Splunk Enterprise Support
Added: Jul 25, 2017 8:37 pm Request for QuoteSplunk Enterprise SupportNotice Type: Request for QuotePosted Date: July 25, 2017Response Date: August 1, 2017Classification Date: RNAICS Code: 541512Department/Agency: Department of EducationFederal Student AidAgency Department: Federal Student AidAcquisitionsTitle: Software MaintenanceDescription: Splunk Enterprise Support1. Software Maintenance Required:Part Number Description QuantityES-P-ESUP Splunk Enterprise Support for 800GBs 1ES-P-ESUP Splunk Enterprise Security App Support for 800GBs 1Software Maintenance for the software product stated above.2. Period of PerformanceBelow is the software maintenance period of performance.Year Period of PerformanceBase 08/02/2017 to 08/01/2018Option 1: 08/02/2018 to 08/01/2019Option 2: 08/02/2019 to 08/01/2020Option 3: 08/02/2020 to 08/01/2021Option 4: 08/01/2021 to 08/01/20223. Price Quote:Offerors shall provide their price quote using the following pricing format:Year Description Quantity Proposed PriceBase: Splunk Enterprise Support 1 Option 1: Splunk Enterprise Support 1 Option 2: Splunk Enterprise Support 1 Option 3: Splunk Enterprise Support 1 Option 4: Splunk Enterprise Support 1 Total Price4. Instructions to Offerors:A. Type of Purchase Orders: The purchase order awarded will be a firm-fixed price.B. Certified Reseller: Offeror must be a Splunk re-seller.C. Price Quote: Offeror shall provide their price quote in the formatted outlined in Section 3 of this Request for Quote.D. Proposal Due Date: August 1, 2017E. Quote Submission: Quotes shall be submitted by email to Bernard.Barr@ed.gov by 4PM on August 1, 2107.F. Federal Student Aid Points of Contact:Contracts Specialist:Bernard BarrEmail: Bernard.Barr@ed.govPhone: 202-377-4210G. Multi-year or Bundle Offers: Federal Student Aid cannot commit to multi-year or bundled offers, proposals/quotes requiring multi-year commitments or bundled pricing requiring acceptance of all associated years - will not be accepted, and considered non-responsive.5. Terms and Conditions52.212-1 Instructions to Offerors-Commercial ItemsInstructions to Offerors-Commercial Items (Oct 2015)(a) North American Industry Classification System (NAICS) code and small business size standard. The NAICS code and small business size standard for this acquisition appear in Block 10 of the solicitation cover sheet (SF 1449). However, the small business size standard for a concern which submits an offer in its own name, but which proposes to furnish an item which it did not itself manufacture, is 500 employees. (b) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. Offers may be submitted on the SF 1449, letterhead stationery, or as otherwise specified in the solicitation. As a minimum, offers must show- (1) The solicitation number;(2) The time specified in the solicitation for receipt of offers;(3) The name, address, and telephone number of the offeror;(4) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary;(5) Terms of any express warranty;(6) Price and any discount terms;(7) "Remit to" address, if different than mailing address;(8) A completed copy of the representations and certifications at FAR 52.212-3 (see FAR 52.212-3(b) for those representations and certifications that the offeror shall complete electronically); (9) Acknowledgment of Solicitation Amendments;(10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the same or similar items and other references (including contract numbers, points of contact with telephone numbers and other relevant information); and(11) If the offer is not submitted on the SF 1449, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. Offers that fail to furnish required representations or information, or reject the terms and conditions of the solicitation may be excluded from consideration. (c) Period for acceptance of offers. The offeror agrees to hold the prices in its offer firm for 30 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation. (d) Product samples. When required by the solicitation, product samples shall be submitted at or prior to the time specified for receipt of offers. Unless otherwise specified in this solicitation, these samples shall be submitted at no expense to the Government, and returned at the sender's request and expense, unless they are destroyed during preaward testing. (e) Multiple offers. Offerors are encouraged to submit multiple offers presenting alternative terms and conditions or commercial items for satisfying the requirements of this solicitation. Each offer submitted will be evaluated separately. (f) Late submissions, modifications, revisions, and withdrawals of offers.(1) Offerors are responsible for submitting offers, and any modifications, revisions, or withdrawals, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that offers or revisions are due.(2)(i) Any offer, modification, revision, or withdrawal of an offer received at the Government office designated in the solicitation after the exact time specified for receipt of offers is "late" and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and-(A) If it was transmitted tough an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of offers; or(B) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or(C) If this solicitation is a request for proposals, it was the only proposal received.(ii) However, a late modification of an otherwise successful offer, that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.(3) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the offer wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.(4) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.(5) Offers may be withdrawn by written notice received at any time before the exact time set for receipt of offers. Oral offers in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile offers, offers may be withdrawn via facsimile received at any time before the exact time set for receipt of offers, subject to the conditions specified in the solicitation concerning facsimile offers. An offer may be withdrawn in person by an offeror or its authorized representative if, before the exact time set for receipt of offers, the identity of the person requesting withdrawal is established and the person signs a receipt for the offer.(g) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with offerors. Therefore, the offeror's initial offer should contain the offeror's best terms from a price and technical standpoint. However, the Government reserves the right to conduct discussions if later determined by the Contracting Officer to be necessary. The Government may reject any or all offers if such action is in the public interest; accept other than the lowest offer; and waive informalities and minor irregularities in offers received. (h) Multiple awards. The Government may accept any item or group of items of an offer, unless the offeror qualifies the offer by specific limitations. Unless otherwise provided in the Schedule, offers may not be submitted for quantities less than those specified. The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit prices offered, unless the offeror specifies otherwise in the offer. (i) Availability of requirements documents cited in the solicitation. (1)(i) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to-GSA Federal Supply Service Specifications Section Suite 8100 470 East L'Enfant Plaza, SW Washington, DC 20407 Telephone (202) 619-8925 Facsimile (202) 619-8978. (ii) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (i)(1)(i) of this provision. Additional copies will be issued for a fee.(2) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites:(i) ASSIST (https://assist.dla.mil/online/start/). (ii) Quick Search (http://quicksearch.dla.mil/). (iii) ASSISTdocs.com (http://assistdocs.com). (3) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point (DoDSSP) by-(i) Using the ASSIST Shopping Wizard (https://assist.dla.mil/wizard/index.cfm); (ii) Phoning the DoDSSP Customer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST; or(iii) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone (215) 697-2667/2179, Facsimile (215) 697-1462.(4) Nongovernment (voluntary) standards must be obtained from the organization responsible for their preparation, publication, or maintenance.(j) Data Universal Numbering System (DUNS) Number. (Applies to all offers exceeding $3,500, and offers of $3,500 or less if the solicitation requires the Contractor to be registered in the System for Award Management (SAM) database.) The offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation "DUNS" or "DUNS+4" followed by the DUNS or DUNS+4 number that identifies the offeror's name and address. The DUNS+4 is the DUNS number plus a 4-character suffix that may be assigned at the discretion of the offeror to establish additional SAM records for identifying alternative Electronic Funds Transfer (EFT) accounts (see FAR Subpart 32.11) for the same concern. If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one. An offeror within the United States may contact Dun and Bradstreet by calling 1-866-705-5711 or via the internet at http://fedgov.dnb.com/webform. An offeror located outside the United States must contact the local Dun and Bradstreet office for a DUNS number. The offeror should indicate that it is an offeror for a Government contract when contacting the local Dun and Bradstreet office. (k) System for Award Management. Unless exempted by an addendum to this solicitation, by submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance and tough final payment of any contract resulting from this solicitation. If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror. Offerors may obtain information on registration and annual confirmation requirements via the SAM database accessed tough https://www.acquisition.gov. (l) Debriefing. If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable: (1) The agency's evaluation of the significant weak or deficient factors in the debriefed offeror's offer.(2) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.(3) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.(4) A summary of the rationale for award;(5) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror.(6) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.52.212-4 Contract Terms and Conditions-Commercial Items (Jan 2017)(a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights- (1) Within a reasonable time after the defect was discovered or should have been discovered; and(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.(b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C. 3727). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract. (c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties. (d) Disputes. This contract is subject to 41 U.S.C. chapter 71, Contract Disputes. Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at FAR 52.233-1, Disputes, which is incorporated herein by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract. (e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference. (f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence. (g) Invoice.(1) The Contractor shall submit an original invoice and tee copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include-(i) Name and address of the Contractor;(ii) Invoice date and number;(iii) Contract number, line item number and, if applicable, the order number;(iv) Description, quantity, unit of measure, unit price and extended price of the items delivered;(v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading;(vi) Terms of any discount for prompt payment offered;(vii) Name and address of official to whom payment is to be sent;(viii) Name, title, and phone number of person to notify in event of defective invoice; and(ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract.(x) Electronic funds transfer (EFT) banking information.(A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract.(B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer-System for Award Management, or 52.232-34, Payment by Electronic Funds Transfer-Other Than System for Award Management), or applicable agency procedures. (C) EFT banking information is not required if the Government waived the requirement to pay by EFT.(2) Invoices will be handled in accordance with the Prompt Payment Act (31 U.S.C. 3903) and Office of Management and Budget (OMB) prompt payment regulations at 5 CFR Part 1315. (h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings. (i) Payment.-(1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract. (2) Prompt payment. The Government will make payment in accordance with the Prompt Payment Act (31 U.S.C. 3903) and prompt payment regulations at 5 CFR Part 1315. (3) Electronic Funds Transfer (EFT). If the Government makes payment by EFT, see 52.212-5(b) for the appropriate EFT clause. (4) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the specified payment date if an electronic funds transfer payment is made. (5) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall- (i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the-(A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment); (B) Affected contract number and delivery order number, if applicable; (C) Affected line item or subline item, if applicable; and(D) Contractor point of contact.(ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer.(6) Interest. (i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in 41 U.S.C. 7109 , which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period as fixed by the Secretary until the amount is paid. (ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract.(iii) Final decisions. The Contracting Officer will issue a final decision as required by 33.211 if- (A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days;(B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or(C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see 32.607-2). (iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment. (v) Amounts shall be due at the earliest of the following dates:(A) The date fixed under this contract.(B) The date of the first written demand for payment, including any demand for payment resulting from a default termination. (vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on-(A) The date on which the designated office receives payment from the Contractor;(B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or(C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor.(vii) The interest charge made under this clause may be reduced under the procedures prescribed in 32.608-2 of the Federal Acquisition Regulation in effect on the date of this contract. (j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon: (1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or(2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b. destination.(k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties. (l) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided. (m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience. (n) Title. Unless specified elsewhere in this contract, title to items furnished under this contract shall pass to the Government upon acceptance, regardless of when or where the Government takes physical possession. (o) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract. (p) Limitation of liability. Except as otherwise provided by an express warranty, the Contractor will not be liable to the Government for consequential damages resulting from any defect or deficiencies in accepted items. (q) Other compliances. The Contractor shall comply with all applicable Federal, State and local laws, executive orders, rules and regulations applicable to its performance under this contract. (r) Compliance with laws unique to Government contracts. The Contractor agrees to comply with 31 U.S.C. 1352 relating to limitations on the use of appropriated funds to influence certain Federal contracts; 18 U.S.C. 431 relating to officials not to benefit; 40 U.S.C. chapter 37, Contract Work Hours and Safety Standards; 41 U.S.C. chapter 87, Kickbacks; 41 U.S.C. 4712 and 10 U.S.C. 2409 relating to whistleblower protections; 49 U.S.C. 40118, Fly American; and 41 U.S.C. chapter 21 relating to procurement integrity. (s) Order of precedence. Any inconsistencies in this solicitation or contract shall be resolved by giving precedence in the following order: (1) The schedule of supplies/services.(2) The Assignments, Disputes, Payments, Invoice, Other Compliances, Compliance with Laws Unique to Government Contracts, and Unauthorized Obligations paragraphs of this clause;(3) The clause at 52.212-5. (4) Addenda to this solicitation or contract, including any license agreements for computer software.(5) Solicitation provisions if this is a solicitation.(6) Other paragraphs of this clause.(7) The Standard Form 1449. (8) Other documents, exhibits, and attachments.(9) The specification.(t) System for Award Management (SAM).(1) Unless exempted by an addendum to this contract, the Contractor is responsible during performance and tough final payment of any contract for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in the SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document.(2)(i) If a Contractor has legally changed its business name, "doing business as" name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in FAR subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to (A) change the name in the SAM database; (B) comply with the requirements of subpart 42.12; and (C) agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide with the notification sufficient documentation to support the legally changed name. (ii) If the Contractor fails to comply with the requirements of paragraph (t)(2)(i) of this clause, or fails to perform the agreement at paragraph (t)(2)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the "Suspension of Payment" paragraph of the electronic funds transfer (EFT) clause of this contract.(3) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims (see subpart 32.8, Assignment of Claims). Assignees shall be separately registered in the SAM database. Information provided to the Contractor's SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the "Suspension of payment" paragraph of the EFT clause of this contract. (4) Offerors and Contractors may obtain information on registration and annual confirmation requirements via SAM accessed tough https://www.acquisition.gov. 52.212-5 -- Contract Terms and Conditions Required to Implement Statutes or Executive Orders -- Commercial Items.(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:(1) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Dec 2014)(2) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).(3) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77, 108-78 (19 U.S.C. 3805 note)).(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:[Contracting Officer check as appropriate.]___ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).___ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (41 U.S.C. 3509).___ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub L. 111-5) (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009)._X__ (4) 52.204-10, Reporting Executive compensation and First-Tier Subcontract Awards (Jul 2013) (Pub. L. 109-282) (31 U.S.C. 6101 note).___ (5) [Reserved]___ (6) 52.204-14, Service Contract Reporting Requirements (Jan 2014) (Pub. L. 111-117, section 743 of Div. C).___ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Jan 2014) (Pub. L. 111-117, section 743 of Div. C)._X__ (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Aug 2013) (31 U.S.C. 6101 note).___ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41 U.S.C. 2313).___ (10) [Reserved]___ (11) (i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a).___ (ii) Alternate I (Nov 2011) of 52.219-3.___ (12) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C. 657a).___ (ii) Alternate I (Jan 2011) of 52.219-4.___ (13) [Reserved]___ (14) (i) 52.219-6, Notice of Total Small Business Aside (Nov 2011) (15 U.S.C. 644).___ (ii) Alternate I (Nov 2011).___ (iii) Alternate II (Nov 2011).___ (15) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644).___ (ii) Alternate I (Oct 1995) of 52.219-7.___ (iii) Alternate II (Mar 2004) of 52.219-7.___ (16) 52.219-8, Utilization of Small Business Concerns (Oct 2014) (15 U.S.C. 637(d)(2) and (3)).___ (17) (i) 52.219-9, Small Business Subcontracting Plan (Oct 2014) (15 U.S.C. 637 (d)(4)).___ (ii) Alternate I (Oct 2001) of 52.219-9.___ (iii) Alternate II (Oct 2001) of 52.219-9.___ (iv) Alternate III (Oct 2014) of 52.219-9.___ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)).___ (19) 52.219-14, Limitations on Subcontracting (Nov 2011) (15 U.S.C. 637(a)(14)).___ (20) 52.219-16, Liquidated Damages-Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)).___ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657f)._X__ (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)).___ (23) 52.219-29, Notice of Set-Aside for Economically Disadvantaged Women-Owned Small Business (EDWOSB) Concerns (Jul 2013) (15 U.S.C. 637(m)).___ (24) 52.219-30, Notice of Set-Aside for Women-Owned Small Business (WOSB) Concerns Eligible Under the WOSB Program (Jul 2013) (15 U.S.C. 637(m))._X__ (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755)._X__ (26) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Jan 2014) (E.O. 13126)._X__ (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015)._X__ (28) 52.222-26, Equal Opportunity (Apr 2015) (E.O. 11246).___ (29) 52.222-35, Equal Opportunity for Veterans (Jul 2014) (38 U.S.C. 4212)._ __ (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).___ (31) 52.222-37, Employment Reports on Veterans (Jul 2014) (38 U.S.C. 4212).___ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496)._X__ (33) (i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627).___ (ii) Alternate I (Mar 2015) of 52.222-50, (22 U.S.C. chapter 78 and E.O. 13627).___ (34) 52.222-54, Employment Eligibility Verification (Aug 2013). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)___ (35) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)___ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)___ (36) (i) 52.223-13, Acquisition of EPEAT® -Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514___ (ii) Alternate I (Jun 2014) of 52.223-13.___ (37) (i) 52.223-14, Acquisition of EPEAT® -Registered Television (Jun 2014) (E.O.s 13423 and 13514).___ (ii) Alternate I (Jun 2014) of 52.223-14.___ (38) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b).___ (39) (i) 52.223-16, Acquisition of EPEAT® -Registered Personal Computer Products (Jun 2014) (E.O.s 13423 and 13514).___ (ii) Alternate I (Jun 2014) of 52.223-16._X__ (40) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging while Driving (Aug 2011) (E.O. 13513).___ (41) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83).___ (42) (i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43).___ (ii) Alternate I (May 2014) of 52.225-3.___ (iii) Alternate II (May 2014) of 52.225-3.___ (iv) Alternate III (May 2014) of 52.225-3._ __ (43) 52.225-5, Trade Agreements (Nov 2013) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).__X_ (44) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).___ (45) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).___ (46) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).___ (47) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150).___ (48) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505), 10 U.S.C. 2307(f)).___ (49) 52.232-30, Installment Payments for Commercial Items (Oct 1995) (41 U.S.C. 4505, 10 U.S.C. 2307(f))._X__ (50) 52.232-33, Payment by Electronic Funds Transfer- System for Award Management (Jul 2013) (31 U.S.C. 3332).___ (51) 52.232-34, Payment by Electronic Funds Transfer-Other Than System for Award Management (Jul 2013) (31 U.S.C. 3332).___ (52) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).___ (53) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).___ (54) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631).___ (ii) Alternate I (Apr 2003) of 52.247-64.(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or executive orders applicable to acquisitions of commercial items:[Contracting Officer check as appropriate.]___ (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495)___ (2) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67.).___ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).___ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (Multiple Year and Option Contracts) (May 2014) (29 U.S.C.206 and 41 U.S.C. chapter 67).___ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).___ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67).___ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67).___ (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2014) (E.O. 13658).___ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792).___ (10) 52.237-11, Accepting and Dispensing of $1 Coin (Sep 2008) (31 U.S.C. 5112(p)(1)).(d) Comptroller General Examination of Record The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition teshold, and does not contain the clause at 52.215-2, Audit and Records -- Negotiation.(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract.(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.(e)(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c) and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause-(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (41 U.S.C. 3509).(ii) 52.219-8, Utilization of Small Business Concerns (Oct 2014) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $650,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.(iii) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495). Flow down required in accordance with paragraph (1) of FAR clause 52.222-17.(iv) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).(v) 52.222-26, Equal Opportunity (Apr 2015) (E.O. 11246).(vi) 52.222-35, Equal Opportunity for Veterans (Jul 2014) (38 U.S.C. 4212).(vii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).(viii) 52.222-37, Employment Reports on Veterans (Jul 2014) (38 U.S.C. 4212).(ix) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.(x) 52.222-41, Service Contract Labor Standards (May 2014), (41 U.S.C. chapter 67).(xi) ____ (A) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627).___ (B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 E.O. 13627).(xii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67.)(xiii) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67)(xiv) 52.222-54, Employment Eligibility Verification (Aug 2013).(xv) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2014) (E.O. 13658).(xvi) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).(xvii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.(xviii) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.(2) While not required, the contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.(End of Clause)52.217-9 OPTIONS TO EXTEND THE TERM OF THE CONTRACT (MAR 2000)The Government may extend the term of this contract by written notice to the Contractor within _30_ days before the contract expires. The preliminary notice does not commit the Government to an extension.If the Government exercises this option, the extended contract shall be considered to include this option clause.The total duration of this contract, including the exercise of any options under this clause, shall not exceed 48 months.(End of clause)52.227-19 COMMERCIAL COMPUTER SOFTWARE LICENSE. (Dec 2007)(a) Notwithstanding any contrary provisions contained in the Contractor's standard commercial license or lease agreement, the Contractor agrees that the Government will have the rights that are set forth in paragraph (b) of this clause to use, duplicate or disclose any commercial computer software delivered under this contract. The terms and provisions of this contract shall comply with Federal laws and the Federal Acquisition Regulation.(b)(1) The commercial computer software delivered under this contract may not be used, reproduced, or disclosed by the Government except as provided in paragraph (b)(2) of this clause or as expressly stated otherwise in this contract.(2) The commercial computer software may be-(i) Used or copied for use with the computer(s) for which it was acquired, including use at any Government installation to which the computer(s) may be transferred;(ii) Used or copied for use with a backup computer if any computer for which it was acquired is inoperative;(iii) Reproduced for safekeeping (archives) or backup purposes;(iv) Modified, adapted, or combined with other computer software, provided that the modified, adapted, or combined portions of the derivative software incorporating any of the delivered, commercial computer software shall be subject to same restrictions set forth in this contract;(v) Disclosed to and reproduced for use by support service Contractors or their subcontractors, subject to the same restrictions set forth in this contract; and(vi) Used or copied for use with a replacement computer.(3) If the commercial computer software is otherwise available without disclosure restrictions, the Contractor licenses it to the Government without disclosure restrictions.(c) The Contractor shall affix a notice substantially as follows to any commercial computer software delivered under this contract:Notice-Notwithstanding any other lease or license agreement that may pertain to, or accompany the delivery of, this computer software, the rights of the Government regarding its use, reproduction and disclosure are as set forth in Government Contract No. ED-FSA-15-P-0076.(End of clause)ED 316-1 ACCESSIBILITY OF SOFTWAREThe Department of Education (ED) considers universal accessibility to information a priority for all its employees and external customers, including individuals with disabilities. Under Sections 504 and 508 of the Rehabilitation Act of 1973 (29 U.S.C. sections 794 and 794d,as amended), ED must ensure the accessibility of its programs and activities, specifically its obligation to acquire and use accessible electronic and information technology. ED maintains the manual, "Requirements for Accessible Software Design," to convey the accessibility needs of the Department to the developers and suppliers of computer applications. To comply with the provisions of this clause, the contractor may use the edition of the ED manual "Requirements for Accessible Software Design" in effect at the date of award of this contract or any more recent edition. A copy of the most recent edition of the manual may be found at http://www.ed.gov/fund/contract/apply/clibrary/software.html (a) Software delivered to or developed for ED--Except as provided in paragraph (b) or (c) of this clause, all software delivered to or developed for ED, under this contract, for use by ED's employees or external customers must meet all the requirements of the ED manual "Requirements for Accessible Software Design." However, in accordance with paragraph (c) of this clause, the contracting officer may waive a particular requirement of the ED Manual, provided that ED's use of the software will meet the requirements of Sections 504 and 508 of the Rehabilitation Act of 1973 (29 U.S.C. sections 794 and 794d, as amended). (b) Software enhanced or modified for ED--Any enhancements and other modifications, made under this contract to software for use by ED's employees or external customers, are subject to the requirements of paragraph (a) of this clause, regardless of where or how the software was first developed. Except as otherwise specified elsewhere in the contract schedule, the contractor is only required to ensure that enhancements or modifications (not other, preexisting features or components) of the software fully comply with the accessibility requirements of paragraph (a). However, the contractor is encouraged point out any preexisting features or components that do not meet accessibility requirements and to suggest solutions to ensure the software complies. (c) Waiver of requirements--It is recognized that new technologies may provide solutions that are not envisioned in or consistent with the provisions of the manual "Requirements for Accessible Software Design." Also, compliance with certain requirements of the manual may not be feasible for the particular software required. In such extraordinary circumstances, the contracting officer may grant a waiver, in writing, to any requirement of the manual or of this clause if it furthers a public interest of ED and will not significantly impair ED's ability to ensure accessibility of its programs and activities to all its employees and external customers, including individuals with disabilities. To request a waiver, the contractor shall notify the contracting officer in writing, listing the specific accessibility requirements that would not be met and explaining how the accessibility of a particular feature can be achieved by alternative means or why it is not feasible to make a feature of the software accessible. (d) Condition of payment--The contractor agrees that compliance with the provisions of this clause upon delivery of the software to ED is a condition of payment under this contract.(End of clause) ED 317-1 ACCOMMODATION/ACCESSIBILITY FOR THE DISABLED (OCT 1999)The acquisition and management of Federal Information Processing (FIP) resources shall be conducted in a manner that ensures access to computer and telecommunications products and services by all individuals, both federal employees and the public sector, including individuals with disabilities. The acquisition, management and utilization of FIP resources are subject to the computer accommodation and information accessibility for individuals with disabilities contained in Section 508 of the Workforce Investment Act of 1998, P.L. 105-220; Telecommunications Act of 1996,P.L. 104-104 February 1996, 110 Stat. 56; and in the Telecommunications Accessibility Enhancement Act, P.L. 100-542 October 1988. FIP resources required under this contract include computer accommodation and information accessibility where the goal is to ensure full access, integration, and continuity of support to all individuals, including individuals with disabilities. "Computer accommodation" means the acquisition or modification of FIP resources to minimize the functional limitations of individuals with disabilities so as to promote productivity and provide access to work-related or public information resources. "Individuals with disabilities" are individuals with limitations of vision, hearing, speech and/or mobility. The contractor shall ensure that FIP resources are equally provided to all individuals, including individuals with disabilities.(End of clause)FSA 27-1 LABELING OF DOCUMENTS. (JUN 2007)The Contractor shall not label any data produced in performance of this contract in a way that would restrict the Government's right to use or release the information. If applicable, the Contractor shall include a legend that identifies sensitive data that should not be released for security reasons. Under FAR clause 52.227-14, Rights in Data-General (or 52.227-15, -16, -17) clause, this data may be used for any purpose the Government deems appropriate. Deliverables shall not contain vendor-specific logos, mottos, watermarks, or holograms. The Contractor shall not use, particularly for proposals, U.S. Government logos, such as the U.S. Department of Education or Federal Student Aid.(End of clause) FSA 32-1 INVOICE PROCEDURES. (MAR 2012)The Contractor must submit an invoice via mail, fax, or e-mail for this contract in order to be paid for products and/or services rendered. For Prompt Payment Act purposes, Invoices received after 3 p.m. will be processed on the next business day.Federal Student Aid's "Designated Billing Office" (DBO) is: US Department of EducationUnion Center PlazaFederal Student Aid Administration830 First Street, NE - Suite 54B1Washington, D.C. 20201-0001E-mail: InvoiceAdmin@ed.govFax: (202) 275-3477A contractor shall also simultaneously submit copies of the invoice to the Contracting Officer (CO) and one to the Contracting Officer's Representative (COR). The CO and COR should receive copies via the same means as the invoice sent to the DBO.When submitting an invoice via mail, the Contractor shall submit the original invoice and two copies of the invoice.At a minimum, the following items must be addressed in order for the invoice to be considered "proper" for payment:(1) Name and Address of the Contractor.(2) Invoice Number and Invoice Date. (3) The Contract number, contract line item, and if applicable, the order number.(4) Description, quantity, unit of measure, unit price, and extended price of the delivered item or service, as defined in the contract or order.(5) Terms of any offered prompt payment discount.(6) Name, title, and phone number of persons to be notified in event of a defective invoice.(7) The period of time covered by the invoice.(8) Totals, supported by subtotals, and subtotals should be supported by detail (i.e. documentation for categories of labor, hours performed, unit prices) and deliverables provided.(9) If required by this contract or order, receipts must be provided to support documentation of "other direct costs" (ODCs) or materials.(10) Special instructions for finance payments: Invoices for finance payments shall specifically and prominently identify the payment request as follows: REQUEST FOR FINANCING PAYMENTFinance payments are not subject to the Prompt Payment Act. Failure to identify the invoice as a request for financing may result in delay of payment. Invoices that are identified as Requests for Finance Payments shall only include the finance payments listed in the contract. Requests for finance payments shall not be combined with other types of invoice payments.(End of clause) Virtual Data Center and Next Generation Data Center Transition Support Clause:The contractor shall allow FSA to use the software at both its Virtual Data Center and the Next Generation Data Center during transition at no additional cost. The transition period is from June 1, 2017 to August 31, 2018. ED-FSA-17-Q-0027 Department of Education Office of Federal Student Aid
7/25/17, 8:37 PM