PS28
OTHER FUNCTIONS CONSTRUCTION GENERAL CONTRACTOR (GC) SERVICES AT U.S. DEPARTMENT OF STATE, NEW OFFICE BUILDING, CRC (FLETC) BUILDING F, NORTH CHARLESTON, SOUTH CAROLINA A. PURPOSE: ADD THE FOLLOWING THREE (3) GC SERVICES AS DESCRIBED IN THE SCOPE OF WORK AND COPS FOR GENERAL CONTRACTOR CONSTRUCTION SERVICES FOR DOS CHARLESTON, SC BUILDING F DUE TO DESIGN CHANGES AND REVISIONS. B. SCOPE OF WORK: ADDITION OF THE FOLLOWING THREE (3) GC SERVICES AS DESCRIBED IN THE SCOPE OF WORK, COP #S 192, 201 AND 202, BULLETINS #29 AND PER THE DIRECTION OF DOS AND AE FOR GENERAL CONTRACTOR CONSTRUCTION SERVICES DUE TO DESIGN CHANGES AND REVISIONS. - LINE ITEM 0115: COP 192 AV CREDENZA CHANGES - $5,950.00 - LINE ITEM 0116: COP 201 SECURITY SERVER WARRANTY CHANGES - $0.00 - LINE ITEM 0117: COP 202 OPTIONS AND BASE FEES - $124,100.00 TOTAL AMOUNT INCREASED: $130,050.00 C. CONTRACT PRICE: THE TOTAL COST OF THIS MODIFICATION RESULTS IN AN INCREASE OF $130,050.00. THE CONTRACT TOTAL INCREASES FROM $54,016,198.18 TO $54,146,248.18. D. PERIOD OF PERFORMANCE: THE CONTRACT COMPLETION DATE WILL REMAIN THE SAME AT AUGUST 31, 2018. THE EFFECTIVE DATE OF THIS MODIFICATION IS PURSUANT TO THE DATE SIGNED BY THE CONTRACTING OFFICER IN SECTION #16B OF THIS MODIFICATION. E. CONTRACTORS STATEMENT OF RELEASE: IN CONSIDERATION OF THIS MODIFICATION AGREED TO HEREIN AS COMPLETE EQUITABLE ADJUSTMENT AS DESCRIBED ABOVE, BL HARBERT INTERNATIONAL, LLC, HEREBY RELEASES THE GOVERNMENT FROM ANY AND ALL LIABILITY UNDER THIS CONTRACT FOR FURTHER EQUITABLE ADJUSTMENTS ATTRIBUTABLE TO SUCH FACTS OR CIRCUMSTANCES GIVING RISE TO THIS MODIFICATION. ALL OTHER TERMS AND CONDITIONS REMAIN THE SAME.
Supplemental Agreement for work within scope $130.1k 7/23/18 PS27
OTHER FUNCTIONS CONSTRUCTION GENERAL CONTRACTOR (GC) SERVICES AT U.S. DEPARTMENT OF STATE, NEW OFFICE BUILDING, CRC (FLETC) BUILDING F, NORTH CHARLESTON, SOUTH CAROLINA A. PURPOSE: ADD THE FOLLOWING THIRTEEN 13 GC SERVICES AS DESCRIBED IN THE SCOPE OF WORK AND COPS FOR GENERAL CONTRACTOR CONSTRUCTION SERVICES FOR DOS CHARLESTON, SC BUILDING F DUE TO DESIGN CHANGES AND REVISIONS. B. SCOPE OF WORK: ADDITION OF THE FOLLOWING THIRTEEN 13 GC SERVICES AS DESCRIBED IN THE SCOPE OF WORK, COP #S 44, 184, 185, 188, 189, 190, 191, 194, 195, 196, 197, 199 AND 200, BULLETINS #26 AND 27 AND PER THE DIRECTION OF DOS-AE FOR GENERAL CONTRACTOR CONSTRUCTION SERVICES DUE TO DESIGN CHANGES AND REVISIONS. LINE ITEM 0095: NOTICE TO PROCEED COP 184 DS SUITE TELECOM AND POWER - $3,500.00 (NTP FIRMED UP ON CLIN 0101) LINE ITEM 0096: NOTICE TO PROCEED COP 185 N. SECURITY COUNTER - $500.00 (NTP FIRMED UP ON CLIN 0111) LINE ITEM 0097: NOTICE TO PROCEED COP 194 TV OUTLETS IN FITNESS RM - $500.00 (NTP FIRMED UP ON CLIN 0112) LINE ITEM 0099: NOTICE TO PROCEED COP 190 R1 BULLETIN #26 - $10,000.00 (NTP FIRMED UP ON CLIN 0102) LINE ITEM 0101: COP 184 ADD DS SUITE TELECOM AND POWER DATED 02/01/18 - $10,660.00 (FIRMS UP CLIN 0095) LINE ITEM 0102: COP 190 R1 ADD BULLETIN #26 UPS FIRE RATING DATED 03/26/18 - $16,587.00 (FIRMS UP CLIN 0099) LINE ITEM 0103: COP 189 ADD CUTS IN CONTROL JOINTS STAIRWELL DATED 03/13/18 - $13,537.00 LINE ITEM 0104: COP 195 ADD IT RUN CHANGES BLDG F - A,E,D AND BLDG 84 DATED 04/19/18 - $15,430.00 LINE ITEM 0105: COP 199 ADD 5 AED-CABINETS DATED 02/22/18 - $9,095.00 LINE ITEM 0106: COP 44 R3 ADD PARKING LOT CAMERAS DATED 02/09/17 - $8,458.00 LINE ITEM 0107: COP 191 MODIFY PENTHOUSE DOOR AND HARDWARE DATED 02/22/18 - $7,918.00 LINE ITEM 0109: COP 196 REWORK CISCO NETWORK SWITCH DATED 04/27/18 - $5,115.00 LINE ITEM 0110: COP 200 PROVIDE ADDTL ELEVATOR INSPECTION DATED 06/06/18 - $2,777.00 LINE ITEM 0111: COP 185 R1 MODIFY N. SECURITY COUNTER DATED 02/01/18 - $1,777.00 (FIRMS UP CLIN 0096) LINE ITEM 0112: COP 194 AND 193 MODIFY TV OUTLETS PER DOS DATED 04/17/18 - $880.00 (FIRMS UP CLIN 0097) LINE ITEM 0113: COP 188 MODIFY TEST HEADER DATED 02/27/18 - $1,177.00 LINE ITEM 0114: COP 197 REMOVE BLACK BOXES DATED 04/27/18 - $1,010.00 (PR-M0038 NTP ISSUED ON FEBRUARY 5, 2018 FOR CLINS 95, 96, 97 AND 99 IN THE AMOUNT OF $14,500.00) C. CONTRACT PRICE: THE TOTAL COST OF THIS MODIFICATION RESULTS IN AN INCREASE OF $108,921.00. THE CONTRACT TOTAL INCREASES FROM $53,907,277.18 TO $54,016,198.18. D. PERIOD OF PERFORMANCE: THE CONTRACT COMPLETION DATE WILL BE EXTENDED FROM MAY 30, 2018 TO AUGUST 31, 2018. THIS MODIFICATION DEFINITIZES THE WORK AUTHORIZED UNDER THE NOTICE TO PROCEED ISSUED BY THE CONTRACTING OFFICER ON FEBRUARY 5, 2018. THE EFFECTIVE DATE OF THIS MODIFICATION IS PURSUANT TO THE DATE SIGNED BY THE CONTRACTING OFFICER IN SECTION #16B OF THIS MODIFICATION.
Supplemental Agreement for work within scope $108.9k 7/3/18 PS26
OTHER FUNCTIONS CONSTRUCTION GENERAL CONTRACTOR (GC) SERVICES AT U.S. DEPARTMENT OF STATE, NEW OFFICE BUILDING, CRC (FLETC) BUILDING F, NORTH CHARLESTON, SOUTH CAROLINA A. PURPOSE: ADD THE FOLLOWING GC SERVICES AS DESCRIBED IN THE SCOPE OF WORK FOR GENERAL CONTRACTOR CONSTRUCTION SERVICES FOR DOS CHARLESTON, SC BUILDING F DUE TO DESIGN CHANGES AND REVISIONS. B. SCOPE OF WORK: ADDITION OF IT CHANGES TO 4TH FL AND CHANGE IT LABELS PER COP 186R2, BULLETIN #28 AND DOS/AE DIRECTION AS DESCRIBED IN THE SCOPE OF WORK FOR GENERAL CONTRACTOR CONSTRUCTION SERVICES DUE TO DESIGN CHANGES AND REVISIONS. LINE ITEM 0098: NOTICE TO PROCEED COP 186R2 IT CHANGES BULLETIN #28 - $48,000.00 (NTP) LINE ITEM 0100: ADD COP 186R2 IT CHANGES BULLETIN #28 - $380,645.00 (FIRM UP) *(PR-M0098 IS THE NTP AMOUNT OF $48,000.00 ISSUED ON MARCH 12, 2018 AND THE INCREASED AMOUNT OF $380,645.00 IS FIRMED UP IN CLIN 0100 FOR A REVISED TOTAL AMOUNT - $428,645.00) TOTAL ADDED: $428,645.00 C. CONTRACT PRICE: THE TOTAL COST OF THIS MODIFICATION RESULTS IN AN INCREASE OF $428,645.00. THE CONTRACT TOTAL INCREASES FROM $53,478,632.18 TO $53,907,277.18. D. PERIOD OF PERFORMANCE: THE CONTRACT WILL BE EXTENDED FROM MARCH 30, 2018 TO MAY 30, 2018. THIS MODIFICATION DEFINITIZES THE WORK AUTHORIZED UNDER THE NOTICE TO PROCEED ISSUED BY THE CONTRACTING OFFICER ON MARCH 12, 2018.THE EFFECTIVE DATE OF THIS MODIFICATION IS PURSUANT TO THE DATE SIGNED BY THE CONTRACTING OFFICER IN SECTION #16B OF THIS MODIFICATION.
Supplemental Agreement for work within scope $428.6k 3/28/18 PS25
OTHER FUNCTIONS CONSTRUCTION GENERAL CONTRACTOR (GC) SERVICES AT U.S. DEPARTMENT OF STATE, NEW OFFICE BUILDING, CRC (FLETC) BUILDING F, NORTH CHARLESTON, SOUTH CAROLINA A. PURPOSE: COMBINATION 15 MODIFICATION FOR 2 SERVICES AS DESCRIBED IN THE SCOPE OF WORK FOR GENERAL CONTRACTOR CONSTRUCTION SERVICES FOR DOS CHARLESTON, SC BUILDING F DUE TO DESIGN CHANGES AND REVISIONS. B. SCOPE OF WORK: ADDITION OF THE FOLLOWING TWO (2) GC SERVICES AS DESCRIBED IN THE SCOPE OF WORK FOR GENERAL CONTRACTOR CONSTRUCTION SERVICES DUE TO DESIGN CHANGES AND REVISIONS. LINE ITEM 0093: ADD COP 183 FIBER COMPONENTS - $23,501.88 LINE ITEM 0094: ADD ADDITIONAL KITCHEN EQUIPMENT - $2,557.00 TOTAL ADDED: $26,058.88 C. CONTRACT PRICE: THE TOTAL COST OF THIS MODIFICATION RESULTS IN AN INCREASE OF $26,058.88. THE CONTRACT TOTAL INCREASES FROM $53,452,573.30 TO $53,478,632.88. D. PERIOD OF PERFORMANCE: THE CONTRACT HAS MET SUBSTANTIAL COMPLETION AS OF DECEMBER 15, 2017 AND WILL EXTEND THE CONTRACT TO AN ESTIMATED ULTIMATE COMPLETION DATE OF MARCH 30, 2018 TO ACCOMMODATE CLOSE-OUT. THE EFFECTIVE DATE OF THIS MODIFICATION IS PURSUANT TO THE DATE SIGNED BY THE CONTRACTING OFFICER IN SECTION #16B OF THIS MODIFICATION.
Supplemental Agreement for work within scope $26.1k 1/31/18 PS24
OTHER FUNCTIONS A. PURPOSE: COMBINATION 14 MODIFICATION FOR 3 SERVICES AS DESCRIBED IN THE SCOPE OF WORK FOR GENERAL CONTRACTOR CONSTRUCTION SERVICES FOR DOS CHARLESTON, SC BUILDING F DUE TO DESIGN CHANGES AND REVISIONS. B. SCOPE OF WORK: ADDITION OF THE FOLLOWING THREE (3) GC SERVICES AS DESCRIBED IN THE SCOPE OF WORK FOR GENERAL CONTRACTOR CONSTRUCTION SERVICES DUE TO DESIGN CHANGES AND REVISIONS. LINE ITEM 0090: ADD COP 180 FP MODS TO MECHNICAL ROOM 1M1 - $6,833.00 LINE ITEM 0091: ADD COP 181R1 RADIO OPS INFRASTRUCTURE - $6,717.00 LINE ITEM 0092: ADD COP 182 ADDITIONAL KITCHEN EQUIPMENT - $61,645.00 (15 DAY NO COST TIME EXTENSION) TOTAL ADDED: $75,195.00 C. CONTRACT PRICE: THE TOTAL COST OF THIS MODIFICATION RESULTS IN AN INCREASE OF $75,195.00. THE CONTRACT TOTAL INCREASES FROM $53,377,378.30 TO $53,452,573.30. D. PERIOD OF PERFORMANCE: THE CONTRACT COMPLETION DATE IS INCREASED BY 10 WORKING DAYS FOR COP 180 AND 5 WORKING DAYS FOR COP 181R1, RESULTING IN 15 NO COST WORKING DAYS IN TOTAL. THE CONTRACT COMPLETION DATE WILL BE EXTENDED FROM NOVEMBER 24, 2017 TO DECEMBER 15, 2017.
Supplemental Agreement for work within scope $75.2k 11/21/17