MAY 2014)

52.222-8 Payrolls and Basic Records (MAY 2014)

52.222-9 Apprentices and Trainees (JUL 2005)

52.222-10 Compliance with Copeland Act Requirements (FEB 1988)

52.222-11 Subcontracts (Labor Standards) (MAY 2014) 52.222-12 Contract Termination - Debarment (MAY 2014)

52.222-13 Compliance with Construction Wage Rate Requirements and Related Act Regulations (MAY 2014)

52.222-14 Disputes Concerning Labor Standards (FEB 1988)

52.222-15 Certification of Eligibility (MAY 2014)

52.222-21 Prohibition of Segregated Facilities (FEB 1999) 52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction (FEB 1999) 52.222-26 Equal Opportunity (MAR 2007) (Applicable if contract exceeds $10,000)

52.222-27 Affirmative Action Compliance Requirements for Construction (FEB 1999) (Applicable if contract exceeds $10,000) 52.222-30 Construction Wage Rate Requirements – Price Adjustment (None or Separately Specified Method) (MAY 2014) 52.222-31 Construction Wage Rate Requirements – Price Adjustment (Percentage Method) (MAY 2014)

52.222-32 Construction Wage Rate Requirements – Price Adjustment (Actual Method) (MAY 2014)

52.222-33 Notice of Requirement for Project Labor Agreement (MAY 2010)

52.222-36 Affirmative Action For Workers With Disabilities. (JUL 2014) 52.222-36 Equal Opportunity for Workers with Disabilities (JUL 2014) 52.222-50 Combating Trafficking in Persons (MAR 2015)

52.222-54 Employment Eligibility Verification (AUG 2013)

52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts (SEP 2013) 52.223-3 Hazardous Material Identification and Material Safety Data (JAN 1997) 52.223-5 Pollution Prevention and Right-to-Know Information (MAY 2011)

52.223-6 Drug-Free Workplace (MAY 2001) (Applicable if contract is awarded to an individual) 52.223-17 Affirmative Procurement of EPA-designated items in Service and Construction Contracts (MAY 2008)

52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving (AUG 2011)

52.223-19 Compliance with Environmental Management Systems (MAY 2011) 52.224-1 Privacy Act Notification (APR 1984)

52.224-2 Privacy Act (APR 1984)

52.225-9 Buy American Act - Construction Materials. (MAY 2014) 52.225-13 Restrictions on Certain Foreign Purchases (JUN 2008)

52.226-4 Notice of Disaster or Emergency Area Set-Aside (NOV 2007)

52.226-5 Restrictions on Subcontracting Outside Disaster or Emergency Area (NOV 2007)

52.227-1 Authorization and Consent (DEC 2007)

52.227-4 Patent Indemnity – Construction Contracts (DEC 2007)

52-227-5 Waiver of Indemnity (APR 1984)

52.228-11 Pledges of Assets (JAN 2012) 52.228-12 Prospective Subcontractor Requests For Bonds. (MAY 2014) 52.228-14 Irrevocable Letter Of Credit (NOV 2014) 52.228-15 Performance And Payment Bonds—Construction. (OCT 2010) 52.229-2 North Carolina State and Local Sales and Use Tax (APR 1984)

52.229-3 Federal, State, and Local Taxes (FEB 2013) 52.232-5 Payments Under Fixed-Price Construction Contracts (MAY 2014)

52.232-16 Progress Payments (APR 2012)

52.232-17 Interest (MAY 2014)

52.232-18 Availability of Funds (APR 1984) 52.232-23 Assignment of Claims (MAY 2014) 52.232-27 Prompt Payment for Construction Contracts (MAY 2014)

52.232-33 Payment by Electronic Funds Transfer – System For Award Management (JUL 2013) 52.232-39 Unenforceability of Unauthorized Obligations (JUN 2013)

52.232-40 Providing Accelerated Payments to Small Business Subcontractors (DEC 2013)

52.233-1 Disputes (MAY 2014)

52.233-3 Protest After Award (AUG 1996)

52.233-4 Applicable Law for Breach of Contract Claim (OCT 2004) 52.236-2 Differing Site Conditions (APR 1984)

52.236-3 Site Investigation and Conditions Affecting the Work (APR 1984)

52.236-5 Material and Workmanship (APR 1984)

52.236-6 Superintendence by the Contractor (APR 1984)

52.236-7 Permits and Responsibilities (NOV 1991)

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

(APR 1984)

52.236-10 Operations and Storage Areas (APR 1984)

52.236-11 Use and Possession Prior to Completion (APR 1984)

52.236-12 Cleaning Up (APR 1984)

52.236-13 Accident Prevention (NOV 1991)

52.236-14 Availability And Use Of Utility Services (APR 1984)

52.236-15 Schedules for Construction Contracts (APR 1984)

52.236-16 Quality Surveys (APR 1984)

52.236-17 Layout of Work (APR 1984)

52.236-21 Specifications and Drawings for Construction (FEB 1997)

52.236-26 Preconstruction Conference (FEB 1995)

52.242-13 Bankruptcy (JUL 1995)

52.242-14 Suspension of Work (APR 1984)

52.243-4 Changes (JUN 2007)

52.243-5 Changes and Changed Conditions (APR 1984)

52.243-7 Notification of Changes (APR 1984)

52.244-2 Subcontractors (OCT 2010)

52.244-6 Subcontracts for Commercial Items (MAR 2015)

52.246-12 Inspection of Construction (AUG 1996)

52.246-21 Warranty of Construction (MAR 1994) Alternate I (APR 1984)

52.249-2 Termination for Convenience of the Government (Fixed-Price) (APR 2012) Alternate 1 (SEP 1996), and Alternate 3 (SEP 1996)

52.249-10 Default (Fixed-Price Construction) (APR 1984) 52.253-1 Computer Generated Forms (JAN 1991)

AGRICULTURE ACQUISITION REGULATION (48 CFR CHAPTER 4) CLAUSES

452.236-71 Prohibition Against the Use of Lead-Paint (NOV 1996)

452.236-72 Use of Premises (NOV 1996)

452.236-73 Archeological or Historic Sites (FEB 1988)

452.236-74 Control of Erosion, Sedimentation and Pollution (NOV 1996)

452.236-76 Samples and Certificates (FEB 1988)

452.236-77 Emergency Response (NOV 1996)

52.225-9 Buy American—Construction Materials.

As prescribed in 25.1102(a), insert the following clause:

Buy American—Construction Materials (May 2014)

(a) Definitions. As used in this clause—

“Commercially available off-the-shelf (COTS) item”—

(1) Means any item of supply (including construction material) that is—

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

“Component” means an article, material, or supply incorporated directly into a construction material.

“Construction material” means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

“Cost of components” means—

(3) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(4) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

“Domestic construction material” means—

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if—

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

“Foreign construction material” means a construction material other than a domestic construction material.

“United States” means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows:

_______NONE_____________________________________

[Contracting Officer to list applicable excepted materials or indicate “none”]

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that—

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute.

(1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including—

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison

Item 1:

Domestic construction material

[List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.]

[Include other applicable supporting information.]

[* Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).]

52.225-10 Notice of Buy American Requirement—Construction Materials.

As prescribed in 25.1102(b)(1), insert the following provision:

Notice of Buy American Requirement—Construction Materials (May 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American—Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers.

(1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested—

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

(End of provision)

Alternate I (May 2014). As prescribed in 25.1102(b)(2), substitute the following paragraph (b) for paragraph (b) of the basic provision:

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute shall submit the request with its offer, including the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9.

SECTION J—LIST OF ATTACHMENTS

ATTACHMENT NUMBER AND NAME

# OF PAGES IN ATCH

Attachment 1 Schedule of Items

1 Page

Attachment 2 Bristol Maps and Plans 3 Pages Attachment 3 Bristol Specifications

84 Pages Attachment 4 DOL Wage Determination

5 Pages

Attachment 5 Experience Questionaire

4 Pages

SECTION K—REPRESENTATIONS, CERTIFICATIONS, AND

OTHER STATEMENTS OF OFFERORS OR RESPONDENTS

52.222-38 Compliance with Veterans’ Employment Reporting Requirements (SEP 2010)

NOTE: Offerors should address questions concerning VETS-100 reporting and reporting requirements to the Office of Veterans Employment and Training Services offices at the following address:

U. S. Department of Labor

VETS-100 Reporting

6101 Stevenson Avenue

Alexandria, VA 22304-3540

Telephone: (703) 461-2460

E-mail: VETS100@dyncorp.com Website: www.vets100.cudenver.edu

AGAR 452.219-70 SIZE STANDARD AND NAICS CODE INFORMATION (JANUARY 2005)

The North American Industrial classification System Code(s) and business size standard(s) describing the products and/or services to be acquired under this solicitation are listed below:

Contract line item(s): ALL

· NAICS Code 237310

· Size Standard

$36.5 MILLION

The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

52.203-11 Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions

(SEP 2007)

52.204-6 Data Universal Numbering System Number (JUL 2013)

52.204-7 System for Award Management (JUL 2013)

52.223-1 Biobased Product Certification (MAY 2012)

52.225-25 Prohibitation on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-Representation and Certificates (DEC 2012)

52.236-28 Preparation of Proposals – Construction (OCT 1997)

52.204-8 Annual Representations and Certifications.

As prescribed in 4.1202(a), insert the following provision:

Annual Representations and Certifications (Dec 2014)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is ___237310_______________ [insert NAICS code].

(2) The small business size standard is ___$36.5 M__________ [insert size standard].

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in the System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

□ (i) Paragraph (d) applies.

□ (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(iv) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(v) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations—Representation.

(vi) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(vii) 52.214-14, Place of Performance—Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(viii) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(ix) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(x) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xi) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xii) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xiii) 52.222-38, Compliance with Veterans’ Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xiv) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA–designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xv) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA–designated items.

(xvi) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xvii) 52.225-4, Buy American—Free Trade Agreements—Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $79,507, the provision with its Alternate II applies.

(D) If the acquisition value is $79,507 or more but is less than $100,000, the provision with its Alternate III applies.

(xviii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xix) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan—Certification. This provision applies to all solicitations.

(xx) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-Representation and Certifications. This provision applies to all solicitations.

(xxi) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

__ (i) 52.204-17, Ownership or Control of Offeror.

__ (ii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

__ (iii) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment- Certification.

__ (iv) 52.222-52, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Certification.

__ (v) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA–Designated Products (Alternate I only).

__ (vi) 52.227-6, Royalty Information.

__ (A) Basic.

__(B) Alternate I.

__ (vii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

52.209-5 Certification Regarding Responsibility Matters.

As prescribed in 9.104-7(a), insert the following provision:

Certification Regarding Responsibility Matters (Apr 2010)

(a)(1) The Offeror certifies, to the best of its knowledge and belief, that—

(i) The Offeror and/or any of its Principals—

(A) Are [ ] are not [ ] presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(B) Have [ ] have not [ ], within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) contract or subcontract; violation of Federal or State antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property (if offeror checks “have”, the offeror shall also see 52.209-7, if included in this solicitation);

(C) Are [ ] are not [ ] presently indicted for, or otherwise criminally or civilly charged by a governmental entity with, commission of any of the offenses enumerated in paragraph (a)(1)(i)(B) of this provision;

(D) Have [ ], have not [ ], within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,000 for which the liability remains unsatisfied.

(1) Federal taxes are considered delinquent if both of the following criteria apply:

(i) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(ii) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(2) Examples.

(i) The taxpayer has received a statutory notice of deficiency, under I.R.C. § 6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(ii) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. § 6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(iii) The taxpayer has entered into an installment agreement pursuant to I.R.C. § 6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment.

(iv) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. 362 (the Bankruptcy Code).

(ii) The Offeror has [ ] has not [ ], within a three-year period preceding this offer, had one or more contracts terminated for default by any Federal agency.

(2) “Principal,” for the purposes of this certification, means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

This Certification Concerns a Matter Within the Jurisdiction of an Agency of the United States and the Making of a False, Fictitious, or Fraudulent Certification May Render the Maker Subject to Prosecution Under Section 1001, Title 18, United States Code.

(b) The Offeror shall provide immediate written notice to the Contracting Officer if, at any time prior to contract award, the Offeror learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.

(c) A certification that any of the items in paragraph (a) of this provision exists will not necessarily result in withholding of an award under this solicitation. However, the certification will be considered in connection with a determination of the Offeror’s responsibility. Failure of the Offeror to furnish a certification or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible.

(d) Nothing contained in the foregoing shall be construed to require…