36C25718Q0486-002.docx

The Network Contracting Office 17 intends to award a firm-fixed contract in accordance with FAR Part 12, Acquisition of Commercial Items for the purchase of a NMIS enterprise software solution for VA North Texas Medical Center, Nuclear Medicine Department. This is a Combined Synopsis/Solicitation for commercial items prepared in accordance with the format in Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation. The solicitation number is 36C25718Q0486. This acquisition is issued as a Request for Quote (RFQ). The solicitation document and incorporated provisions and clauses are those in effect through Federal Acquisition Circular 2005-92, effective December 19, 2016. The associated North American Industrial Classification System Code (NAICS) for this procurement is 325412 with a size standard of 1,250 employees.

Responses to the solicitation are due by March 1, 2018 at 1:00PM Central Time (CT) via e-mail to severino.sarabia@va.gov.

ADDNEDUM TO FAR 52.212-1 INSTRUCTIONS TO OFFERORS – COMMERCIAL ITEMS (OCT 2015)

Provisions that are incorporated by reference (by Citation Number, Title, and Date), have the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available.

The following provisions are incorporated into 52.212-1 as an addendum to this solicitation:

The respondent shall submit their quote in section III below.

All interested parties MUST be registered in the System for Award Management (SAM) Database and have completed On-Line Representation and Certifications Application (ORCA) in order to receive a contract award. If you are not registered with SAM, you may request an application via phone at 866-606-8220 or register on-line at https://www.sam.gov. To keep informed of changes: Check www.fbo.gov frequently.

This Request for Quote (RFQ) is issued in accordance with Far 12 and in conjunction with Simplified Acquisition Procedures Far 13.5. Evaluation lowest price technically acceptable will be performed in accordance with procedures outlined in FAR 13.106. A single award will be made to the lowest priced quote who meets the requirements in schedule below.

All Invoices from the contractor shall be submitted electronically in accordance with VAAR Clause 852.232-72 Electronic Submission of Payment Requests.

For assistance setting up e-Invoice, the below information is provided:

*OB10 e-Invoice Setup Information: 1-877-489-6135 *OB10 e-Invoice email: VA.Registration@ob10.com http://VA.Registration@ob10.com/ *FSC e-invoice contact information: 1-877-353-9791 *FSC e-invoice email: vafsccshd@va.gov http://va.gov/

TYPE OF CONTRACT: VA anticipates a Single Award, Firm-Fixed Price contract. The contractor shall propose a fixed amount for NMIS, or equivalent products, line items below –

SCHEUDLE OF SUPPLIES AND SERVICES

Delivery/Installation:

30 days after receipt of award to VA Medical Center Dallas (Nuclear Medicine)

Delivery/Installation:

1. VA Medical Center Dallas (Nuclear Medicine)

Period of Performance (PoP): 12 months

Unlimited User License for any site that has a Network Software – 3 user licenses

PoP: 12 months

Delivery/Installation:

1. VA Medical Center Dallas (Nuclear Medicine)

2. VA Forth Worth Outpatient Clinic (Outpatient Imaging Center)

PoP: 15 days

Delivery/Installation:

1. VA Medical Center Dallas (Nuclear Medicine)

PoP: 30 days

Delivery:

1. Fort Worth Outpatient Clinic (Outpatient Imaging Center)

PoP: 12 months

Delivery:

1. VA Medical Center Dallas (Nuclear Medicine)

2. Fort Worth Outpatient Clinic (Outpatient Imaging Center)

PoP: 12 months

Delivery:

1. VA Medical Center Dallas (Nuclear Medicine)

2. Fort Worth Outpatient Clinic (Outpatient Imaging Center)

PoP: 12 months

PoP: 12 months

PoP: 12 months

PoP: 12 months

PoP: 12 months

SCHEDULE OF SUPPLIES: The Contractor shall provide the required equipment, licenses, support, and maintenance in accordance with the below statement of work.

STATEMENT OF WORK

1. CONTRACTING OFFICERS TECHNICAL REPRESENTATIVE (COR): VANTHCS will appoint one (1) COR for this contract. The COR will come from the Nuclear Medicine Service. When a service call has been placed, the contractor will always contact the Nuclear Medicine Service at 214-857-0138.

2. PROJECT SCOPE AND REQUIREMNTS: The NMIS has been utilized with the Nuclear Medicine Service for 16 years. It is used as an extensive electronic patient record keeping system for the receipt and return of all radioactive material.

a. Enterprise Solution: Allows data to be installed on a single server and accessed from multiple hospitals/clinics and includes unlimited user license for the Dallas VA Medical Center and VA Fort Worth Outpatient Clinic

b. HL7 Interface: Provides the ability to share data between any hospital or radiology information system and the NMIS program; all pertinent patient demographic data will already be pre-filled within the scheduler module of NMIS.

c. Patient Reporting: Allows health professionals to customize and build patients’ reports as they move through the Nuclear Cardiac stress testing exam process

d. NMIS Enterprise Annual Software & Support: To ensure proper maintenance of software to include software upgrades and technical support

e. On-site Training: To ensure proper utilization, familiarity, and management of Enterprise Solution by users and Biomedical staff

VANTHCS NMIS capabilities (Current)

f. Bar Coding Capability: To ensure proper documentation and record keeping of all radiopharmaceuticals. Limit manually input data.

g. Patient Database (Filecard): Tracks patient study history and radiopharmaceutical administration.

h. Quality Control: Maintains all quality control records for Radiopharmacy equipment; such as dose calibrator, well counters and monitoring devices, IAW with local and federal inspection guidelines.

i. Area Monitoring & Wipes: Maintains all wipes and daily surveys with ability to divide into specific areas and groups: IAW local and federal guidelines.

j. Disposal: Tracks and records all disposal records from receipt to decay, ability to create individual disposal bins.

k. Statistical Analysis: Complete and accurate statistical analysis of exams, radiopharmaceutical and other categories of Nuclear Medicine data.

l. Dosimetry: Radiation absorbed doses can be calculated for exact dose administered including all critical organs, IAW with all local, federal and TJC requirements.

m. Patient reports: Print multiple reports on usage, disposal & dosimetry

n. Backup System: Automated back-ups to run at preset times and locations

Recommended/Required hardware specifications:

NMIS Network Systems - Workstation A. Operating System requirements (Any one of the following):

1. Windows 8

2. Windows 7 B. Hardware Requirements:

1. Intel Core 2 Duo System

2. 4 GB RAM

3. Hard Drive: 500 GB 7.2k RMP SATA Hard Drive

4. Monitor: 17” LCD Display w/speakers

5. DVD/RW Drive

6. Windows Server 2012 R2 Standard

7. 1 GB NIC

8. Rack Rails

9. Mouse & Keyboard C. Internet requirements:

1. Internet access suggested for program updates D. Backup Requirements

1. Shared network drive with full control for users

3. SCHEDULED MAINTENANCE & REPAIR PROCEDURES: Contractor must provide Nuclear Medicine Service with a written description of the procedures to be performed on the aforementioned equipment item. The description must be provided in sufficient detail so as to be acceptable to the field inspectors of the Joint Commission on Accreditation of Healthcare Organizations. This shall be provided within 30 days service performed

a. All equipment covered under equipment warranty will receive preventive maintenance and repairs when contacted in accordance with manufacturer’s specifications.

b. All scheduled preventive maintenance, and repairs performed, shall be accompanied by a technician’s work-order, describing in detail, all work that has been done, including parts used, and P/N’s, (part numbers).

c. The C&A requirements do not apply, and that a Security Accreditation Package is not required.

4. SCHEDULING ARRANGEMENTS: When service is needed, repairs, and preventative maintenance will be provided onsite, 7:00 a.m. to 5:00 p.m., CST (Central Standard Time) Monday thru Friday, (excluding holidays). The Contractor must provide the COR with a statement describing an acceptable arrangement for notifying the VANTHCS when equipment should be made available for servicing. This shall be provided within 30 days of requested service.

NMIS Network Software

a) Software support agreement covers all questions associated with operation & functionality of software system

b) Support also involves restoring of data, transferring data to another system or software issues that involve NMIS program

c) Provide all necessary software upgrades to the equipment at no cost to the facility.

5. PERSONNEL CLEARANCES AND PRIVACY CONSIDERATIONS: The Vendor will ensure that their personnel and subcontractor personnel meet the privacy standards as set forth by HIPPA (Health Insurance Portability and Accountability Act of 1996) with respect personal and confidential information that they may come upon, while servicing medical equipment

6. DOCUMENTATION: Contractor will provide the COR, and/or the Nuclear Medicine Service’s designee with individual written reports which describe the maintenance and repair service performed on the equipment in sufficient detail so as to be acceptable by field inspectors of the Joint Commission of Accreditation of Healthcare Organizations. This shall include a list of all parts replaced, all service performed as well as a statement that the equipment is operating per manufacturer’s specifications after repair. The service report will be signed by the contractor’s service technician, and by designated VANTHCS personnel. A copy will be given to the VANTHCS for their internal records.

a. Prior to award, bidder must have a facility to include personnel, test equipment, parts inventory, licenses and technical documentation available for inspection by VA Medical Center personnel and be able to show written evidence to technical qualifications of personnel, test equipment (and calibration documentation) licenses and availability of parts. Parts availability must be written documentation from either the equipment manufacturer or authorized parts supplier. In either case, bidder must be able to show the availability of parts to him/her within 24 hours after initial call. For contracts for maintenance and repair services form other than the original manufacturer or a designated representative, the Contractor will be fully responsible for obtaining all technical documentation necessary to fulfill contractual obligations.

b. The Contractor warrants that the services to be performed under this contract will be performed in a good workmanship manner and shall conform to the standards of the industry. This warranty is given expressly and in place of all other warranties, expressed or implied, statutory or otherwise, and is the only warranty given by the Contractor.

c. Warranty items that expire during the contract period will be added to the contract as appropriate.

7. NEGLIGANCE CLAUSE: When services and parts are required as a result of accident, abuse, misuse or negligence by other than the Contractor or his representative, and are not included as a part of PM inspection or service calls, such needs will be reported to the Contracting Officer’s representative along with estimates of charges. The Contracting Officer and Representative will evaluate these needs and authorize appropriate action. The parts will be installed under the terms of the contact and each invoice is to include a legible itemized list of labor charges and parts costs. The government will incur no charges for service and parts including glassware due to accident, abuse, misuse or negligence by the contractor or his representative.

8. FAILURE TO RESTORE THE FULL PERFOMANCE: For failure to restore equipment to full performance within a reasonable amount of time, from the original service call, a deduction of one month’s rate will taken. This penalty will be waived under unusual or extraordinary circumstances at the decision of the VA.

9. END OF CONTRACT: Contractor guarantees that all equipment covered in this contract shall meet or exceed manufacturer’s performance specifications at the contract expiration date. At the end of the contract term and within the two weeks following the award to the new Contractor, there will be a final inspection of all equipment at which the Contractor, the new Contractor and the Contracting Officer’s representative will be present. Any deficiencies noted will be the responsibility of the previous Contractor and shall be corrected by the terms of this contract.

11. Security Statement Requirements:

1. No memory device will be removed from the VA Facility without the approval of the Facility Information Security Officer (ISO).

Bio-Medical devices and other equipment or systems (workstations, copies, FAX, prints) containing media (hard drives, optical disks, etc.) with VA sensitive information must not be returned to the vendor during off site repairs, warranty period, at the end of lease, for trade-in, or other purposes. Vendor must accept the system without the drive;

1. Information made available to the contractor or subcontractor by VA for the performance or administration of this contract or information developed by the contractor/subcontractor in performance or administration of the contract shall be used only for those purposes and shall not be used in any other way without the prior written agreement of the VA. This clause expressly limits the contractor/subcontractor's rights to use data as described in Rights in Data General, FAR 52.227-14(d) (1).

No VA information shall be transferred outside of the VA.

1. The term “security incident” means an event that has, or could have, resulted in unauthorized access to, loss or damage to VA assets, or sensitive information, or an action that breaches VA security procedures. In such an event, the contractor/subcontractor shall immediately notify the COTR and simultaneously, the designated ISO and Privacy Officer for the contract of any known or suspected security/privacy incidents, or any unauthorized disclosure of sensitive information, including that contained in system(s) to which the contractor/subcontractor has access.

1. Consistent with the requirements of 38 U.S.C. §5725, a contract may require access to sensitive personal information. If so, the contractor is liable to VA for liquidated damages in the event of a data breach or privacy incident involving any SPI the contractor/subcontractor processes or maintains under this contract.

1. Based on the determinations of the independent risk analysis, the contractor shall be responsible for paying to the VA liquidated damages in the amount of $29.95 per affected individual to cover the cost of providing credit protection services to affected individuals consisting of the following:

4. Notification;

4. One year of credit monitoring services consisting of automatic daily monitoring of at least 3 relevant credit bureau reports;

4. Data breach analysis;

4. Fraud resolution services, including writing dispute letters, initiating fraud alerts and credit freezes, to assist affected individuals to bring matters to resolution;

4. One year of identity theft insurance with $20,000.00 coverage at $0 deductible; and

4. Necessary legal expenses the subjects may incur to repair falsified or damaged credit records, histories, or financial affairs.

1. Training

5. All contractor employees and subcontractor employees requiring access to VA information and VA information systems shall complete the following before being granted access to VA information and its systems:

0. Sign and acknowledge (either manually or electronically) understanding of and responsibilities for compliance with the Contractor Rules of Behavior, Appendix E relating to access to VA information and information systems;

0. Successfully complete the VA Cyber Security Awareness and Rules of Behavior training and annually complete required security training;

0. Successfully complete the appropriate VA privacy training and annually complete required privacy training; and

0. Successfully complete any additional cyber security or privacy training, as require VA personnel with equivalent information system access [to be defined by the VA program official and provided to the contracting officer for inclusion in the solicitation document – e.g., any role-based information security training required in accordance with NIST Special Publication 800-16, Information Technology Security Training Requirements.]

5. The contractor shall provide to the contracting officer and/or the COTR a copy of the training certificates and certification of signing the Contractor Rules of Behavior for each applicable employee within 1 week of the initiation of the contract and annually thereafter, as required.

5. Failure to complete the mandatory annual training and sign the Rules of Behavior annually, within the timeframe required, is grounds for suspension or termination of all physical or electronic access privileges and removal from work on the contract until such time as the training and documents are complete.

5. If a vendor that anticipates that the services under the contract will be performed by 10 or more individual, the Contractor Rules of Behavior may be signed by the vendor’s designated representative. By signing the Rules of Behavior on behalf of the vendor that the designated representative agrees to ensure that all such individual review and understand the Contractor Rule of Behavior when accessing the VA’s information and information systems.

Records Management

1) All records (administrative and program specific) created during the period of the contract belong to VA North Texas Health care System (VANTHCS) and must be returned to VANTHCS at the end of the contract or destroyed in accordance to the VHA Record Control Schedule (RCS) 10-1.

A.1 52.212-2 EVALUATION—COMMERCIAL ITEMS (OCT 2014)

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, based on lowest price, technically acceptable. The technical specification of proposed solution must at a minimum meet the deliverables on schedule.

(b) Options. The Government will evaluate quotes for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that a quote is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the Government to exercise the option(s).

(c) A written notice of award or acceptance of a quote, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

(End of Provision) A.2 52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS—COMMERCIAL ITEMS (DEC 2016) The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (t) of this provision.

(a) Definitions. As used in this provision— Administrative merits determination means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

Arbitral award or decision means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

Civil judgment means—

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

DOL Guidance means the Department of Labor (DOL) Guidance entitled: “Guidance for Executive Order 13673, ‘Fair Pay and Safe Workplaces’ “. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

Economically disadvantaged women-owned small business (EDWOSB) concern means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

Enforcement agency means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are—

(1) Department of Labor Wage and Hour Division (WHD) for—

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(v) The Family and Medical Leave Act; and

(vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for—

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for—

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for—

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

Forced or indentured child labor means all work or service—

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

Highest-level owner means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

Immediate owner means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

Inverted domestic corporation means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

Labor compliance agreement means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

Labor laws means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

Labor law decision means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of “labor laws”.

Manufactured end product means any end product in product and service codes (PSCs) 1000-9999, except—

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

Place of manufacture means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

Predecessor means an entity that is replaced by a successor and includes any predecessors of the predecessor.

Restricted business operations means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate—

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

“Sensitive technology”—

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically—

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

Service-disabled veteran-owned small business concern—

(1) Means a small business concern—

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

Small disadvantaged business concern, consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that—

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by—

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

Subsidiary means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

Successor means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

Veteran-owned small business concern means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

Women-owned business concern means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

Women-owned small business concern means a small business concern—

(1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127), means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: “Administrative merits determination”, “Arbitral award or decision”, paragraph (2) of “Civil judgment”, “DOL Guidance”, “Enforcement agency”, “Labor compliance agreement”, “Labor laws”, and “Labor law decision”. The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(b)(1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAM website.

(2) The offeror has completed the annual representations and certifications electronically via the SAM website access through http://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications—Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs .

(c) Offerors must complete the following representations when the resulting contract will be performed in the United States or its outlying areas. Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it [ ] is, [ ] is not a small business concern.

(2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [ ] is, [ ] is not a veteran-owned small business concern.

(3) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.] The offeror represents as part of its offer that it [ ] is, [ ] is not a service-disabled veteran-owned small business concern.

(4) Small disadvantaged business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [ ] is, [ ] is not a small disadvantaged business concern as defined in 13 CFR 124.1002.

(5) Women-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [ ] is, [ ] is not a women-owned small business concern.

(6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that—

(i) It [ ] is, [ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: ___________.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that—

(i) It [ ] is, [ ] is not an EDWOSB concern, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: ___________.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

Note: Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold.

(8) Women-owned business concern (other than small business concern). [Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [ ] is a women-owned business concern.

(9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price:

(10) HUBZone small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that—

(i) It [ ] is, [ ] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material change in ownership and control, principal office, or HUBZone employee percentage has occurred since it was certified by the Small Business Administration in accordance with 13 CFR Part 126; and

(ii) It [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR Part 126, and the representation in paragraph (c)(10)(i) of this provision is accurate for the HUBZone small business concern or concerns that are participating in the joint venture. [The offeror shall enter the name or names of the HUBZone small business concern or concerns that are participating in the joint venture:____________.] Each HUBZone small business concern participating in the joint venture shall submit a separate signed copy of the HUBZone representation.

(d) Representations required to implement provisions of Executive Order 11246—

(1) Previous contracts and compliance. The offeror represents that—

(i) It [ ] has, [ ] has not participated in a previous contract or subcontract subject to the Equal Opportunity clause of this solicitation; and

(ii) It [ ] has, [ ] has not filed all required compliance reports.

(2) Affirmative Action Compliance. The offeror represents that—

(i) It [ ] has developed and has on file, [ ] has not developed and does not have on file, at each establishment, affirmative action programs required by rules and regulations of the Secretary of Labor (41 CFR parts 60-1 and 60-2), or

(ii) It [ ] has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor.

(e) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352). (Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract. If any registrants under the Lobbying Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made.

(f) Buy American Certificate. (Applies only if the clause at Federal Acquisition Regulation (FAR) 52.225-1, Buy American—Supplies, is included in this solicitation.)

(1) The offeror certifies that each end product, except those listed in paragraph (f)(2) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.” The terms “commercially available off-the-shelf (COTS) item,” “component,” “domestic end product,” “end product,” “foreign end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American—Supplies.”

(2) Foreign End Products:

Line Item No Country of Origin [List as necessary]

(3) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.

(g)(1) Buy American—Free Trade Agreements—Israeli Trade Act Certificate. (Applies only if the clause at FAR 52.225-3, Buy American—Free Trade Agreements—Israeli Trade Act, is included in this solicitation.)

(i) The offeror certifies that each end product, except those listed in paragraph (g)(1)(ii) or (g)(1)(iii) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The terms “Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end product,” “commercially available off-the-shelf (COTS) item,” “component,” “domestic end product,” “end product,” “foreign end product,” “Free Trade Agreement country,” “Free Trade Agreement country end product,” “Israeli end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act.”

(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”:

Free Trade Agreement Country End Products (Other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products:

Line Item No. Country of Origin [List as necessary]

(iii) The offeror shall list those supplies that are foreign end products (other than those listed in paragraph (g)(1)(ii) of this provision) as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act.” The offeror shall list as other foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.”

Other Foreign End Products:

Line Item No. Country of Origin [List as necessary]

(iv) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.

(2) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate I. If Alternate I to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”:

Canadian End Products:

Line Item No.

[List as necessary]

(3) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate II. If Alternate II to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products or Israeli end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”:

Canadian or Israeli End Products:

Line Item No. Country of Origin [List as necessary]

(4) Buy American—Free Trade Agreements—Israeli Trade Act Certificate, Alternate III. If Alternate III to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled “Buy American—Free Trade Agreements—Israeli Trade Act”:

Free Trade Agreement Country End Products (Other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products:

Line Item No. Country of Origin [List as necessary]

(5) Trade Agreements Certificate. (Applies only if the clause at FAR 52.225-5, Trade Agreements, is included in this solicitation.)

(i) The offeror certifies that each end product, except those listed in paragraph (g)(5)(ii) of this provision, is a U.S.-made or designated country end product, as defined in the clause of this solicitation entitled “Trade Agreements”.

(ii) The offeror shall list as other end products those end products that are not U.S.-made or designated country end products.

Other End Products:

Line Item No. Country of Origin [List as necessary]

(iii) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. For line items covered by the WTO GPA, the Government will evaluate offers of U.S.-made or designated country end products without regard to the restrictions of the Buy American statute. The Government will consider for award only offers of U.S.-made or designated country end products unless the Contracting Officer determines that there are no offers for such products or that the offers for such products are insufficient to fulfill the requirements of the solicitation.

(h) Certification Regarding Responsibility Matters (Executive Order 12689). (Applies only if the contract value is expected to exceed the simplified acquisition threshold.) The offeror certifies, to the best of its knowledge and belief, that the offeror and/or any of its principals—

(1) [ ] Are, [ ] are not presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(2) [ ] Have, [ ] have not, within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission…