ABL-1981_LANDSCAPE_RFQ.docx

REQUEST FOR QUOTATION

(THIS IS NOT AN ORDER)

Of Pages

1. REQUEST NO.

ABL – 19081

2. DATE ISSUED

06/04/2019

3. REQUISITION/PURCHASE REQUEST NO.

5a. ISSUED BY: U.S. DEPT. OF COMMERCE, NOAA, NMFS, AUKE BAY LABORATORIES

17109 PT LENA LOOP RD, JUNEAU, AK 99801

6. DELIVER BY (Date)

5b. FOR INFORMATION CALL (NO COLLECT CALLS)

7. DELIVERY

HEATHER MAHLE

HEATHER.MAHLE@NOAA.GOV

AREA CODE

NUMBER

789-6021

9. DESTINATION

a. NAME OF CONSIGNEE USDOC/NOAA

AFSC, AUKE BAY LABORATORIES, TSMRI FACILITY

8. TO:

a. NAME

b. COMPANY

b. STREET ADDRESS

17109 PT. LENA LOOP ROAD

c. STREET ADDRESS

c. CITY

JUNEAU

d. CITY

e. STATE

AK

e. ZIP CODE 99801

10. PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE IN BLOCK 5a ON OR BEFORE 11:00AM, ALASKA TIME:

06/19/2019 IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State and local Taxes)

ITEM NO.

(a)

SUPPLIES/SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e)

AMOUNT

(f)

Base Period: 20 weeks of service June 2019 through October 2019.

Option 01: 20 weeks of service May 2020 through October 2020.

Option 02: 20 weeks of service May 2021 through October 2021.

Option 03: 20 weeks of service May 2021 through October 2021.

Option 04: Utility Hours

FIRM FIXED AWARD WILL BE ISSUED TO THE BEST VALUE, AS DETAILED HERIN. AWARD ANTICIPATED IMMEDIATELY.

EA

EA

HR

b. 20 CALENDAR DAYS %

c. 30 CAHRSLENDAR DAYS %

d. $____________

CALENDAR DAYS

NUMBER

PERCENTAGE

NOTE: Additional provisions and representations [ ] are [ ] are not attached.

QUOTATION

15. DATE OF QUOTATION

a. NAME OF QUOTER

16. SIGNER

b. STREET ADDRESS

c. CITY, STATE, ZIP

AREA CODE

c. TITLE (type or print)

Authorized for Local Reproduction STANDARD FORM 18 (Rev. 6-95) Previous Edition Not Usable Prescribed by GSA FAR (48 CFR) 53.215-1(a) OMB Approval No. 9000-0009

QUOTED BY:______________________________ DATE:___________________________________

COMPANY NAME:_________________________ EMAIL:___________________________________

PHONE:______________________________ SMALL BUSINESS: Yes No (Indicate One)

FAX:_________________________________ TAX ID NUMBER:_____________________________

ADDRESS:_____________________________

_____________________________________ DUNS no.___________________________________

_____________________________________ SAM #:___________________________

FEDERAL SUPPLY SCHEDULE (if applicable):____________________________________________

Send Your Response to Heather Mahle & Reference Solicitation # (ABL#) in the Subject Line:

· Mail/Hand Deliver to NMFS/Auke Bay Laboratories, 17109 Pt Lena Loop Rd, Juneau, AK 99801

· Fax to 907-789-6004

· Email to Heather.Mahle@noaa.gov Award will only be issued to Vendors/Contractors who:

1. Have a Data Universal Numbering System (DUNS)

2. Is registered and Active in the System for Award Management (SAM).

1. According to FAR 52.204-7, a firm must have a Data Universal Numbering System (DUNS) number. The DUNS Number (DUN & BRADSTREENT #) is assigned by Dun & Bradstreet, Inc. (D&B) to identify unique business entities. A DUNS may be acquired free of charge by going on-line at WWW.DNB.COM/EUPDATE or by phone at (800) 333-0505.

2. The System for Award Management (SAM) is combining federal procurement systems and the Catalog of Federal Domestic Assistance into one new system. This consolidation is being done in phases. The first phase of SAM includes the functionality from the following systems:

* Central Contractor Registry (CCR)

* Federal Agency Registration (Fedreg)

* Online Representations and Certifications Application

* Excluded Parties List System (EPLS) Register at WWW.SAM.GOV

STATEMENT OF WORK

Landscape Maintenance at TSMRI NMFS Auke Bay Laboratories

OBJECTIVE

The objective of this order is to provide landscape maintenance support for the Ted Stevens Marine Research Institute in accordance with the terms and conditions stated herein.

SCOPE OF WORK

Provide landscape maintenance and for Auke Bay Laboratories at Ted Stevens Marine Research Institute in Juneau, Alaska. The contractor will be need to schedule the appropriate number of hours and personnel to conduct the following tasks on a WEEKLY BASIS at the Ted Stevens Marine Research Institute in Juneau, Alaska for the amount of time indicated within the solicitation.

Perform landscape services each year from September to September, to include the following tasks:

1. Weekly mowing and electric weeding grass area and rock area next to UAF (UAF Facility is not included)

· This task is to be performed weekly.

· 3-4 man hours is the Estimate for this task.

· Remove all grass clipings and ensure surrounding area is clean

· Key Card Swipe is required at entry and exit each time this task is performed to verify receipt of weekly service. A specific Key Card will be issued to Contractor for this specific task. Service must be verified for payment.

2. Weekly Weeding and Pruning Pulling Weeds in landscaped areas:

A. Weeding of rock beds in front of TSMRI building.

B. Weeding of rock beds around entrance gate.

C. Weeding of Plaza behind TSMRI building.

D. Weeding of Path area across from TSMRI.

E. Remove any garbage and small debris from landscaped areas.

· This task is listed in order of Priority above (A-E).

· 4-8 man hours each week is the Minimum amount of time that must be provided for this task in order to stay on top of weeds in all areas identified.

· Remove all weeds, pruned clippings, and dead vegetation.

· Prune and remove dead vegetation in the Spring, Fall, and as needed. Special attention is to be paid to flower beds for spring pruning to remove all dead foliage and any dead plants.

· Key Card Swipe is required at entry and exit each time this task is performed to verify receipt of weekly service. A specific Key Card will be issued to Contractor for this specific task. Service must be verified for payment.

3. Replacement of Dead Plants in Plaza Area:

· Contractor will identify dead plants in plaza area during site visit and will identify and replace plants with like plants.

· Diseased plants will also be identified and removed and replaced.

LAST PAGE OF THIS DOCUMENT SHOWS MAP WITH PRIORITY AREAS.

Utility Hours:

Utility hours may be requested for any of the weekly service tasks if continued service is needed for additional time frames or for additional areas not covered. Only actual hours will be paid for and at least 7 days notice will be provided for the additional work. An example of this may be if the ground thaws earlier then expected or summer goes later than expected.

PERIOD OF PERFORMANCE

Base Year allows for 20 weeks of service for summer and fall of 2019. Fall work must be completed before ground freezes.

Option Year allows for 1 to 2 week of service September and October, and 22 weeks of service May through October. Fall work must be completed before ground freezes.

OPTIONS: There is no guarantee that the above listed option will be exercised; however, there is a reasonable likelihood that the option will be exercised in the future. When exercising an option below, the contracting officer shall provide written notice to the contractor prior to start date of service period specified below if time allows, otherwise a Bilateral Modification will be issued by the Contracting Officer that must be signed by Contractor to accept Option Terms. Options may be exercised if funds are available and if it is still the most advantageous method of fulfilling the Government’s need, price and other factors.

GENERAL CONDITIONS

Equipment and Materials The contractor shall provide all equipment and materials needed to accomplish the tasks in this agreement.

Damage The Government will not be responsible in any way for damage occasioned by fire, theft, accidents or otherwise, to the Contractors personal belongings brought into the Government buildings.

Performance of Work

1. Key Card Swipe is required at entry and exit each time service is performed to verify receipt of weekly service. A specific Key Card will be issued to Contractor for each task within the weekly service. This will be verified at time of invoice.

2. The services shall be carried on in such a manner that there will be maximum coordination between the Contractor and the Government POC.

3. The Contractor shall comply with all building regulations while on the premisis.

4. The Contractor shall comply with all federal regulations while working with the Government and when obtaining services on behalf of the government.

Workmanship The work involved in this order must be performed accurately, on a timely basis and must closely follow Statement of Work and established protocols as provided.

INVOICING

In compliance with the Prompt Payment Act, the Financial Management Division will pay an invoice in accordance with the terms set forth in the contracts with vendors if a "proper invoice" is received. A "proper invoice" has:

1. Name of the vendor and an invoice date

2. Purchase order number

3. Description, price and quantity of property and services actually delivered or rendered

4. Payment terms are “Net 30”.

6. Name, title, phone number, and complete mailing address of the responsible official to whom payment is to be made

Invoices are to be submitted to: DOC/NOAA/NMFS

Or to abl.invoice@noaa.gov

PAYMENT TERMS

Award will be issued as NET 30, however the Government makes best attempts to pay small businesses within 15 days.

GOVERNMENT RESPONSIBILITY

The Contracting Officer (CO) or a her technical pont of contact will be available during normal working hours to provide guidance to the Contractor in performance of the contract tasks. Questions and clarificiaotn should be sent to Contracting Officer and Technical point of contact via email.

The CO and designees shall regularly inspect the work of the Contractor on a weekly basis to ensure that acceptable performance was received.

The Government will issue Key Cards for each task and then will verify services rendered through Key Card Records. Key cards are to be swipped and entry and exit although gate will already be open most of the time.

IT REQUIREMENTS

This contract will not require assignment of a user account and access to DOC data systems. This contractor does not need access to Government hardware, application software, system software, and sensitive data. This service will be performed on federal government's premises for more then 180 calendar days. IT security considerations and controls will be put into place before commencement of service.

INSURANCE COVERAGE

The contractor will be responsible for providing their own workman's compensation and health insurance. The government will not be responsible for providing insurance. The government takes no responsibility in event of injury.

FEDERAL, STATE, AND LOCAL TAXES

Except as may be otherwise provided in this contract price includes all applicable federal, state, and local taxes and duties in effect on the date of this contract but does not include any taxes from which the Government the Contractor or this transaction is exempt. Upon request of the contractor, the Government shall furnish a tax exemption certificate or similar evidence of exemption with respect to any such tax not included in the contract price pursuant to this clause. For the purpose of this clause, the term "date of this contract" means the date of the contractor's quotation or, if no quotation, the date of this Purchase Order.

Suspension of Work and Government Shut Down

In the case of a Government Wide Shutdown, this contract/order may be subject to a stop-work order. A stop-work order may be issued by writing by the Contracting Officer or Government Official. In accordance with FAR 42.13 – Suspension of Work, Stop-Work Orders, and Government Delay of Work is also made a part of this Acquisition. NOAA will not make payments to contractors for products or services not obligated before the funding lapse.

If a contract or order has been issued and funded and productive work is possible then Contractor may continue to operate under your Contract during Laps. However, depending on the duration of a funding lapse, the absence of available Federal employee oversight may lead an agency to reconsider whether the contract or grant activity should continue to be performed. Federal employees will not be available to make timely payments to the contractor or grantee in accordance with the contract.

SUBMISSION OF QUOTES

A response to this Request for Quote shall consist of the following:

· Completed Standard Form 18 (page 1 & 2) – with pricing and signature.

· Written responses to each of the evaluated items listed above (vessel requirements, availability during preferred dates, price, crew requirements, and non-essential specifications).

· Verification that the vendor is registered and active at WWW.SAM.GOV

Supporting documentation including photos, certifications, and schematics may help support requirements. An incomplete response to the requirements or incompletion of the required attachments may be counted against you in the evaluation stage.

Please send required documentation to Heather Mahle at NMFS/Auke Bay Laboratories, 17109 Pt Lena Loop Rd, Juneau, AK 99801, or FAX 907-789-6004, or to Heather.Mahle@noaa.gov. If there are any questions, please submit them via email to Heather.Mahle@noaa.gov. She will contact the requisitioner and/or technical representative for the answer. All responses or correspondence should reference the solicitation number in the Subject line to ensure proper receipt.

PROVISIONS

52.212-3 Offeror Representations and Certifications (FT)

52.212-2 Evaluation—Commercial Items

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:

[Contracting Officer shall insert the significant evaluation factors, such as (i) technical capability of the item offered to meet the Government requirement; (ii) price; (iii) past performance (see FAR 15.304); and include them in the relative order of importance of the evaluation factors, such as in descending order of importance.] Technical and past performance, when combined, are __________ [Contracting Officer state, in accordance with FAR 15.304, the relative importance of all other evaluation factors, when combined, when compared to price.]

(b) Options. The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the Government to exercise the option(s).

(c) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer’s specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

(End of provision)

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS—COMMERCIAL ITEMS (JAN 2017)

The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) website located at https://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision— “Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means–

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: “Guidance for Executive Order 13673, ‘Fair Pay and Safe Workplaces’”. The DOL Guidance was initially published in the Federal Register on August 25, 2016, and significant revisions will be published for public comment in the Federal Register. The DOL Guidance and subsequent versions can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are–

(1) Department of Labor Wage and Hour Division (WHD) for–

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(v) The Family and Medical Leave Act; and

(vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for–

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for–

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans’ Readjustment Assistance Act of 1972 and the Vietnam Era Veterans’ Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for–

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

“Forced or indentured child labor” means all work or service—

(6) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(7) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation”, means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans’ Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of “labor laws”.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except—

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Predecessor” means an entity that is replaced by a successor and includes any predecessors of the predecessor.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate—

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

“Sensitive technology”—

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically—

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

“Service-disabled veteran-owned small business concern”—

(1) Means a small business concern—

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern”, consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that—

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by—

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Veteran-owned small business concern” means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Successor” means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

“Women-owned business concern” means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

“Women-owned small business concern” means a small business concern—

(1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program” (in accordance with 13 CFR part 127), means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: “Administrative merits determination”, “Arbitral award or decision”, paragraph (2) of “Civil judgment”, “DOL Guidance”, “Enforcement agency”, “Labor compliance agreement”, “Labor laws”, and “Labor law decision”. The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, GSA, DoD and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(b)(1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAM website.

(2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through http://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications—Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ______________.

[Offeror to identify the applicable paragraphs at (c) through (t) of this provision that the offeror has completed for the purposes of this solicitation only, if any.

These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.]

(c) Offerors must complete the following representations when the resulting contract will be performed in the United States or its outlying areas. Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it □ is, □ is not a small business concern.

(2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it □ is, □ is not a veteran-owned small business concern.

(3) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.] The offeror represents as part of its offer that it □ is, □ is not a service-disabled veteran-owned small business concern.

(4) Small disadvantaged business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, that it □ is, □ is not a small disadvantaged business concern as defined in 13 CFR 124.1002.

(5) Women-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it □ is, □ is not a women-owned small business concern.

(6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that—

(i) It □ is,□ is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It □ is, □ is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: __________.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that—

(i) It □ is, □ is not an EDWOSB concern, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It □ is, □ is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: __________.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

Note: Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold.

(8) Women-owned business concern (other than small business concern). [Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it □ is a women-owned business concern.

(9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price:____________________________________

(10) HUBZone small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that—

(i) It □ is, □ is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR Part 126; and

(ii) It □ is, □ is not a HUBZone joint venture that complies with the requirements of 13 CFR Part 126, and the representation in paragraph (c)(10)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: __________.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

(d) Representations required to implement provisions of Executive Order 11246—

(1) Previous contracts and compliance. The offeror represents that—

(i) It □ has, □ has not participated in a previous contract or subcontract subject to the Equal Opportunity clause of this solicitation; and

(ii) It □ has, □ has not filed all required compliance reports.

(2) Affirmative Action Compliance. The offeror represents that—

(i) It □ has developed and has on file, □ has not developed and does not have on file, at each establishment, affirmative action programs required by rules and regulations of the Secretary of Labor (41 cfr parts 60-1 and 60-2), or

(ii) It □ has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor.

(e) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352). (Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract. If any registrants under the Lobbying Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made.

(f) Buy American Certificate. (Applies only if the clause at Federal Acquisition Regulation (FAR) 52.225-1, Buy American—Supplies, is included in this solicitation.)

(1) The offeror certifies that each end product, except those listed in paragraph (f)(2) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.” The terms “commercially available off-the-shelf (COTS) item” “component,” “domestic end product,” “end product,” “foreign end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American—Supplies.”

(2) Foreign End Products:

[List as necessary]

(3) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.

(g)(1) Buy American—Free Trade Agreements—Israeli Trade Act Certificate. (Applies only if the clause at FAR 52.225-3, Buy American—Free Trade Agreements—Israeli Trade Act, is included in this solicitation.)

(i) The offeror certifies that each end product, except those listed in paragraph (g)(1)(ii) or (g)(1)(iii) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The terms “Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end product,” “commercially available off-the-shelf (COTS) item,” “component,” “domestic end product,” “end product,” “foreign end product,” “Free Trade Agreement country,” “Free Trade Agreement country end product,” “Israeli end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements–Israeli Trade Act.”

(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”:

Free Trade Agreement Country End Products (Other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products:

(iii) The offeror shall list those supplies that are foreign end products (other than those listed in paragraph (g)(1)(ii) of this provision) as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act.” The offeror shall list as other foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.”

Other Foreign End Products:

(iv) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.

(2) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate I. If Alternate I to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”:

Canadian End Products:

Line Item No.

(3) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate II. If Alternate II to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products or Israeli end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”:

Canadian or Israeli End Products:

(4) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate III. If Alternate III to the clause at 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled “Buy American-Free Trade Agreements-Israeli Trade Act”:

Free Trade Agreement Country End Products (Other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products:

(5) Trade Agreements Certificate. (Applies only if the clause at FAR 52.225-5, Trade Agreements, is included in this solicitation.)

(i) The offeror certifies that each end product, except those listed in paragraph (g)(5)(ii) of this provision, is a U.S.-made or designated country end product, as defined in the clause of this solicitation entitled “Trade Agreements.”

(ii) The offeror shall list as other end products those end products that are not U.S.-made or designated country end products.

Other End Products:

(iii) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. For line items covered by the WTO GPA, the Government will evaluate offers of U.S.-made or designated country end products without regard to the restrictions of the Buy American statute. The Government will consider for award only offers of U.S.-made or designated country end products unless the Contracting Officer determines that there are no offers for such products or that the offers for such products are insufficient to fulfill the requirements of the solicitation.

(h) Certification Regarding Responsibility Matters (Executive Order 12689). (Applies only if the contract value is expected to exceed the simplified acquisition threshold.) The offeror certifies, to the best of its knowledge and belief, that the offeror and/or any of its principals—

(1) □ Are, □ are not presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(2) □ Have, □ have not, within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a Federal, state or local government contract or subcontract; violation of Federal or state antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property;

(3) □ Are, □ are not presently indicted for, or otherwise criminally or civilly charged by a Government entity with, commission of any of these offenses enumerated in paragraph (h)(2) of this clause; and

(4) □ Have, □ have not, within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied.

(i) Taxes are considered delinquent if both of the following criteria apply:

(A) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(B) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(ii) Examples.

(A) The taxpayer has received a statutory notice of deficiency, under I.R.C. §6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(B) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. §6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability.