36C26122Q1111 Reno PMCM Service.pdf

PAGE 1 OF 66 1. REQUISITION NO.

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NO. 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

a. NAME b. TELEPHONE NO. (No Collect Calls) 8. OFFER DUE DATE/LOCAL

TIME

9. ISSUED BY CODE 10. THIS ACQUISITION IS UNRESTRICTED OR SET ASIDE: % FOR:

SMALL BUSINESS

HUBZONE SMALL

BUSINESS

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

WOMEN-OWNED SMALL BUSINESS

(WOSB) ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

8(A)

NAICS:

SIZE STANDARD:

11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

13a. THIS CONTRACT IS A

RATED ORDER UNDER

DPAS (15 CFR 700)

13b. RATING

14. METHOD OF SOLICITATION

RFQ IFB RFP

15. DELIVER TO CODE 16. ADMINISTERED BY CODE

17a. CONTRACTOR/OFFEROR CODE FACILITY CODE 18a. PAYMENT WILL BE MADE BY CODE

TELEPHONE NO. UEI: EFT:

PHONE: FAX:

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN OFFER

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK BELOW IS CHECKED

SEE ADDENDUM

19. 20. 21. 22. 23. 24.

ITEM NO. SCHEDULE OF SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Govt. Use Only)

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1, 52.212-4. FAR 52.212-3 AND 52.212-5 ARE ATTACHED. ADDENDA ARE ARE NOT ATTACHED.

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN _______________ 29. AWARD OF CONTRACT: REF. ___________________________________ OFFER COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND DATED ________________________________. YOUR OFFER ON SOLICITATION DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY (BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED SET FORTH HEREIN IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

30b. NAME AND TITLE OF SIGNER (TYPE OR PRINT) 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER (TYPE OR PRINT) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION (REV. NOV 2021)

PREVIOUS EDITION IS NOT USABLE Prescribed by GSA - FAR (48 CFR) 53.212

7. FOR SOLICITATION

INFORMATION CALL:

STANDARD FORM 1449

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, & 30

36C26122Q1111 08-31-2022

John Da Silva N/A 09-14-2022

11:00 PDT

612MCP

Department of Veterans Affairs Network Contracting Office (NCO) 21 VA Northern California HealthCare System 5342 Dudley Blvd, Bldg 209 McClellan CA 95652-2609

X 100

X

541330

$16.5 Million

N/A

X

VA Sierra Nevada Healthcare System

975 Kirman ave Reno NV 89502

612MCP

Department of Veterans Affairs Network Contracting Office (NCO) 21 VA Northern California HealthCare System 3230 Peacekeeper Way, Bldg. 209 McClellan CA 95652-1012

Department of Veterans Affairs FMS VA-9(101) Financial Services Center

PO Box 149971 Austin TX 78714-9971

See CONTINUATION Page

Construction Management and Project Management services In accordance with the Performance Work Statement

See CONTINUATION Page

X X

RICO L. JOHNSON

36C26122Q1111

Table of Contents

SECTION A ...................................................................................... Error! Bookmark not defined.

A.1 SF 1449 SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL PRODUCTS

AND COMMERCIAL SERVICES ...................................... Error! Bookmark not defined.

SECTION B - CONTINUATION OF SF 1449 BLOCKS

B.1 CONTRACT ADMINISTRATION DATA

B.2 PRICE/COST SCHEDULE

ITEM INFORMATION

B.3 DELIVERY SCHEDULE

SECTION C - CONTRACT CLAUSES

C.1 52.212-4 CONTRACT TERMS AND CONDITIONS—COMMERCIAL PRODUCTS

AND COMMERCIAL SERVICES (NOV 2021)

C.2 52.217-8 OPTION TO EXTEND SERVICES (NOV 1999)

C.3 52.217-9 OPTION TO EXTEND THE TERM OF THE CONTRACT (MAR 2000) ... 20

C.4 52.223-6 DRUG-FREE WORKPLACE (MAY 2001)

C.5 SUPPLEMENTAL INSURANCE REQUIREMENTS

C.6 VAAR 852.212-70 PROVISIONS AND CLAUSES APPLICABLE TO VA

ACQUISITION OF COMMERCIAL ITEMS (APR 2020)

C.7 VAAR 852.219-74 LIMITATIONS ON SUBCONTRACTING—MONITORING AND

COMPLIANCE (JUL 2018)

C.8 VAAR 852.219-77 VA NOTICE OF LIMITATIONS ON SUBCONTRACTING—

CERTIFICATE OF COMPLIANCE FOR SERVICES AND CONSTRUCTION (SEP 2021)

(DEVIATION)

C.9 VAAR 852.242-71 ADMINISTRATIVE CONTRACTING OFFICER (OCT 2020) ... 28

C.10 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

C.11 52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT

STATUTES OR EXECUTIVE ORDERS—COMMERCIAL PRODUCTS AND

COMMERCIAL SERVICES (MAY 2022) (JUL 2020) (DEVIATION)

SECTION D - CONTRACT DOCUMENTS, EXHIBITS, OR ATTACHMENTS

SECTION E - SOLICITATION PROVISIONS

E.1 52.212-1 INSTRUCTIONS TO OFFERORS—COMMERCIAL PRODUCTS AND

COMMERCIAL SERVICES (NOV 2021)

E.2 52.204-24 REPRESENTATION REGARDING CERTAIN TELECOMMUNICATIONS

AND VIDEO SURVEILLANCE SERVICES OR EQUIPMENT (NOV 2021)

E.3 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

E.4 52.216-1 TYPE OF CONTRACT (APR 1984)

E.5 52.233-2 SERVICE OF PROTEST (SEP 2006)

E.6 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB

1998)

E.7 52.212-2 EVALUATION—COMMERCIAL PRODUCTS AND COMMERCIAL

SERVICES (NOV 2021)

E.8 52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS—

COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (MAY 2022) (JUL 2020)

(DEVIATION)

SECTION B - CONTINUATION OF SF 1449 BLOCKS

B.1 CONTRACT ADMINISTRATION DATA

1. Contract Administration: All contract administration matters will be handled by the following individuals:

a. CONTRACTOR:

b. GOVERNMENT: Contracting Officer 36C261

Department of Veterans Affairs

Network Contracting Office (NCO) 21

VA Northern California HealthCare System

5342 Dudley Blvd, Bldg 209

McClellan CA 95652-2609

2. CONTRACTOR REMITTANCE ADDRESS: All payments by the Government to the contractor will be made in accordance with:

[X] 52.232-33, Payment by Electronic Funds Transfer—System For Award Management, or

[] 52.232-36, Payment by Third Party

3. INVOICES: Invoices shall be submitted in arrears:

a. Quarterly []

b. Semi-Annually []

c. Other [X] TERMS WILL BE AGREED UPON PRIOR TO

CONTRACT START DATE

4. GOVERNMENT INVOICE ADDRESS: All Invoices from the contractor shall be submitted electronically in accordance with VAAR Clause 852.232-72 Electronic Submission of Payment Requests.

ACKNOWLEDGMENT OF AMENDMENTS: The offeror acknowledges receipt of amendments to the Solicitation numbered and dated as follows:

AMENDMENT NO DATE

Performance Work Statement (PWS) for

Project Management/Construction Management Services March 31, 2022

1. General

1.1. Introduction

1.1.1. The mission of the Department of Veterans Affairs is to care for those “who shall have borne the battle”. This acquisition will expand VASNHC ability to design, construct and renovate facilities.

1.2. Objective

1.2.1. The objective of this acquisition is to secure additional qualified personnel to assist VA Engineering staff in the design, construction, and renovation of structures in various stages of design or construction.

1.3. Scope of Work

1.3.1. The VA Sierra Nevada Health Care System (VASNHCS) is seeking design and construction services from engineering consultants with mid-level experience to oversee plan preparation and construction.

1.3.2. The Contractor shall provide all the services requested by the VASNHCS as detailed in section (2). The Contractor shall demonstrate proven PM/CM expertise for projects of various sizes and complexity. The Contractor shall provide efficient and comprehensive project management through all phases of the projects, with particular emphasis placed on the capability to work in partnership with VA, consultants, and contractors during pre-solicitation, contract award, project design, and construction phases.

1.4. Background

1.4.1. SNCHS has experienced several key construction project delays and cancellations due to insufficient engineering staff over the past several years. The proposed PM/CM acquisition will provide comprehensive, professional, and competent project management for reviewing, logging, monitoring, and archiving construction submittals, Requests for Information (RFI’s), and other communications with all parties in the pre-solicitation, design, and construction process.

1.5. Type of Contract Contemplated

1.5.1. The contractual type is expected to be Firm Fixed Price for a contracted amount of professional time, calculated hourly. The contract may be cancelled at any time by the Contracting Officer on advice from the VASNHCS it is no longer necessary.

1.6. Period of Performance

1.6.1. The period of performance of this contract is 365 days from Notice to Proceed.

1.6.2. SNHCS wishes option years to continue the contract if the need remains and performance by the contractor is satisfactory.

1.7. Place of Performance

1.7.1. All work to be performed at the VA Sierra Nevada Health Care System (VASNHCS) located at:

PWS for PM/CM

1.7.1.1. 975 Kirman Avenue

1.7.1.2. Reno, Nevada

1.8. Applicable Documents

1.8.1. All applicable documentation on the Office of Construction & Facilities

Management’s (CFM) Technical Information Library (TIL):

https://www.cfm.va.gov/til/index.asp.

2. Specific Requirements/Tasks

2.1. All work performed by the Contractor will be determined and specifically assigned by the VA Contracting Officer’s Representative (COR). Assignment shall be made and withdrawn solely at the discretion of the VA COR with the concurrence of the Contracting Officer.

2.2. The Contractor during design shall provide a variety of project management services as described in this document including, but not limited to: design and constructability reviews (including value engineering); pre-solicitation document and procurement support; feasibility studies which may include providing a minimal design; construction management; development of a Project Management Plan; assistance for building commissioning and building commissioning; and post-construction support in cooperation with VA personnel, building occupants, and project architect-engineers.

Design oversight commences on assignment by the VA to the Contractor and ceases when instructed to do so by the VA.

2.3. During construction the Contractor shall be responsible for, but not limited to: ensuring that all labor, material, tools, equipment, excavation, shoring and reshoring, testing, inspection, commissioning, and all necessary work set forth in the specifications and plans required by or may be reasonably inferred from the contract documents is performed in adherence to VA plans and specifications; and to provide the project management services and construction management services for the selected facility projects in an acceptable manner. Construction management services of the Contractor commence at project assignment by the VA and cease when instructed by the VA.

2.4. During the execution of the contract unless otherwise directed by the VA, the Contractor shall provide a Project Manager with the authority to commit resources of the Contractor’s firm to monitor, manage and administer all phases of the project activities and to help achieve the completion of all pre-solicitation, pre-construction services, and construction activities on all assigned projects subject to this contract. The Contractor shall provide all necessary qualified personnel to perform PM/CM services under this contract. If the PM/CM Contractor personnel fail to perform to VA’s satisfaction, VA may, upon 10 days written notice, require the Contractor to remove such person(s) from the project and replace them with personnel acceptable to VA. The Project Manager may provide dual or multiple roles dependent on his or her skill set and experience upon approval of the VA. The intent of this contract is to require the assigned Project Manager or Construction Manager to primarily perform his/her duties at the Contractor’s facilities, but also necessarily visit the project sites and attend VA/Construction Contractor meetings when required.

2.5. Identification of the method proposed to satisfy requirements does not relieve the PM/CM Contractor from its obligation to ensure compliance with said requirements or its contractual responsibility to VA for such work https://www.cfm.va.gov/til/index.asp

2.6. The PM/CM shall prepare, if required by VA, a project specific Project Management Plan (PMP) on assigned projects.

2.7. All documents within the PMP will serve as a roadmap for executing this project. The PM/CM will review the PMP with the Facilities Projects Managers for approval prior to executing the plan. A minimum of 10 working days shall be given to VA for review of the

PMP.

2.8. The PM/CM shall prepare, if required by VA, a Construction Management Plan (CMP) on assigned projects. The CMP’s shall be a written project-specific plan which outlines the project’s scope, organization, and specific approach that the PM/CM will undertake to accomplish the various management tasks for the project. The Quality Management Plan should be integrated into the CMP to maintain a focus on project quality. The PM/CM shall maintain the CMP throughout the entire course of involvement with the project. The PM/CM shall provide an approved means for revisions to the project documents as changes become necessary. In addition to the CMP, the PM/CM shall include scheduling data that includes Actual Cost of Work Performed (ACWP); actual schedule progress, milestones reached and earned value; variance analysis and corrective actions needed; display of the present critical path for conventional facilities;

and a narrative describing the status of technical work, significant project accomplishments, and potential problems.

3. Contractor Quality Assurance.

3.1. Adherence to VA standards as defined on the Technical Information Library (TIL) maintained by the VA’s Office of Construction and Facilities Management shall be the measurement of success in the management of design and construction.

3.2. Qualified VA engineers will examine work produced by the Contractor to determine if VA standards are being met.

4. Delivery or Deliverables

4.1. Satisfactory completion of design and construction oversight with assigned projects adhering to VA Standards.

5. Meetings

5.1. For all meetings, the contractor shall be responsible for providing meeting materials, and administrative and facilitation support. Meetings may be conducted by teleconferencing, as approved by the Contracting Officer or the Contracting Officers Representative.

5.2. Post-award Kickoff Meeting

5.2.1. Within 5 business days of contract award, the Government will conduct a post-award kickoff meeting by teleconference. The contractor will be responsible for arranging the meeting.

5.3. Intermittent Project Status Reviews

5.3.1. At the sole discretion of the Government, intermittent project status reviews may be conducted on an informal basis by telephone or teleconference upon 1-day advance notice as approved by the Contracting Officer or Contracting Officer’s Representative.

5.4. Monthly Project Status Reviews

5.4.1. Monthly status meetings to be conducted each month at a time to be determined at the post-award kickoff meeting. The Contractor is responsible for reporting the previous month’s activities (including any risks, issues, or concerns, and actual or recommended actions for their mitigation), and projected activities for the following month. A written monthly summary of activities performed during the month may be accepted in lieu of a meeting at the discretion of the Contracting Officer or the Contracting Officers Representative.

5.4.2. Government requires a monthly review of costs from the Contractor with the COR. This shall include a breakdown of costs per project and a one month look ahead for work in the next month.

5.5. Program Management Review

5.5.1. The Government will conduct quarterly program management reviews by teleconference to review the progress of the program, identify any risks, issues, or concerns, and provide feedback on the Contractor’s progress and performance.

The Contractor shall provide written data and verbal presentations as to the financial status of the projects administered (projected vs. incurred costs), any identified any risks, issues, or concerns (and their mitigation or its plans for their mitigation).

6. Required Travel

6.1. Required travel will be agreed on by the Contracting Officer or Contracting Officer’s

Representative (COR) in advance of the travel.

7. Government Furnished Property/Equipment/Information

6.1. No Government Furnished Property will be used in this procurement.

B.2 PRICE/COST SCHEDULE

ITEM INFORMATION

ITEM

NUMBE

R

DESCRIPTION OF

SUPPLIES/SERVIC

ES

QUANTIT

Y

UNI

T UNIT PRICE AMOUNT

700.00 hr ________________

Professional Engineer Services in accordance with the Performance Work Statement Contract Period: Base POP Begin: 10-01-2022 POP End: 09-30-2023 PRINCIPAL NAICS CODE: 541330 - Engineering Services PRODUCT/SERVICE CODE: R408 - Support - Professional:

Program Management/Support

20.00 HR ________________

Administrative Services in accordance with the Performance

Work Statement Contract Period: Base POP Begin: 10-01-2022 POP End: 09-30-2023 PRINCIPAL NAICS CODE: 541330 - Engineering Services

5.00 TRP ________________

On-site Visits Contract Period: Base POP Begin: 10-01-2022 POP End: 09-30-2023 PRINCIPAL NAICS CODE: 541330 - Engineering Services

1,050.00 HR ________________

Professional Engineer Services in accordance with the Performance Work Statement Contract Period: Option 1 POP Begin: 10-01-2023 POP End: 09-30-2024 PRINCIPAL NAICS CODE: 541330 - Engineering Services

Administrative Services in accordance with the Performance Work Statement Contract Period: Option 1 POP Begin: 10-01-2023 POP End: 09-30-2024 PRINCIPAL NAICS CODE: 541330 - Engineering Services

On-site Visits Contract Period: Option 1 POP Begin: 10-01-2023 POP End: 09-30-2024 PRINCIPAL NAICS CODE: 541330 - Engineering Services

Professional Engineer Services in accordance with the

Performance Work Statement.

Contract Period: Option 2 POP Begin: 10-01-2024 POP End: 09-30-2025 PRINCIPAL NAICS CODE: 541330 - Engineering Services

Administrative Services in accordance with the Performance Work Statement.

Contract Period: Option 2 POP Begin: 10-01-2024 POP End: 09-30-2025 PRINCIPAL NAICS CODE: 541330 - Engineering Services

On-site Visits Contract Period: Option 2 POP Begin: 10-01-2024 POP End: 09-30-2025 PRINCIPAL NAICS CODE: 541330 - Engineering Services

Professional Engineer Services in accordance with the Performance Work Statement.

Contract Period: Option 3 POP Begin: 10-01-2025 POP End: 09-30-2026 PRINCIPAL NAICS CODE: 541330 - Engineering Services

Administrative Services in accordance with the Performance Work Statement.

Contract Period: Option 3 POP Begin: 10-01-2025 POP End: 09-30-2026 PRINCIPAL NAICS CODE: 541330 - Engineering Services

On-site Visits Contract Period: Option 3 POP Begin: 10-01-2025 POP End: 09-30-2026 PRINCIPAL NAICS CODE: 541330 - Engineering Services

Professional Engineer Services in accordance with the Performance Work Statement.

Contract Period: Option 4 POP Begin: 10-01-2026 POP End: 09-30-2027 PRINCIPAL NAICS CODE: 541330 - Engineering Services

Administrative Services in accordance with the Performance Work Statement.

Contract Period: Option 4 POP Begin: 10-01-2026 POP End: 09-30-2027 PRINCIPAL NAICS CODE: 541330 - Engineering Services

On-site Visits Contract Period: Option 4 POP Begin: 10-01-2026 POP End: 09-30-2027 PRINCIPAL NAICS CODE: 541330 - Engineering Services

GRAND TOTAL ________________

B.3 DELIVERY SCHEDULE

ITEM NUMBER QUANTITY

DELIVERY

DATE

700.00

MARK Clarence Cassady

FOR: 775-789-6685

Clarence.Cassady@VA.gov

20.00

MARK

FOR:

Clarence Cassady 775-789-6685

5.00

Clarence Cassady

1,050.00

Clarence Cassady

Clarence Cassady

Clarence Cassady

Clarence Cassady

Clarence Cassady

Clarence Cassady

Clarence Cassady

Clarence Cassady

FOR:

Clarence Cassady

Clarence Cassady

Clarence Cassady

Clarence Cassady

SECTION C - CONTRACT CLAUSES

C.1 52.212-4 CONTRACT TERMS AND CONDITIONS—COMMERCIAL

PRODUCTS AND COMMERCIAL SERVICES (NOV 2021)

(a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights—

(1) Within a reasonable time after the defect was discovered or should have been discovered;

and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C. 3727). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract.

(c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties.

(d) Disputes. This contract is subject to 41 U.S.C. chapter 71, Contract Disputes. Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at Federal Acquisition Regulation (FAR) 52.233-1, Disputes, which is incorporated herein by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract.

(e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference.

(f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(g) Invoice.

(1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include—

(i) Name and address of the Contractor;

(ii) Invoice date and number;

(iii) Contract number, line item number and, if applicable, the order number;

(iv) Description, quantity, unit of measure, unit price and extended price of the items delivered;

(v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading;

(vi) Terms of any discount for prompt payment offered;

(vii) Name and address of official to whom payment is to be sent;

(viii) Name, title, and phone number of person to notify in event of defective invoice; and

(ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract.

(x) Electronic funds transfer (EFT) banking information.

(A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract.

(B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer—System for Award Management, or 52.232-34, Payment by Electronic Funds Transfer—Other Than System for Award Management), or applicable agency procedures.

(C) EFT banking information is not required if the Government waived the requirement to pay by EFT.

(2) Invoices will be handled in accordance with the Prompt Payment Act (31 U.S.C. 3903) and Office of Management and Budget (OMB) prompt payment regulations at 5 CFR part 1315.

(h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings.

(i) Payment.—

(1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract.

(2) Prompt payment. The Government will make payment in accordance with the Prompt Payment Act (31 U.S.C. 3903) and prompt payment regulations at 5 CFR part 1315.

(3) Electronic Funds Transfer (EFT). If the Government makes payment by EFT, see 52.212- 5(b) for the appropriate EFT clause.

(4) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the specified payment date if an electronic funds transfer payment is made.

(5) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall—

(i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the—

(A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment);

(B) Affected contract number and delivery order number, if applicable;

(C) Affected line item or subline item, if applicable; and

(D) Contractor point of contact.

(ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer.

(6) Interest.

(i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in 41 U.S.C. 7109, which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period as fixed by the Secretary until the amount is paid.

(ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract.

(iii) Final decisions. The Contracting Officer will issue a final decision as required by 33.211 if—

(A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days;

(B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or

(C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see 32.607-2).

(iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment.

(v) Amounts shall be due at the earliest of the following dates:

(A) The date fixed under this contract.

(B) The date of the first written demand for payment, including any demand for payment resulting from a default termination.

(vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on—

(A) The date on which the designated office receives payment from the Contractor;

(B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or

(C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor.

(vii) The interest charge made under this clause may be reduced under the procedures prescribed in FAR 32.608-2 in effect on the date of this contract.

(j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon:

(1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or

(2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b. destination.

(k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties.

(l) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided.

(m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(n) Title. Unless specified elsewhere in this contract, title to items furnished under this contract shall pass to the Government upon acceptance, regardless of when or where the Government takes physical possession.

(o) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

(p) Limitation of liability. Except as otherwise provided by an express warranty, the Contractor will not be liable to the Government for consequential damages resulting from any defect or deficiencies in accepted items.

(q) Other compliances. The Contractor shall comply with all applicable Federal, State and local laws, executive orders, rules and regulations applicable to its performance under this contract.

(r) Compliance with laws unique to Government contracts. The Contractor agrees to comply with 31 U.S.C. 1352 relating to limitations on the use of appropriated funds to influence certain Federal contracts; 18 U.S.C. 431 relating to officials not to benefit; 40 U.S.C. chapter 37, Contract Work Hours and Safety Standards; 41 U.S.C. chapter 87, Kickbacks; 41 U.S.C. 4712 and 10 U.S.C. 2409 relating to whistleblower protections; 49 U.S.C. 40118, Fly American; and 41 U.S.C. chapter 21 relating to procurement integrity.

(s) Order of precedence. Any inconsistencies in this solicitation or contract shall be resolved by giving precedence in the following order:

(1) The schedule of supplies/services.

(2) The Assignments, Disputes, Payments, Invoice, Other Compliances, Compliance with Laws Unique to Government Contracts, and Unauthorized Obligations paragraphs of this clause;

(3) The clause at 52.212-5.

(4) Addenda to this solicitation or contract, including any license agreements for computer software.

(5) Solicitation provisions if this is a solicitation.

(6) Other paragraphs of this clause.

(7) The Standard Form 1449.

(8) Other documents, exhibits, and attachments

(9) The specification.

(t) [Reserved]

(u) Unauthorized Obligations.

(1) Except as stated in paragraph (u)(2) of this clause, when any supply or service acquired under this contract is subject to any End User License Agreement (EULA), Terms of Service (TOS), or similar legal instrument or agreement, that includes any clause requiring the Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C. 1341), the following shall govern:

(i) Any such clause is unenforceable against the Government.

(ii) Neither the Government nor any Government authorized end user shall be deemed to have agreed to such clause by virtue of it appearing in the EULA, TOS, or similar legal instrument or agreement. If the EULA, TOS, or similar legal instrument or agreement is invoked through an “I agree” click box or other comparable mechanism (e.g., “click-wrap” or “browse-wrap” agreements), execution does not bind the Government or any Government authorized end user to such clause.

(iii) Any such clause is deemed to be stricken from the EULA, TOS, or similar legal instrument or agreement.

(2) Paragraph (u)(1) of this clause does not apply to indemnification by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulations and procedures.

(v) Incorporation by reference. The Contractor’s representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

(End of Clause)

ADDENDUM to FAR 52.212-4 CONTRACT TERMS AND CONDITIONS—COMMERCIAL

PRODUCTS AND COMMERCIAL SERVICES

Clauses that are incorporated by reference (by Citation Number, Title, and Date), have the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available.

The following clauses are incorporated into 52.212-4 as an addendum to this contract:

C.2 52.217-8 OPTION TO EXTEND SERVICES (NOV 1999)

The Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates provided by the Secretary of Labor. The option provision may be exercised more than once, but the total extension of performance hereunder shall not exceed 6 months. The Contracting Officer may exercise the option by written notice to the Contractor within 30 days prior to the expiration of the period of performance.

(End of Clause)

C.3 52.217-9 OPTION TO EXTEND THE TERM OF THE CONTRACT (MAR

2000)

(a) The Government may extend the term of this contract by written notice to the Contractor within 30 days prior to the expiration of the period of performance; provided that the Government gives the Contractor a preliminary written notice of its intent to extend at least 60 days before the contract expires. The preliminary notice does not commit the Government to an extension.

(b) If the Government exercises this option, the extended contract shall be considered to include this option clause.

(c) The total duration of this contract, including the exercise of any options under this clause, shall not exceed five (5) years.

(End of Clause)

C.4 52.223-6 DRUG-FREE WORKPLACE (MAY 2001)

(a) Definitions. As used in this clause, "Controlled substances" means a controlled substance in schedules I through V of section 202 of the Controlled Substances Act (21 U.S.C. 812) and as further defined in regulation at 21 CFR 1308.11-1308.15.

"Conviction" means a finding of guilt (including a plea of nolo contendere) or imposition of sentence, or both, by any judicial body charged with the responsibility to determine violations of the Federal or State criminal drug statutes.

"Criminal drug statute" means a Federal or non-Federal criminal statute involving the manufacture, distribution, dispensing, possession or use of any controlled substance.

"Drug-free workplace" means the site(s) for the performance of work done by the Contractor in connection with a specific contract where employees of the Contractor are prohibited from engaging in the unlawful manufacture, distribution, dispensing, possession, or use of a controlled substance.

"Employee" means an employee of a Contractor directly engaged in the performance of work under a Government contract. "Directly engaged" is defined to include all direct cost employees and any other Contractor employee who has other than a minimal impact or involvement in contract performance.

"Individual" means an offeror/contractor that has no more than one employee including the offeror/contractor.

(b) The Contractor, if other than an individual, shall—within 30 days after award (unless a longer period is agreed to in writing for contracts of 30 days or more performance duration); or as soon as possible for contracts of less than 30 days performance duration—

(1) Publish a statement notifying its employees that the unlawful manufacture, distribution, dispensing, possession, or use of a controlled substance is prohibited in the contractor's workplace and specifying the actions that will be taken against employees for violations of such prohibition;

(2) Establish an ongoing drug-free awareness program to inform such employees about—

(i) The dangers of drug abuse in the workplace;

(ii) The contractor's policy of maintaining a drug-free workplace;

(iii) Any available drug counseling, rehabilitation, and employee assistance programs; and

(iv) The penalties that may be imposed upon employees for drug abuse violations occurring in the workplace.

(3) Provide all employees engaged in performance of the contract with a copy of the statement required by subparagraph (b)(1) of this clause;

(4) Notify such employees in writing in the statement required by subparagraph (b)(1) of this clause, that as a condition of continued employment on this contract, the employee will—

(i) Abide by the terms of the statement; and

(ii) Notify the employer in writing of the employee's conviction under a criminal drug statute for a violation occurring in the workplace no later than 5 days after such conviction;

(5) Notify the Contracting Officer in writing within 10 calendar days after receiving notice under subdivision (a)(4)(ii) of this clause, from an employee or otherwise receiving actual notice of such conviction. The notice shall include the position title of the employee;

(6) Within 30 days after receiving notice under subparagraph (b)(4)(ii) of this provision of a conviction, take one of the following actions with respect to any employee who is convicted of a drug abuse violation occurring in the workplace:

(i) Taking appropriate personnel action against such employee, up to and including termination; or

(ii) Require such employee to satisfactorily participate in a drug abuse assistance or rehabilitation program approved for such purposes by a Federal, State, or local health, law enforcement, or other appropriate agency; and

(7) Make a good faith effort to maintain a drug-free workplace through implementation of subparagraphs (b)(1) through (b)(6) of this clause.

(c) The Contractor, if an individual, agrees by award of the contract or acceptance of a purchase order, not to engage in the unlawful manufacture, distribution, dispensing, possession, or use of a controlled substance while performing this contract.

(d) In addition to other remedies available to the Government, the Contractor's failure to comply with the requirements of paragraph (b) and (c) of this clause may, pursuant to FAR 23.506, render the contractor subject to suspension of contract payments, termination of the contract for default, and suspension or debarment.

(End of Clause)

VHA Supplemental Contract Requirements for Combatting COVID-19

1. Contractor employees who work in or travel to VHA locations must comply with the following:

a. Documentation requirements:

1) If fully vaccinated, contractors shall show proof of vaccination.

i. NOTE: Acceptable proof of vaccination includes a signed record of immunization from a health care provider or pharmacy, a copy of the COVID-19 Vaccination Record Card (CDC Form MLS-319813_r, published on September 3, 2020), or a copy of medical records documenting the vaccination.

2) If unvaccinated, contractors shall show negative COVID-19 test results dated within three calendar days prior to desired entry date. Test must be approved by the Food and Drug Administration (FDA) for emergency use or full approval. This includes tests available by a doctor's order or an FDA approved over-the-counter test that includes an affiliated telehealth service.

3) Documentation cited in this section shall be digitally or physically maintained on each contractor employee while in a VA facility and is subject to inspection prior to entry to VA facilities and after entry for spot inspections by Contracting Officer Representatives (CORs) or other hospital personnel.

4) Documentation will not be collected by the VA; contractors shall, at all times, adhere to and ensure compliance with federal laws designed to protect contractor employee health information and personally identifiable information.

2. Contractor employees are subject to daily screening for COVID-19 and may be denied entry to VA facilities if they fail to pass screening protocols. As part of the screening process contractors may be asked screening questions found on the COVID-19 Screening Tool. Check regularly for updates.

a. Contractor employees who work away from VA locations, but who will have direct contact with VA patients shall self-screen utilizing the COVID-19 Screening Tool, in advance, each day that they will have direct patient contact and in accordance with their person or persons who coordinate COVID-19 workplace safety efforts at covered contractor workplaces. Contractors shall, at all times, adhere to and ensure compliance with federal laws designed to protect contractor employee health information and personally identifiable information.

3. Contractor must immediately notify their COR or Contracting Officer if contract performance is jeopardized due to contractor employees being denied entry into VA Facilities.

C.5 SUPPLEMENTAL INSURANCE REQUIREMENTS

In accordance with FAR 28.307-2 and FAR 52.228-5, the following minimum coverage shall apply to this contract:

(a) Workers' compensation and employers liability: Contractors are required to comply with applicable Federal and State workers' compensation and occupational disease statutes. If occupational diseases are not compensable under those statutes, they shall be covered under the employer's liability section of the insurance policy, except when contract operations are so commingled with a Contractor's commercial operations that it would not be practical to require this coverage. Employer's liability coverage of at least $100,000 is required, except in States with exclusive or monopolistic funds that do not permit workers' compensation to be written by private carriers.

(b) General Liability: $500,000.00 per occurrences.

(c) Automobile liability: $200,000.00 per person; $500,000.00 per occurrence and $20,000.00 property damage.

(d) The successful bidder must present to the Contracting Officer, prior to award, evidence of general liability insurance without any exclusionary clauses for asbestos that would void the general liability coverage.

(End of Clause)

C.6 VAAR 852.212-70 PROVISIONS AND CLAUSES APPLICABLE TO VA

ACQUISITION OF COMMERCIAL ITEMS (APR 2020)

(a) The Contractor agrees to comply with any provision or clause that is incorporated herein by reference to implement agency policy applicable to acquisition of commercial items or components. The following provisions and clauses that have been checked by the Contracting Officer are incorporated by reference.

[X] 852.203–70, Commercial Advertising.

[] 852.209–70, Organizational Conflicts of Interest.

[] 852.211–70, Equipment Operation and Maintenance Manuals.

[] 852.214–71, Restrictions on Alternate Item(s).

[] 852.214–72, Alternate Item(s). [Note: this is a fillable clause.]

[] 852.214–73, Alternate Packaging and Packing.

[] 852.214–74, Marking of Bid Samples.

[] 852.215–70, Service-Disabled Veteran-Owned and Veteran-Owned Small Business Evaluation Factors.

[] 852.215–71, Evaluation Factor Commitments.

[] 852.216–71, Economic Price Adjustment of Contract Price(s) Based on a Price Index.

[] 852.216–72, Proportional Economic Price Adjustment of Contract Price(s) Based on a Price Index.

[] 852.216–73, Economic Price Adjustment—State Nursing Home Care for Veterans.

[] 852.216–74, Economic Price Adjustment—Medicaid Labor Rates.

[] 852.216–75, Economic Price Adjustment—Fuel Surcharge.

[] 852.219–9, VA Small Business Subcontracting Plan Minimum Requirements.

[X] 852.219–10, VA Notice of Total Service-Disabled Veteran-Owned Small Business Set- Aside.

[] 852.219–11, VA Notice of Total Veteran-Owned Small Business Set-Aside.

[] 852.222–70, Contract Work Hours and Safety Standards—Nursing Home Care for Veterans.

[] 852.228–70, Bond Premium Adjustment.

[] 852.228–71, Indemnification and Insurance.

[] 852.228–72, Assisting Service-Disabled Veteran-Owned and Veteran-Owned Small Businesses in Obtaining Bonds.

[X] 852.232–72, Electronic Submission of Payment Requests.

[X] 852.233–70, Protest Content/Alternative Dispute Resolution.

[X] 852.233–71, Alternate Protest Procedure.

[] 852.237–70, Indemnification and Medical Liability Insurance.

[] 852.246–71, Rejected Goods.

[] 852.246–72, Frozen Processed Foods.

[] 852.246–73, Noncompliance with Packaging, Packing, and/or Marking Requirements.

[X] 852.270–1, Representatives of Contracting Officers.

[] 852.271–72, Time Spent by Counselee in Counseling Process.

[] 852.271–73, Use and Publication of Counseling Results.

[] 852.271–74, Inspection.

[X] 852.271–75, Extension of Contract Period.

[] 852.273–70, Late Offers.

[] 852.273–71, Alternative Negotiation Techniques.

[] 852.273–72, Alternative Evaluation.

[] 852.273–73, Evaluation—Health-Care Resources.

[] 852.273–74, Award without Exchanges.

(b) All requests for quotations, solicitations, and contracts for commercial item services to be provided to beneficiaries must include the following clause:

[] 852.237–74, Nondiscrimination in Service Delivery.

(End of Clause)

C.7 VAAR 852.219-74 LIMITATIONS ON SUBCONTRACTING—

MONITORING AND COMPLIANCE (JUL 2018)

(a) This solicitation includes VAAR 852.219-10 VA Notice of Total Service-Disabled Veteran- Owned Small Business Set-Aside.

(b) Accordingly, any contract resulting from this solicitation is subject to the limitation on subcontracting requirements in 13 CFR 125.6, or the limitations on subcontracting requirements in the FAR clause, as applicable. The Contractor is advised that in performing contract administration functions, the Contracting Officer may use the services of a support contractor(s) retained by VA to assist in assessing the Contractor's compliance with the limitations on subcontracting or percentage of work performance requirements specified in the clause. To that end, the support contractor(s) may require access to Contractor's offices where the Contractor's business records or other proprietary data are retained and to review such business records regarding the Contractor's compliance with this requirement.

(c) All support contractors conducting this review on behalf of VA will be required to sign an “Information Protection and Non-Disclosure and Disclosure of Conflicts of Interest Agreement” to ensure the Contractor's business records or other proprietary data reviewed or obtained in the course of assisting the Contracting Officer in assessing the Contractor for compliance are protected to ensure information or data is not improperly disclosed or other impropriety occurs.

(d) Furthermore, if VA determines any services the support contractor(s) will perform in assessing compliance are advisory and assistance services as defined in FAR 2.101, Definitions, the support contractor(s) must also enter into an agreement with the Contractor to protect proprietary information as required by FAR 9.505-4, Obtaining access to proprietary information, paragraph (b). The Contractor is required to cooperate fully and make available any records as may be required to enable the Contracting Officer to assess the Contractor's compliance with the limitations on subcontracting or percentage of work performance requirement.

(End of Clause)

C.8 VAAR 852.219-77 VA NOTICE OF LIMITATIONS ON

SUBCONTRACTING—CERTIFICATE OF COMPLIANCE FOR SERVICES AND

CONSTRUCTION (SEP 2021) (DEVIATION)

(a) Pursuant to 38 U.S.C.