solicitation_-_Bismarck_dampers.pdf

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair) IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

CODE

6. PROJECT NUMBER

8. ADDRESS OFFER TO

4. CONTRACT NUMBER

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 8/2014)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

27. PAYMENT WILL BE MADE BY

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

GSA Solicitation No. 47PJ0019Q0023

Simplified Acquisition Construction Contract to replace dampers on AHUs at two federal buildings in Bismarck, ND

The Agreement

Table of Contents

I. Project Information A. Project Summary B. The Contract C. Period of Performance D. Work Conditions/Site Requirements E. Authorized Representative F. Contract Liquidated Damages Rate G. Buy American Exceptions H. Statement of Work, Specifications, Drawings, Exhibits, and Other Attachments

II. Prices A. Basis of Pricing

III. Terms and Conditions

A. Commencement, Prosecution, and Completion of Work B. Contractor Responsibilities C. Contractor Management and Personnel D. Material and Workmanship E. Project Schedule F. Extensions of Time G. Interpretation of Specifications and Drawings H. Submittals I. Government’s Right to Stop Work for Non-Compliance J. Other Contracts K. Substantial Completion and Contract Completion L. Use and Possession Prior to Substantial Completion M. Equitable Adjustments N. Finality of Contract Modifications O. Liquidated Damages P. Administrative Matters Q. Bonds R. Safeguarding Sensitive Data and Information Technology Resources S. Additional Terms and Conditions

IV. Contract Clauses A. Clauses Incorporated in Full Text B. Clauses Incorporated by Reference

I. Project Information

I.A. Project Summary Replace designated dampers on air handler units at two federal buildings in Bismarck, ND. 1) Federal Building, 304 E. Broadway and 2) William Guy Fed Bldg/Post Office/Courthouse, 220 E.

Rosser Ave.

I.B. The Contract

(1) The Contract consists of the SF 1442, the Agreement, the Statement of Work, Specifications, Drawings, Exhibits, Amendments, Modifications, and other Attachments identified herein (collectively, the Contract Documents). The Contract contains the entire agreement of the Parties, and no prior written or oral agreement, express or implied, shall be admissible to contradict or modify any part of the Contract.

(2) The Contractor shall provide and pay for all labor, materials, equipment, tools, water, heat, utilities, transportation, and other facilities and services necessary for the proper execution of the work described in and reasonably inferable from the Contract Documents (the Work), whether temporary or permanent. In consideration for, and upon condition of, the Contractor's completion of the Work, GSA shall pay the Contractor the price or prices established in Section II, subject to the terms and conditions set forth in this Contract.

I.C. Period of Performance

(1) Commencement. The Contractor shall commence performance of the Work within 10 days after the Contractor receives the Notice to Proceed (NTP).

(2) Substantial Completion. The Contractor shall achieve Substantial Completion of the Work, as that term is defined in this Agreement, no later than 110 calendar days from issuance of Notice to Proceed (NTP).

(3) Contract Completion. The Contractor shall achieve Contract Completion, as the term is defined in this Agreement, within 10 calendar days of Substantial Completion.

I.D. Work Conditions/Site Requirements Interior work in occupied space.

I.E. Authorized Representative

(1) This Contract is between the United States of America, acting by and through the Administrator of General Services (GSA), and the Contractor (the Parties). References in this Contract to "the Owner" or "the Government" shall be understood to refer to GSA. The following individual is designated as the only authorized GSA representative under this Contract, unless other warranted contracting officers are designated in writing:

Contracting Officer Name: Pam Burley Address: GSA, 657 2nd Ave. N., Room 244, Fargo, ND 58102 Telephone: 701-566-6129 Email: pam.burley@gsa.gov

(2) Authorities and Limitations

(a) All rights, responsibilities and authorities of GSA under this Contract are vested in the Contracting Officer. The Contracting Officer may delegate these rights, responsibilities, and authorities to other GSA representatives. Such delegations shall be effective and binding only if communicated in writing to the Contractor, and subject to any limitations specified therein.

(b) The Contractor shall perform the Contract in accordance with any order (including but not limited to instruction, direction, interpretation, or determination) issued by the Contracting Officer or other representative to whom the Contracting Officer has delegated authority. The Contractor assumes all the risk and consequences of performing work in accordance with an order issued by a person lacking authority to issue such order.

I.F. Contract Liquidated Damages Rate In accordance with “Liquidated Damages” clause in Section III (Terms and Conditions), liquidated damages shall be calculated at the rate of $0 per calendar day.

I.G. Buy American Exceptions For the applicable Buy American clause and any exceptions, see Section IV of this Agreement.

I.H. Statement of Work, Specifications, Drawings, Exhibits, and Other Attachments The following documents are incorporated into this Contract.

(1) Statement of Work for Solicitation 47PJ0019Q0023, Dated 3/13/19

(2) Wage Determination ND12, Dated 2/15/19

The following files are incorporated into this Contract by reference:

1) Universal Scope requirements

Scope of Work

Damper Replacement 3/13/19

Section 1: Project Title Damper Replacement

Section 2: Project Location, Building Name Federal Building, 304 East Broadway, Bismarck, ND 58501 William Guy Fedl Building/Post Office/Courthouse, 220 East Rosser Ave, Bismarck, ND 58501

Section 3: Contact List

Contracting Officer (CO) Name: Pam Burley Email: pam.burley@gsa.gov Address: 657 2nd Ave North Fargo, ND 58102 Phone (O): 701 566-6129

Property Manager Name: James Langlois Email: james.langlois@gsa.gov Address: 220 East Rosser Ave Bismarck, ND 58501 Phone (O): 701 566-6115

Project Manager Name: Jesse Johnson Email: jesse.johnson@gsa.gov Address: 220 East Rosser Ave Bismarck, ND 58501 Phone (O): 701 557-9649

Section 4: Project Background & Project Description The purpose of this project is to replace the existing fresh air dampers with insulated dampers to help with the drastic temperature changes within the HVAC system itself. The insulated dampers shall help with the overall efficiency of the air handler unit.

Section 5: Project Objectives Federal Building: It has been determined that the five (5) fresh air supply dampers on the 1st & 3rd floors require modernization due to excessive cold air migration during winter season.

Therefore, the government wants to install new insulated dampers, along with controls, at the indicated locations. The contractor shall provide labor, materials, equipment, commissioning and supervision to complete the project.

William Guy Fed Bldg/Post Office/CH: It has been determined that the four (4) dampers on two (2) AHU’s require modernization due to excessive cold air migration during winter season.

The government wants to replace the dampers on AHUs #10 and the dampers on AHUs #8.

The contractor shall provide labor, materials, equipment, commissioning and supervision to complete the project. Confirm existing fire detection system is in place and functioning properly.

1) Confirm existing fire detection system is in place and functioning properly

2) Contractor shall be responsible for gaining access to all required locations, including but not limited to moving of furniture, man lift, scaffolding, installation of access panels, etc.

3) Provide testing of newly installed equipment to ensure that actuators are functioning as intended and are being properly controlled by the Building Automation System (BAS).

Contact the GSA Project Manager as to when these tests will occur. Provide test report for review by GSA Project Manager.

4) The contractor shall make an access hatch at each damper location if one does not exist. Verify size and location with GSA Project Manager for location.

5) The contractor shall install automatic controls to the relief dampers (or an approved equal) of the existing supply damper actuator.

6) Remove old pneumatic actuators and install new BELIMO actuators or an approved equal with its damper, making sure each actuator can supply enough torque to sufficiently open and close the damper. Contractor shall provide testing of newly installed equipment to ensure that actuators are functioning as intended and are being properly controlled by the BAS. Provide test report for review by GSA Property Manager.

7) All work shall comply with codes and standards applicable to each type of work through the course of this project. Contractor shall also comply with the requirements of GSA BuildGreen Standards and the PBS P100.

8) It is recommended to replace the dampers by removing the exterior louvers and replacing from the outside. Seal exterior louver to prevent leakage.

9) Damper installation location: Dampers are to be installed at the location of the existing damper.

Damper: Install relief dampers with low leak, metal, “double-thickness”, 1” thick with Styrofoam insulation sandwiched between metal skins insulated blade dampers. The damper blades insulating factors shall be R-value 4 or better and U-factor .25 BTU per hour per square foot per degree F with a specific low leak of 3 CFM or less. The damper seals blade and jamb shall be made out of polyurethane neoprene isolator between metal skins. The damper shall be insulated type robust construction. This damper shall be fitted with easily accessible operating mechanism, complete with links, levers, quadrant for proper control and setting in a desire position. Damper splitters shall be fabricated out of galvanized steel at least two gauges higher than the duct piece having these fittings. Damper shall be installed in duct at the required location.

Federal Building

AHU Damper Size QTY

#1 Fresh Air 72" x 54" 1

#2 Fresh Air 42" x 48" 2

#3 Fresh Air 42" x 70" 2

William Guy FB/PO/CH

Fresh Air Relief/Supply Air

Location Damper Size Damper Size

AHU10 1st Floor 34"H x 60''W 22"H x 30''W

AHU8 Basement 30''H x 30'' W 12'' H x 18''W

*Dampers dimensions are approximate and must be verified.

Section 6: Proposal Pricing & Site Walk

1) Pre-proposal Site Visit Meeting:

a. The site visit shall consist of a meeting to review construction requirements followed by a walk-thru of the project site. The meeting shall be attended by the contractor and GSA project personnel, and appropriate sub-contractors.

b. Review existing conditions of the project area including any field verification.

c. Review the solicitation/evaluation requirements.

d. Contact Project Manager to schedule a site visit.

2) Cost Proposal Requirements:

a) When submitting a proposal, provide a cost breakdown for each task into the following categories: Materials, equipment, labor hours, subcontractor's quotes, overhead, profit, and bond. Pricing shall be broken down by Construction Specification Institute (CSI) divisions.

b) Base Price-

Section 7: Period of Performance Once award has been issued, the contractor has 120 calendar days to complete the project.

The contractor must also promptly begin the badging process at the time of award. Please allow a minimum of 30 days to complete the badging process. Extensions will be granted for unforeseen conditions and other factors outside of the contractor’s control at the Contracting Officer’s discretion.

Section 8: Universal Scope Requirements

ALL of the requirements in this section are MANDATORY for ALL GSA projects

See the attached Universal Scope Requirements document for the full details outlining each item

Failure to comply with any and all of the requirements will result in the project not being accepted as complete

REQUIREMENTS for ALL Projects (Construction)

a. Safety and Health Program

b. Lead Containing Paint / Lead Based Paint Plan

c. Green Purchasing Plan

d. Construction Indoor Air Quality (IAQ) Management Plan

e. Construction Waste Diversion Plan

REQUIREMENTS for ALL projects IF APPLICABLE (Remove if not needed AFTER consulting with OFM and/or other appropriate groups)

f. Commissioning (for all new AHUs or all new building system equipment)

g. Building Monitoring and Control Systems (BMC)

Section 9: Submittals After Award

1) Contractor shall submit a Method of Procedures (MOP) to the GSA Delivery Project Manager (PM) for approval prior to commencement of work. At a minimum, the MOP shall include:

a) Brief narrative describing method of accomplishment, construction techniques, etc.

b) Project schedule (to include critical path, major milestones, long lead time items, mob & de-mob, inspection dates, substantial completion, and occupancy dates)

c) Service/Utility Outages (if necessary)

d) Phasing schedule (if necessary)

e) Any building infrastructure/BAS equipment that may be impacted

2) Manufacturer's specifications, instructions and material specification sheets in original form

3) Submittal register/ log for all products specified to establish a standard of quality to include. Submittal register response by the government shall be (14) calendar days or less.

a) For pricing purposed please assume 1 hard copy of submittals and 1 electronic copy to be sent to the project manager. Distribution list including final quantities will be finalized after receipt of the submittal log/ register by GSA project manager.

4) If product samples are not submitted in a timely fashion, any delays caused by the contractor will not warrant a time extension. After completion of all work, the Contractor shall submit to the project manager the manufacturer's specifications, instructions and material specification sheets in original form. Additionally, the Contractor shall submit all inventory changes (removals, additions, upgrades, etc., and new condition codes) to the

COR.

5) Submittal response by the government shall be (14) calendar days or less.

Section 10: General Requirements

1) Contractor Use of the Premises

a) During the period of the project, the contractor will have access to the site only during business hours of 7:00 am to 5:00pm. No on-site work shall be performed outside these hours or on holidays unless otherwise directed by the Contracting Officer. The contractor will need to coordinate with the Contracting Officer to arrange access to the parking lot. The contractor shall make every effort to cause a minimum of damage to parking lots, any other paved areas, any items that need to be moved during the course of the project, and any areas not included in this scope of work. Any damage caused will be repaired at the contractor’s expense.

b) Operations will continue during this project so particular attention shall be given to phasing of project to minimize disruptions to their activities. Contractor shall coordinate with GSA representatives and then provide a schedule with phasing and duration for each activity. Schedule approval is to be obtained at least seven days prior to any work commencing. Communication during this project will be critical to meet this need.

2) Progress Meetings The contractor shall schedule weekly meetings with the GSA and subcontractors. The contractor shall keep meeting minutes and distribute copies at the following meetings.

The meeting agenda will include the following as a minimum: Approval of previous meeting, review of work progress, field observations, problems and decisions, identification of problems which impede planned progress, review of submittals schedule and status of submittals, maintenance of progress schedules, planned progress during the succeeding work period.

3) Equipment The contractor shall provide all equipment associated with the entire project, operate in a safe manner and adhere to all OSHA and GSA standards.

4) Equipment and Material Storage The contractor shall provide and store all equipment, the materials specified above, and any other materials required completing the project. The materials are required to be kept clean and dry throughout the duration of the project. Contractor to coordinate with building manager for location of storage sheds.

5) Electricity, Water, and Gas GSA will pay for electricity, water, and gas during the course of this project. The contractor is responsible for making connections to the existing systems. Temporary electrical work shall meet the requirements of NFPA 70-1996 (NEC), Article 305.

When temporary connections are removed, restore existing utility services to their original condition.

6) Contractor’s Field Office The contractor may provide an office for their own use. Size, location, and construction shall be subject to approval.

7) Fire Watch Contractor shall be responsible for providing fire watch if required per attached GSA fire watch guidelines.

8) Fire Alarm Impairment and Hot Work When a fire suppression or alarm system impairment is required, contractor shall provide written outage request to GSA for approval in advance of impairing any systems.

Contractor shall be responsible for having a GSA approved NICET certified fire alarm contractor perform all system impairments. During fire alarm/suppression impairments or hot work procedures, contractor shall provide a fire watch per the GSA Regional Fire Watch Guidelines.

9) Protection of Public The building site will continue to be used by tenants. The contractor shall fence, barricade, or otherwise block off the immediate work area to prevent unauthorized entry. The contractor shall illuminate barricades and obstructions at night and maintain safe building access and egress for tenants.

10) Housekeeping The project site shall be kept in a neat, orderly, and safe condition at all times. The contractor shall provide enough containers for collecting construction debris and construction materials to be recycled. The contractor shall wet down dry materials and rubbish to prevent blowing dust and keep volatile wastes in covered containers.

11) Transportation and Deliveries The contractor shall arrange deliveries of materials in accordance with construction schedules; coordinate with COR to avoid conflict with other tenants and other work conditions at the site. Contractor must make GSA PM & CO aware of any lead times that may affect the project schedule.

12) Cleaning Before scheduling the final inspection, the Contractor shall accomplish six items: (1) Remove all tools, equipment, surplus material, and rubbish; (2) Restore or refinish, to original condition, surfaces that are damaged due to the work of this contract; (3) Remove grease, dirt, stains, foreign materials, and labels from finished surfaces; (4) Thoroughly clean building interiors; (5) Pickup all construction debris from the site;

and (6) At time of final inspection, project shall be thoroughly cleaned and ready for use.

13) Protection of the Building The construction contractor is responsible for the protection of all existing building property for damage due to work performed under this contract. Any damage caused by the performance of this contract shall be repaired to match like or better condition at no additional cost to the government

14) Disruptive Work All painting, staining, or other activity which may cause noxious or undesirable fumes and/ or any noisy work that may be disruptive to the tenants/ public must be performed after normal working hours. The use of paint or stain that does not generate odors is preferred and may be required if the space will be occupied the following day with prior written approval from GSA.

Section 11: Substantial Completion & Final Inspection

1) When project, or designated portion of project is complete, request a final inspection.

Upon receipt of request that project is substantially complete, the Contracting Officer will proceed with the inspection within ten days of receipt of request or will advise the contractor of items that prevent the project from being designated substantially complete.

2) Red-lined drawings and CAD and/or BIM as-built drawings, and field training for Operations and Maintenance (O&M) personnel shall be provided at completion of project. Maintain one complete set of contract drawings. Clearly mark changes, deletions, and additions using GSA CAD Standards to show actual construction conditions. Show additions in red, deletions in green, and special instructions in blue print. Provide to GSA within timeframe negotiated at time of award.

3) The contractor shall provide O&M manuals. The O&M manuals shall contain the following:

o Executed Warranties (at project completion) o Maintenance and operation manuals

Section 12: Historical Building: The Federal Building in Bismarck, North Dakota is a Historic Building and is listed on the National Register of Historic Places (NRID# 83004064 10/1983).

As such, projects in the building are required to follow the guidelines set forth in the following publications.

ADM 1020.2 GSA Procedures for Historic Properties The National Historic Preservation Act of 1966, as amended and Executive Order

11593.

The Secretary of the Interior's Standards and Illustrated Guidelines for Rehabilitating

Historic Buildings, Revised 1992 (36 CFR 67).

GSA Technical Preservation Guidelines: http://www.gsa.gov/portal/content/101402 GSA Historic Preservation Technical Procedures:

http://www.gsa.gov/portal/hp/hpc/category/100371/hostUri/portal National Park Service Preservation Briefs:

http://www.nps.gov/tps/how-to-preserve/briefs.htm http://www.gsa.gov/portal/content/101402 http://www.gsa.gov/portal/hp/hpc/category/100371/hostUri/portal http://www.nps.gov/tps/how-to-preserve/briefs.htm

Any work that could alter the building’s historic fabric, character, or appearance, both on the interior and exterior must first be approved by the GSA Historic Preservation Officer/Historic Preservation Specialist and the North Dakota State Historic Preservation Office (SHPO) before any actions are to take place. This project has SHPO approval.

Section 13: Attachments

Universal Scope requirements

Guy FB/PO/CH Existing Actuator

Guy FB/PO/CH Supply Damper #10 AHU

Guy FB/PO/CH - Existing Fresh Air Damper #10 AHU

Federal Building

General Decision Number: ND190012 02/15/2019 ND12

Superseded General Decision Number: ND20180020

State: North Dakota

Construction Type: Building

County: Burleigh County in North Dakota.

BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories).

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.60 for calendar year 2019 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.60 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2019. If this contract is covered by the EO and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must pay workers in that classification at least the wage rate determined through the conformance process set forth in 29 CFR 5.5(a)(1)(ii) (or the EO minimum wage rate, if it is higher than the conformed wage rate). The EO minimum wage rate will be adjusted annually. Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29

CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date

0 01/04/2019

1 02/15/2019

BOIL0647-006 03/01/2018

Rates Fringes

BOILERMAKER......................$ 37.22 27.14

ELEC0714-013 07/01/2018

ELECTRICIAN......................$ 34.01 10.00+10.5%

IRON0512-006 05/01/2018

IRONWORKER, STRUCTURAL...........$ 32.05 27.85

PLUM0300-017 06/05/2017

PLUMBER..........................$ 31.38 15.30

PLUM0300-020 06/04/2018

PIPEFITTER.......................$ 34.44 16.42

SFND0669-002 04/01/2017

SPRINKLER FITTER (Fire

Sprinklers)......................$ 32.87 16.99

SHEE9010-001 06/02/2014

SHEET METAL WORKER (HVAC Duct

Installation Only)...............$ 23.71 14.26

SUND2012-001 08/18/2014

BRICKLAYER.......................$ 24.46 13.96

CARPENTER........................$ 15.78 0.00

CEMENT MASON/CONCRETE FINISHER...$ 17.73 4.24

HVAC MECHANIC (Installation of HVAC Unit Only)...............$ 24.46 5.47

INSULATOR - MECHANICAL

(Duct, Pipe & Mechanical

System Insulation)...............$ 16.73 2.94

LABORER: Common or General......$ 13.64 0.00

LABORER: Mason Tender - Brick...$ 15.32 0.00

LABORER: Mason Tender -

Cement/Concrete..................$ 14.23 4.50

OPERATOR:

Backhoe/Excavator/Trackhoe.......$ 23.06 4.00

OPERATOR: Crane.................$ 26.18 9.39

OPERATOR: Forklift..............$ 23.06 15.47

OPERATOR: Loader................$ 25.98 0.00

PAINTER (Brush and Roller).......$ 21.86 8.41

ROOFER...........................$ 17.17 2.66

SHEET METAL WORKER, Excludes

HVAC Duct Installation...........$ 24.14 0.00

TRUCK DRIVER: Dump Truck........$ 19.81 5.42

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal

Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January

1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to

56 hours of paid sick leave each year. Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate

(weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than "SU" or "UAVG" denotes that the union classification and rate were prevailing for that classification in the survey. Example: PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the "SU" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010

08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.) and

3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage

Determinations. Write to:

Branch of Construction Wage Determinations

Wage and Hour Division

U.S. Department of Labor

200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party

(those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7).

Write to:

Wage and Hour Administrator

U.S. Department of Labor

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the

Wage Appeals Board). Write to:

Administrative Review Board

U.S. Department of Labor

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

II. Prices

II.A. Basis of Pricing

(1) Contract Prices. All Contract prices set forth in this Section include all costs necessary to complete the work for which the price is established (e.g., Base Contract, Unit Price, Options) in accordance with the Contract Documents, including, but not limited to, the cost of work performed by subcontractors and consultants, indirect costs, fees, expenses, taxes, and profit.

(2) Knowledge of Conditions Affecting Price. FAR 52.236-3, Site Investigations and Conditions Affecting the Work, is incorporated by reference in this Contract. The Contractor shall be presumed to have established all prices with knowledge of general and local conditions that may affect the cost of Contract performance at the site where the Work is to be performed, to the extent that such information is reasonably obtainable.

(3) Unit Prices and Allowances. If any portion of the Work is to be performed on a unit price basis, the Unit Price shall include all costs of coordinating and incorporating the unit-priced portion of the Work into the Base Contract Work. The Contractor shall only be obligated to perform unit-priced work to the extent that an Allowance has been established. The Contractor shall be obligated to perform such work in excess of a unit quantity for which an Allowance is established only if directed by the Contracting Officer in writing. The Contractor shall be bound to the unit price or prices set forth herein in all equitable adjustments for changes including unit priced work, and no markups shall be applied to such unit prices.

III. Terms and Conditions

III.A. Commencement, Prosecution, and Completion of Work The Contractor shall not commence the Work until the Contracting Officer has issued NTP. The Contractor shall diligently prosecute the Work so as to achieve Substantial Completion of the Work, as defined in Section III (Terms and Conditions), “Substantial Completion and Contract Completion” clause, within the time specified in Section I (Project Information), “Period of Performance” clause. If the Contract specifies different completion dates for different phases or portions of the Work, the Contractor shall diligently prosecute the Work so as to achieve Substantial Completion of such phases or portions of the Work within the times specified.

III.B. Contractor Responsibilities

(1) Unless otherwise expressly stated in the Contract, the Contractor shall be responsible for all means and methods employed in the performance of the Contract.

(2) The Contractor shall be responsible for providing professional design services in connection with performance of the Work or portions of the Work only if this responsibility is expressly stated and the Contract Documents provide the performance and design criteria that such services will be required to satisfy. In the performance of such work, the Contractor shall be responsible for retaining licensed design professionals, who shall sign and seal all drawings, calculations, specifications and other submittals that the licensed professional prepares. The Contractor shall be responsible for, and GSA shall be entitled to rely upon, the adequacy and completeness of all professional design services provided under this Contract.

(3) The Contractor shall be responsible for coordinating all activities of subcontractors. This responsibility includes coordination of: preparation of shop drawings produced by different subcontractors where their work interfaces or may potentially conflict or interfere and the installation of such work; scheduling of work by subcontractors; and use of the Project site for staging and logistics.

(4) Where installation of separate Work components as shown in the Contract Documents will result in conflict or interference between such components or with existing conditions, including allowable tolerances, it is the Contractor's responsibility to bring such conflict or interference to the attention of the Contracting Officer and seek direction before fabrication, construction, or installation of any affected work. If the Contractor fabricates, constructs, or installs any work prior to receiving such direction, the Contractor shall be responsible for all cost and time incurred to resolve or mitigate such conflict or interference.

(5) Where drawings show work without specific routing, dimensions, locations, or position relative to other work or existing conditions, and such information is not specifically defined by reference to specifications or other information supplied in the Contract Documents, the Contractor is responsible for routing, dimensioning, and locating such work in coordination with other work or existing conditions in a manner consistent with Contract requirements.

(6) The Contractor shall secure and pay for all necessary permits and governmental fees, licenses, and inspections that are customarily secured after award of the Contract and that are legally required at the time of award. The Contractor shall provide a copy of the permits required for execution of the work to the Contracting Officer prior to commencement of any related work.

(7) The Contractor shall immediately bring to the Contracting Officer's attention any hazardous materials or conditions not disclosed in the Contract Documents discovered by or made known to the Contractor during the performance of the Contract

(8) The Contractor must submit a safety plan before commencing work.

(9) It is not the Contractor's responsibility to ensure that the Contract Documents comply with applicable laws, statutes, building codes, and regulations. If it comes to the attention of the Contractor that any of the Contract Documents do not comply with such requirements, the Contractor shall promptly notify the Contracting Officer in writing. If the Contractor performs any of the Work prior to notifying and receiving direction from the Contracting Officer, the Contractor shall assume full responsibility for correction of such work and any fees or penalties that may be assessed for non-compliance.

(10) The Contractor assumes the risk of, and shall be responsible for, any loss, damage, destruction, or theft of Government property upon its delivery to the Contractor as Government-furnished property. However, the Contractor is not responsible for reasonable wear and tear to Government property or for Government property properly consumed in performing this Contract.

III.C. Contractor Management and Personnel

(1) The Contractor shall employ sufficient management and contract administration resources, including personnel responsible for project management, field superintendence, change order administration, estimating, coordination, inspection, and quality control, to ensure the proper execution and timely completion of the Work. The Contractor shall designate a principal of the firm or other senior management official to provide executive oversight and problem resolution resources to the Project for the life of the Contract.

(2) The Contractor shall employ, and require its subcontractors to employ, qualified personnel to perform the Work. The Government reserves the right to exclude, or remove from the site or building, any personnel for reasons of incompetence, carelessness, or insubordination, who violate rules and regulations concerning conduct on federal property, or whose continued employment on the site is otherwise deemed by the Government to be contrary to the public interest.

(3) Repeated failure or excessive delay by the Contractor to provide qualified personnel shall be deemed a default for the purposes of the “Termination for Default” clause.

III.D. Material and Workmanship All equipment, material, and articles incorporated into the Work shall be new and of the most suitable grade for the purpose intended, unless otherwise specified in this Contract. References in the specifications to equipment, material, articles, or patented processes by trade name, make, or catalog number shall be regarded as establishing a standard of quality and performance and shall not be construed as limiting competition.

Unless specifically directed by the Contracting Officer, the Contractor may use any equipment, material, article, or process that is equal to that named in the specifications, so long as it is of comparable quality and meets specified characteristics, or, if no such characteristics are specified, the relevant performance characteristics of the specified item.

III.E. Project Schedule

(1) The Contractor shall use a Project Schedule to plan, coordinate, and perform the Work.

The Project Schedule shall show all critical milestones in a MS Word or Excel format.

(2) The Project Schedule shall be a rational, reasonable and realistic plan for completing the Work, and conform to requirements specified in this clause and elsewhere in this Contract.

(3) The Contractor understands and acknowledges that the preparation and proper management of the Project Schedule is a material component of the Work, and that the Contract price includes all costs of compliance with Project Schedule requirements.

(4) The Project Schedule shall depict all major activities necessary to complete the Work.

(5) Prior to NTP, the Contractor shall submit its Project Schedule to the Contracting Officer.

The Contractor shall submit the Project Schedule in both electronic and hardcopy print format.

(6) The Project Schedule shall also include Contractor-defined milestones to identify target dates for critical events, based upon the Contractor's chosen sequence of work and be linked to the tasks that drive those milestones.

(7) If the Contractor revises the Project Schedule after initial submission, the Contractor shall provide in writing to the Contracting Officer a narrative describing the substance of the revision, the rationale for the revision, and the impact of the revision on the Completion date.

(8) If at any time the Contracting Officer finds that the Project Schedule does not comply with any Contract requirement, the Contractor shall, upon written notice of exceptions taken by the Contracting Officer, revise the Project Schedule, adjust activity progress, or provide sufficient information demonstrating compliance. Regardless of whether the Contracting Officer takes any such exception, the Contractor shall not be relieved of its responsibility for the rationality, reasonableness or realism of the Project Schedule,

(9) If the Contractor fails to sufficiently address the Contracting Officer's exceptions to the Project Schedule within thirty (30) calendar days of written notice of same, the Contracting Officer may withhold retainage until the Project is Substantially Complete or until such time as the Contractor has complied with Project Schedule requirements.

(10) The Contracting Officer shall be entitled, but not required, to rely upon the Project Schedule to evaluate the Contractor's progress, evaluate entitlement to extensions of time.

III.F. Extensions of Time

(1) If the Contractor requests an extension of the time for Substantial Completion, the Contractor shall base its request on analysis of time impact using the Project Schedule as its baseline, and the new Substantial Completion date projected by the Project Schedule as revised to account for the impact. The Contractor's request must be submitted to the Contracting Officer in writing, and set forth facts and analysis in sufficient detail to enable the Contracting Officer to evaluate the Contractor's entitlement to an extension of time.

(2) The Contractor shall only be entitled to an extension of time to the extent that Substantial Completion of the Work is delayed by causes for which the Contractor is not responsible under this Contract and to the extent that the actual or projected Substantial Completion date is later than the date required by this Contract for Substantial Completion.

(3) The Contractor shall not be entitled to an extension of time if the Contractor has not updated the Project Schedule in accordance with this Contract.

(4) The Government shall not be liable for any costs to mitigate time impacts incurred by the Contractor that occur less than 30 calendar days after the date the Contractor submits a request for extension of time complying with this clause.

III.G. Interpretation of Specifications and Drawings

(1) The specifications and drawings shall be interpreted to complement each other.

Requirements set forth in the specifications and not shown on the drawings, or shown on the drawings and not set forth in the specifications, shall be of like effect as if shown or set forth in both.

(2) Different requirements within the Contract Documents shall be deemed inconsistent only if compliance with both cannot be achieved.

(3) If a requirement set forth in one location is more restrictive than that set forth elsewhere in the Contract Documents, requirements set forth in specifications shall govern over requirements set forth in drawings; otherwise, the more restrictive shall govern.

(4) In case of inconsistent requirements within the drawings, the following order of precedence shall apply:

(a) Requirements indicated in large-scale drawings shall govern over inconsistent requirements indicated in small-scale drawings.

(b) Requirements indicated in schedules shall govern over inconsistent information shown in drawings.

(5) Unless otherwise noted, the drawings shall be interpreted to provide for a complete construction, assembly, or installation of the Work, without regard to the detail with which material components are shown in the drawings.

(6) If any inconsistency within the drawings or specifications cannot be reconciled by reference to this clause, the Contractor shall promptly request a determination from the Contracting Officer as to which requirement shall govern. Election by the Contractor to follow either requirement without a determination from the Contracting Officer shall be at the Contractor's risk; should the Contracting Officer subsequently determine that the requirement not followed by the Contractor governs, the Contractor shall be responsible for all cost and time required to comply with the Contracting Officer's determination.

III.H. Submittals

(1) The Contractor shall prepare and submit to the Contracting Officer shop drawings, samples, calculations, product information, mockups, and other submittals (collectively, "submittals")…