36C26019Q0635-001.docx

36C26019Q0635

PAGE 1 OF

1. REQUISITION NO.

2. CONTRACT NO.

3. AWARD/EFFECTIVE DATE

4. ORDER NO.

5. SOLICITATION NUMBER

6. SOLICITATION ISSUE DATE

a. NAME

b. TELEPHONE NO. (No Collect Calls)

8. OFFER DUE DATE/LOCAL

TIME

9. ISSUED BY

CODE

10. THIS ACQUISITION IS

UNRESTRICTED OR

SET ASIDE:

% FOR:

SMALL BUSINESS

HUBZONE SMALL

BUSINESS

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

WOMEN-OWNED SMALL BUSINESS

(WOSB) ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

8(A)

NAICS:

SIZE STANDARD:

11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

13a. THIS CONTRACT IS A

RATED ORDER UNDER

DPAS (15 CFR 700)

13b. RATING

14. METHOD OF SOLICITATION

RFQ

IFB

RFP

15. DELIVER TO

CODE

16. ADMINISTERED BY

CODE

17a. CONTRACTOR/OFFEROR

CODE

FACILITY CODE

18a. PAYMENT WILL BE MADE BY

CODE

TELEPHONE NO.

DUNS:

DUNS+4:

PHONE:

FAX:

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN OFFER 18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK BELOW IS CHECKED

SEE ADDENDUM

19.

20.

21.

22.

23.

24.

ITEM NO.

SCHEDULE OF SUPPLIES/SERVICES

QUANTITY

UNIT

UNIT PRICE

AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA

26. TOTAL AWARD AMOUNT (For Govt. Use Only) 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1, 52.212-4. FAR 52.212-3 AND 52.212-5 ARE ATTACHED. ADDENDA

ARE

ARE NOT ATTACHED.

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

ARE

ARE NOT ATTACHED

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN _______________

29. AWARD OF CONTRACT: REF. ___________________________________ OFFER

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

DATED ________________________________. YOUR OFFER ON SOLICITATION

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED

SET FORTH HEREIN IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER) 30b. NAME AND TITLE OF SIGNER (TYPE OR PRINT) 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER (TYPE OR PRINT) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

(REV. 2/2012)

PREVIOUS EDITION IS NOT USABLE

Prescribed by GSA - FAR (48 CFR) 53.212

7. FOR SOLICITATION

INFORMATION CALL:

STANDARD FORM 1449

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, & 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

653-20-1-188-0002 36C26019Q0635 09-03-2019 Ricki Worthey 360-553-7616 09-10-2019 12:00 Department of Veterans Affairs Network Contracting Office 20 5115 NE 82nd Ave, Suite 102 Vancouver

WA

98662 X X 561492 $15 Million N/A X Department of Veterans Affairs Portland VA Medical Center Warehouse 1601 East Fourth Plain Blvd Vancouver

WA

98661 Y Department of Veterans Affairs Network Contracting Office 20 5115 NE 82nd Ave, Suite 102 Vancouver

WA

98662

Department of Veterans Affairs

FMS-VA-2(101)

Financial Services Center

PO BOX 149971

Austin

TX

78714-9971 See CONTINUATION Page Contract shall provide court recorder services for the Roseburg VA in accordance with the Statement of Work Period of Performance:

Base Period: 10/1/2019 - 9/30/2020 Option Year 1: 10/1/2020 - 9/30/2021 Option Year 2: 10/1/2021 - 9/30/2022 Option Year 3: 10/1/2022 - 9/30/2023 Option Year 4: 10/1/2023 - 9/30/2024 See CONTINUATION Page 653-3600152-188-841100-2580 010044143 X X X Table of Contents

SECTION B - CONTINUATION OF SF 1449 BLOCKS

B.1 CONTRACT ADMINISTRATION DATA

1. Contract Administration: All contract administration matters will be handled by the following individuals:

a. CONTRACTOR:

b. GOVERNMENT: Contracting Officer 36C260

Department of Veterans Affairs Network Contracting Office 20 5115 NE 82nd Ave, Suite 102 Vancouver WA 98662

2. CONTRACTOR REMITTANCE ADDRESS: All payments by the Government to the contractor will be made in accordance with:

3. INVOICES: Invoices shall be submitted in arrears:

4. GOVERNMENT INVOICE ADDRESS: All Invoices from the contractor shall be submitted electronically in accordance with VAAR Clause 852.232-72 Electronic Submission of Payment Requests.

Department of Veterans Affairs

FMS-VA-2(101)

Financial Services Center

PO BOX 149971

Austin TX 78714-9971 ACKNOWLEDGMENT OF AMENDMENTS: The offeror acknowledges receipt of amendments to the Solicitation numbered and dated as follows:

Court Reporter Performance Work Statement

SECTION 1 GENERAL

1.1. The Contractor shall provide all personnel, equipment, tools, materials, supplies, vehicles, certifications, supervision, and all other technologies and technical services to provide Court Reporter services for the Roseburg, Oregon VA Medical Center (VAMC) upon request. The services may be required for, but not limited to: Administrative Investigations, Disciplinary Appeals Boards, Equal Employment Opportunity (EEO) hearings or Merit Systems Protection Board (MSPB) hearings, Office of Resolution Management, or Regional Counsel requirements. It will also be used for any other meetings that require legal documentation.

1.2. PERIOD OF PERFORMANCE.

The period of performance for Court Reporting services shall be for one base and four option years. Court reporting requirements shall occur intermittently through each fiscal year; the requirement may be an urgency of need with only one day in advance notice. However, the VAMC shall strive to inform the Contractor at least thirty (30) days in advance. It must be noted here that the Government does not automatically extend contracts beyond their initial period of performance period. Option periods are always subject to the availability of funds, Contractor’s Performance, Continued Need and FAR Clause 52.217-9, Option to Extend the Term of the Contract.

1.3. BACKGROUND INFORMATION.

The chart below represents best-known estimates for the total number of exams performed per year.

NOTE: The estimated quantities are based on annual historic data based on prior year needs. Actual quantities may be more or less of these estimated amounts.

1.3.4. The term “Administrative Investigation” (AI) refers to a systematic process for determining facts and documenting evidence about matters of significant interest to VA. AIs are conducted to collect and analyze evidence to determine what actually happened and why it happened, so that individual and systemic deficiencies can be identified and effectively corrected. These investigations are governed by VA Directive 0700, Administrative Investigations and VA Handbook 0700, Administrative Investigations. These investigations are established by the Medical Center Director as the convening authority. Administrative Investigation Boards are not scheduled in advance; therefore, short notice will be provided for the need of transcription services. Once scheduled, the schedule may change or even be cancelled at any time up until the time scheduled because of unforeseen events that may arise.

1.3.5. EEO Hearings and MSPB and/or arbitration hearings are similar processes and are established by a judge or other government source. EEO Hearings may be scheduled a few weeks in advance; MSPB hearings may be scheduled several weeks to a month or more in advance. These hearings may also have to be rescheduled or cancelled because of unforeseen events.

1.3.6. The number of witnesses can only be estimated in advance of the start of the process and may change during the course of the investigation or activity.

1.4. PERSONNEL

1.4.1. The Contractor shall provide only qualified certified Court Reporters to perform these services. Only one Court Reporter shall be assigned to each administrative process from its beginning to end. If an unforeseen emergency should occur that would require absence of the assigned Court Reporter, the proposed substitute shall have comparable qualifications to those of the person being replaced. The contractor shall provide a detailed explanation of the circumstances necessitating the proposed substitutions, complete resumes for the proposed substitutes, and any additional information requested by the Contracting Officer (CO).

1.4.2. The Contractor must provide competent, efficient Court Reporters who are experienced and have the necessary training and education in Court Reporting with adequate and appropriate court reporting equipment, in order to produce accurate, timely, appropriately bound and indexed transcribed testimony from witnesses in these processes. Court Reporters must have at least one- year experience in court reporting and have the necessary training and education required in Court Reporting along with adequate and appropriate court reporting equipment, in order to produce accurate, timely, appropriately bound and indexed transcribed testimony from witnesses in these processes. The Court Reporter must hold the certification as a National Court Reports Association (NCRA) Registered Professional Reporter (RPR), or equivalent (determination of equivalency at the discretion of VAMC). Appropriate credentials must be provided within one (1) week upon request. The Court Reporter shall be punctual and present at all proceedings, demonstrate a professional demeanor, and provide all the necessary equipment to perform their duties and accomplish the deliverables described below. VAMC will provide seating and a work surface for the Court Report to perform their duties. The court reporter shall read portions of transcript during the proceedings at the request of the board or other presiding body and ask speakers to clarify inaudible statements. Proceedings may occur over multiple days and the services of the Court Reporter may be needed for varying lengths of time each day. Court Reporters who have experience with the Administrative Investigation Board (AIB) process, Equal Opportunity Hearing, Human Resources Management Merit System Protection Board (MSPB) or arbitration hearings are preferred in the performance of this contract.

1.4.3 OATHS AND NOTARY SERVICES - The Reporter shall be competent to administer oaths. Depositions shall be transcribed by a duly authorized notary. No separate fee is to be charged for notary services, administering oath, or affixing seal.

1.4.4. The Contractor shall assume full responsibility for the protection of its personnel furnishing services under this contract, in accordance with the personnel policy of the Contractor. To carry out this responsibility, the contractor shall provide the following for these personnel:

0. Worker’s compensation

0. Professional liability insurance NOTE: A copy of liability insurance on an individual must be presented to the CO prior that person being assigned to this facility.

0. Health examinations

0. Income tax withholding, and

0. Social security payments

1.4.5. The parties agree that such personnel shall not be considered VA employees for any purpose and shall be considered employees of the contractor. Note: To be in compliance with Homeland Security standards, each Court Reporter assigned to work at this Medical Center shall be subject to the same rules and regulations as all contracted employees. Parking is allowed only in those areas not designated for patient use. All traffic laws and parking rules on the grounds are strictly enforced. Failure to follow these laws and regulations may result in a citation being issued that will have to be resolved through the Federal Court system. Prior to reporting to work, the contracted employee will need to contact the designated POC who will take him/her to the on-site PIV Officer located in building 9. This Officer will issue a temporary ID badge to the contracted employee, who in turn, will properly display the badge while working at the Medical Center. Upon completion of the assignment, the employee will return the badge to the PIV Officer.

1.4.6. The contractor shall ensure that all assigned court reporters perform all work in a professional business-like manner and in accordance with the best standards of the reporting profession and the contractor.

1.4.7. Removing Employees for Misconduct or Security Reasons: The Government, may, at its sole discretion, direct the contractor to remove their employee from the Medical Center or CBOC facilities for misconduct or for security reasons. Removal does not relieve the Contractor the responsibility to continue providing the services required under this contract. The CO will provide the contractor with a written explanation to support any request to remove an employee.

1.4.8. Conflict of Interest: The contractor shall not assign any person who is an employee of the United States Government to work under this contract if that employment would appear to cause a conflict of interest.

1.4.8.1. In any instance where the contractor has knowledge that any actual or potential situation may delay or threaten to delay the timely performance of this contract, the contractor shall immediately notify the POC and the CO. This notice shall include all relevant information and corrective actions that are being taken. The Government reserves the right to hold the contractor fully accountable for problems incurred as a result of such delays, including denial of delivery time extensions, if such notification is not provided.

1.4.8.2. If, after notice of a proposed hearing, the Contractor’s employee does not appear at the time and place specified for the hearing, the contractor shall be responsible for finding another equally qualified individual for the hearing. The Contractor may be responsible for the reimbursement to the VA Medical Center for any expenses over and above that which would have been incurred if the Contractor had performed in accordance with this Performance Work Statement. The Government may deduct such expenses from any other sums due or that may become due the Contractor.

1.4.9. Place of Performance: Most services will be provided at the Roseburg, Oregon VA Medical Center in a conference room setting. Only on a rare occasion, will it be necessary for an investigation or hearing be held at a Community Based Outpatient Clinic (CBOC) or another location as determined by the Government.

North Bend, OR 97459

Brookings, OR 97415

The Government reserves the right to add any additional CBOC’s to the contract as they become available. During the life of this contract, there may be a need or an occasion that may arise that will require the services of the Court Reporter to be at another location other than these mentioned. If so, the POC will give explicit instructions as to where and when the needed services will be required.

1.5. SECURITY REQUIREMENTS

1.5.1 The Contractor will be responsible for ensuring compliance by its employees with the security regulations of the Veteran’s Administration where work is performed under this Contract. A Business Associate’s Agreement (BAA) will be entered into by both parties. Contracted employees will have to complete VA’s Cyber Security and Privacy Act Training annually and sign the VA’s Rules of Behavior document.

Note: All work associated with this contract shall be performed in the United States of America. Because this contract is funded with American appropriated tax dollars, all persons working under this contract shall be American Citizens. There shall be no exception to this requirement.

1.5.2. The information obtained in the performance of this contract is considered to be confidential and must not be revealed to anyone who is not authorized to know. Portions of information disclosed during the performance of this contract are protected by the provisions of the Privacy Act of 1974; therefore, all personnel assigned to this Contract are required to take proper precautions to protect the information from disclosure.

1.5.3. Commitment to Protect Sensitive Information. The Contractor and its employees shall not release, publish, or disclose sensitive information to unauthorized personnel, and shall protect such information in accordance with provisions of 18 U.S.C. 641 (Criminal Code: Public Money, Property or Records) and any other pertinent laws and regulations governing the confidentiality of sensitive information.

1.5.4. In the performance of official duties, the Contractor's employees shall have access to information containing sensitive data, which must be protected under the provisions of the Privacy Act of 1974 (5 USC 552a); the Health Insurance Portability and Accountability Act of 1996 (HIPAA); 45 CFR Parts 160 and 164, Subparts A and E, the Standards for Privacy of Individually Identifiable Health Information (“Privacy Rule”); and 45 CFR Parts 160 and 164, Subparts A and C, the Security Standard (“Security Rule”); Federal Regulations and statutes; and VAMC policies and standard operating procedures. The Contractor and Contractor's employees are responsible for:

· Protecting that data from unauthorized release or from loss, alteration, or unauthorized deletion.

· Completing annual privacy training that conforms to the requirements of VHA Privacy Training.

· Completing annual security awareness training that conforms to the requirement of the Department of Veterans Affairs Office of Cyber and Information Security Training.

· Within 24 hours of first becoming aware of a HIPAA Electronic Transaction and Code Set, Privacy, Security or Standard Identifier Incident, or use or Disclosure of PHI not provided for by this contract, notify the POC and CO, and promptly provide a report to the POC and CO.

· An incident will be considered any attempted or successful unauthorized access to, use, disclosure, modification, or destruction of, or interference with PHI, or an event that causes the VAMC to be considered non-compliance with the Administrative Simplification provisions of HIPAA as determined by the Department of Health and Human Services.

· Use only contractors, subcontractors, or agents who are physically located within a jurisdiction subject to the laws of the United States. Ensure there is no use or disclosure of PHI received from the VAMC in any way that will remove the PHI from such jurisdiction.

· Upon completion of the applicable contract(s), return all PHI gathered, created, received or processed during the performance of the contract(s), and no data will be retained by the Contractor, or any agents or subcontractors, unless retention is required by law or regulation or expressly permitted herein.

· Assure that all PHI has been returned to the POC.

· If immediate return of all data is not possible, assure that all PHI retained will be safeguarded to prevent unauthorized uses or disclosures. Until assurance is provided, the Department of Veterans Affairs may withhold 15% of the final payment of the contract(s).

1.5.5. Computer Security is a vital part of patient rights and privacy. All computer information from VAMC is considered sensitive and shall not be disclosed to anyone by the Contractor, or its employees. The Contractor and its employees shall follow all VAMC computer security guidelines. Violation of this Policy could result in the Federal prosecution of the individual(s) involved.

1.5.6. Confidentiality. All Contractor personnel performing services under this contract must complete a confidentiality certification.

1.6. QUALITY CONTROL.

1.6.1. The contractor shall provide the reviews and quality checks necessary to ensure that the reporting, recording, transcripts and photocopying conform to acceptable government standards. No transcripts shall be forwarded to the government until the quality checks reveal full format conformance and freedom from error.

1.6.2. The Contractor shall closely monitor its performance in meeting the requirements for timely delivery of hearing transcripts. The Contractor shall advise the POC in advance, by specific case number only (no names, SSNs or any other personal identification data) when timely delivery cannot be made, and estimated time when correction of delivery will be made.

1.8. HOURS OF OPERATION.

1.8.1. Normal Business Hours. The VA Medical Center’s normal business hours are 8:00AM to 4:30PM, Monday through Friday, excluding Federal Holidays. Services required by this contract will only be required during normal business hours.

1.8.2. Federal Holidays. The ten holidays observed by the Federal Government are: New Year’s Day; Martin Luther King’s Birthday; President’s Day; Memorial Day; Independence Day; Labor Day; Columbus Day; Veterans’ Day; Thanksgiving Day and Christmas Day and any other day specifically declared by the President of the United States to be a national holiday. In the event a holiday falls on a week end day (Saturday or Sunday), the normal observance is the connecting weekday.

SECTION 2 STANDARD DEFINITIONS

Acceptable Quality Level (AQL). The AQL is the maximum percent defective that, for purposes of sampling inspections can be considered satisfactory.

Administrative Investigation (AI). A process of gathering evidence and ascertaining facts about particular matters, conducted primarily to enhance administrative effectiveness and efficiency.

Administrative Investigation Board (AIB). The standard procedures established under VA Directive 0700 and this Handbook for collecting and analyzing evidence, ascertaining facts, and documenting complete and accurate information regarding matters of interest to VA. “Members” are the person or persons appointed by a Convening Authority to conduct the AIB.

Contracting Officer (CO). A sole individual appointed with the authority to enter into and administer contracts on behalf of the U.S. Government.

Contracting Officer’s Representative (COR). An individual designated by the CO to act as his representative to assist in administering a contract. The source and authority for a COR are contained in the written letter of designation from the CO.

Convening Authority. The authority responsible for convening and supervising administrative investigations under VA Directive 0700. Convening Authorities include the Heads of VA Administrations and Staff Offices, Chief executives of VA facilities, and authorities senior to any of them in the VA organization.

Defective Service. A service output that does not meet the standard of performance associated with it in the Performance Requirements Summary (PRS).

Federal Acquisition Regulations (FAR). The laws governing Government contracting procedures.

Investigative Report (IR). The standard format for conveying the results of an AIB, designed to enhance clarity and to facilitate review and decision-making. The essential components an investigative report are findings of fact, conclusions, and exhibits.

Performance Requirements Summary (PRS). Identifies the key service outputs of the contract that will be evaluated by the government to assure contract performance standards are met by the contractor.

Performance Work Statement (PWS). A statement that outlines the services needed for a Performance Based Service contract.

Quality Control. Those actions taken by a contractor to control the performance of services so that they meet the requirements of the PWS.

SECTION 3 GOVERNMENT FURNISHED PROPERTY AND SERVICES.

The government will provide to the contractor for contract performance at no cost a shared meeting location, utilities, and the use of a telephone (local calls only). Normally, the usage of cell phones within the Medical Center are permitted. However, there are some areas of the hospital where the usage of such devices are restricted because of their possible interference with operating medical equipment. Strict adherence to the rules concerning the usage of these devices must be observed throughout the Medical Center.

SECTION 4 CONTRACTOR FURNISHED ITEMS AND SERVICES.

4.1. GENERAL. Except for those items or services specifically stated to be government furnished in Section 3, the contractor shall furnish everything required to perform this contract.

SECTION 5 SPECIFIC TASKS.

5.1. The contractor agrees that, at a minimum, all assigned court reporters shall:

· Prior to the scheduled meeting time:

· Present himself/herself to the local VA security office in order to obtain a Temporary Identification badge from the appropriate VA Office. (Estimated time for this evolution is 30 minutes.) This badge will have to be returned by the Contracted Employee to the VA issuing office upon completion of the assignment.

· After receipt of badge, proceed to the designated hearing location and have all equipment set up and ready by the scheduled hearing time.

· Adhere strictly to the instructions of the presiding official in matters affecting the composition of the record, adjourning to other times or places, the hours of hearing, and associated matters.

· Report everything spoken while a hearing is in session unless the presiding official directs an off-the-record proceeding for which notes have been taken as required.

5.2. Hearings shall be properly recorded by Court Reporters using electronic recording devices, in addition to their physical presence at the hearing. The Contractor shall provide a back-up system to whichever primary recording method is used. When proceedings are recorded by an electronic recording device, it shall at a minimum:

· have two (2) channels.

· be continuously monitored by an operator.

· have simultaneous playback, listening pre-amplification and speaker identification capabilities.

· have an equipment malfunction indicator.

The Court Reporter must maintain an audio recording of the testimony, available to the team leader or POC for the process as needed to clarify issues associated with testimony content.

5.3. An experienced, competent Court Reporter shall be present in the room when witnesses are interviewed, testimony is given and/or when witnesses are called back for additional testimony. The team leader or other designated VA staff member will inform the Court Reporter of the anticipated duration of the process, and when the process has been completed.

5.4. The Contractor shall provide the reviews and quality checks necessary to ensure that the reporting, recording, transcripts and photocopying conform to acceptable Government standards. No transcripts shall be forwarded to the Government until the quality checks reveal full format conformance and freedom from error.

5.5. When actual discrepancies in the transcribed testimony and the audio recording are identified and verified by the team leader or other designated point of contact, the Court Reporter shall produce a corrected version at no additional cost to the Government.

5.6. The contractor shall be fully responsible for all loss or damage to materials associated with this PWS while in the contractor’s care and custody. The contractor shall keep accurate records of the materials picked up from the government. The listing shall include a list of materials, the status of the assignment and the case number assigned by the Government.

5.7. HEARING AND DELIVERABLES TIMELINES:

5.7.1. The Administrative Investigation Boards have an established timeframe for completion of 45 calendar days of the date the AIB is convened; whereby sworn or affirmed testimony is obtained by a team charged with investigating a particular issue or event. Transcribed testimony must be returned to the Team Leader within 5 business days of each testimony in order for the deadline to be met. In the event that an extension of time should become necessary for completion beyond the initial 45-day period, the presiding official/Team Leader will notify the Court Reporter of this change.

5.7.2. EEO Hearings may have a short turnaround time for completion of 3 Days to 14 Days as established by a judge. Transcribed testimony must be returned to the Team Leader within 3 business days of each testimony in order for the deadline to be met.

5.7.3. MSPB processes rarely exceed 3-5 days. Transcribed testimony must be returned to the Team Leader within 3 business days of each testimony in order for the deadline to be met.

5.8. TRANSCRIPTION FORMAT:

5.8.1. The Court Reporter shall index each individual transcript and include behind each bound testimony a tabbed index stating “WORD INDEX.” The evidence and information gathered during the course of the investigation shall be organized in an appropriately indexed investigative file that includes a numerical or alphabetical list of each time a symbol, number or word was used and the page number and line number.

5.8.2. The transcribed testimony product must be accurate, double-spaced, printed, and bound in a satisfactory manner, according to accepted standards for court reporting, which at a minimum includes one original and one copy of each witnesses’ testimony. All are to be securely fastened with metal prongs (not plastic binding). Line numbers must be listed in the left margin and the page number in the bottom right corner of each page. The court reporter shall include their signed, dated, and officially sealed certificate as the last page of the testimony.

5.8.3. An “ACKNOWLEDGEMENT” sheet shall be included as the last page of each testimony to include a certification statement at the top that the testimony is accurate to include blanks for a date to be filled in and a signature block for each. The second half of this acknowledgement sheet shall include a place for corrections, i.e., Page No. ____, Line No. ____, and a blank to write in the corrections.

5.8.4. Visible Black Character.

5.8.4.1. A Visible Black Character is defined strike-able and visible characters and includes any printed letter, number, symbol, and/or punctuation mark excluding any or all formatting (e.g., bold, underline, italics, table structure, formatting codes). All visible black characters can be seen with the naked eye as a mark, regardless of whether viewed electronically or on a printed page.

5.8.4.2. Visual Black Character (VBC) Line or ASCII no Spaces Line. A VBC Line is defined as the total number of characters you can see with the naked eye, divided by 65. It includes any character contained within a header or footer. Spaces, carriage returns, and hidden format instructions, such as bold, underline, text boxes, printer configurations, spell check, etc., which are not counted in the total character count. A VBC Line is calculated by counting all visual characters and simply dividing the total number of characters by 65 to arrive at the number of defined lines.

5.8.5. All documents shall by typed using black ink on white good quality paper. Paper shall be 8 ½ by 11 inches with ruled margin of 1.5” at the left side and ruled margin of 0.5” at the right side, and a ruled margin of 1” at the top and bottom. A number indicating each line of the document upon each page, i.e., 1 to 25 inclusive, shall be printed at the left side of the left marginal line of the original and copies of the transcript.

5.8.6. Typing shall be 10 letters to the inch, 25 lines to the page, exclusive of pager number, with 2 single spaces between lines. Whenever testimony is continuous, requiring more than 1 line, the typing shall begin as close as possible to the left ruled marginal line. Words shall be properly hyphenated when necessary.

5.8.7. In the original and each copy of the transcript, outside the ruled margin, the cover page and each subsequent page of the transcript (including the Certificate and Acknowledgement) shall show the name, address, and phone number of court reporting service centered at the bottom and the page number of the transcript in the bottom right corner.

5.8.8. The paging of the transcript shall be in a single series by consecutive numbers regardless of the number of days consumed in the investigation, hearing, etc.

5.8.9. The original transcript and (1) copy shall be authenticated by the Official Reporter by a certificate page in the following form, which shall be included before the Acknowledgement:

CERTIFICATE

Certificate of Reporter:

Name of Hearing/Type of Proceeding:

Docket Number:

Place of Hearing:

Date of Hearing:

I, (name of transcriber), do hereby certify that said witness (name of witness), whose testimony appears herein, was duly sworn, that said transcript is a true record of the testimony given by said witness. I further certify that I am neither attorney, nor counsel for, nor related to or employed by, any of the parties in which this action is taken and further that I am not a relative or employee of any attorney or counsel employed by the parties hereto or financially interested in the action.

Name and Signature of Court Reporter Date

Name of Company

5.9. Retention of Notes and Transcripts: The Contractor agrees that all recordings, stenographic notes, or their equivalent, taken in connection with the services rendered under this contract, and typed plate made therefrom, shall be filed and held by the contractor, subject to authority and control of the Department of Veterans Affairs for a period of one year.

5.10. Should the Contractor cause the Government to re-hear any case or hearing or other proceeding, the Contractor shall provide the reporting services at that re-hearing at no cost to the Government. In addition, the Contractor shall be liable for all Government expenses, claimant expenses and attorney's fees incidental to the re-hearing. Although not a comprehensive list of examples, causes for re-hearings may include:

· Loss of original recordings, transcripts or photocopies.

· Failure of the contractor’s court reporter/stenographer to appear, and a substitute cannot be obtained in sufficient time.

· Receipt of products by the Government in such poor condition as to be unusable.

· Attempted use of electronic recording equipment which does not conform to the requirements noted herein.

· Failure of the Contractor to deliver transcripts (original and 1 copy) within three (3) business days after a hearing.

VA Information and Information System Security/Privacy Language

1. General:

Contractors, contractor personnel, subcontractors, and subcontractor personnel shall be subject to the same Federal laws, regulations, standards, and VA Directives and Handbooks as VA and VA personnel regarding information and information system security.

2. Access to VA Information and VA Information Systems:

a. A contractor/subcontractor shall request logical (technical) or physical access to VA information and VA information systems for their employees, subcontractors, and affiliates only to the extent necessary to perform the services specified in the contract, agreement, or task order.

b. All contractors, subcontractors, and third-party servicers and associates working with VA information are subject to the same investigative requirements as those of VA appointees or employees who have access to the same types of information. The level and process of background security investigations for contractors must be in accordance with VA Directive and Handbook 0710, Personnel Suitability and Security Program. The Office for Operations, Security, and Preparedness is responsible for these policies and procedures.

c. Contract personnel who require access to national security programs must have a valid security clearance. National Industrial Security Program (NISP) was established by Executive Order 12829 to ensure that cleared U.S. defense industry contract personnel safeguard the classified information in their possession while performing work on contracts, programs, bids, or research and development efforts. The Department of Veterans Affairs does not have a Memorandum of Agreement with Defense Security Service (DSS). Verification of a Security Clearance must be processed through the Special Security Officer located in the Planning and National Security Service within the Office of Operations, Security, and Preparedness.

d. Custom software development and outsourced operations must be located in the U.S. to the maximum extent practical. If such services are proposed to be performed abroad and are not disallowed by other VA policy or mandates, the contractor/subcontractor must state where all non-U.S. services are provided and detail a security plan, deemed to be acceptable by VA, specifically to address mitigation of the resulting problems of communication, control, data protection, and so forth. Location within the U.S. may be an evaluation factor.

e. The contractor or subcontractor must notify the Contracting Officer immediately when an employee working on a VA system or with access to VA information is reassigned or leaves the contractor or subcontractor’s employ. The Contracting Officer must also be notified immediately by the contractor or subcontractor prior to an unfriendly termination.

3. VA Information Custodial Language:

a. Information made available to the contractor or subcontractor by VA for the performance or administration of this contract or information developed by the contractor/subcontractor in performance or administration of the contract shall be used only for those purposes and shall not be used in any other way without the prior written agreement of the VA. This clause expressly limits the contractor/subcontractor's rights to use data as described in Rights in Data - General, FAR 52.227-14(d) (1).

b. VA information should not be co-mingled, if possible, with any other data on the contractors/subcontractor’s information systems or media storage systems in order to ensure VA requirements related to data protection and media sanitization can be met. If co-mingling must be allowed to meet the requirements of the business need, the contractor must ensure that VA’s information is returned to the VA or destroyed in accordance with VA’s sanitization requirements. VA reserves the right to conduct on- site inspections of contractor and subcontractor IT resources to ensure data security controls, separation of data and job duties, and destruction/media sanitization procedures are in compliance with VA directive requirements.

c. Prior to termination or completion of this contract, contractor/subcontractor must not destroy information received from VA, or gathered/created by the contractor in the course of performing this contract without prior written approval by the VA. Any data destruction done on behalf of VA by a contractor/subcontractor must be done in accordance with National Archives and Records Administration (NARA) requirements as outlined in VA Directive 6300, Records and Information Management and its Handbook 6300.1 Records Management Procedures, applicable VA Records Control Schedules, and VA Handbook 6500.1, Electronic Media Sanitization. Self-certification by the contractor that the data destruction requirements above have been met must be sent to the VA Contracting Officer within 30 days of termination of the contract.

d. The contractor/subcontractor must receive, gather, store, back up, maintain, use, disclose and dispose of VA information only in compliance with the terms of the contract and applicable Federal and VA information confidentiality and security laws, regulations and policies. If Federal or VA information confidentiality and security laws, regulations and policies become applicable to the VA information or information systems after execution of the contract, or if NIST issues or updates applicable FIPS or Special Publications (SP) after execution of this contract, the parties agree to negotiate in good faith to implement the information confidentiality and security laws, regulations and policies in this contract.

e. The contractor/subcontractor shall not make copies of VA information except as authorized and necessary to perform the terms of the agreement or to preserve electronic information stored on contractor/subcontractor electronic storage media for restoration in case any electronic equipment or data used by the contractor/subcontractor needs to be restored to an operating state. If copies are made for restoration purposes, after the restoration is complete, the copies must be appropriately destroyed.

f. If VA determines that the contractor has violated any of the information confidentiality, privacy, and security provisions of the contract, it shall be sufficient grounds for VA to withhold payment to the contractor or third party or terminate the contract for default or terminate for cause under Federal Acquisition Regulation (FAR) part 12.

g. If VHA contract is terminated for cause, the associated BAA must also be terminated, and appropriate actions taken in accordance with VHA Handbook 1600.01, Business Associate Agreements. Absent an agreement to use or disclose protected health information, there is no business associate relationship.

h. The contractor/subcontractor contract is terminated for cause, the associated BAA must also be terminated, and appropriate actions taken in accordance with VHA Handbook 1600.01, Business Associate Agreements. Absent an agreement to use or disclose protected health information, there is no business associate relationship.

i. The contractor/subcontractor’s firewall and Web services security controls, if applicable, shall meet or exceed VA’s minimum requirements. VA Configuration Guidelines are available upon request.

j. Except for uses and disclosures of VA information authorized by this contract for performance of the contract, the contractor/subcontractor may use and disclose VA information only in two other situations: (i) in response to a qualifying order of a court of competent jurisdiction, or (ii) with VA’s prior written approval. The contractor/subcontractor must refer all requests for, demands for production of, or inquiries about, VA information and information systems to the VA contracting officer for response.

k. Notwithstanding the provision above, the contractor/subcontractor shall not release VA records protected by Title 38 U.S.C. 5705, confidentiality of medical quality assurance records and/or Title 38 U.S.C. 7332, confidentiality of certain health records pertaining to drug addiction, sickle cell anemia, alcoholism or alcohol abuse, or infection with human immunodeficiency virus. If the contractor/ subcontractor is in receipt of a court order or other requests for the above-mentioned information, that contractor/subcontractor shall immediately refer such court orders or other requests to the VA contracting officer for response.

l. For service that involves the storage, generating, transmitting, or exchanging of VA sensitive information but does not require C&A or an MOU-ISA for system interconnection, the contractor/subcontractor must complete a Contractor Security Control Assessment (CSCA) on a yearly basis and provide it to the COTR.

4. Information System Design and Development

a. Information systems that are designed or developed for or on behalf of VA at non-VA facilities shall comply with all VA directives developed in accordance with FISMA, HIPAA, NIST, and related VA security and privacy control requirements for Federal information systems. This includes standards for the protection of electronic PHI, outlined in 45 C.F.R. Part 164, Subpart C, information and system security categorization level designations in accordance with FIPS 199 and FIPS 200 with implementation of all baseline security controls commensurate with the FIPS 199 system security categorization (reference Appendix D of VA Handbook 6500, VA Information Security Program). During the development cycle a Privacy Impact Assessment (PIA) must be completed, provided to the COTR, and approved by the VA Privacy Service in accordance with Directive 6507, VA Privacy Impact Assessment.

b. The contractor/subcontractor shall certify to the COTR that applications are fully functional and operate correctly as intended on systems using the VA Federal Desktop Core Configuration (FDCC), and the common security configuration guidelines provided by NIST or the VA. This includes Internet Explorer 7 configured to operate on Windows XP and Vista (in Protected Mode on Vista) and future versions, as required.

c. The standard installation, operation, maintenance, updating, and patching of software shall not alter the configuration settings from the VA approved and FDCC configuration. Information technology staff must also use the Windows Installer Service for installation to the default “program files” directory and silently install and uninstall.

d. Applications for normal end users shall run in the standard user context without elevated system administration privileges.

e. The security controls must be designed, developed, approved by VA, and implemented in accordance with the provisions of VA security system development life cycle as outlined in NIST Special Publication 800-37, Guide for Applying the Risk Management Framework to Federal Information Systems, VA Handbook 6500, Information Security Program and VA Handbook 6500.5, Incorporating Security and Privacy in System Development Lifecycle.

f. The contractor/subcontractor is required to design, develop, or operate a System of Records Notice (SOR) on individuals to accomplish an agency function subject to the Privacy Act of 1974, (as amended), Public Law 93-579, December 31, 974 (5 U.S.C. 552a) and applicable agency regulations. Violation of the Privacy Act may involve the imposition of criminal and civil penalties.

g. The contractor/subcontractor agrees to:

i. Comply with the Privacy Act of 1974 (the Act) and the agency rules and regulations issued under the Act in the design, development, or operation of any system of records on individuals to accomplish an agency function when the contract specifically identifies:

1. The System of Records (SOR): and

2. The design, development, or operation work that the contractor/subcontractor is to perform;

ii. Include the Privacy Act notification contained in this contract in every solicitation and resulting subcontract and in every subcontract awarded without a solicitation, when the work statement in the proposed subcontract requires the redesign, development, or operation of a SOR on individuals that is subject to the Privacy Act; and

iii. Include this Privacy Act clause, including this subparagraph (3), in all subcontracts awarded under this contract which requires the design, development, or operation of such a SOR.

h. In the event of violations of the Act, a civil action may be brought against the agency involved when the violation concerns the design, development, or operation of a SOR on individuals to accomplish an agency function, and criminal penalties may be imposed upon the officers or employees of the agency when the violation concerns the operation of a SOR on individuals to accomplish an agency function. For purposes of the Act, when the contract is for the operation of a SOR on individuals to accomplish an agency function, the contractor/subcontractor is considered to be an employee of the agency.

i. “Operation of a System of Records” means performance of any of the activities associated with maintaining the SOR, including the collection, use, maintenance, and dissemination of records.

ii. “Record” means any item, collection, or grouping of information about an individual that is maintained by an agency, including, but not limited to, education, financial transactions, medical history, and criminal or employment history and contains the person’s name, or identifying number, symbol, or any other identifying particular assigned to the individual, such as a fingerprint or voiceprint, or a photograph.

iii. “Systems of Records” means a group of any records under the control of any agency from which information is retrieved by the name of the individual or by some identifying number, symbol, or other identifying particular assigned to the individual.

i. The vendor shall ensure the security of all procured or developed systems and technologies, including their subcomponents (hereinafter referred to as “Systems”), throughout the life of this contract and any extension, warranty, or maintenance periods.