Stony Quarry Development and Aggregate Supply
Added: Jun 17, 2016 6:59 pm Combined Solicitation & SynopsisAG-9JGP-S-16-0122The Department of Agriculture, US Forest Service, Central California Acquisition Services Area, Plumas National Forest requires services for Pit development and site reclamation, crush and stockpile Aggregate product from the Stony Quarry located on the Beckwourth Ranger District. This is a combined / solicitation for commercial items prepared in accordance with the format in Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; quotes are being requested and a written solicitation will not be issued. It is the contractor's responsibility to be familiar with the applicable clauses and provisions. The clauses may be accessed in full text at these addresses: https://acquisition.gov/far.This is solicitation no.AG-9JGP-S-16-0122, a Request for Quotations (RFQ) and is a 100% Total Small Business Set-Aside. The NAICS code is 212321 Support Activities for Forestry. The size requirement for this NAICS code is 500 employees. The government intends to award a Firm Fixed Price Contract. Closing date of Solicitation is: July 5, 2016: 3:00 PM PST.Projected Award Date is: July 7, 2016B.1ITEM NO. DESCRIPTION UNIT QTY UNIT PRICE TOTAL PRICE1 Mobilization LSQ 1. $______________ $_____________2 Pit Development LSQ 1. $______________ $_____________ & Reclamation 3 Crush & Stockpile CY 22,000 $_____________ $_____________ Aggregate Surface Course, 1-inch minus gradationAS PER THE GENERAL SPECIFICATIONS IN ATTACHMENT 1 AND THE FOLLOWING ADDITIONAL REQUIREMENTS:This is a commercial test item.Contractor Responsibility: Except as otherwise specified under 1.2 and 1.4, the contractor shall furnish the necessary personnel, supplies and transportation to perform the services and insure that the designated areas present a clean, healthy, orderly and well-kept appearance.Estimated Start Date & Contract Time:Date/Time Start July 11,2016Contract Time 120 daysLicenses & InsuranceThe contractor shall obtain the insurance and licenses listed here; (see also Section L, Notices to Offerors and Respondents).Other: Worker's Compensation Insurance: The Contactor shall provide evidence of Worker's Compensation Insurance or a written explanation as to why the Contractor is exempt from the requirement. NOTE: The Contractor working alone is not required to carry the insurance.DESCRIPTION OF WORK:1. COMMENCEMENT PROSECUTION, AND COMPLETION OF WORK (FAR 52.211-10) (APR 1984)The Contractor shall be required to (a) commence work under this contract within 3 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than July 11, 2016.Work is estimated to begin July 11, 2016.1 DESCRIPTION OF WORKFurnish all labor, equipment, and materials, to accomplish the Work under this Supply contract. Services consist mainly of the extraction of material from previously exposed quarry slopes, then crushing it into the aggregate surface course, meeting the gradation provided in the specifications, and as Specified by the Schedule of Items. Work includes but is not limited to the following major items:o Production of the specified aggregate surface course gradation from extracted material source shown on drawings; includes the stockpiling of aggregates at sites designated by the drawings, also submittal of required quality control tests for the produced materials.o Pit development of the quarry includes removal of weed-contaminated soil prior to all other work, then stockpiling it at area designated by drawings, removal of overburden from extraction area shown on drawings, consolidation of existing stockpiles for each gradation prior to stockpiling new crushed aggregate.o Site Reclamation is part of the pit development after completion of aggregate crushing and stockpiling operations. Excavated slopes will be pulled down and stabilized as required by the drawings, also meeting OSHA and MSHA requirements for open pit mines. All disturbed areas will be sloped to drain and re-contoured to the line and grades shown on the drawings. o Submittals of a Traffic Control Plan, Project Quality Control Plan, Proposed Project Schedule, All Required Permits, Licenses, and Certifications for review and approval.The Contractor should refer to the Schedule of Items, Project Area Map, and Specifications when making estimates of quantities or work.2. PROJECT LOCATIONState of California, County of Plumas, Plumas National Forest, Beckwourth Ranger District, Stony Quarry, Township 26 North, Range 13 East, Section 11, (Lat. 40° 07'32.40", Lon 120° 28'59.70").The Plumas Project Site, Stony Quarry is located on the Beckwourth District of the Plumas National Forest. Directions below are to initial mobilization point for the project at Stony Quarry.From Town of Portola CA: Proceed East on CA State Highway 70 approximately 5.0 miles to the junction left with FSR 177/County 111 in Beckwourth CA. Turn Left and proceed approximately 9.5 miles to where the roads split, junction road left is County 111, proceed on junction road right FSR 177-also marked 26N70 for another approximate 11.7 miles. Veer Left onto FSR 176-also marked 28N03 proceed approximately another 7.6 miles to junction right with FSR 26N16. Turn Right onto FSR 26N16 proceed approximately 150 feet; turn left onto a Spur Road-marked 26N16A and proceed approximately another 0.9 mile and make one final left turn into the quarry, arriving at the beginning of the project site.3 WORK TIMINGThe Contractor shall begin work within ___3_______ calendar days after the effective date of the Notice to Proceed and shall prosecute the work at a rate that will result in completion of all work within the following time frame:Item No. Estimated Start Work Date Contract Time (Calendar Days)1 July 11 120 days2 July 11 120 days3 July 11 120 daysFailure to begin work on schedule will make the contract subject to immediate termination for default.Delays due to normal adverse weather, weekends, and holidays have been included in the calculation of contract time. The Government reserves the right to set the priority of items or subitems. Contractor shall complete all work on one sub-item before proceeding to another.If this solicitation has more than one numbered item, award of more than one item to one contractor will not change the start work dates or the amount of contract time; times will run concurrently.Winter ShutdownWhen winter weather sets in and the continuation of work is impractical, the Contracting Officer may authorize a total suspension until such time as work can proceed. During the period of total suspension, the calendar days elapsed will not be charged against the contract time.4 PROJECT SITE CLEAN UPProject site cleanup includes the removal and proper disposal of all project trash, debris, and residue off of National Forest Land.All spills of petroleum products including leak spots from parked vehicles shall be removed and properly disposed according to all Local, State, and Federal rules, regulations, and laws governing such disposal. Any Fuel Trucks staged on-site must be equipped with spill containment kits and portable berms that meet all state and federal regulations. A Spill Containment Plan must be submitted and approved prior to the start of work. If a Single Oil or Oil Product Container exceed 660 Gallons, or if the Combined On-Site Storage exceeds 1,320 Gallons, the Contractor shall prepare, and submit for review and approval, then later for implementation a Spill Prevention and Countermeasures Plan. The (SPCC) Plan shall meet applicable EPA requirements (40 CFR 112), including required certification by a Registered Professional Engineer. Contractor is responsible for all clean-up costs of petroleum product spills within the project vicinity area caused directly or indirectly by their employees or from their contract operations.6 SPECIAL CONDITIONS AFFECTING THE WORKa. Physical Conditions. The indications of physical conditions on the drawings and in the specifications are the result of site investigations and surveys performed by the Government. 1. A geotechnical assessment of the site was conducted and the site geology is as follows:• Site Morphology: located on a hillside beginning at the base of a basalt flow• Lithology: basalt underlain by an ignimbrite and decomposed granite.• Texture: Aphanitic• Alteration: Some weathered pockets; mostly just stained• Competency: Rebounds to pits• Fines Availability: Expect little to none, majority of aggregate fines are produced.• Small Scale Structures: Basalt naturally breaks into 4-6" sized blocky pieces• Large Scale Structures: Basalt flow• Soil Development: A few very rocky, weathered pockets; generally minimal• Surface Vegetation: Sparse grasses and some trees above and below the site; some invasive weeds located in the northwest and southeast sections of the pit.• Groundwater Level: Deepb. Weather. Low temperatures at the project site range from temperatures of less than 30 ºF in December and January to lows of 50 ºF in July and August. High temperatures range from 45 ºF in December and January to over 90 ºF in July and August. The annual precipitation at the project site is less than 30 inches per year including snow fall. Winter snow storms and freezing temperatures will occur during the winter months that result in a winter project shutdown. Icy conditions on local roads and highways can occur during the fall, winter and spring. Highway curves in shaded areas will remain covered with ice or frost for weeks.c. Work Hours. Work hours are from 7:00 am to 5:00 pm Monday tough Friday. Weekend equipment work is not allowed at any time during the Work. Dogs and pets are not allowed on the project site at any time.d. Safety, Emergency Communications and Evacuation. Contractor is responsible for the safety of the Contractor's employees including Subcontractors employees, Government employees associated with the project, and any visitors to the site both Government and private. The Contractor shall submit a Project Safety Plan to the Contracting Officer for review prior to commencement of Work. The project safety plan shall comply with the appropriate California OSHA and Federal OSHA rules and regulations and must include a medical evacuation and emergency communications plan.e. Highway Permits. Contractor is responsible for securing any overload or over width limit permits required for the transport of materials or equipment to the project site. The Contractor is responsible for conducting a thorough reconnaissance of all routes leading to the site.f. Toilets. No toilet or shower facilities are available on site. Contractor shall provide portable toilet facilities for its employees.g. Camping. Contractor may use a self-contained travel trailer or recreational vehicle to camp on the premises. All waste material must be transported off-site to a station equipped to handle such waste. This is subject to availability and must be coordinated tough the Contracting Officer.h. Water. Water for the project can be drafted out of two tributaries of the Cottonwood Creek, located about 1500 to 2000 feet away from the project.i. Security. Contractor is responsible for the Contractor's equipment and materials supplied to the site, including all produced and stockpiled aggregate. Any aggregate stolen during performance of the contract, shall be replaced at the contractor's expense. All equipment not equipped with a key lock system shall be secured in such a manner as to make it inoperable to the average person at the end of each working day. All hand tools and other equipment shall be secured at the end of each working day. The quarry shall be closed to the public at all times, but remain open to authorized government employees. The contractor shall be responsible for signing, limiting public access, and safety of the public and/or government employees in the area. On Fridays all construction debris, trash, and refuse shall be properly stored in dumpsters or trash bins or removed from the site.j. Traffic Control. Contractor shall submit a Traffic Control and Signage Plan for review and approval, prior to the start of operations. Construction signing for traffic control shall conform to the Manual of Uniform Traffic Control Devices (MUTCD). All traffic control signs will be placed in areas adequate for a truck pulling a fifth wheel trailer to be turned around. Contractor shall not be paid directly for this item, rather it will be considered incidental to other items of work listed in the Schedule of Items.k. Air Quality Permits. Contractor shall submit an Air Pollution Permit (Northern Sierra Air Quality Management District) and National Pollutant Discharge Elimination System (NPDES) Permit (State).l. Burning Permits. Contractor is subject to all rules and regulations governing the on site burning of slash and other debris. Contractor shall obtain a burning permit from the jurisdiction having control over burning. The Contractor shall comply with Fire Plan for Construction and Service Contracts included in the Contract.m. Protection of Resources. Contractor shall thoroughly clean all equipment prior to delivery to the project site to remove weeds, mud, grease and oil buildup from the tires, wheels, tracks, engines and engine compartments, and other surfaces. Spills of petroleum products and other hazardous substances shall be reported, contained, and removed in accordance with all applicable rules, regulations and laws. Contractor shall submit a project spill response plan at the pre-work meeting for review by the Contracting Officer.7 PRE-BID CONFERENCE OR TOURSThere will be no Pre-Bid Tour for the project. The Contractor acknowledges that they have taken the necessary steps to ascertain the nature and location of work, and have investigated and satisfied themselves as to the general and local conditions that can affect the work or its cost. Any failure of the contractor to take the actions described and acknowledged in this paragraph will not relieve the Contractor from the responsibility of estimating properly the difficulty and cost of successfully performing the work, or for proceeding to successfully perform the work without additional expenses to the government.8 EQUIPMENT CLEANING & NOXIOUS WEED-FREE CERTIFICATIONUnless the entire project area is already infected with noxious weeks, the contractor shall ensure that prior to moving on to another part of the project area all off-road equipment, which last operated in areas known by Forest Service to be infected with noxious weeds, is free of soil, seeds, vegetative matter, or other debris that could contain or hold seeds. Contractor shall certify in writing that off-road equipment is free of noxious weeds prior to each start-up of operations and for subsequent moves of equipment to other project areas. Measures taken to ensure that off-road equipment is free of noxious weeds will be identified. "Off-road equipment" includes all equipment operating off of paved roadways. A Current list of noxious weeks of concern to Forest Service is available at the Forest Supervisor's office. Contractor shall clean off-road equipment prior to moving between project areas with known infestations with noxious weeds and other project areas, if any, which are free of such weeds. Project Area maps show areas known by Forest Service that contain specific noxious weeds species of concern. Contractor shall employ whatever cleaning methods are necessary to ensure that off-road equipment is free of noxious weeds. Equipment shall be considered free of soil, seeds, and other such debris when a visual inspection does not disclose such material. Disassembly of equipment components or specialized inspection tools is not required.Contractor shall notify Forest Service at least 24 hours prior to beginning of work in area designated as a noxious weed area, unless otherwise agreed. Notification shall include the location of the equipment's most recent operations. If the prior location of the off-road equipment cannot be identified, forest service may assume that it was infested with noxious weed seeds. Upon request of Forest Service, Contractor must arrange for forest Service to inspect each piece of off-road equipment prior to it being placed into service. If Contractor desires to clean off-road equipment on National forest land, such as at the end of a project or prior to moving to a new unit that is free from noxious weeds, Contractor and Forest service shall agree on methods of cleaning, locations for the cleaning, and control of off-site impacts, if any. New infestations of noxious weeds, of concern to Forest Service and identified by either Contractor or Forest Service, within the project area or on the haul route, shall be promptly reported to the other party.52.211-16 Variation in Quantity.As prescribed in 11.703(a), insert the following clause:Variation in Quantity (Apr 1984)(a) A variation in the quantity of any item called for by this contract will not be accepted unless the variation has been caused by conditions of loading, shipping, or packing, or allowances in manufacturing processes, and then only to the extent, if any, specified in paragraph (b) of this clause.(b) The permissible variation shall be limited to:_15__ Percent increase_15__ Percent decreaseThis increase or decrease shall apply to _Item 3 only___________.*AGAR 452.211-74 Period of Performance (FEB 1988)The period of performance of this contract is from July 11, 2016 tough November 7, 2016.Contractor shall immediately after award, plan and coordinate with the Contracting Officer the approximate start date for the pit development, then production and stockpiling of the specified surface course gradation during the listed period of performance for the Stony Quarry.Factors which will help determine the Approved Schedule, but are not limited to; Contractor's mobilization of equipment, employees, and vehicles to the project site, also material production rate capabilities and quality control compliance testing.Contractor shall comply with the Approved Schedule, to finish all work under this contract.Contractor shall immediately notify the Contracting Officer of any unforeseen delay or needed change to the Approved Schedule, so adjustments to the Period of Performance can be made in a timely manner.9. PRE-WORKPre-work conference. Before work begins on service contracts, a pre-work conference is normally held to discuss the contract--especially the specifications, labor provisions, plan of work, and selected standard clauses. The pre-work meeting should be attended by an officer of the firm or someone designated in writing to act on behalf of the firm. The pre-work meeting may be waived at the discretion of the Contracting Officer.Notice to Proceed.No work may begin on this contract until the Contracting Officer has issued a Notice to Proceed.10. PAYMENTPayments . Payment will be made for fully acceptable work at the prices bid in the schedule of items. Payment will be made monthly or at the milestones as specified in the contract specifications.Deductions In accordance with the inspection clause, payment may be made for less than fully acceptable work at a reduced price. Other exceptions are noted below:Contract Release. Before final payment will be made the Contractor shall sign a release of all claims against the Government arising by virtue of this contract, other than claims, in stated amounts, that the Contractor has specifically excepted from the operation of the release. A release may also be required of the assignee if the Contractor's claim to amounts payable under this contract has been assigned under the Assignment of Claims Act of 1940 (31 U.S.C. 3727 and 41 U.S.C. 15).Invoices. Invoices. Payment will be made from Contractor's invoice submitted tough The Invoice Processing Platform (IPP).RETAINAGE (applicable to service contracts where work accomplishments are measured in units other than time)The following supplements Clause 52.232-1, Payments:The Contracting Officer may retain up to 10 percent of the invoiced amount if the contractor is behind schedule at the time the invoice is presented. "Behind schedule" means that the percentage of work completed is less than the percentage of time used. Payment will be made from Contractor's invoice.11. GOVERNMENT-FURNISHED PROPERTYThe Government will provide the following item(s) of Government property to the Contractor for use in the performance of this contract. This property shall be used and maintained by the Contractor in accordance with the provisions of the "Government Property" FAR clause contained elsewhere in the contract.NONE12. INSPECTION AND ACCEPTANCEFAR 52.252-2 Clauses Incorporated by Reference (FEB 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): www.acquisition.gov/far/FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES52.246-4 Inspection of Services--Fixed-Price (AUG 1996)12.1 Quality Control Plan - The Contractor shall conduct inspections on all units in accordance with his/her Quality Control Plan (QCP). The Contractor's Quality Control Plan shall be submitted and accepted by the Government prior to any work starting.12.2. Government InspectionsGovernment inspections are for the purpose of satisfying the Government that the services are acceptable and do not relieve the Contractor of the responsibility for maintaining quality control.The Contracting Officer's Representative or designated inspector will conduct all inspections. The Contractor (or designated representative) is encouraged to be present to observe inspections. Summary results will be made available on request.Compliance Inspections. Visual compliance inspections will be made on a periodic basis. Such inspections are not final and do not constitute acceptance by the Government.Final Inspections. Final (formal) inspections for payment will be made on completed sub-items only. Contractor shall request final inspections in writing and give the Forest Service at least four working days advanced notice. Inspections will be completed within four working days after the notice is received. If the work is not ready for inspection at the time specified by the Contractor, the cost associated with the inspection attempt may be charged to the Contractor. Final inspection will involve a USFS check cruise. A check cruise will be conducted by the USFS Quality Control Group and must pass with 80 percent for each element and 85 percent overall or better. Check cruise that does not pass with 85 percent or better will need to be re-cruised at the contractor's expense. Refer to USFS Timber Cruising Handbook 2409.12 Chapter 60 for specific requirements. Final check cruise will be completed within 10 business days of receiving written request form contractor.Disputed Inspection. The Contractor may request reinspection without rework if the results are unacceptable. Reinspection must be requested in writing within 48 hours after receiving written notice of the inspection results. Reinspection will be accomplished within five working days after receipt of the contractor's written request.The same sampling and inspection procedures will be used, but new samples will be taken. The inspection pattern will be shifted so that new samples will not overlap previously inspected samples. Results will be rounded to the nearest whole percent.If reinspection results are within five percentage points of the first inspection, the original inspection result will be used in determining acceptability and payment. If reinspection results are greater than five percentage points above or below the first inspection, the reinspection results will be used.If the reinspection results are within five percentage points of the first inspection, the Contractor shall pay the actual costs of the reinspection.Reinspection after Rework. Where rework after a failed inspection may improve the inspection results, the Contractor may rework the area and request (in writing) a second inspection. The Government will charge to the Contractor the cost of this additional inspection. Reinspection will be accomplished within five working days after the notice is received. The results of the second inspection will be final, and no further rework will be permitted. Areas not ready for reinspection at the time specified by the Contractor will not be reinspected, and the results of the first inspection will be final.12.3 Sampling (Government's inspection system)Each item will be 100% visually inspected randomly. With 10% random sampling post weed disposal. 10% of aggregate production will be inspected randomly toughout the contracted period.12.4. Specific Inspection ProceduresCompliance Inspections.A. Walk-toughs: Compliance inspections shall be held toughout the performance of the contract. Inspections may be in the form of "walk-toughs" to visually confirm the proper application of the contract specifications. The Government reserves the right to perform formal inspections for verification of compliance to contract specifications.B. Formal Inspections: The Government will inspect marking to determine compliance with specifications. Formal inspection will occur randomly and will inspect 10% of aggregate produced to meet specifications attached.13 AcceptanceWork on this contract will be deemed acceptable when: For all units, determination of acceptability of the work performed will be based on the Government inspections and shall be considered conclusive except as otherwise provided in the Contract. The inspection results of each unit will not be averaged with the results of any other unit. The Contractor or a designated representative is encouraged to observe inspections while they are underway. 14. Pre-workPre-work conference. Before work begins on service contracts, a pre-work conference is normally held to discuss the contract--especially the specifications, labor provisions, plan of work, and selected standard clauses. The pre-work meeting should be attended by an officer of the firm or someone designated in writing to act on behalf of the firm. The pre-work meeting may be waived at the discretion of the Contracting Officer.Notice to Proceed. No work may begin on this contract until the Contracting Officer has issued a Notice to Proceed.15. PaymentPayments and Deductions. Payment will be made for fully acceptable work at the prices bid in the schedule of items. In the event of extended non-work periods because of adverse weather, the Contracting Officer may authorize progress payments for partially completed sub-items on a case-by- case basis. In accordance with the inspection clause, payment may be made for less than fully acceptable work at a reduced price. Other exceptions are noted below:Payment will be made in full if inspection results are 90 percent or higher. If inspection results are below 90 percent, a deduction will be made equal to 1 percent for every 1 percent below 90. For example, if inspection results are 87 percent, the bid price would be reduced by 3 percent. No payment will be made if results are less than 80 percent.16. Contract Release. The following supplements the Payments clause in Section I: Before final payment will be made the Contractor shall sign a release of all claims against the Government arising by virtue of this contract, other than claims, in stated amounts, that the Contractor has specifically excepted from the operation of the release. A release may also be required of the assignee if the Contractor's claim to amounts payable under this contract has been assigned under the Assignment of Claims Act of 1940 (31 U.S.C. 3727 and 41 U.S.C. 15).Invoices. Payment will be made from Contractor's invoice submitted tough The Invoice Processing Platform (IPP).RETAINAGE (applicable to service contracts where work accomplishments are measured in units other than time)The following supplements Clause 52.232-1, Payments:The Contracting Officer may retain up to 10 percent of the invoiced amount if the contractor is behind schedule at the time the invoice is presented. "Behind schedule" means that the percentage of work completed is less than the percentage of time used.17. EmergenciesFire PlanSee Section J, Fire PlanArea of Responsibility for Fire. Unless otherwise noted elsewhere in the contract, the following define the limits of a contractor's area of responsibility for fire under the terms of the Fire Plan (Section J):18. Superintendence by Contractor The name and the specific authorities of the foreman or superintendent must be designated in writing to the Contracting Officer. The Contractor may use his/her own prepared letterhead stationery or a "Designation of Contractor's Representative" form available from the Contracting Officer. If the Contractor or the designee is not present when work is being performed on the contract, a Suspend Work Order may be issued with contract time continuing to run. The Contractor shall have a person on-site that is fully conversant in the English language.19. Camping Permit Compliance Contractor shall comply with all terms and conditions of any camping permit issued to allow use of premises. Any non-compliance will result in suspension of work until compliance is achieved.20. Archaeological and Historic SitesLocation of known archaeological, historic, or pre-historic materials--such as Amerind artifacts and/or historic mining, logging, or fur trapping remains protected by the American Antiquities Act (l6 USC 433)--will be identified for the contractor before work commences.21. Spill PlanIf the total oil or oil products storage exceeds 1,320 gallons or if any single container exceeds a capacity of 660 gallons, the Contractor shall prepare and implement a Spill Prevention and Countermeasures (SPCC) Plan. Such plan shall meet applicable EPA requirements (40 CFR 112), including certification by a registered professional engineer. The Contractor under the direction of the Contracting Officer, or in the absence of said officer, acting independently, shall immediately take action to contain and clean up, without expense to the Government, all petroleum products spills on or in the vicinity of the project which are caused by the Contractor's employees directly or indirectly as a result of contract operations. The Contractor may be held liable for all damages and costs of additional labor, subsistence, equipment, supplies, and transportation deemed necessary by the Government for the containment and clean up of petroleum products spills caused by Contractor's employees or resulting from contract operations. The Contractor shall immediately report all petroleum products spills to the Contracting Officer.22. Equipment CleaningAll off-road equipment used on this project shall be washed before moving into the project area so that the equipment is free of soil, seeds, vegetative material, or other debris that could contain or hold seeds of noxious weeds. "Off-road equipment" includes all logging and construction equipment and such brushing equipment as brush hogs, masticators, and chippers; it does not include log trucks, chip vans, service vehicles, water trucks, pickup trucks, and similar vehicles not intended for off-road use.Equipment will be considered clean when visual inspection does not reveal soil, seeds, plant material, or other such debris. Disassembly of equipment components or specialized inspection equipment is not required. Contractor shall notify the Contracting Officer at least five days in advance of moving equipment in so that arrangements can be made for inspection.If the project area is known to contain noxious weeds, the equipment shall be cleaned before moving to other Forest Service system lands which do not contain noxious weeds.23. LIST OF ATTACHMENTSThe following attachments are made a part of this solicitation and any resultant contract and are included below.Title PagesMaps 6 PagesFire Plan Attachment 9 pagesSCA Wage Determination Attachment 424. EVAUATIONGOVERNMENT CONTACT CONTRACT: O'Laine Martinez. She may be contacted at tracymartinez@fs.fed.us or (530) 478 6823.SUBMISSION OF QUOTES: The response date is July 5, 2016 before time: 3:00 pm. PST.Quotes may be:(1)Emailed to O'Laine Martinez, tracymartinez@fs.fed.us, it is the contractor's responsibility to obtain confirmation receipt. Contact O'Laine Martinez (530) 478-6823 delivery receipt. Delivery via Facsimile to: 530-478-6126. Pages allowed to be faxed is limited to 20 pages. (2) Quotes may be mailed/hand carried to Tahoe National Forest, attention: OLaine Martinez, Contracting Officer to the following address: 631 Coyote Street, Nevada City, CA 95959.52.212-2 Evaluation-Commercial Items (Oct 2014)(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:Technical Past PerformancePriceTechnical and past performance, when combined, are approximately equal to cost or price. (b) Options. The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the Government to exercise the option(s).(c) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.The selection official will base the award decision on a tradeoff between price and non-price factors, comparing the relative risk to the government of poor or non-performance posed by each of the offerors, and making a judgment as to whether or not reduced risk of performance is worth the additional cost. In some cases this will result in award to a lower-ranked but lower-priced offer; in other cases the result will be award to a higher-ranked but higher-priced offer.Factors. Award will be made to the responsible offeror whose offer conforming to the solicitation is determined to be most advantageous to the government based on an evaluation of the following factors: Technical, Past performance, and price. (1) Technical. The Government will evaluate each offeror's relative understanding of the Government's requirements on the basis of its written submittals addressing the following subfactors:a) Any information that indicates the extent to which the site for this project was visited.b) The resources (personnel and equipment) which are planned for use on the project, and how realistic that plan is given concurrent obligations.c) Site-specific safety plan.d) Plan of work.e) Where applicable, estimated production ratesf) If a technical proposal is submitted, whether or not the proposed method of work is practical and demonstrates an understanding of the government's requirement.(2) Past Performance. Past performance is a measure of the degree to which an offeror satisfied its customers in the past and complied with Federal, state, and local laws and regulations. The Government will contact some of each offeror's customers to ask whether or not that: (1) that the offeror was capable, efficient, and effective; (2) the offeror's performance conformed to the terms and conditions of its contract (specifications); (3) finished within the contract time; (4) the offeror was reasonable and cooperative during performance; and (5) the offeror was committed to customer satisfaction. In evaluating past performance, the Government will contact some of the references provided by the offeror and other sources of information, including, but not limited to: Federal, state, and local government agencies, better business bureaus, published media, and electronic data bases. The Government may evaluate the organizational past performance of the offeror's proposed key subcontractors.Responsible sources may submit an offer which will be considered by the government. In accordance with FAR 4.1102(a), prospective contractors must be registered in the System for Award Management (SAM) database prior to award of a contract. Lack of registration in SAM on the part of the offeror will render an offeror ineligible for award. Offerors may obtain information on registration and annual confirmation requirements by visiting www.sam.govPROVISIONS AND CLAUSES: (a) The contractor shall comply with the following FAR clauses (current revision) which are incorporated in this contract by reference, to implement provisions of law or Executive Orders applicable to acquisitions of commercial items: (full text of all provisions and clauses to be found at: http://acquisition.gov/comp/far/loadmainre.html ) The solicitation document and incorporate provisions and clauses are those in effect tough Federal Acquisition Circular 2005-057, effective March 15, 2012.52.212-1 Instructions to Offerors-Commercial Items (OCT 2015)52.212-4 Contract Terms and Conditions--Commercial Items (May 2015)FAR 52.252-2 Clauses Incorporated by Reference (FEB 1998)This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): www.acquisition.gov/far/FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES52.242-14 Suspension of Work (APR 1984)52.212-3 Offeror Representations and Certifications--Commercial Items (APR 2016)The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) website accessed tough http://www.acquisition.gov. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) tough (r) of this provision.(a) Definitions. As used in this provision-"Economically disadvantaged women-owned small business (EDWOSB) concern" means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program."Forced or indentured child labor" means all work or service-(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties."Highest-level owner" means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner."Immediate owner" means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees."Inverted domestic corporation", means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c)."Manufactured end product" means any end product in product and service codes (PSCs) 1000-9999, except-(1) PSC 5510, Lumber and Related Basic Wood Materials;(2) Product or Service Group (PSG) 87, Agricultural Supplies;(3) PSG 88, Live Animals;(4) PSG 89, Subsistence;(5) PSC 9410, Crude Grades of Plant Materials;(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;(8) PSC 9610, Ores;(9) PSC 9620, Minerals, Natural and Synthetic; and(10) PSC 9630, Additive Metal Materials."Place of manufacture" means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture."Predecessor" means an entity that is replaced by a successor and includes any predecessors of the predecessor."Restricted business operations" means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate-(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;(3) Consist of providing goods or services to marginalized populations of Sudan;(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;(5) Consist of providing goods or services that are used only to promote health or education; or(6) Have been voluntarily suspended."Sensitive technology"-(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically-(i) To restrict the free flow of unbiased information in Iran; or(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3))."Service-disabled veteran-owned small business concern"-(1) Means a small business concern-(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16)."Small business concern" means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation."Small disadvantaged business concern", consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that-(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by-(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition."Subsidiary" means an entity in which more than 50 percent of the entity is owned-(1) Directly by a parent corporation; or(2) Tough another subsidiary of a parent corporation."Veteran-owned small business concern" means a small business concern-(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and(2) The management and daily business operations of which are controlled by one or more veterans."Successor" means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often tough acquisition or merger). The term "successor" does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances."Women-owned business concern" means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women."Women-owned small business concern" means a small business concern-(1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and(2) Whose management and daily business operations are controlled by one or more women."Women-owned small business (WOSB) concern eligible under the WOSB Program" (in accordance with 13 CFR part 127), means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.(b)(1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAM website.(2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed tough http://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications-Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ______________.[Offeror to identify the applicable paragraphs at (c) tough (r) of this provision that the offeror has completed for the purposes of this solicitation only, if any.These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.](c) Offerors must complete the following representations when the resulting contract will be performed in the United States or its outlying areas. Check all that apply.(1) Small business concern. The offeror represents as part of its offer that it □ is, □ is not a small business concern.(2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it □ is, □ is not a veteran-owned small business concern.(3) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.] The offeror represents as part of its offer that it o is, o is not a service-disabled veteran-owned small business concern.(4) Small disadvantaged business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, that it □ is, □ is not a small disadvantaged business concern as defined in 13 CFR 124.1002.(5) Women-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it □ is, □ is not a women-owned small business concern.(6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that-(i) It □ is,□ is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and(ii) It □ is, □ is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: __________.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.(7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that-(i) It □ is, □ is not an EDWOSB concern, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and(ii) It □ is, □ is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: __________.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.Note: Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition teshold.(8) Women-owned business concern (other than small business concern). [Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it □ is a women-owned business concern.(9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price:____________________________________(10) HUBZone small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that-(i) It □ is, □ is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR Part 126; and(ii) It □ is, □ is not a HUBZone joint venture that complies with the requirements of 13 CFR Part 126, and the representation in paragraph (c)(10)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: __________.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.(d) Representations required to implement provisions of Executive Order 11246-(1) Previous contracts and compliance. The offeror represents that-(i) It □ has, □ has not participated in a previous contract or subcontract subject to the Equal Opportunity clause of this solicitation; and(ii) It □ has, □ has not filed all required compliance reports.(2) Affirmative Action Compliance. The offeror represents that-(i) It □ has developed and has on file, □ has not developed and does not have on file, at each establishment, affirmative action programs required by rules and regulations of the Secretary of Labor (41 cfr parts 60-1 and 60-2), or(ii) It □ has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor.(e) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352). (Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract. If any registrants under the Lobbying Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made.(f) Buy American Certificate. (Applies only if the clause at Federal Acquisition Regulation (FAR) 52.225-1, Buy American-Supplies, is included in this solicitation.)(1) The offeror certifies that each end product, except those listed in paragraph (f)(2) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of "domestic end product." The terms "commercially available off-the-shelf (COTS) item" "component," "domestic end product," "end product," "foreign end product," and "United States" are defined in the clause of this solicitation entitled "Buy American-Supplies."(2) Foreign End Products:Line Item No.Country of Origin_____________________________________________________________________________________________[List as necessary](3) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.(g)(1) Buy American-Free Trade Agreements-Israeli Trade Act Certificate. (Applies only if the clause at FAR 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act, is included in this solicitation.)(i) The offeror certifies that each end product, except those listed in paragraph (g)(1)(ii) or (g)(1)(iii) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The terms "Baainian, Moroccan, Omani, Panamanian, or Peruvian end product," "commercially available off-the-shelf (COTS) item," "component," "domestic end product," "end product," "foreign end product," "Free Trade Agreement country," "Free Trade Agreement country end product," "Israeli end product," and "United States" are defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act."(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Baainian, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act":Free Trade Agreement Country End Products (Other than Baainian, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products:Line Item No.Country of Origin____________________________________________________________________________________________[List as necessary](iii) The offeror shall list those supplies that are foreign end products (other than those listed in paragraph (g)(1)(ii) of this provision) as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act." The offeror shall list as other foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of "domestic end product."Other Foreign End Products:Line Item No.Country of Origin___________________________________________________________________________________________[List as necessary](iv) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.(2) Buy American-Free Trade Agreements-Israeli Trade Act Certificate, Alternate I. If Alternate I to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act":Canadian End Products:Line Item No._____________________________________________________________________________________________________________________[List as necessary](3) Buy American-Free Trade Agreements-Israeli Trade Act Certificate, Alternate II. If Alternate II to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products or Israeli end products as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act":Canadian or Israeli End Products:Line Item No.Country of Origin_____________________________________________________________________________________________[List as necessary](4) Buy American-Free Trade Agreements-Israeli Trade Act Certificate, Alternate III. If Alternate III to the clause at 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:(g)(1)(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Baainian, Korean, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act":Free Trade Agreement Country End Products (Other than Baainian, Korean, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products:Line Item No.Country of Origin_____________________________________________________________________________________________[List as necessary](5) Trade Agreements Certificate. (Applies only if the clause at FAR 52.225-5, Trade Agreements, is included in this solicitation.)(i) The offeror certifies that each end product, except those listed in paragraph (g)(5)(ii) of this provision, is a U.S.-made or designated country end product, as defined in the clause of this solicitation entitled "Trade Agreements."(ii) The offeror shall list as other end products those end products that are not U.S.-made or designated country end products.Other End Products:Line Item No.Country of Origin____________________________________________________________________________________________[List as necessary](iii) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. For line items covered by the WTO GPA, the Government will evaluate offers of U.S.-made or designated country end products without regard to the restrictions of the Buy American statute. The Government will consider for award only offers of U.S.-made or designated country end products unless the Contracting Officer determines that there are no offers for such products or that the offers for such products are insufficient to fulfill the requirements of the solicitation.(h) Certification Regarding Responsibility Matters (Executive Order 12689). (Applies only if the contract value is expected to exceed the simplified acquisition teshold.) The offeror certifies, to the best of its knowledge and belief, that the offeror and/or any of its principals-(1) □ Are, □ are not presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;(2) □ Have, □ have not, within a tee-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a Federal, state or local government contract or subcontract; violation of Federal or state antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property;(3) □ Are, □ are not presently indicted for, or otherwise criminally or civilly charged by a Government entity with, commission of any of these offenses enumerated in paragraph (h)(2) of this clause; and(4) □ Have, □ have not, within a tee-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied.(i) Taxes are considered delinquent if both of the following criteria apply:(A) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.(B) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.(ii) Examples.(A) The taxpayer has received a statutory notice of deficiency, under I.R.C. §6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.(B) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. §6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.(C) The taxpayer has entered into an installment agreement pursuant to I.R.C. §6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment.(D) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. §362 (the Bankruptcy Code).(i) Certification Regarding Knowledge of Child Labor for Listed End Products (Executive Order 13126). [The Contracting Officer must list in paragraph (i)(1) any end products being acquired under this solicitation that are included in the List of Products Requiring Contractor Certification as to Forced or Indentured Child Labor, unless excluded at .](1) Listed end products.Listed End ProductListed Countries of Origin____________________________________________________________________________(2) Certification. [If the Contracting Officer has identified end products and countries of origin in paragraph (i)(1) of this provision, then the offeror must certify to either (i)(2)(i) or (i)(2)(ii) by checking the appropriate block.]□ (i) The offeror will not supply any end product listed in paragraph (i)(1) of this provision that was mined, produced, or manufactured in the corresponding country as listed for that product.□ (ii) The offeror may supply an end product listed in paragraph (i)(1) of this provision that was mined, produced, or manufactured in the corresponding country as listed for that product. The offeror certifies that it has made a good faith effort to determine whether forced or indentured child labor was used to mine, produce, or manufacture any such end product furnished under this contract. On the basis of those efforts, the offeror certifies that it is not aware of any such use of child labor.(j) Place of manufacture. (Does not apply unless the solicitation is predominantly for the acquisition of manufactured end products.) For statistical purposes only, the offeror shall indicate whether the place of manufacture of the end products it expects to provide in response to this solicitation is predominantly-(1) □ In the United States (Check this box if the total anticipated price of offered end products manufactured in the United States exceeds the total anticipated price of offered end products manufactured outside the United States); or(2) □ Outside the United States.(k) Certificates regarding exemptions from the application of the Service Contract Labor Standards (Certification by the offeror as to its compliance with respect to the contract also constitutes its certification as to compliance by its subcontractor if it subcontracts out the exempt services.) [The contracting officer is to check a box to indicate if paragraph (k)(1) or (k)(2) applies.]□ (1) Maintenance, calibration, or repair of certain equipment as described in FAR 22.1003-4(c)(1). The offeror □ does □ does not certify that-(i) The items of equipment to be serviced under this contract are used regularly for other than Governmental purposes and are sold or traded by the offeror (or subcontractor in the case of an exempt subcontract) in substantial quantities to the general public in the course of normal business operations;(ii) The services will be furnished at prices which are, or are based on, established catalog or market prices (see FAR 22.1003-4(c)(2)(ii)) for the maintenance, calibration, or repair of such equipment; and(iii) The compensation (wage and fringe benefits) plan for all service employees performing work under the contract will be the same as that used for these employees and equivalent employees servicing the same equipment of commercial customers.□ (2) Certain services as described in FAR 22.1003-4(d)(1). The offeror □ does □ does not certify that-(i) The services under the contract are offered and sold regularly to non-Governmental customers, and are provided by the offeror (or subcontractor in the case of an exempt subcontract) to the general public in substantial quantities in the course of normal business operations;(ii) The contract services will be furnished at prices that are, or are based on, established catalog or market prices (see FAR 22.1003-4(d)(2)(iii));(iii) Each service employee who will perform the services under the contract will spend only a small portion of his or her time (a monthly average of less than 20 percent of the available hours on an annualized basis, or less than 20 percent of available hours during the contract period if the contract period is less than a month) servicing the Government contract; and(iv) The compensation (wage and fringe benefits) plan for all service employees performing work under the contract is the same as that used for these employees and equivalent employees servicing commercial customers.(3) If paragraph (k)(1) or (k)(2) of this clause applies-(i) If the offeror does not certify to the conditions in paragraph (k)(1) or (k)(2) and the Contracting Officer did not attach a Service Contract Labor Standards wage determination to the solicitation, the offeror shall notify the Contracting Officer as soon as possible; and(ii) The Contracting Officer may not make an award to the offeror if the offeror fails to execute the certification in paragraph (k)(1) or (k)(2) of this clause or to contact the Contracting Officer as required in paragraph (k)(3)(i) of this clause.(l) Taxpayer Identification Number (TIN) (26 U.S.C. 6109, 31 U.S.C. 7701). (Not applicable if the offeror is required to provide this information to the SAM database to be eligible for award.)(1) All offerors must submit the information required in paragraphs (l)(3) tough (l)(5) of this provision to comply with debt collection requirements of 31 U.S.C. 7701(c) and 3325(d), reporting requirements of 26 U.S.C. 6041, 6041A, and 6050M, and implementing regulations issued by the Internal Revenue Service (IRS).(2) The TIN may be used by the Government to collect and report on any delinquent amounts arising out of the offeror's relationship with the Government (31 U.S.C. 7701(c)(3)). If the resulting contract is subject to the payment reporting requirements described in FAR 4.904, the TIN provided hereunder may be matched with IRS records to verify the accuracy of the offeror's TIN.(3) Taxpayer Identification Number (TIN).□ TIN: ________________________________.□ TIN has been applied for.□ TIN is not required because:□ Offeror is a nonresident alien, foreign corporation, or foreign partnership that does not have income effectively connected with the conduct of a trade or business in the United States and does not have an office or place of business or a fiscal paying agent in the United States;□ Offeror is an agency or instrumentality of a foreign government;□ Offeror is an agency or instrumentality of the Federal Government.(4) Type of organization.□ Sole proprietorship;□ Partnership;□ Corporate entity (not tax-exempt);□ Corporate entity (tax-exempt);□ Government entity (Federal, State, or local);□ Foreign government;□ International organization per 26 CFR 1.6049-4;□ Other ________________________________.(5) Common parent.□ Offeror is not owned or controlled by a common parent;□ Name and TIN of common parent:Name ________________________________.TIN _________________________________.(m) Restricted business operations in Sudan. By submission of its offer, the offeror certifies that the offeror does not conduct any restricted business operations in Sudan.(n) Prohibition on Contracting with Inverted Domestic Corporations.(1) Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation, unless the exception at 9.108-2(b) applies or the requirement is waived in accordance with the procedures at 9.108-4.(2) Representation. The Offeror represents that-(i) It □ is, □ is not an inverted domestic corporation; and(ii) It □ is, □ is not a subsidiary of an inverted domestic corporation.(o) Prohibition on contracting with entities engaging in certain activities or transactions relating to Iran.(1) The offeror shall e-mail questions concerning sensitive technology to the Department of State at CISADA106@state.gov.(2) Representation and Certifications. Unless a waiver is granted or an exception applies as provided in paragraph (o)(3) of this provision, by submission of its offer, the offeror-(i) Represents, to the best of its knowledge and belief, that the offeror does not export any sensitive technology to the government of Iran or any entities or individuals owned or controlled by, or acting on behalf or at the direction of, the government of Iran;(ii) Certifies that the offeror, or any person owned or controlled by the offeror, does not engage in any activities for which sanctions may be imposed under section 5 of the Iran Sanctions Act; and(iii) Certifies that the offeror, and any person owned or controlled by the offeror, does not knowingly engage in any transaction that exceeds $3,500 with Iran's Revolutionary Guard Corps or any of its officials, agents, or affiliates, the property and interests in property of which are blocked pursuant to the International Emergency Economic Powers Act (50 U.S.C. 1701 et seq.) (see OFAC's Specially Designated Nationals and Blocked Persons List at http://www.treasury.gov/ofac/downloads/t11sdn.pdf).(3) The representation and certification requirements of paragraph (o)(2) of this provision do not apply if-(i) This solicitation includes a trade agreements certification (e.g., 52.212-3(g) or a comparable agency provision); and(ii) The offeror has certified that all the offered products to be supplied are designated country end products.(p) Ownership or Control of Offeror. (Applies in all solicitations when there is a requirement to be registered in SAM or a requirement to have a DUNS Number in the solicitation.(1) The Offeror represents that it □ has or □ does not have an immediate owner. If the Offeror has more than one immediate owner (such as a joint venture), then the Offeror shall respond to paragraph (2) and if applicable, paragraph (3) of this provision for each participant in the joint venture.(2) If the Offeror indicates "has" in paragraph (p)(1) of this provision, enter the following information:Immediate owner CAGE code: ____________________.Immediate owner legal name: _____________________.(Do not use a "doing business as" name)Is the immediate owner owned or controlled by another entity: □ Yes or □ No.(3) If the Offeror indicates "yes" in paragraph (p)(2) of this provision, indicating that the immediate owner is owned or controlled by another entity, then enter the following information:Highest-level owner CAGE code: __________________.Highest-level owner legal name: ___________________.(Do not use a "doing business as" name)(q) Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law.(1) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, The Government will not enter into a contract with any corporation that-(i) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or(ii) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.(2) The Offeror represents that-(i) It is □ is not □ a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and(ii) It is □ is not □ a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.(r) Predecessor of Offeror. (Applies in all solicitations that include the provision at 52.204-16, Commercial and Government Entity Code Reporting.)(1) The Offeror represents that it □ is or □ is not a successor to a predecessor that held a Federal contract or grant within the last tee years.(2) If the Offeror has indicated "is" in paragraph (r)(1) of this provision, enter the following information for all predecessors that held a Federal contract or grant within the last tee years (if more than one predecessor, list in reverse conological order):Predecessor CAGE code: ________ (or mark "Unknown")Predecessor legal name: _________________________(Do not use a "doing business as" name)AGAR 452.209 - 70 REPRESENTATION BY CORPORATIONS REGARDING AN UNPAID DELINQUENT TAX LIABILITY OR A FELONY CONVICTION (DEVIATION 2012-01) ALTERNATE 1 (FEB 2012)(a.) Awards made under this solicitation are subject to the provisions contained in the Consolidated Appropriations Act, 2012 (P.L. No. 112-74), Division E, Sections 433 and 434 regarding corporate felony convictions and corporate federal tax delinquencies. To comply with these provisions, all offerors must complete paragraph (1) of this representation, and all corporate offerors also must complete paragraphs (2) and (3) of this representation.(b) The Offeror represents that -(1) The Offeror is [ ], is not [ ] (check one) an entity that has filed articles of incorporation in one of the fifty states, the District of Columbia, or the various territories of the United States including American Samoa, Federated States of Micronesia, Guam, Midway Islands, Northern Mariana Islands, Puerto Rico, Republic of Palau, Republic of the Marshall Islands, U.S. Virgin Islands. (Note that this includes both for-profit and non-profit organizations.)If the Offeror checked "is" above, the Offeror must complete paragraphs (2) and (3) of the representation. If Offeror checked "is not" above, Offeror may leave the remainder of the representation blank.(2) (i) The Offeror has [ ], has not [ ] (check one) been convicted of a felony criminal violation under Federal or State law in the 24 months preceding the date of offer. (ii) Offeror has [ ], has not [ ] (check one) had any officer or agent of Offeror convicted of a felony criminal violation for actions taken on behalf of Offeror under Federal law in the 24 months preceding the date of offer.(3) The Offeror does [ ], does not [ ] (check one) have any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability.52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders-Commercial Items. (Jun 2016)(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:(1) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015)(2) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).(3) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004)(Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)).(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:[Contracting Officer check as appropriate.]_x_ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).__ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509)).__ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (June 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)_x_ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2015) (Pub. L. 109-282) (31 U.S.C. 6101 note).__ (5) [Reserved].__ (6) 52.204-14, Service Contract Reporting Requirements (Jan 2014) (Pub. L. 111-117, section 743 of Div. C).__ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Jan 2014) (Pub. L. 111-117, section 743 of Div. C)._x_ (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Oct 2015) (31 U.S.C. 6101 note)._x_ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41 U.S.C. 2313).__ (10) [Reserved].__ (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a).__ (ii) Alternate I (Nov 2011) of 52.219-3.__ (12)(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).__ (ii) Alternate I (Jan 2011) of 52.219-4.__ (13) [Reserved]_x_ (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2011) (15 U.S.C. 644).__ (ii) Alternate I (Nov 2011).__ (iii) Alternate II (Nov 2011).__ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644).__ (ii) Alternate I (Oct 1995) of 52.219-7.__ (iii) Alternate II (Mar 2004) of 52.219-7._x_ (16) 52.219-8, Utilization of Small Business Concerns (Oct 2014) (15 U.S.C. 637(d)(2) and (3)).__ (17)(i) 52.219-9, Small Business Subcontracting Plan (Oct 2015) (15 U.S.C. 637(d)(4)).__ (ii) Alternate I (Oct 2001) of 52.219-9.__ (iii) Alternate II (Oct 2001) of 52.219-9.__ (iv) Alternate III (Oct 2015) of 52.219-9.__ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r))._x_ (19) 52.219-14, Limitations on Subcontracting (Nov 2011) (15 U.S.C. 637(a)(14))._x_ (20) 52.219-16, Liquidated Damages-Subcon-tracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)).__ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657 f)._x_ (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)).__ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)).__ (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m))._x_ (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755).__ (26) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Feb 2016) (E.O. 13126)._x_ (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015)._x_ (28) 52.222-26, Equal Opportunity (Apr 2015) (E.O. 11246)._x_ (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015)(38 U.S.C. 4212)._x_ (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793)._x_ (31) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212)._x_ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496)._x_ (33)(i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627).__ (ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627)._x_ (34) 52.222-54, Employment Eligibility Verification (Oct 2015). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)__ (35)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)__ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)__ (36) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693).__ (37) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O. 13693).__ (38)(i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514).__ (ii) Alternate I (Oct 2015) of 52.223-13.__ (39)(i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (Jun 2014) (E.O.s 13423 and 13514).__ (ii) Alternate I (Jun 2014) of 52.223-14._x_ (40) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b).__ (41)(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (Oct 2015) (E.O.s 13423 and 13514).__ (ii) Alternate I (Jun 2014) of 52.223-16.__ (42) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Aug 2011) (E.O. 13513).__ (43) 52.223-20, Aerosols (Jun 2016) (E.O. 13693).__ (44) 52.223-21, Foams (Jun 2016) (E.O. 13693).__ (45) 52.225-1, Buy American-Supplies (May 2014) (41 U.S.C. chapter 83).__ (46)(i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.__ (ii) Alternate I (May 2014) of 52.225-3.__ (iii) Alternate II (May 2014) of 52.225-3.__ (iv) Alternate III (May 2014) of 52.225-3.__ (47) 52.225-5, Trade Agreements (Feb 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).__ (48) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).__ (49) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note)._x_ (50) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).__ (51) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150).__ (52) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).__ (53) 52.232-30, Installment Payments for Commercial Items (Oct 1995) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).__ (54) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (Jul 2013) (31 U.S.C. 3332).__ (55) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Jul 2013) (31 U.S.C. 3332).__ (56) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).__ (57) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).__ (58)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631).__ (ii) Alternate I (Apr 2003) of 52.247-64.(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:[Contracting Officer check as appropriate.]__ (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014)(E.O. 13495)._x_ (2) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67)._x_ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67)._x_ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).__ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).__ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67).__ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67)._x_ (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015)._x_ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792).__ (10) 52.237-11, Accepting and Dispensing of $1 Coin (Sept 2008) (31 U.S.C. 5112(p)(1)).(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition teshold, and does not contain the clause at 52.215-2, Audit and Records-Negotiation.(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract.(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.(e)(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause-(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).(ii) 52.219-8, Utilization of Small Business Concerns (Oct 2014) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.(iii) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495). Flow down required in accordance with paragraph (l) of FAR clause 52.222-17.(iv) 52.222-21, Prohibition of Segregated Facilities (Apr 2015)(v) 52.222-26, Equal Opportunity (Apr 2015) (E.O. 11246).(vi) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).(vii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).(viii) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212)(ix) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.(x) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67).(xi) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O 13627). Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O 13627). (xii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67).(xiii) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67).(xiv) 52.222-54, Employment Eligibility Verification (Oct 2015) (E.O. 12989).(xv) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015).(xvi) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).(xvii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.(xviii) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.(2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.(End of clause)
AG-9JGP-S-16-0122 Department of Agriculture Forest Service R5-Pacific Southwest Region
6/17/16, 6:59 PM